W9128F23B0002 FP Toe Drain Outfall Repair Specs.pdf

SPECIFICATIONS

(For Construction Contract)

Step 2 (100% Design) Solicitation Number W9128F23B0002

Toe Drain Outfall Repair and Monitoring System

Fort Peck Dam and Reservoir, MT

November 2022

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 12 00 CONSTRUCTION GENERAL

01 22 00 MEASUREMENT AND PAYMENT

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 78 39.00 24 AS-BUILT DRAWINGS

DIVISION 02 - EXISTING CONDITIONS

02 31 60 EXCAVATION, TRENCHING, AND BACKFILLING FOR UTILITIES

SYSTEMS

DIVISION 03 - CONCRETE

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

03 42 13.00 10 PLANT-PRECAST CONCRETE PRODUCTS FOR BELOW GRADE

CONSTRUCTION

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 26 00 DEWATERING

33 46 16 SUBDRAINAGE SYSTEM

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 31 19.00 STONE (RIPRAP) PROTECTION

DIVISION 43 - PROCESS GAS AND LIQUID HANDLING, PURIFICATION, AND STORAGE

EQUIPMENT

43 21 29 FLOW MEASURING EQUIPMENT

-- End of Project Table of Contents --

This page was intentionally left blank for duplex printing.

Toe Drain Outfall Repair and Monitoring System Fort Peck Dam FP85

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

04/07

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.4 CARE OF WATER

1.5 Project Survey and Layout

1.6 DISPOSITION OF CONSTRUCTION FACILITIES

1.7 ACCESS ROADS AND HAUL ROADS

1.7.1 Access Roads

1.7.2 Haul Roads

1.7.3 Joint Use of Transportation Facilities

1.8 PUBLIC ROADS

1.8.1 Traffic Control Devices

1.8.2 Temporary Traffic Control (TTC)

1.8.3 Road Closure

1.8.4 State and Federal Highways

1.8.5 State and Local Public Roads

1.8.6 City Streets

1.9 COOPERATION WITH OTHER CONTRACTORS

1.10 SUBMITTALS

1.11 WARRANTY OF CONSTRUCTION (MAR 1994)

1.12 TELEPHONE/INTERNET

1.13 PORTABLE TOILETS

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

-- End of Section Table of Contents --

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

04/07

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract, subject to the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Operations and Storage Areas."

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The

SECTION 01 12 00 Page 2

Contractor shall make the needed investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the work.

1.5 Project Survey and Layout

In addition to the requirements of FAR 52.236-17 Layout of Work, the Contractor shall provide a licensed land surveyor to check initial project control, and to provide and set hubs for project construction. The Contractor shall use (and reference in all as-built data) project stationing as described on the contract drawings. If applicable a licensed land surveyor shall also provide, set and verify as built condition of major flood control structures/features; i.e. flood wall control. These surveys shall provide and verify both horizontal and vertical project control. This survey shall be used for final as-built embankment profile and cross section, and major flood control structure records, and recorded on the as-built condition in accordance with Section, As-Built Drawings.

The Contractor may utilize their own quality control personnel to provide interim surveys for quantity determination for payment in accordance with paragraph entitled Quantity Surveys (Apr 1984).

1.6 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.7 ACCESS ROADS AND HAUL ROADS

1.7.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, and traffic control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to construction. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by the Contractor's operation.

1.7.2 Haul Roads

The Contractor shall construct haul roads as may be necessary for the conduct of the work without additional cost to the Government. The Contractor shall arrange the hauling operations so as to cause a minimum interference with traffic and shall develop Temporary Traffic Control (TTC) plan(s) and furnish all necessary traffic control devices and personnel as required to avoid additional hazards to the public. The Contractor shall perform routine day and night inspections of TTC elements as required by MUTCD and maintain all furnished traffic control devices at

SECTION 01 12 00 Page 3 their expense and without additional cost to the Government. Lines, grades and widths for haul roads, shall be selected to fulfill the requirements for safe and efficient hauling operations and shall be approved by the Contracting Officer prior to construction. Haul roads shall have ample width to provide safety. Preference shall be given to one-way haul roads when these are feasible. All roads shall be maintained in original as-built condition during all periods of their use. Roads shall be sprinkled whenever, in the opinion of the Contracting Officer, control of dust is necessary to insure safe movements of construction traffic. Upon completion of work under this contract, roads shall be disposed of as directed by the Contracting Officer. All traffic control devices, culverts, guards, fences and other improvements on roads constructed for the Contractor's convenience and operations shall be removed from the project site and shall remain property of the Contractor. Use and repair of existing roads and bridges shall be subject to the requirements of local authorities. Prior to start of hauling operations on public roads, the Contractor shall furnish written evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.7.3 Joint Use of Transportation Facilities

The Contractor may use jointly with Contractors and others, existing access and haul roads constructed by the Government or by others. Unless otherwise specifically authorized in writing, the Contractor will not be granted exclusive use of any access or haul road whether it be an existing road or one constructed by the Contractor. However, the use by others of roads constructed by or assigned to the Contractor primarily for the Contractor's use will be limited by the Contracting Officer to the minimum considered consistent with efficient prosecution of the work under this and other contracts in force. Maintenance of jointly used facilities shall be shared in proportion to use. In the event of a disagreement between this Contractor and others as to the use of any road, the decision of the Contracting Officer shall be final. The Contractor shall not obstruct any existing road on the land controlled by the Government.

1.8 PUBLIC ROADS

1.8.1 Traffic Control Devices

All traffic control devices (signs, arrow boards, barricades, lighting etc) by the Contractor, must conform with the U.S. Department of Transportation, Federal Highway Administration, Manual on Uniform Traffic Control Devices.

1.8.2 Temporary Traffic Control (TTC)

The Contractor shall be responsible for the safe control of traffic on all haul and access roads used primarily for the work under these specifications and at their crossings with roads used by others. The Contractor shall, at the Contractor's own expense, furnish all personnel, and traffic control devices necessary for the safe movement of all road users through or around Temporary Traffic Control zone. Temporary traffic control plans, including a listing of equipment and its employment, shall be submitted for review and approval prior to construction.

SECTION 01 12 00 Page 4

1.8.3 Road Closure

At each location designated by the Contracting Officer and where safe operation requires the closing of roads, streets or other travel arteries leading to the work under this contract, the Contractor shall furnish all appropriate traffic control devices to provide safety for motorists, bicyclists, pedestrians, workers, enforcement/emergency officials, and equipment during construction as required by MUTCD. Arrangements for closure of roads, streets or other travel arteries shall be made by the Contractor with local State, County or City officials. The Contractor shall notify the appropriate official in writing at least ten (10) days in advance of the date desired to close a road to traffic and shall furnish a copy of the agreement and approved Temporary Traffic Control plans to the Contracting Officer prior to closure.

1.8.4 State and Federal Highways

Where the Contractor hauls across or on State or Federal highways, the Contractor shall enter into all agreements with the Montana Department of Transportation and shall comply with any restrictions they may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the Government of any responsibility for damages resulting from hauling across or on State highways. Copies of such agreements shall be furnished to the Contracting Officer before the Contractor begins hauling on these highways.

1.8.5 State and Local Public Roads

(a) Load Limits:

The Montana Department of Transportation and local County Road Commissions restrict the load weights of haul vehicles using highways and county roads during the spring thaw period. The load restrictions are usually imposed from 1 April through June depending on actual weather conditions.

(b) Hauling Regulations:

Prior to start of hauling operations on public roads, the Contractor shall furnish evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.8.6 City Streets

Where the Contractor intends to cross or to use city streets for haul roads the Contractor shall enter into an agreement with the City and shall comply with any restrictions the City may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these highways. A copy of all such agreements shall be furnished the Contracting Officer before the Contractor begins hauling in city streets.

SECTION 01 12 00 Page 5

1.9 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of the State and other entities (public and private) working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits. The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.10 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Proposed Methods of Operation; G-AO

Construction Right-of-Way

(Right-of-Way Agreements)

State and Federal Highways

(Agreements for hauling on highways)

State and Local Public Roads

(Agreements for hauling on roads)

Temporary Traffic Control (TTC); G, AO

SD-02 Shop Drawings

Care of Water; G-AO

SD-11 Closeout Submittals

Warranty of Construction

(List of warranties with copy of each)

1.11 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

SECTION 01 12 00 Page 6

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

SECTION 01 12 00 Page 7

1.12 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company

1.13 PORTABLE TOILETS

Toilet facilities will not be available for Contractor's use. The Contractor shall provide and maintain portable toilets for use by the Contractor's staff . Toilet(s) shall be placed at the location directed by the Contracting Officer. To prevent overturning by high winds, all portable toilets shall be anchored down.

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1700 hrs Monday through Friday, excluding any federally recognized holidays or observance days. The Contractor shall plan all work accordingly. These hours will be strictly adhered to unless the Government determines work outside this time is beneficial to the Government or a bilateral modification for extended working hours is executed.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

-- End of Section --

SECTION 01 12 00 Page 8

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00

MEASUREMENT AND PAYMENT

6/2000

PART 1 DEWATERING - CLIN 0001

1.1 Work Included

1.2 Measurement

1.3 Payment

PART 2 ALL WORK TO REPAIR TOE DRAIN OUTFALL AND MONITORING SYSTEM - CLIN

2.1 Work Included

2.2 Measurement

2.3 Payment

PART 3 ALL WORK TO REPLACE FOUR CULVERTS - CLIN 0003

3.1 Work Included

3.2 Measurement

3.3 Payment

PART 4 ALL WORK TO REPLACE FLUME - CLIN 0004

4.1 Work Included

4.2 Measurement

4.3 Payment

SECTION 01 22 00 Page 1

SECTION 01 22 00

MEASUREMENT AND PAYMENT

6/2000

SCOPE: This section covers the methods and procedures which will be used to measure the Contractor's work and to effect payment.

GENERAL: The general outline of the principal features of each item as listed does not in any way limit the responsibility of the Contractor for making a thorough investigation of the Drawings and Specifications to determine the scope of work under the entire Contract. Payment to the Contractor of the amounts based on the quantities of work as measured in accordance with the specified methods of measurement and the prices stipulated in the accepted proposal will constitute complete compensation for all work shown on the Drawings, provided in the specifications or other Contract Documents and all costs of accepting the general risks, liabilities and obligations expressed or implied. Payment under all items must include, but not necessarily be limited to, compensation for furnishing all supervision, labor, equipment, and materials and services (including overhead and profit), as well as performing all work required to accomplish and complete the work specified under each item and all other work required.

LUMP SUM ITEMS

Quantities: The quantities under lump sum items will not be measured except for the purpose of determining reasonable interim payments.

Interim Payments: Interim payments will be made in accordance with the estimated value of work done as determined by the Contracting Officer's Representative (COR) or as specified in this section, and in accordance with contract clause for payments.

UNIT PRICE ITEMS

Excavation/Removal Items: Excavation and/or removal items will be measured from existing ground levels to excavation surfaces shown on the Drawings or as directed by the COR.

Fill Items: Fill items will be measured from existing ground levels or excavation surfaces shown on the drawings or as directed by the COR.

Existing Ground Levels: Existing ground levels must be surveyed prior to any disturbances in accordance with the relevant provisions of these specifications.

Excavation Surfaces Not Shown: In the event excavation surfaces are not clearly shown on the Drawings, the Contractor must obtain clarification from the COR prior to commencement of excavation and/or removal.

Payments to Contractor: Payments will be made to the Contractor and approved by for unit price items in accordance with measurements determined by COR at the unit prices entered in the proposal schedule.

Interim Measurement/Payments: Interim measurements and/or payments maybe adjusted to take account of partially completed work.

SECTION 01 22 00 Page 2

BI DDI NG I TEMS

PART 1 DEWATERING - CLIN 0001

1.1 Work Included

The work of this item must include but not be limited to all materials, equipment, labor, supervision to complete all necessary investigations, testings, submittals, design, operation, maintenance, and removal/abandonment of the dewatering system as specified herein and shown on the drawings.

1.2 Measurement

Job.

1.3 Payment

Payment for this item must be the job amount as indicated on the Bidding Schedule.

PART 2 ALL WORK TO REPAIR TOE DRAIN OUTFALL AND MONITORING SYSTEM - CLIN

2.1 Work Included

The work included in this item must include but not be limited to furnishing all labor, supervision, equipment, tools, subcontractors, and material needed to complete all Work To Repair Toe Drain Outfall and Monitoring System excluding CLINs 0001, 0003, and 0004. All work must include but not be limited to: mobilization/demobilization; temporary traffic control; topsoil stripping, excavation, demolition and disposal off-site of the existing pipes, flared end, riser, weir box; installation of flowable fill, coarse filter aggregate, fine filter aggregate, bedding;

installation of new perforated 18" diameter corrugated HDPE pipe, solid 18" diameter corrugated HDPE pipe, precast concrete manhole, and fiberglass metering manhole; backfill; seeding; placement of road surfacing, riprap; video camera inspection of the new pipe; conduct closeout inspection; as-builts; and other miscellaneous items.

2.2 Measurement

Job.

2.3 Payment

Payment for "ALL WORK TO REPAIR TOE DRAIN OUTFALL AND MONITORING SYSTEM" must be made on a progressive basis, based on the amount of work completed.

PART 3 ALL WORK TO REPLACE FOUR CULVERTS - CLIN 0003

3.1 Work Included

The work included in this item must include but not be limited to furnishing all labor, supervision, equipment, tools, subcontractors, and material needed to complete ALL OPTION 1 WORK TO REPLACE FOUR CULVERTS covered in Bid Item CLIN 0003. All work must include but not be limited to: demolition work and legal disposal off-site of the existing culverts and flared ends; placement of fill materials, road surface, riprap, etc.;

SECTION 01 22 00 Page 3 installation of new solid 24" diameter corrugated HDPE pipe and solid 36" diameter corrugated HDPE pipe; video camera inspection of the new pipe;

closeout inspection; as-builts; and other miscellaneous items.

3.2 Measurement

Job.

3.3 Payment

Payment for "ALL WORK TO REPLACE FOUR CULVERTS" must be made on a progressive basis, based on the amount of work completed.

PART 4 ALL WORK TO REPLACE FLUME - CLIN 0004

4.1 Work Included

The work included in this item must include but not be limited to furnishing all labor, supervision, equipment, tools, subcontractors, and material needed to complete ALL WORK TO REPLACE FLUME covered in Bid Item CLIN 0004. All work must include but not be limited to: demolition work and legal disposal off-site of the existing flume; installation and removal of trench protective systems; transportation and stockpiling of excavated materials; placement of fill materials; erosion control;

transport within Fort Peck Dam Project and installation of the new government furnished flume; closeout inspection; as-builts; and other miscellaneous items.

4.2 Measurement

Job.

4.3 Payment

Payment for "ALL WORK TO REPLACE FLUME" must be made on a progressive basis, based on the amount of work completed.

SECTION 01 22 00 Page 4

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

12/21

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.6 EXCEPTION TO COMPLETION TIME AND LIQUIDATED DAMAGES SCHEDULES

1.7 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

1.8 CONTRACT DRAWINGS AND SPECIFICATIONS

1.8.1 SETS FURNISHED

1.8.2 DISTRIBUTION

1.8.3 NOTIFICATION OF DISCREPANCIES

1.8.4 OMISSIONS

1.9 PAYMENT

1.9.1 PROMPT PAYMENT ACT

1.9.2 PAYMENT FOR MATERIALS STORED OFFSITE

1.10 AVAILABILITY AND USE OF UTILITY SERVICES

1.11 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.12 INSURANCE REQUIRED

1.13 CONTRACTOR QUALITY CONTROL (CQC)

1.14 NONDOMESTIC CONSTRUCTION MATERIALS

1.15 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.16 AS-BUILT DRAWINGS

1.17 PARTNERING

1.18 PROFIT

1.19 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.20 DRAWING SCALES

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

12/21

PART 1 GENERAL

Attachments:

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.publications.usace.army.mil/USACE-Publications/Engineer-Pamphlets/ on pages 10 and 11 of 13.

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a. Use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. The electronic payroll service must be capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

c. The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

SECTION 01 30 00.24 Page 2

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. This durable record copy of data from the electronic payroll processing system must be provided to the Government during contract closeout.

d. All Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service must be included in the Contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services must not be a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.

For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called

SECTION 01 30 00.24 Page 3

PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. Not Used

2. Access and General Protection/Security Policy and Procedures All Contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The Contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in Contractor security matters or processes.

3. thru 14 Not Used.

15. Pre-Screen Candidates using E-Verify Program The Contractor must pre-screen Candidates using the E-verify Program (http://www.dhs.gov/E-Verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

16. & 17 Not Used

1.6 EXCEPTION TO COMPLETION TIME AND LIQUIDATED DAMAGES SCHEDULES

In case the Contracting Officer determines that seeding, and/or the specified maintenance thereof is not feasible during the construction period, such work will be exempt from the completion and liquidated damages schedules. Accomplish this work during the first seeding, period and the specified maintenance period following the completion date.

1.7 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

No work will be required at the construction site during the period 01 November through 31 March inclusive. The days in this period have been included in computing the calendar days for completion of the work. The Contractor may perform work at the site during all or any part of this period upon giving prior written notice to the Contracting Officer.

Working during this non-work period requires approval by the Contracting Officer. No time extensions will be granted for delays during this period.

SECTION 01 30 00.24 Page 4

1.8 CONTRACT DRAWINGS AND SPECIFICATIONS

1.8.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein. The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.8.2 DISTRIBUTION

The Government will provide the Contractor with a CD-ROM or DVD-ROM or sent electronically containing Adobe Acrobat.pdf contract drawings and conformed specification sets and editable CAD file drawings (format defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS). Prepare final record or as-built drawings as defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS.

1.8.3 NOTIFICATION OF DISCREPANCIES

Check all drawing files furnished by the Government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies.

Follow dimensions marked on drawings in lieu of scale measurements.

Enlarged plans and details govern where the same work is shown at smaller scales. All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted adjust the scales accordingly. Advise sub-contractors of the above. Compare all drawings and verify the figures before laying out the work and take responsibility for any errors which might have been avoided thereby.

1.8.4 OMISSIONS

Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing such omitted or misdescribed details of the work but work must be performed as if fully and correctly set forth and described in the drawings and specifications.

1.9 PAYMENT

1.9.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

SECTION 01 30 00.24 Page 5

1.9.2 PAYMENT FOR MATERIALS STORED OFFSITE

a. As allowed under (FAR) 52.232-5 "Payments Under Fixed Price Construction Contracts", the Administrative Contracting Officer, at their discretion, may authorize progress payments for any material stored off-site provided:

(1) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract,

(2) Material is stored in such a manner to protect it from damage, fire, theft, etc .

(3) The Contractor provides evidence of insurance for material, and,

(4) Material is clearly identified and delineated by contract number for use on the applicable project.

b. The Administrative Contracting Officer reserves the right to inspect any off-site material prior to authorizing progress payments. Provide paid invoices listing the value of material and labor incorporated in the items.

1.10 AVAILABILITY AND USE OF UTILITY SERVICES

Use of public and private utilities will be as found available. Make arrangements for use of public and private utilities.

1.11 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default:

(Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 17

SECTION 01 30 00.24 Page 6

Feb 15 Mar 8 Apr 4 May 6 Jun 5 Jul 3 Aug 4 Sep 2 Oct 3 Nov 7 Dec 17

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.12 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.13 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00.00 10 QUALITY CONTROL.

SECTION 01 30 00.24 Page 7

1.14 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials or their components referenced in the Buy American Construction Material Contract Clauses includes the list set forth in paragraph 25.104 of the Federal Acquisition Regulation.

1.15 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, prepare a written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service at which time the Contractor must submit for coordination and approval, their proposed daily work schedule for the next two week period. Provide a copy of modifications (MODs), Serial Letters, Requests for Information (RFIs)and any other information that is needed in the minutes of the meeting.

Include required temporary utility services, time and duration of interruptions, and protection of adjoining areas with the Contractor's proposed 2-week work schedule. At this meeting, the Contractor must also submit their schedule of proposed dates and times of all preparatory inspections to be performed during the next 2 weeks. All schedules shall be in developed in accordance with Section 01 32 01.00 10 PROJECT SCHEDULE Coordination action by the Contracting Officer relative to these schedules will be accomplished during these weekly meetings. Daily reports must be completed and given to the Contracting Officer or Representative within 24 hours of work. All official correspondence such as serial letters and RFIs, with attachments are to be provided in one hardcopy original with original signatures and one electronic (Adobe pdf format) copy by email.

The Government will consider the correspondence to be received when the official hardcopy or electronic copy is received by the designated office.

1.16 AS-BUILT DRAWINGS

See SECTION 01 78 39.00 24 - AS-BUILT DRAWINGS

1.17 PARTNERING

a. The Government intends to encourage the formation of a cohesive partnership with the Contractor. This partnership will be structured to draw on the strengths of each organization to identify and achieve reciprocal goals. The objective is effective contract performance in achieving completion within budget, on schedule and in accordance with plans and specifications. This partnership between the Contractor and the Government will be voluntary and its implementation will not be part of the contract requirements nor will it result in a change to contract price or terms.

b. Not Applicable.

1.18 PROFIT

a. Use the weighted guidelines method of determining profit on any equitable adjustment change order or modification issued under this contract. The profit factors must be as follows:

Factor Rate Weight Value Degree of Risk 20 See Item Relative difficulty of work 15 b. below

SECTION 01 30 00.24 Page 8

Size of Job 15 Period of performance 15 Contractor's investment 5 Assistance by Government 5 Subcontracting 25

b. Based on the circumstances of each procurement action, each of the above factors must be weighted from .03 to .12 as indicated below. Obtain the value by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

(1) Degree of Risk. Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12.

Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider:

the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

(2) Relative Difficulty of Work. If the work is most difficult and complex, the weighting should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Some things to consider: the nature of the work, by whom it is to be done, where, and what is the time schedule.

(3) Size of Job. All work not in excess of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05.

(4) Periods of Performance. Jobs in excess of 24 months are to be weighted at .12. Jobs of lesser duration are to be proportionately weighted to a minimum of .03 for jobs not to exceed 30 days. No weight where additional time not required.

(5) Contractor's Investment. To be weighted from .03 to .12 on the basis of below average, average, and above average. Things to consider: amount of subcontracting, mobilization payment item, Government furnished property, equipment and facilities, and expediting assistance.

(6) Assistance by Government. To be weighted from .12 to .03 on the basis of average to above average. Things to consider: use of Government-owned property, equipment and facilities, and expediting assistance.

(7) Subcontracting. To be weighted inversely proportional to the amount of subcontracting. Where 80 percent or more of the work is to be subcontracted, the weighting is to be .03 and such weighting proportionately increased to .12 where all the work is performed by the Contractor's own forces.

1.19 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

It is the position of the Department of Defense that the Davis-Bacon Act, 40 U.S.C. 276a is applicable to temporary facilities such as job headquarters, tool yards, batch plants, borrow pits, sandpits, rock

SECTION 01 30 00.24 Page 9 quarries, and similar operations, provided they are dedicated exclusively, or nearly so, to performance of the contract or project, and provided they are adjacent or virtually adjacent to the site of the work and are established after receipt of the proposal or bid. Clause "Payrolls and Basic Records" of the GENERAL CONDITIONS (CONTRACT CLAUSES) is applicable to such operations.

1.20 DRAWING SCALES

All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted, the contractor adjust the scales accordingly. The Contractor must also advise their sub-contractors of the above.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 10

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01.00 10

PROJECT SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PROJECT SCHEDULER QUALIFICATIONS

PART 2 PRODUCTS

2.1 SOFTWARE

2.1.1 Government…