W9128F22B0015 Repair Intake Bridge Pier 10 specs.pdf

SPECIFICATIONS

(For Construction Contract)

Solicitation Number W9128F22B0015

Repair Intake Bridge Pier 10 Oahe Dam, SD

August 2022

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 12 00 CONSTRUCTION GENERAL

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 78 39.00 24 AS-BUILT DRAWINGS

DIVISION 03 - CONCRETE

03 23 00 STEEL STRESSING THREADED ROD

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

DIVISION 05 - METALS

05 05 20 POST-INSTALLED ADHESIVE CONCRETE ANCHORS

-- End of Project Table of Contents --

Intake Bridge Pier 10 Bearing Modification Oahe Dam SD OA00100

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.4 CARE OF WATER

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

1.6 ACCESS ROADS AND HAUL ROADS

1.6.1 Access Roads

1.7 PUBLIC ROADS

1.7.1 State and Federal Highways

1.7.2 State and Local Public Roads

1.8 COOPERATION WITH OTHER CONTRACTORS

1.9 SUBMITTALS

1.10 SPECIAL INSTRUCTIONS FOR PROGRESS CHARTS

1.11 WARRANTY OF CONSTRUCTION (MAR 1994)

1.12 TELEPHONE/INTERNET

1.13 PORTABLE TOILETS

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

-- End of Section Table of Contents --

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract, subject to the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Operations and Storage Areas."

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The

SECTION 01 12 00 Page 2

Contractor shall make the needed investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the work.

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.6 ACCESS ROADS AND HAUL ROADS

1.6.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, and traffic control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to construction. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by the Contractor's operation.

1.7 PUBLIC ROADS

1.7.1 State and Federal Highways

Where the Contractor hauls across or on State or Federal highways, the Contractor shall enter into all agreements with the State Highway Commission and shall comply with any restrictions they may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the Government of any responsibility for damages resulting from hauling across or on State highways. Copies of such agreements shall be furnished to the Contracting Officer before the Contractor begins hauling on these highways.

1.7.2 State and Local Public Roads

(a) Load Limits:

The South Dakota Department of Transportation and local County Road Commissions restrict the load weights of haul vehicles using highways and county roads during the spring thaw period. The load restrictions are usually imposed from 1 April through June depending on actual weather conditions.

(b) Hauling Regulations:

Prior to start of hauling operations on public roads, the Contractor shall furnish evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and

SECTION 01 12 00 Page 3 bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.8 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of the State and others (public and private) working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits. The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Proposed Methods of Operation; G-PO

Progress Charts; G-PO

Construction Right-of-Way

(Right-of-Way Agreements)

State and Federal Highways

(Agreements for hauling on highways)

State and Local Public Roads

(Agreements for hauling on roads)

SD-02 Shop Drawings

Care of Water; G-PO

SD-11 Closeout Submittals

Warranty of Construction

(List of warranties with copy of each)

1.10 SPECIAL INSTRUCTIONS FOR PROGRESS CHARTS

To be submitted in accordance with the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Schedule for Construction Contracts" shall indicate the required data for each of the principal features of the work. Contract changes or modifications will not include extensions of time unless the updated progress chart shows that the contract completion date is delayed due to the affect of the change on one

SECTION 01 12 00 Page 4 or more principal features of the work.

1.11 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or

SECTION 01 12 00 Page 5 subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.12 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company.

1.13 PORTABLE TOILETS

Toilet facilities will not be available for Contractor's use. The Contractor shall provide and maintain portable toilets for use by the Contractor's staff . Toilet(s) shall be placed at the location directed by the Contracting Officer. To prevent overturning by high winds, all portable toilets shall be anchored down.

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1700 hrs Monday through Friday, excluding any federally recognized holidays or observance days. The Contractor shall plan all work accordingly. Working outside these work hours will need written permission from the COR. The Contractor will not be allowed to work on Federal holidays.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

-- End of Section --

SECTION 01 12 00 Page 6

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.6 CONTRACT DRAWINGS AND SPECIFICATIONS

1.6.1 SETS FURNISHED

1.6.2 DISTRIBUTION

1.6.3 NOTIFICATION OF DISCREPANCIES

1.6.4 OMISSIONS

1.7 PAYMENT

1.7.1 PROMPT PAYMENT ACT

1.7.2 PAYMENT FOR MATERIALS STORED OFFSITE

1.8 AVAILABILITY AND USE OF UTILITY SERVICES

1.9 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.10 INSURANCE REQUIRED

1.11 CONTRACTOR QUALITY CONTROL (CQC)

1.12 NONDOMESTIC CONSTRUCTION MATERIALS

1.13 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.14 AS-BUILT DRAWINGS

1.15 PARTNERING

1.16 PROFIT

1.17 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.18 DRAWING SCALES

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

Attachments:

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.publications.usace.army.mil/USACE-Publications/Engineer-Pamphlets/ on pages 10 and 11 of 13.

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a. Use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. The electronic payroll service must be capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

c. The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

SECTION 01 30 00.24 Page 2

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. This durable record copy of data from the electronic payroll processing system must be provided to the Government during contract closeout.

d. All Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service must be included in the Contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services must not be a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.

For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60

SECTION 01 30 00.24 Page 3 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. Not Used

2. Access and General Protection/Security Policy and Procedures All Contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The Contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in Contractor security matters or processes.

3. thru 14 Not Used.

15. Pre-Screen Candidates using E-Verify Program The Contractor must pre-screen Candidates using the E-verify Program (http://www.dhs.gov/E-Verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

16. & 17 Not Used

1.6 CONTRACT DRAWINGS AND SPECIFICATIONS

1.6.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein. The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.6.2 DISTRIBUTION

The Government will provide the Contractor with a CD-ROM or DVD-ROM or

SECTION 01 30 00.24 Page 4 sent electronically containing Adobe Acrobat.pdf contract drawings and conformed specification sets and editable CAD file drawings (format defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS). Prepare final record or as-built drawings as defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS.

1.6.3 NOTIFICATION OF DISCREPANCIES

Check all drawing files furnished by the Government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies.

Follow dimensions marked on drawings in lieu of scale measurements.

Enlarged plans and details govern where the same work is shown at smaller scales. All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted adjust the scales accordingly. Advise sub-contractors of the above. Compare all drawings and verify the figures before laying out the work and take responsibility for any errors which might have been avoided thereby.

1.6.4 OMISSIONS

Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing such omitted or misdescribed details of the work but work must be performed as if fully and correctly set forth and described in the drawings and specifications.

1.7 PAYMENT

1.7.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

1.7.2 PAYMENT FOR MATERIALS STORED OFFSITE

a. As allowed under (FAR) 52.232-5 "Payments Under Fixed Price Construction Contracts", the Administrative Contracting Officer, at their discretion, may authorize progress payments for any material stored off-site provided:

(1) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract,

(2) Material is stored in such a manner to protect it from damage, fire, theft, etc .

(3) The Contractor provides evidence of insurance for material, and,

(4) Material is clearly identified and delineated by contract number for use on the applicable project.

SECTION 01 30 00.24 Page 5

b. The Contracting Officer's Representative reserves the right to inspect any off-site material prior to authorizing progress payments. Provide paid invoices listing the value of material and labor incorporated in the items.

1.8 AVAILABILITY AND USE OF UTILITY SERVICES

Use of public and private utilities will be as found available. Make arrangements for use of public and private utilities.

1.9 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default:

(Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 14 Feb 12 Mar 8 Apr 4 May 4 Jun 5 Jul 3 Aug 3 Sep 3 Oct 3 Nov 5 Dec 13

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the

SECTION 01 30 00.24 Page 6 critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.10 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.11 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00.00 10 QUALITY CONTROL.

1.12 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials or their components referenced in the Buy American Construction Material Contract Clauses includes the list set forth in paragraph 25.104 of the Federal Acquisition Regulation.

1.13 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, prepare a written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service at which time the Contractor must submit for coordination and approval, their proposed daily work schedule for the next two week period. Provide a copy of modifications (MODs), Serial Letters, Requests for Information (RFIs)and any other information that is needed in the minutes of the meeting.

Include required temporary utility services, time and duration of interruptions, and protection of adjoining areas with the Contractor's proposed 2-week work schedule. At this meeting, the Contractor must also submit their schedule of proposed dates and times of all preparatory

SECTION 01 30 00.24 Page 7 inspections to be performed during the next 2 weeks. All schedules shall be in developed in accordance with paragraph: PROGRESS CHARTSCoordination action by the Contracting Officer relative to these schedules will be accomplished during these weekly meetings. Daily reports must be completed and submitted via RMS within 24 hours of the work. All official correspondence such as serial letters and RFIs shall be submitted via RMS and one electronic (Adobe pdf format) copy by email. The Government will consider the correspondence to be received when the official electronic copy is received by the designated office.

1.14 AS-BUILT DRAWINGS

See SECTION 01 78 39.00 24 - AS-BUILT DRAWINGS

1.15 PARTNERING

a. The Government intends to encourage the formation of a cohesive partnership with the Contractor. This partnership will be structured to draw on the strengths of each organization to identify and achieve reciprocal goals. The objective is effective contract performance in achieving completion within budget, on schedule and in accordance with plans and specifications. This partnership between the Contractor and the Government will be voluntary and its implementation will not be part of the contract requirements nor will it result in a change to contract price or terms.

b. Not Applicable.

1.16 PROFIT

a. Use the weighted guidelines method of determining profit on any equitable adjustment change order or modification issued under this contract. The profit factors must be as follows:

Factor Rate Weight Value Degree of Risk 20 See Item Relative difficulty of work 15 b. below Size of Job 15 Period of performance 15 Contractor's investment 5 Assistance by Government 5 Subcontracting 25

b. Based on the circumstances of each procurement action, each of the above factors must be weighted from .03 to .12 as indicated below. Obtain the value by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

(1) Degree of Risk. Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12.

Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider:

the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

SECTION 01 30 00.24 Page 8

(2) Relative Difficulty of Work. If the work is most difficult and complex, the weighting should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Some things to consider: the nature of the work, by whom it is to be done, where, and what is the time schedule.

(3) Size of Job. All work not in excess of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05.

(4) Periods of Performance. Jobs in excess of 24 months are to be weighted at .12. Jobs of lesser duration are to be proportionately weighted to a minimum of .03 for jobs not to exceed 30 days. No weight where additional time not required.

(5) Contractor's Investment. To be weighted from .03 to .12 on the basis of below average, average, and above average. Things to consider: amount of subcontracting, mobilization payment item, Government furnished property, equipment and facilities, and expediting assistance.

(6) Assistance by Government. To be weighted from .12 to .03 on the basis of average to above average. Things to consider: use of Government-owned property, equipment and facilities, and expediting assistance.

(7) Subcontracting. To be weighted inversely proportional to the amount of subcontracting. Where 80 percent or more of the work is to be subcontracted, the weighting is to be .03 and such weighting proportionately increased to .12 where all the work is performed by the Contractor's own forces.

1.17 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

It is the position of the Department of Defense that the Davis-Bacon Act, 40 U.S.C. 276a is applicable to temporary facilities such as job headquarters, tool yards, batch plants, borrow pits, sandpits, rock quarries, and similar operations, provided they are dedicated exclusively, or nearly so, to performance of the contract or project, and provided they are adjacent or virtually adjacent to the site of the work and are established after receipt of the proposal or bid. Clause "Payrolls and Basic Records" of the GENERAL CONDITIONS (CONTRACT CLAUSES) is applicable to such operations.

1.18 DRAWING SCALES

All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted, the contractor adjust the scales accordingly. The Contractor must also advise their sub-contractors of the above.

SECTION 01 30 00.24 Page 9

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 10

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 GENERAL

1.1 SUMMARY

1.1.1 Submittal Information

1.1.2 Project Type

1.1.3 Submission of Submittals

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

1.2.2 Approving Authority

1.2.3 Work

1.3 SUBMITTALS

1.3.1 Action Codes

1.3.1.1 Contractor Action Codes

1.3.1.2 Government Reviewer Designations

1.4 SUBMITTAL CLASSIFICATION

1.4.1 Government Approved (G)

1.4.2 For Information Only

1.5 PREPARATION

1.5.1 Transmittal Form

1.5.2 Submittal Format

1.5.2.1 Format of SD-01 Preconstruction Submittals

1.5.2.2 Format for SD-02 Shop Drawings

1.5.2.2.1 Drawing Identification

1.5.2.3 Format of SD-03 Product Data

1.5.2.3.1 Product Information

1.5.2.3.2 Standards

1.5.2.3.3 Data Submission

1.5.2.4 Format of SD-04 Samples

1.5.2.4.1 Sample Characteristics

1.5.2.4.2 Sample Incorporation

1.5.2.4.3 Comparison Sample

1.5.2.5 Format of SD-05 Design Data

1.5.2.6 Format of SD-06 Test Reports

1.5.2.7 Format of SD-07 Certificates

1.5.2.8 Format of SD-08 Manufacturer's Instructions

1.5.2.8.1 Standards

1.5.2.9 Format of SD-09 Manufacturer's Field Reports

1.5.2.10 Format of SD-10 Operation and Maintenance Data (O&M)

1.5.2.11 Format of SD-11 Closeout Submittals

1.5.3 Source Drawings for Shop Drawings

1.5.3.1 Source Drawings

1.5.3.2 Terms and Conditions

1.5.4 Electronic File Format

1.6 QUANTITY OF SUBMITTALS

1.6.1 Number of SD-04 Samples

1.7 INFORMATION ONLY SUBMITTALS

SECTION 01 33 00 Page 1

1.8 PROJECT SUBMITTAL REGISTER

1.8.1 Submittal Management

1.8.2 Preconstruction Use of Submittal Register

1.8.3 Contractor Use of Submittal Register

1.8.4 Approving Authority Use of Submittal Register

1.8.5 Action Codes

1.8.6 Delivery of Copies

1.9 VARIATIONS

1.9.1 Considering Variations

1.9.2 Proposing Variations

1.9.3 Warranting that Variations are Compatible

1.9.4 Review Schedule Extension

1.10 SCHEDULING

1.11 GOVERNMENT APPROVING AUTHORITY

1.11.1 Review Notations

1.12 DISAPPROVED SUBMITTALS

1.13 APPROVED SUBMITTALS

1.14 APPROVED SAMPLES

1.15 WITHHOLDING OF PAYMENT

1.16 CERTIFICATION OF SUBMITTAL DATA

PART 2 PRODUCTS

PART 3 EXECUTION

ATTACHMENTS:

ENG Form 4025

Project Submittal Register

SECTION 01 33 00 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 GENERAL

1.1 SUMMARY

1.1.1 Submittal Information

The Contractor is responsible for total management of their work including, but not limited to, approval, scheduling, control, certification of all submittals and compliance with all applicable Buy-American and Trade Agreement clauses. The submittal management system provided in these specifications is intended to be a complete system for the Contractor to use to control the quality of materials, equipment and workmanship provided by manufacturers, fabricators, suppliers and subcontractors. Review each submittal for contract compliance.

Compl i ance wi t h al l appl i cabl e Buy Amer i can and Tr ade Agr eement Cl auses i s t o be i ncl uded i n t hi s r evi ew. The Cont r act or must pr ovi de t he count r y of or i gi n on ENG For m 4025 f or each i t em submi t t ed. The Submittal Register (ENG Form 4288) will be utilized to log and monitor all submittal activities.

The Contracting Officer may request submittals, in addition to those specified, when deemed necessary to adequately describe the work covered in the respective sections. Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.

Units of weights and measures used on all submittals are to be the same as those used in the contract drawings.

1.1.2 Project Type

The Contractor's Quality Control (CQC) System Manager is to check and approve all items before submittal and stamp, sign, and date indicating action taken. Clearly identify proposed deviations from the contract requirements. Include within submittals items such as: Contractor's, manufacturer's, or fabricator's drawings; descriptive literature including (but not limited to) catalog cuts, diagrams, operating charts or curves;

test reports; test cylinders; samples; O&M manuals (including parts list);

certifications; warranties; and other such required items.

1.1.3 Submission of Submittals

Schedule and provide submittals requiring Government approval, after notice to proceed (NTP). Provide ample lead time to ensure the submittal's processing by the Government and any lead time needed by the manufacturer upon ordering after approval. Dispose of samples not incorporated into the work in accordance with manufacturer's Safety Data Sheets (SDS) and in compliance with existing laws and regulations.

SECTION 01 33 00 Page 3

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

Submittal requirements are specified in the technical sections. Examples and descriptions of submittals identified by the Submittal Description (SD) numbers and titles follow:

SD-01 Preconstruction Submittals

Submittals that are required prior to or at the start of construction (work) or the next major phase of the construction on a multiphase contract.

Preconstruction Submittals include schedules and a tabular list of locations, features, and other pertinent information regarding products, materials, equipment, or components to be used in the work.

The Government reserves the right to handle pre-construction submittals (listed below) as administrative submittals via a Serial Letter, as directed by the Project, Area or Resident Office. When directed by the Project, Area or Resident Office (as directed), submit administrative submittals for acceptance by the Government. Format for the Serial Letter will be as directed by the Project, Area or Resident Office.

Certificates Of Insurance

Surety Bonds

List Of Proposed Subcontractors

List Of Proposed Products

Baseline Network Analysis Schedule (NAS)

Submittal Register

Schedule Of Prices Or Earned Value Report

Accident Prevention Plan

Work Plan

Quality Control (QC) plan

Permits

Environmental Protection Plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

SECTION 01 33 00 Page 4

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards ensuring work can be judged. Includes assemblies or portions of assemblies that are to be incorporated into the project and those that will be removed at conclusion of the work.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report that includes findings of a test required to be performed on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report that includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports

Daily logs and checklists

Final acceptance test and operational test procedure

SD-07 Certificates

SECTION 01 33 00 Page 5

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that the product, system, or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits

Text of posted operating instructions

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (SDS)concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative at the job site, in the vicinity of the job site, or on a sample taken from the job site, on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must be signed by an authorized official of a testing laboratory or agency and state the test results; and indicate whether the material, product, or system has passed or failed the test.

Factory test reports.

SD-10 Operation and Maintenance Data

Data provided by the manufacturer, or the system provider, including manufacturer's help and product line documentation, necessary to maintain and install equipment, for operating and maintenance use by facility personnel.

Data required by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

Data incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, SECTION 01 33 00 Page 6 submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

1.2.2 Approving Authority

Office or designated person authorized to approve the submittal.

1.2.3 Work

As used in this section, on-site and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction. In exception, excludes work to produce SD-01 submittals.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having any designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with this section. When directed by the Government, the submittal register may be submitted via Section of 01 45 00.15 10 RESIDENTIAL MANAGMENT SYSTEM CONTRACTOR MODE (RMS-CM) in lieu of the copy attached to this section. SpecsIntact is the software system used by Government to generate the Submittal Register that is loaded into RMS-CM.

SD-01 Preconstruction Submittals

Submittal Register; G -PO

1.3.1 Action Codes

1.3.1.1 Contractor Action Codes

DESIGN BID BUILD SUBMITTALS

Submittal Classifications shown in UFGS Sections

Submittal Classification

Corresponding SpecsIntact

Submittal Register Code which is populated in the SI Submittal Register.

Software Limitations:

(The software shows one character delineation in the SpecsIntact Submittal Register)

RMS – The following Submittal

Classifications are populated in RMS when the SpecsIntact

Submittal Data File is pulled into

RMS)

SECTION 01 33 00 Page 7

DESIGN BID BUILD SUBMITTALS

G Submittal requires Government Approval

G GA

BLANK Submittal is For Information Only

(FIO)

BLANK FIO

1.3.1.2 Government Reviewer Designations

Following the Submittal Classification designation "G", the following reviewer designations may be included:

RO - Resident Office AO - Area Office DO - District Office PO - Project Office

Additional information will be provided at the pre-design and/or pre-construction conference.

Corps of Engineers, Omaha District Office for "DO" reviewer designations, submittals will be coordinated through:

Michael Hebert U.S. Army Corps of Engineers Omaha District Attn: CENWO-CDS-T 1616 Capitol Ave Omaha, NE 68102-4901 E-mail: CENWO.ConstructionSubmittal@usace.army.mil

1.4 SUBMITTAL CLASSIFICATION

1.4.1 Government Approved (G)

Government approval is required for extensions of design, critical materials, variations, equipment whose compatibility with the entire system must be checked, and other items as designated by the Government.

Within the terms of the Contract Clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION, submittals are considered to be "shop drawings."

1.4.2 For Information Only

Submittals not requiring Government approval will be for information only. Within the terms of the Contract Clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION, they are not considered to be "shop drawings."

SECTION 01 33 00 Page 8

1.5 PREPARATION

1.5.1 Transmittal Form

Use the ENG Form 4025 transmittal form for submitting both Government-approved and information-only submittals. Submit in accordance with the instructions on the reverse side of the form. These forms are included in the RMS CM software that the Contractor is required to use for this contract. Properly complete this form by filling out all the heading blank spaces and identifying each item submitted. If there are multiple Item numbers listed on a particular ENG Form 4025 submittal, combine all submitted items for review into a single Adobe file with bookmarks (for ease of review). Exercise special care to ensure proper listing of the specification paragraph and sheet number of the contract drawings pertinent to the data submitted for each item.

1.5.2 Submittal Format

1.5.2.1 Format of SD-01 Preconstruction Submittals

When the submittal includes a document that is to be used in the project, or is to become part of the project record, other than as a…