Specs_Spillway_NDT_Garrison.pdf

Service Contract

Solicitation No. W9128F19Q0051

Spillway Gates Nondestructive Testing

Garrison Dam, ND

June 2019

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

Spillway Gates Nondestructive Testing

Garrison Dam, ND

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 12 00 SERVICE OPERATIONS

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

DIVISION 05 - METALS

05 05 24 NON-DESTRUCTIVE TESTING OF WELDS AND METALS

DIVISION 09 - FINISHES

09 97 02 PAINTING: HYDRAULIC STRUCTURES

-- End of Project Table of Contents --

Spillway Gates Nondestructive Testing, Garrison Dam ND GR98

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

SERVICE OPERATIONS

04/07

PART 1 GENERAL

1.1 SCOPE

1.2 RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.4 CARE OF WATER

1.5 ACCESS ROADS

1.5.1 Access Roads

1.6 PUBLIC ROADS

1.6.1 Road Closure

1.6.2 Traffic Control Devices

1.6.3 Traffic Control

1.6.4 Operations

1.6.4.1 Signalmen/Flagmen

1.7 COOPERATION WITH OTHER CONTRACTORS

1.8 SUBMITTALS

1.9 USE OF GOVERNMENT EQUIPMENT

1.9.1 Spillway Monorail Crane Operation

1.9.2 Working Hours

1.10 CONTRACTOR CRANE AND LIFTING DEVICES

1.11 POWER AVAILABILITY

1.12 STAGING PLAN

1.13 PORTABLE TOILETS

PART 2 NOT USED

PART 3 NOT USED

-- End of Section Table of Contents --

SECTION 01 12 00 Page 1

SECTION 01 12 00

SERVICE OPERATIONS

04/07

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a performance work statement requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract.

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and plant shall be kept within the limits of the areas assigned. Prior to performance on this contract, , the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of operations. Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, report thereof shall be made immediately to the Contracting Officer. The Contractor will be responsible for the protection of structures from any structural damage during the performance on this contraact. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the work areas.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate the needed work and to protect the work from damage by water. The Contractor shall make his own investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to starting work. Facilities shall be removed upon completion of the work.

SECTION 01 12 00 Page 2

1.5 ACCESS ROADS

1.5.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, signals and control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to performance on this contract. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by his operation.

1.6 PUBLIC ROADS

1.6.1 Road Closure

One lane of the road must remain open at all times. The Contractor will follow all traffic requirements for closing one lane at a time, allowing traffic to pass thru on the one open lane with the use of a flagman or other approved traffic control. The Contractor is required to coordinate the road/lane closure with the NDDOT and COR.

1.6.2 Traffic Control Devices

All traffic control devices (signage, barricades, lighting etc.) by the Contractor, must conform with the U.S. Department of Transportation, Federal Highway Administration, Manual on Uniform Traffic Control Devices.

1.6.3 Traffic Control

The Contractor shall be responsible for the safe control of traffic on all haul and access roads used primarily for the work under these specifications and at their crossings with roads used by others. The Contractor shall, at his own expense, furnish all personnel, signal devices and signal necessary for the safe and efficient control of work traffic on road systems used by the Contractor. A plan for traffic control, including a listing of equipment and its employment, shall be submitted for review and approval prior to performance on this contract. The plan shall comply with requirements of the North Dakota Department of Transportation.

1.6.4 Operations

When operations are being conducted near a U. S. or State Highway or when work equipment is being used on or adjacent to such highway, the Contractor shall furnish signalmen and such warning signs as are necessary to provide adequate warning to the traveling public. The highways and streets shall be kept open at all times.

1.6.4.1 Signalmen/Flagmen

The Contractor shall provide flagmen when:

a) Work equipment and/or vehicles are blocking the roadway making it difficult for vehicles to pass or see or due to terrain.

b) One-way traffic is required thru a work zone.

c) Trucks are pulling onto and/or off of a roadway or operating at a

SECTION 01 12 00 Page 3 reduced speed causing a hazardous situation for drivers.

d) Anytime the Contractor feels that drivers are at risk due to work activity.

1.7 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate his work with that of others working in the area during the life of this contract. The Contractor shall coordinate his work with others to avoid undue interference and shall conduct his operations, other than approved required access, within the limits of the assigned work area or work right-of-way limits. The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.8 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Pre-performance Submittals

Staging Plan

Contractor Crane And Lifting Devices

SD-02 Shop Drawings

Care of Water; G-AO

Traffic Control; G-AO

1.9 USE OF GOVERNMENT EQUIPMENT

1.9.1 Spillway Monorail Crane Operation

Government personnel only will operate the monorail crane. The monorail crane will only be used by the Government for lifting of the stoplogs.

1.9.2 Working Hours

The Contractor shall properly plan ahead for requiring stoplogs to be moved, such that Government operators are required for a minimum number of occasions. Use of the crane for moving stoplogs will only be during normal Government working hours. A crane operator will not be furnished on a standby basis. The Contractor shall coordinate with the Contracting Officer Representative, in writing 48 hours in advance, his needs for a crane operator. The Government will operate the crane and Tainter Gates during the normal daytime working hours of 7:00 am to 5:30 pm Monday thru Thursday.

1.10 CONTRACTOR CRANE AND LIFTING DEVICES

The Contractor may need to provide a crane or lifting devise to move his equipment from the parking area to the Spillway Apron. The Contractor's crane operator will need to be a qualified/certified Crane Operator, and shall submit their qualification/certification.

SECTION 01 12 00 Page 4

1.11 POWER AVAILABILITY

Available temporary power will be one 480 Volt, three-phase plus ground, 60 Amp receptacle. A receptacle is located at each gate on the upper landing. Contractor will be responsible for supplying their own transformer for stepping voltage down for their needs.

1.12 STAGING PLAN

The Contractor shall submit a staging plan that identifies access methods and locations for placement of equipment and material on the spillway apron. The staging plan shall identify the types and quantities of items to be staged on the apron during work, and shall provide approximate locations of where these items will be placed.

1.13 PORTABLE TOILETS

Toilet facilities will not be available for Contractor's use. The Contractor shall provide and maintain portable toilets for use by the Contractor's staff . Toilet(s) shall be placed within the staging area.

To prevent overturning by high winds, all portable toilets shall be anchored down.

PART 2 NOT USED

PART 3 NOT USED

-- End of Section --

SECTION 01 12 00 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

10/17

PART 1 GENERAL

1.1 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.2 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

10/17

PART 1 GENERAL

1.1 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This clause specifies the procedure for the determination of time extensions for unusually severe weather. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 23 Feb 17 Mar 13 Apr 4 May 3 Jun 6 Jul 3 Aug 4 Sep 4 Oct 3 Nov 12 Dec 20

c. Upon contract award and continuing throughout the contract, the contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the

SECTION 01 30 00.24 Page 2 number of days anticipated in paragraph b. above, the contracting officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification.

1.2 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, the Contractor shall prepare a written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service at which time the Contractor shall submit for coordination, the proposed daily work schedule for the next two week period.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

08/18, OMH 02/2019

PART 1 GENERAL

1.1 SUMMARY

1.1.1 Submittal Information

1.1.2 Project Type

1.1.3 Submission of Submittals

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

1.2.2 Approving Authority

1.3 SUBMITTALS

1.3.1 Action Codes

1.3.1.1 Contractor Action Codes

1.3.1.2 Government Reviewer Designations

1.4 SUBMITTAL CLASSIFICATION

1.4.1 Government Approved (G)

1.4.2 For Information Only

1.5 PREPARATION

1.5.1 Transmittal Form

1.5.2 Submittal Format

1.5.2.1 Format of SD-01 Pre-performance Submittals

1.5.2.2 Format for SD-02 Shop Drawings

1.5.2.2.1 Drawing Identification

1.5.2.3 Format of SD-03 Product Data

1.5.2.3.1 Product Information

1.5.2.3.2 Standards

1.5.2.3.3 Data Submission

1.5.2.4 Format of SD-04 Samples

1.5.2.4.1 Sample Characteristics

1.5.2.4.2 Sample Incorporation

1.5.2.4.3 Comparison Sample

1.5.2.5 Format of SD-05 Design Data

1.5.2.6 Format of SD-06 Test Reports

1.5.2.7 Format of SD-07 Certificates

1.5.2.8 Format of SD-08 Manufacturer's Instructions

1.5.2.8.1 Standards

1.5.2.9 Format of SD-09 Manufacturer's Field Reports

1.5.2.10 Format of SD-11 Closeout Submittals

1.5.3 Source Drawings for Shop Drawings

1.5.3.1 Source Drawings

1.5.3.2 Terms and Conditions

1.5.4 Electronic File Format

1.6 QUANTITY OF SUBMITTALS

1.6.1 Number of SD-04 Samples

1.7 INFORMATION ONLY SUBMITTALS

1.8 PROJECT SUBMITTAL REGISTER

1.8.1 Submittal Management

SECTION 01 33 00 Page 1

1.8.2 Pre-performance Use of Submittal Register

1.8.3 Contractor Use of Submittal Register

1.8.4 Approving Authority Use of Submittal Register

1.8.5 Action Codes

1.8.6 Delivery of Copies

1.9 SCHEDULING

1.10 GOVERNMENT APPROVING AUTHORITY

1.10.1 Review Notations

1.11 DISAPPROVED SUBMITTALS

1.12 APPROVED SUBMITTALS

1.13 APPROVED SAMPLES

1.14 WITHHOLDING OF PAYMENT

1.15 STAMPS

PART 2 PRODUCTS

PART 3 EXECUTION

ATTACHMENTS:

ENG Form 4025-R

Project Submittal Register

SECTION 01 33 00 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

08/18, OMH 02/2019

PART 1 GENERAL

1.1 SUMMARY

1.1.1 Submittal Information

The Contractor is responsible for total management of their work including, but not limited to, approval, scheduling, control, certification of all submittals and compliance with all applicable Buy-American and Trade Agreement clauses. The submittal management system provided in these specifications is intended to be a complete system for the Contractor to use to control the quality of materials, equipment and workmanship provided by manufacturers, fabricators, suppliers and subcontractors. Review each submittal for contract compliance. Compliance with all applicable Buy American and Trade Agreement Clauses is to be included in this review. The Contractor must provide the country of origin on ENG Form 4025 for each item submitted. The Submittal Register (ENG Form 4288) will be utilized to log and monitor all submittal activities.

Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.

Units of weights and measures used on all submittals are to be the same as those used in the contract drawings.

1.1.2 Project Type

The Contractor's Quality Control (CQC) System Manager is to check and approve all items before submittal and stamp, sign, and date indicating action taken. Clearly identify proposed deviations from the contract requirements. Include within submittals items such as: Contractor's, manufacturer's, or fabricator's drawings; descriptive literature including (but not limited to) catalog cuts, diagrams, operating charts or curves;

test reports; test cylinders; samples; O&M manuals (including parts list);

certifications; warranties; and other such required items.

1.1.3 Submission of Submittals

Schedule and provide submittals requiring Government approval, after contract award. Provide ample lead time to ensure the submittal's processing by the Government and any lead time needed by the manufacturer upon ordering after approval. Dispose of samples not incorporated into the work in accordance with manufacturer's Safety Data Sheets (SDS) and in compliance with existing laws and regulations.

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

Submittal requirements are specified in the technical sections. Examples and descriptions of submittals identified by the Submittal Description (SD) numbers and titles follow:

SECTION 01 33 00 Page 3

SD-01 Pre-performance Submittals

Submittals that are required prior to or at the start of wor.k

Pre-performance Submittals include schedules and a tabular list of locations, features, and other pertinent information regarding products, materials, equipment, or components to be used in the work.

The Government reserves the right to handle pre--performance submittals (listed below) as administrative submittals via a Serial Letter.

Format for the Serial Letter will be as directed by the Project, Area or Resident Office.

Certificates Of Insurance

List Of Proposed Products

Baseline Network Analysis Schedule (NAS)

Submittal Register

Accident Prevention Plan

Work Plan

Quality Control (QC) plan

Permits

Environmental Protection Plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or

SECTION 01 33 00 Page 4 workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards ensuring work can be judged. Includes assemblies or portions of assemblies that are to be incorporated into the project and those that will be removed at conclusion of the work.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report that includes findings of a test required to be performed on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report that includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports

Final acceptance test and operational test procedure

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that the product, system, or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits

Text of posted operating instructions

SD-08 Manufacturer's Instructions

SECTION 01 33 00 Page 5

Preprinted material describing installation of a product, system or material, including special notices and (SDS) concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative at the job site, in the vicinity of the job site, or on a sample taken from the job site, on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must be signed by an authorized official of a testing laboratory or agency and state the test results; and indicate whether the material, product, or system has passed or failed the test.

Factory test reports.

SD-10 Operation and Maintenance Data

Data provided by the manufacturer, or the system provider, including manufacturer's help and product line documentation, necessary to maintain and install equipment, for operating and maintenance use by facility personnel.

Data required by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

Data incorporated in an operations and maintenance manual or control system.

1.2.2 Approving Authority

Office or designated person authorized to approve the submittal.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having any designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with this section.

SD-01 Pre-performance Submittals

Submittal Register; G-AO

SECTION 01 33 00 Page 6

1.3.1 Action Codes

1.3.1.1 Contractor Action Codes

DESIGN BID BUILD SUBMITTALS

Submittal Classifications shown in UFGS Sections

Submittal Classification

Corresponding SpecsIntact

Submittal Register Code which is populated in the SI Submittal Register.

Software

Limitations: (The software shows one character delineation in the

SpecsIntact Submittal Register)

RMS – The following Submittal

Classifications are populated in RMS when the SpecsIntact

Submittal Data File is pulled into RMS)

G Submittal requires Government Approval

G GA

BLANK Submittal is For Information Only

(FIO)

BLANK FIO

1.3.1.2 Government Reviewer Designations

Following the Submittal Classification designation "G", the following reviewer designations may be included:

RO - Resident Office AO - Area Office DO - District Office AE - Architect Engineer

All submittals shall be coordinated through the project Contracting Officer's Representative.

Additional information will be provided at the pre-performance meeting.

1.4 SUBMITTAL CLASSIFICATION

1.4.1 Government Approved (G)

Government approval is required for extensions of design, critical materials, variations, equipment whose compatibility with the entire system must be checked, and other items as designated by the Government.

1.4.2 For Information Only

Submittals not requiring Government approval will be for information only.

SECTION 01 33 00 Page 7

1.5 PREPARATION

1.5.1 Transmittal Form

Use the ENG Form 4025-R transmittal form for submitting both Government-approved and information-only submittals. Submit in accordance with the instructions on the reverse side of the form. These forms are included in the RMS CM software that the Contractor is required to use for this contract. Properly complete this form by filling out all the heading blank spaces and identifying each item submitted. If there are multiple Item numbers listed on a particular ENG Form 4025-R submittal, combine all submitted items for review into a single Adobe file with bookmarks (for ease of review). Exercise special care to ensure proper listing of the specification paragraph and sheet number of the contract drawings pertinent to the data submitted for each item.

1.5.2 Submittal Format

1.5.2.1 Format of SD-01 Pre-performance Submittals

When the submittal includes a document that is to be used in the project, or is to become part of the project record, other than as a submittal, do not apply the Contractor's approval stamp to the document itself, but to a separate sheet accompanying the document.

Provide data in the unit of measure used in the contract documents.

1.5.2.2 Format for SD-02 Shop Drawings

Provide shop drawings not less than 8 1/2 by 11 inches nor more than 30 by 42 inches, except for full-size patterns or templates. Prepare drawings to accurate size, with scale indicated, unless another form is required.

Ensure drawings are suitable for reproduction and of a quality to produce clear, distinct lines and letters, with dark lines on a white background.

a. Include the nameplate data, size, and capacity on drawings. Also include applicable federal, military, industry, and technical society publication references.

b. Dimension drawings, except diagrams and schematic drawings. Prepare drawings demonstrating interface with other trades to scale. Use the same unit of measure for shop drawings as indicated on the contract drawings. Identify materials and products for work shown.

Submit an electronic copy of drawings in PDF format.

1.5.2.2.1 Drawing Identification

Include on each drawing the drawing title, number, date, and revision numbers and dates, in addition to information required in paragraph

IDENTIFYING SUBMITTALS.

Number drawings in a logical sequence. Each drawing is to bear the number of the submittal in a uniform location next to the title block. Place the Government contract number in the margin, immediately below the title block, for each drawing.

SECTION 01 33 00 Page 8

1.5.2.3 Format of SD-03 Product Data

Present product data submittals for each section. Include a table of contents, listing the page and catalog item numbers for product data.

Indicate, by prominent notation, each product that is being submitted;

indicate the specification section number and paragraph number to which it pertains.

1.5.2.3.1 Product Information

Supplement product data with material prepared for the project to satisfy the submittal requirements where product data does not exist. Identify this material as developed specifically for the project, with information and format as required for submission of SD-07 Certificates.

Provide product data in units used in the Contract documents. Where product data are included in preprinted catalogs with another unit, submit the dimensions in contract document units, on a separate sheet.

1.5.2.3.2 Standards

Where equipment or materials are specified to conform to industry or technical-society reference standards of such organizations as the American National Standards Institute (ANSI), ASTM International (ASTM), National Electrical Manufacturer's Association (NEMA), Underwriters Laboratories (UL), or Association of Edison Illuminating Companies (AEIC), submit proof of such compliance. The label or listing by the specified organization will be acceptable evidence of compliance. In lieu of the label or listing, submit a certificate from an independent testing organization, competent to perform testing, and approved by the Contracting Officer.

State on the certificate that the item has been tested in accordance with the specified organization's test methods and that the item complies with the specified organization's reference standard.

1.5.2.3.3 Data Submission

Collect required data submittals for each specific material, product, unit of work, or system into a single submittal that is marked for choices, options, and portions applicable to the submittal. Mark each copy of the product data identically. Partial submittals will not be accepted for expedition of the work effort.

Submit the manufacturer's instructions before installation.

1.5.2.4 Format of SD-04 Samples

1.5.2.4.1 Sample Characteristics

Furnish samples in the following sizes, unless otherwise specified or unless the manufacturer has prepackaged samples of approximately the same size as specified:

a. Sample of Equipment or Device: Full size.

b. Sample of Materials Less Than 2 by 3 inches: Built up to 8 1/2 by 11 inches.

c. Sample of Materials Exceeding 8 1/2 by 11 inches: Cut down to 8 1/2 by

SECTION 01 33 00 Page 9

11 inches and adequate to indicate color, texture, and material variations.

d. Sample of Linear Devices or Materials: 10 inch length or length to be supplied, if less than 10 inches. Examples of linear devices or materials are conduit and handrails.

e. Sample Volume of Nonsolid Materials: Pint. Examples of nonsolid materials are sand and paint.

f. Color Selection Samples: 2 by 4 inches. Where samples are specified for selection of color, finish, pattern, or texture, submit the full set of available choices for the material or product specified. Sizes and quantities of samples are to represent their respective standard unit.

g. Sample Panel: 4 by 4 feet.

h. Sample Installation: 100 square feet.

1.5.2.4.2 Sample Incorporation

Reusable Samples: Incorporate returned samples into work only if so specified or indicated. Incorporated samples are to be in undamaged condition at the time of use.

Recording of Sample Installation: Note and preserve the notation of any area constituting a sample installation, but remove the notation at the final clean-up of the project.

1.5.2.4.3 Comparison Sample

Samples Showing Range of Variation: Where variations in color, finish, pattern, or texture are unavoidable due to nature of the materials, submit sets of samples of not less than three units showing extremes and middle of range. Mark each unit to describe its relation to the range of the variation.

When color, texture, or pattern is specified by naming a particular manufacturer and style, include one sample of that manufacturer and style, for comparison.

1.5.2.5 Format of SD-05 Design Data

Provide design data and certificates on 8 1/2 by 11 inch page size.

1.5.2.6 Format of SD-06 Test Reports

By prominent notation, indicate each report in the submittal. Indicate the specification number and paragraph number to which each report pertains.

1.5.2.7 Format of SD-07 Certificates

Provide design data and certificates on 8 1/2 by 11 inch page size.

1.5.2.8 Format of SD-08 Manufacturer's Instructions

Present manufacturer's instructions submittals for each section. Include the manufacturer's name, trade name, place of manufacture, and catalog

SECTION 01 33 00 Page 10 model or number on product data. Also include applicable federal, military, industry, and technical-society publication references. If supplemental information is needed to clarify the manufacturer's data, submit it as specified for SD-07 Certificates.

Submit the manufacturer's instructions before installation.

1.5.2.8.1 Standards

Where equipment or materials are specified to conform to industry or technical-society reference standards of such organizations as the American National Standards Institute (ANSI), ASTM International (ASTM), National Electrical Manufacturer's Association (NEMA), Underwriters Laboratories (UL), or Association of Edison Illuminating Companies (AEIC), submit proof of such compliance. The label or listing by the specified organization will be acceptable evidence of compliance. In lieu of the label or listing, submit a certificate from an independent testing organization, competent to perform testing, and approved by the Contracting Officer.

State on the certificate that the item has been tested in accordance with the specified organization's test methods and that the item complies with the specified organization's reference standard.

1.5.2.9 Format of SD-09 Manufacturer's Field Reports

By prominent notation, indicate each report in the submittal. Indicate the specification number and paragraph number to which each report pertains.

1.5.2.10 Format of SD-11 Closeout Submittals

When the submittal includes a document that is to be used in the project or is to become part of the project record, other than as a submittal, do not apply the Contractor's approval stamp to the document itself, but to a separate sheet accompanying the document.

Provide data in the unit of measure used in the contract documents.

1.5.3 Source Drawings for Shop Drawings

1.5.3.1 Source Drawings

The entire set of source drawing files (DWG or DGN) will not be provided to the Contractor. Request the specific Drawing Number for the preparation of shop drawings. Only those drawings requested to prepare shop drawings will be provided. These drawings are provided only after award.

1.5.3.2 Terms and Conditions

Data contained on these electronic files must not be used for any purpose other than as a convenience in the preparation of data for the referenced project. Any other use or reuse is at the sole risk of the Contractor and without liability or legal exposure to the Government. The Contractor must make no claim, and waives to the fullest extent permitted by law any claim or cause of action of any nature against the Government, its agents, or its subconsultants that may arise out of or in connection with the use of these electronic files. The Contractor must, to the fullest extent permitted by law, indemnify and hold the Government harmless against all damages, liabilities, or costs, including reasonable attorney's fees and defense costs, arising out of or resulting from the use of these electronic files.

SECTION 01 33 00 Page 11

These electronic source drawing files are not work documents. Differences may exist between the source drawing files and the corresponding work documents. The Government makes no representation regarding the accuracy or completeness of the electronic source drawing files, nor does it make representation to the compatibility of these files with the Contractor hardware or software. The Contractor is responsible for determining if any conflict exists. In the event that a conflict arises between the signed and sealed work documents prepared by the Government and the furnished source drawing files, the signed and sealed work documents govern. Use of these source drawing files does not relieve the Contractor of the duty to fully comply with the contract documents, including and without limitation the need to check, confirm and coordinate the work of all contractors for the project. If the Contractor uses, duplicates or modifies these electronic source drawing files for use in producing work data related to this contract, remove all previous indication of ownership (seals, logos, signatures, initials and dates).

1.5.4 Electronic File Format

Provide submittals in electronic format, with the exception of material samples required for SD-04 Samples items. Compile the submittal file as a single, complete document, to include the Transmittal Form described within. Name the electronic submittal file specifically according to its contents, and coordinate the file naming convention with the Contracting Officer. Electronic files must be of sufficient quality that all information is legible. Use PDF as the electronic format, unless otherwise specified or directed by the Contracting Officer. All documents must make use of optical character recognition (OCR) routines to make text searchable and selectable, so that the text can be copied. Index and bookmark files exceeding 30 pages to allow efficient navigation of the file. When required, the electronic file must include a valid electronic signature.

E-mail electronic submittal documents smaller than 10MB to an e-mail address as directed by the Contracting Officer, unless directed otherwise by COR. Provide electronic documents over 10 MB on an optical disc or through an electronic file sharing system, such as secure ftp site or Government web application located at the following website:

https://safe.arl.army.mil/. Use of the Government web application must be initiated by the Government, unless Contractor has a Government CAC card.

The Government may allow the AMRDEC SAFE Web Application located at the following website: https://safe.amrdec.army.mil/safe/. Both Government web applications restrict the number of days files are available to download.

1.6 QUANTITY OF SUBMITTALS

Submittals are to be transmitted electronically, unless directed otherwise.

1.6.1 Number of SD-04 Samples

a. Submit two samples, or two sets of samples showing the range of variation, of each required item. One approved sample or set of samples will be retained by the approving authority and one will be returned to the Contractor.

b. Submit one sample panel or provide one sample installation where directed. Include components listed in the technical section or as directed.

SECTION 01 33 00 Page 12

c. Submit one sample installation, where directed.

d. Submit one sample of nonsolid materials.

1.7 INFORMATION ONLY SUBMITTALS

Submittals without an action code must be certified by the QC manager and submitted to the Contracting Officer for information-only. Approval of the Contracting Officer is not required on information only submittals. The Contracting Officer will mark "receipt acknowledged" on submittals for information and will return only the transmittal cover sheet to the Contractor. Normally, submittals for information only will not be returned. However, the Government reserves the right to return unsatisfactory submittals and require the Contractor to resubmit any item found not to comply with the contract. This does not relieve the Contractor from the obligation to furnish material conforming to the plans and specifications; will not prevent the Contracting Officer from requiring removal and replacement of nonconforming material incorporated in the work;

and does not relieve the Contractor of the requirement to furnish samples for testing by the Government laboratory or for check testing by the Government in those instances where the technical specifications so prescribe.

1.8 PROJECT SUBMITTAL REGISTER

A sample Project Submittal Register showing submittals required by the specifications is attached to this section as "Project Submittal Register."

1.8.1 Submittal Management

Prepare and maintain a submittal register, as the work progresses. Do not change data that is output in columns (c), (d), (e), and (f) as delivered by Government; retain data that is output in columns (a), (g), (h), and (i) as approved. As an attachment, provide a submittal register showing items of equipment and materials for which submittals are required by the specifications. This list may not be all-inclusive and additional submittals may be required. Maintain a submittal register for the project in accordance with Section 01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM). The Government will provide the initial submittal register in electronic format with the following fields completed, to the extent that will be required by the Government during subsequent usage.

Column (c): Lists specification section in which submittal is required.

Column (d): Lists each submittal description (SD Number. and type, e.g., SD-02 Shop Drawings) required in each specification section.

Column (e): Lists one principal paragraph in each specification section where a material or product is specified. This listing is only to facilitate locating submitted requirements. Do not consider entries in column (e) as limiting the project requirements.

Thereafter, the Contractor is to track all submittals by maintaining a complete list, including completion of all data columns and all dates on

SECTION 01 33 00 Page 13 which submittals are received by and returned by the Government.

1.8.2 Pre-performance Use of Submittal Register

Submit the submittal register as an electronic database, using the submittal management program furnished to Contractor, unless directed otherwise by COR. Include the QC plan and the project schedule. Verify that all submittals required for the project are listed and add missing submittals. Coordinate and complete the following fields on the register database submitted with the QC plan and the project schedule:

Column (a) Activity Number: Activity number from the project schedule.

Column (g) Contractor Submit Date: Scheduled date for the approving authority to receive submittals.

Column (h) Contractor Approval Date: Date that Contractor needs approval of submittal.

Column (i) Contractor Material: Date that Contractor needs material delivered to Contractor control.

1.8.3 Contractor Use of Submittal Register

Update the following fields in the Government-furnished submittal register program or equivalent fields in the program used by the Contractor with each submittal throughout the contract.

Column (b) Transmittal Number: List of consecutive, Contractor-assigned numbers.

Column (j) Action Code (k): Date of action used to record Contractor's review when forwarding submittals to QC.

Column (l) Date submittal transmitted.

Column (q) Date approval was received.

1.8.4 Approving Authority Use of Submittal Register

Update the following fields:

Column (b) Transmittal Number: List of consecutive, Contractor-assigned numbers.

Column (l) Date submittal was received.

Column (m) through (p) Dates of review actions.

Column (q) Date of return to Contractor.

1.8.5 Action Codes

See paragraph Action Codes above.1.8.6 Delivery of Copies

Submit an updated electronic copy of the submittal register to the Contracting Officer with each invoice request, unless a paper copy is requested by the Contracting Officer. Provide an updated Submittal

SECTION 01 33 00 Page 14

Register monthly regardless of whether an invoice is submitted.

1.9 SCHEDULING

Schedule and submit concurrently product data and shop drawings covering component items forming a system or items that are interrelated. Submit pertinent certifications at the same time. No delay damages or time extensions will be allowed for time lost in late submittals.

a. Coordinate scheduling, sequencing, preparing, and processing of submittals with performance of work so that work will not be delayed by submittal processing. The Contractor is responsible for additional time required for Government reviews resulting from required resubmittals. The review period for each resubmittal is the same as for the initial submittal.

b. Submittals required by the contract documents are listed on the submittal register. If a submittal is listed in the submittal register but does not pertain to the contract work, the Contractor is to include the submittal in the register and annotate it "N/A" with a brief explanation. Approval by the Contracting Officer does not relieve the Contractor of supplying submittals required by the contract documents but that have been omitted from the register or marked "N/A."

c. Resubmit the submittal register and annotate it monthly with actual submission and approval dates. When all items on the register have been fully approved, no further resubmittal is required.

Contracting Officer review will be completed within 20 calendar days after the date of submission.

The Government review period for each submittal does not begin until the submittal is delivered via RMS CM. Contract compliance for all submittals are the Contractor's responsibility. Government acceptance or receipt acknowledged does not remove this responsibility for contract compliance on any submittal.

1.10 GOVERNMENT APPROVING AUTHORITY

When the approving authority is the Contracting Officer, the Government will:

a. Note the date on which the submittal was received.

b. Review submittals for approval within the scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

c. Identify returned submittals with one of the actions defined in paragraph REVIEW NOTATIONS and with comments and markings appropriate for the action indicated.

Upon completion of review of submittals requiring Government approval, stamp and date submittals. An electronic copy of the submittal will be retained by the Contracting Officer and an electronic copy of the submittal will be returned to the Contractor. The Government may process submittals in the RMS CM System.

SECTION 01 33 00 Page 15

1.10.1 Review Notations

Submittals will be returned to the Contractor with the following notations:

a. Submittals marked "approved" or "accepted" authorize proceeding with the work covered.

b. Submittals marked "approved as noted" or "approved, except as noted, resubmittal not required," authorize proceeding with the work covered provided that the Contractor takes no exception to the corrections.

c. Submittals marked "not approved," "disapproved," or "revise and resubmit" indicate incomplete submittal or noncompliance with the contract requirements or design concept. Resubmit with appropriate changes. Do not proceed with work for this item until the resubmittal is approved.

d. Submittals marked "not reviewed" indicate that the submittal has been previously reviewed and approved, is not required, does not have evidence of being reviewed and approved by Contractor, or is not complete. A submittal marked "not reviewed" will be returned with an explanation of the reason it is not reviewed. Resubmit submittals returned for lack of review by Contractor or for being incomplete, with appropriate action, coordination, or change.

e. Submittals marked "receipt acknowledged" indicate that submittals have been received by the Government. This applies only to "information-only submittals" as previously defined.

1.11 DISAPPROVED SUBMITTALS

Make corrections required by the Contracting Officer. If the Contractor considers any correction or notation on the returned submittals to constitute a change to the contract drawings or specifications, give notice to the Contracting Officer as required under the FAR clause titled CHANGES. The Contractor is responsible for the dimensions and design of connection details of the work. Failure to point out variations may cause the Government to require rejection and removal of such work at the Contractor's expense.

If changes are necessary to submittals, make such revisions and resubmit in accordance with the procedures above. No item of work requiring a submittal change is to be accomplished until the changed submittals are approved.

1.12 APPROVED SUBMITTALS

The Contracting Officer's approval of submittals is not to be construed as a complete check, and indicates only that the general method of work, materials, detailing, and other information are satisfactory.

Approval or acceptance by the Government for a submittal does not relieve the Contractor of the responsibility for meeting the contract requirements or for any error that may exist, because under the Quality Control (QC) requirements of this contract, the Contractor is responsible for ensuring information contained with in each submittal accurately conforms with the requirements of the contract documents.

After submittals have been approved or accepted by the Contracting Officer, SECTION 01 33 00 Page 16 no resubmittal for the purpose of substituting materials or equipment will be considered unless accompanied by an explanation of why a substitution is necessary.

1.13 APPROVED SAMPLES

Approval of a sample is only for the characteristics or use named in such approval and is not be construed to change or modify any contract requirements. Before submitting samples, provide assurance that the materials or equipment will be available in quantities required in the project. No change or substitution will be permitted after a sample has been approved.

Match the approved samples for materials and equipment incorporated in the work. If requested, approved samples, including those that may be damaged in testing, will be returned to the Contractor, at its expense, upon completion of the contract. Unapproved samples will also be returned to the Contractor at its expense, if so requested.

Failure of any materials to pass the specified tests will be sufficient cause for refusal to consider, under this contract, any further samples of the same brand or make as that material. The Government reserves the right to disapprove any material or equipment that has previously proved unsatisfactory in service.

Samples of various materials or equipment delivered on the site or in place may be taken by the Contracting Officer for testing. Samples failing to meet contract requirements will automatically void previous approvals.

Replace such materials or equipment to meet contract requirements.

1.14 WITHHOLDING OF PAYMENT

Payment for materials incorporated in the work will not be made if required approvals have not been obtained.

1.15 STAMPS

Certify the submittal data as follows on Form ENG 4025: "I certify that the above submitted items had been reviewed in detail and are correct and in strict conformance with the contract drawings and specifications except as otherwise stated.

______NAME OF CONTRACTOR ______ SIGNATURE OF CONTRACTOR

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 33 00 Page 17

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 1 OF 4 PAGES

Spillway Gates Nondestructive Testing, Garrison Dam ND

01 12 00 SD-01 Preconstruction Submittals 1.10Contractor Crane And Lifting