Solicitation.pdf

SEE ADDENDUM

(No Collect Calls)

W9127N-16-Q-0053 24-Aug-2016

b. TELEPHONE NUMBER 8. OFFER DUE DATE/LOCAL TIME

02:00 PM 13 Sep 2016

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W9127N9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

ERIC J OLDENKAMP

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESS X

WOMEN-OWNED SMALL

BUSINESS (WOSB)

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

USACE PORTLAND DISTRICT

333 SW 1ST AVE

PORTLAND OR 97204-3440

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 960408 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

WILLAMETTE VALLEY PROJECT

CENWP-OD-V

USACE PORTLAND DISTRICT

40386 W BOUNDRY RD

LOWELL OR 97452-0429

TEL: FAX:

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

ECONOMICALLY DISADVANTAGED

WOMEN-OWNED SMALL BUSINESS

(EDWOSB)

SIZE STANDARD:

$15 Million

NAICS:

541720

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF86

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W9127N-16-Q-0053

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Task 1: Kick-off meeting

FFP

Contractor shall provide all materials, equipment and labor to provide kick-off meeting services for the DETROIT / BIG CLIFF PROJECT CULTURAL INVESTIGATIONS per attached Performance Work Statement.

FOB: Destination

NET AMT

0002 1 Job Task 2: Field Work

FFP

Contractor shall provide all materials, equipment and labor to provide field work services for the DETROIT / BIG CLIFF PROJECT CULTURAL

0003 1 Job Task 3: Site Forms Development

FFP

Contractor shall provide all materials, equipment and labor to provide Site Forms Development for the DETROIT / BIG CLIFF PROJECT CULTURAL

0004 1 Job Task 4: Draft Report

FFP

Contractor shall provide all materials, equipment and labor to provide Draft Report for the DETROIT / BIG CLIFF PROJECT CULTURAL INVESTIGATIONS per attached Performance Work Statement.

0005 1 Job Task 5: Final Report

FFP

Contractor shall provide all materials, equipment and labor to provide Final Report for the DETROIT / BIG CLIFF PROJECT CULTURAL INVESTIGATIONS per attached Performance Work Statement.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 POP 22-SEP-2016 TO

01-MAY-2017

N/A WILLAMETTE VALLEY PROJECT

CENWP-OD-V

USACE PORTLAND DISTRICT

40386 W BOUNDRY RD

LOWELL OR 97452-0429

960408

0002 POP 22-SEP-2016 TO

01-MAY-2017

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 22-SEP-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

0004 POP 22-SEP-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

0005 POP 22-SEP-2016 TO

N/A (SAME AS PREVIOUS LOCATION)

PERFORMANCE WORK STATEMENT

TITLE: DETROIT / BIG CLIFF PROJECT CULTURAL INVESTIGATIONS

1.0 PROJECT BACKGROUND AND PURPOSE.

The U.S. Army Corps of Engineers (USACE), Portland District intends to conduct an archaeological inventory of proposed projects within the Detroit and Big Cliff Project areas. USACE is responsible for compliance with

Section 106 of the National Historic Preservation Act (NHPA). USACE works closely with interested and affected Tribes, State Historic Preservation Offices (SHPOs), and other agencies for cultural resource management in compliance with Section 106 of the NHPA. As part of this responsibility, USACE has a requirement to inventory the area for cultural resources.

Work outlined in this Performance Work Statement (PWS) includes a task for archeological inventory. The archeological inventory includes approximately 7.2-acres at the Big Cliff Project and 428.7 acres at the Detroit Project area (See Attachment 2 for survey area maps).

The study area for both Detroit and Big Cliff is located in Linn and Marion Counties, OR. There are three project areas that will be inventoried under this contract (Legacy Contamination sites in both Big Cliff and Detroit, operation and maintenance areas, and additional lands within Detroit, previously unsurveyed). There are no previously recorded archeological sites within the study area. There are seven previously recorded sites within one-mile of the project area. There are seven previously recorded sites within one-mile of the project area, and are listed as follows:

Site Type Description NRHP Status Temp #18- 04-476H

Historic Log Flume with associated historic artifacts

Unevaluated

35MA80 Precontact Lithic Scatter Unevaluated 35MA79 Precontact Lithic Scatter Unevaluated 35MA43 Precontact Possible Habitation site/lithics and groundstone Unevaluated

35MA128 Precontact Lithic Scatter Unevaluated 35MA129 Precontact Lithic Scatter Unevaluated 35LIN89 Precontact Possible campsite / lithic scatter Unevaluated

1.1 Project Specifics are included below:

The Legacy Contamination site areas consists of approximately 10.5-acres, located in Township 10 South, Range 5 East Section 7; Township 10 South, Range 4 East Section 1 and Township 9 South, Range 4 East Section 35. Legacy contamination sites are left over construction spoils from dam construction and pre-1970 household trash, and should be inventoried with consideration for recordation as an archaeological site if they meet the 50 year age requirement. The legacy contamination site will be excavated and removed; if a site is present it will not be avoided; therefore recommendations for eligibility to the National Register of Historic Places should be provided as well as recommendations for mitigation, if applicable.

Detroit Project Operation and Management (O&M) area is approximately 47.3-acres located in

Township 10 South, Range 5 East Section’s 6 and 7 and Township 10 South, Range 4 East Section 1.

The O&M area has not been previously inventoried. Maintenance activities routinely happen within this area.

Detroit additional survey areas are approximately 207.3-acres of uplands, located in Township 10

South, Range 5 East Section’s 6 and 7 and Township 10 South, Range 4 East Section’s 1 and 12.

These areas have not been previously inventoried and are required under Section 110 of the NHPA.

Additional acres to be inventoried include the 64.1 acres of shoreline at Township 10 South, Range 5 East Section’s 4, 11, and 12; and 99.5 acres of uplands at the South Shore Campground located at Township 10 South, Range 5 East Section 15. These additional acres have had portions previously inventoried, however, these inventories don’t meet current survey standards.

Big Cliff Project O&M area is approximately 7.2 acres located in Township 10 South, Range 4 East Section 1. The O&M area has not been previously inventoried. Maintenance activities routinely happen within this area.

1.2 Project Area Conditions.

Inventory may be conducted in a reservoir environment where the field crew may encounter mucky field conditions and areas of dense marsh grasses or reed canary grass. Upland areas of the Detroit and Big Cliff Projects are the majority of the inventory, which may include dense grassy areas and uneven ground. The Legacy Contaminiation sites have had preliminary testing for PCB’s and other chemicals, which are negative.

However, HAZMAT contaminates may be buried on site. How the Contractor (KTR) plans to work through these conditions should be identified within the KTR’s project proposal for work; identifying crew safety as well as field inventory processes.

1.3 References.

Kelly, Cara McCulley 2001 Cultural Resource Inventory Report for the Shorenuf Timber Sale. Willamette National Forest, Detroit Ranger District. On-line SHPO Report No. 17819.

Kelly, Cara McCulley 1992 Cultural Resource Inventory Report for the Detroit Tributaries Integrated Resource Planning Area.

Willamette National Forest, Detroit Ranger District. On-line SHPO Report No. 13487.

2.0 Definitions

Throughout this PWS terms are defined as follows:

Acceptable Quality Level (AQL): Acceptable Quality Level equals the performance standards listed in 5.1 through 5.4. The Contractor must re-perform all unsatisfactory work unless excused by the QAE.

Contracting Officer (KO): The Government employee who is authorized to enter into, administer, and/or terminate contracts and make related determinations and findings.

Contracting Officer’s Representative (COR): The Government employee who has been authorized in writing as the Contracting Officer’s Representative, acting within the limits of their authority.

Quality Assurance Evaluator (QAE): The Government employees responsible for checking Contractor performance.

Contract Discrepancy Report (CDR): A written record of unsatisfactory performance by the contractor as observed by the Quality Assurance Evaluator (QAE).

Willamette Valley Project (WVP): The destination of where the contract is to take place.

3.0 GOVERNMENT FURNISHED ITEMS AND SERVICES

USACE Portland District will provide the following:

A blank geodatabase and the data dictionary for use on the project.

All pertinent GIS data.

Current Legacy Contamination reports and findings.

4.0 CONTRACTOR FURNISHED ITEMS AND RESPONSIBILITIES

The KTR shall furnish all personnel and “standard-to-the-industry” equipment, materials, and supplies necessary to perform the work, including but not limited to the following:

Field Vehicles.

Field Equipment.

All field materials necessary for the successful completion of cultural resource survey tasks.

All computer hardware, software, and office supplies required for recording, mapping, drafting and delivery of assigned task products.

All GPS instruments shall be properly adjusted, calibrated, and capable of providing sub meter accuracy. Any instruments, equipment or materials deemed unsafe, incapable of, or unsatisfactory for performing the required work shall be replaced immediately.

5.0 PERFORMANCE STANDARDS AND REQUIREMENTS.

The Contractor (KTR) shall furnish all materials, equipment and labor necessary to perform the requirements of this PWS. Performance requirements are presented below.

5.1 WORK PLAN.

Within 7 calendar days after receipt of award for this Contract, the KTR shall develop a Work Plan. The Work Plan will be used as a base to discuss methodology and procedures at the Kick-Off meeting (see Task 5.2.1).

Plan will be used as a base to discuss methodology and procedures at the Kick-Off meeting (see Task 5.2.1), which includes, but is not limited to, the following:

Matrix of all KTR and subcontractor (Sub-KTR) personnel on this project, their roles and responsibilities, including all review personnel;

Project objectives and a plan on how to meet those objectives;

Information on project organization; and

Project schedule based on completion date requirements. The schedule shall include all work items, milestones, durations, predecessors, source materials and study requirements, data delivery dates, completion dates, deliverables, review processes including all during requirements for responses, and all coordination activities. USACE will review and provide comments within three calendar days after receipt. The KTR shall submit a final schedule within three calendar days after receipt of Government’s comments.

Quality Control Plan (QCP) will be included as an element of the Work Plan. The QCP shall address each task above, outlining quality control and quality assurance procedures that shall ensure that the Secretary of Interior Standards and the Oregon State Historic Preservation Officer standards for archaeological inventory are met.

5.2 Tasks.

5.2.1 Task 1: Kick-Off Meeting.

The KTR shall schedule a mutual date and time for a kick off two hour teleconference meeting with the Technical Lead (TL) prior to the start of work. The purpose of the kick off meeting is to clarify tasks and methods, set a schedule, and to minimize issues or problems that might arise over the course of the contract.

Kick off meeting will review Work Plan, see PWS paragraph 5.1.

5.2.2 Task 2: Field Work.

The KTR shall conduct an archeological surface survey of up to 437 acres in accordance with the Department of the Interior Standards for Identification and OR SHPO fieldwork (http://www.oregon.gov/oprd/HCD/ARCH/docs/Master_Final_FieldGuidelines_January2016.pdf). Linear resources will follow the 2013 OR SHPO Guidelines for Recording and Evaluating Linear Cultural Resources (http://www.oregon.gov/oprd/HCD/SHPO/docs/ORLinearResourcesGuidancev2.pdf). Reporting standards (state standards) are listed in task four below. The KTR shall record up to 25 newly discovered archeological resources and up to 10 isolated finds. A map depicting the survey areas are included in Attachments 3-6. The KTR shall not exceed 437 acres. The survey is strictly a pedestrian survey below the high water mark or maximum conservation pool level. Subsurface excavation is not authorized under any circumstance.

Survey shall be conducted where surface visibility is adequate (i.e. greater than 20% ground surface visibility) and where survey is feasible (slopes less than 30%, safe for pedestrian survey access). Transect intervals shall be no greater than 20 meters in high probability areas. USACE considers high probability areas those areas identified during the records search or field survey that could contain archeological deposits, or where surface archeological materials have been observed. Any deviation from state standards needs to be coordinated and approved by the TL Point of Contact (POC) and Contracting Officer (KO), and should be adequately explained and justified in the survey report (e.g., nature of field conditions, ground surface visibility, slope, landforms, etc.). Transect intervals may be increased at the Field Director / Principal Investigator’s discretion in areas that exhibit hydric soils, or are low probability. Discussion of areas surveyed greater than 20 meters will need to be included within the report. If the KTR encounters low surface visibility in a high probability area, and believes shovel testing is necessary, the KTR shall show these areas on maps in the survey report and provide recommendations for areas that should be shovel tested in the future.

In areas where ground visibility is less than 20% shovel scrapes may be utilized. Shovel scrapes should be 1 x 1 meter in size and conducted within a survey transect at 20 – 30 meter intervals. Scraps should only lift the duft layer. Duft layer should be replaced where removed.

The Legacy Contamination site is located on a slope that is 30% or greater; it is accecible and will need to be recorded. KTR should coordinate access to the site with the Willamette Valley Natural Resource staff and the Portland District Archaeologist. Due to the remoteness of the site, recordation should include recommendations of eligibility to the National Register of Historic Places.

Crew Chiefs and Surveyors shall be capable of the following:

a) Rigorous physical exercise.

b) Working in extreme weather conditions and rough terrain.

c) Appropriate responses to health and safety situations.

The KTR shall utilize qualified Crew Chiefs and Surveyors who are experienced in conducting intensive pedestrian surveys and who can apply field survey methods and techniques according to current OR SHPO standards and the Secretary of Interior’s Standards and Guidelines, (http://www.cr.nps.gov/local-law/arch_stnds_9.htm). The Field Director / Principal Investigator is expected to directly supervise survey in the field for at least 25% of the field work, in order to ensure compliance with the standards and guidelines.

Crew Chiefs shall plot daily survey transect locations on field maps, record daily observations in field notebooks, identify and describe historic and prehistoric artifacts and features, complete site and isolated find forms, record site boundaries using sub-meter global positioning system equipment, and record survey areas and sites using digital photography. Survey crews shall map areas surveyed, areas not surveyed and reason, and identify areas of high probability that may contain cultural resources but are inaccessible because of current conditions.

The Crew Chiefs shall maintain handwritten notes in a field notebook that includes the date, transects and intervals, information about area surveyed, names of Surveyors, and what was observed during daily survey efforts (e.g., vegetation, cultural materials and archaeological sites, man-made developments, disturbance etc.). A photograph log shall be maintained for all photographs taken during the survey effort. The log sheet shall contain columns for the date, photographer name/initials, subject matter, aspect, film/digital frame numbers and roll number (as appropriate).

For the purposes of this PWS, it is estimated that up to 25 new archaeological resources will be recorded and up to 10 isolated finds. Work shall be performed only on those sites, or portions of those sites, located on Corps land where access has been approved; however, where portions of sites extend beyond the contracted survey area, this shall be noted on site documentation.

Crew Chiefs and Surveyors shall complete individual maps (e.g., pace and compass field maps) of all newly recorded sites. These maps shall contain a scale, north arrow, legend, date, basis of bearing, name of individual responsible for the map, and temporary site number. KTR shall also point provenience diagnostic artifacts, features, and artifact concentrations within the site map. The maps shall contain critical elements present such as vegetation, shoreline, slope, probable site boundary and areas of development and/or disturbance. These maps should be included in site forms, as well as in the final report.

Crew Chiefs and Surveyors shall conduct preliminary site evaluations considering site information recorded in the field using the National Register of Historic Places significance criteria. The preliminary site evaluations shall be conducted by qualified personnel meeting the Secretary of Interior’s Standards and shall be recorded on the site forms. Evaluations shall be fully justified no matter whether the recommendation is “eligible”, “not eligible”, or whether “additional information is needed to make the evaluation determination (i.e. testing or research of existing curated collections)”. The placement of a site in a “needs testing” category should not be used as a catch-all; rather placement of a site in this status requires rigorous justification. The justification statement, including a site condition assessment as it relates to depositional integrity under Criterion D of the National Register of Historic Places, shall be included on the site form.

Digital data collection by electronic instruments and equipment shall be utilized to the fullest extent possible.

Crew Chiefs and/or Surveyors shall capture Global Positioning Systems (GPS) positions at transect start-finish points at enough frequency to establish survey boundaries for all areas surveyed. The GPS positions documenting site boundaries shall be polygons. All GPS data shall be downloaded and corrected frequently throughout the field effort to ensure data preservation. GPS data shall be corrected and converted into shape files and provided to the TL digitally at the completion of fieldwork. The KTR shall also provide raw and corrected GPS data. The KTR shall provide Geographic Information Systems (GIS) site boundaries and survey area boundaries shown on United States Geological Survey (USGS) topographic maps submitted in the final report.

The KTR shall coordinate with the TL regarding the need to cross private landowners and/or ad-joiners land to access federal lands proposed for survey if they cannot be accessed by road. The need to cross private land is not anticipated at this time. The KTR has the right to enter and conduct necessary survey and site recording activities on all Corps lands. However, the KTR must coordinate with the TL to insure that the Corps Willamette Valley Project personnel are notified when survey crews are working within Corps Project boundaries.

Crew Chiefs and Surveyors shall note all cultural items observed but not formally recorded on field maps (i.e., items that may be approaching 50 years of age). Text describing all cultural items not formally recorded and any associated photos and maps shall be included in field notebooks and the final report.

All information generated during field surveys (e.g., handwritten notes, field maps, field notebooks, logs, etc.) shall be submitted to the TL at the completion of all project tasks.

A “no collection/excavation” policy shall be followed. If single artifacts are observed outside of known site boundaries and they are not in danger of loss or damage, they shall not be collected and shall be recorded as isolated finds (e.g., field map location, GPS position, local condition description, etc.). However, if a diagnostic artifact(s)/features are in immediate danger of loss or damage the KTR shall contact the TL and KO to discuss collection options, if necessary. Those artifacts approved for collection shall be collected but only after all readily available and pertinent provenience data on each item is recorded (e.g., field map location, GPS position, local condition description, etc.), and the District Archeologist has coordinated with the appropriate Tribe(s) that the item is not considered sacred or a potential funerary item. The KTR will notify the TL as soon as possible if excavation is required to remove artifacts/features in danger of loss. An assessment of the situation will be made to determine the best course of action, including whether any excavation will be done. If it is determined by USACE that excavation is the best course of action the KTR will receive approval from the KO prior to excavating or removal of any items. The reason(s) for collection shall be noted as part of the data accompanying each artifact and as part of the site form and final report. The artifacts will be transferred to Corps prior to contract expiration; or shall be prepared for curation by the KTR. Excavation and curation will be conducted under a contract modification.

NOTE: If the actual number of newly recorded sites exceeds 25, or newly recorded isolates exceed 10, the KTR should take a GPS point and note the find. The KTR should contact the TL and KO to inform them of the additional resources. USACE will make a decision at that time, to either modify this contract or not.

If human remains are discovered on Corps land, they shall not be disturbed but protected in place. The Contractor shall immediately notify a Corps District Archeologist (Mike Flowers 503-808-4762, Dan Mulligan 503-808-4768, Tara Gauthier 503-808-4754, or Sally Bird-Gauvin 503-808-4778). USACE will follow identified internal procedures to address the situation. (This will include notifying appropriate Indian Tribes, law enforcement, and Coroner’s or Medical Examiner’s offices.) If the remains are determined to be Native American, USACE will comply with the terms of its Inadvertent Discovery Plan and the Native American Graves Protection and Repatriation Act.

5.2.3 Task 3: Site Forms.

KTR shall prepare all new site forms and site update forms in accordance with OR SHPO survey and reporting standard guidelines (Link below). KTR is responsible for submitting documentation to OR SHPO, as stated in the SHPO standards, for new site trinomial numbers and providing those trinomials within the final report.

5.2.4 Task 4: Draft Report.

The report will be clearly marked DRAFT throughout and shall include: front matter (title page, executive summary, tables of contents, figures, plates, tables, and appendices); body of report (introduction, basic research design, methods, environmental overview, cultural context, results of investigations including acreage surveyed, site descriptions, number of new sites recorded, and number of previously documented site records updated, recommendations for future site management, conclusions, and references cited); and appendices (USGS 7.5’ map sheets showing survey areas and sites, UTM coordinates for sites, photographs of survey areas, photographs of diagnostic artifacts, etc.).

The executive summary shall include survey results, major findings, and statements of National Register significance for identified and recorded cultural resource sites, and proposed management recommendations.

The cover of the report shall include USACE contract number and also a statement indicating: “Work funded by the U.S. Army Corps of Engineers”.

Text materials shall be typed on bond paper, 8.5 inches by 11 inches with a 1.25-inch binding margin on the left side, .75 inch on the right side, 1 inch at the top and 1 inch at the bottom. Larger graphics may be submitted on 11 x 17 inch paper.

All pages, photographs, tables, etc. shall be consecutively numbered throughout the report and where applicable, shall have titles and appropriate explanatory notes. A Draft Report shall be submitted, along with draft GIS data, and draft site forms, to the TL for review and comment.

The Report shall adhere to requirements of the Oregon SHPO survey and inventory guidelines are located at the following website address:

http://www.oregon.gov/oprd/HCD/ARCH/docs/Reporting_Guidelines_FINAL.pdf (http://www.oregon.gov/oprd/HCD/ARCH/Pages/index.aspx). On-line site forms and instructions are located at the following website address:

http://www.oregon.gov/oprd/HCD/ARCH/docs/online_site_form_for_field.pdf

5.2.5 Task 5: Final Report.

KTR shall address Government comments and submit Final Report, GIS Data, and Site Forms in both hard copy and digital media format. The final report, any final site forms not previously submitted and appendices incorporating the Government’s comments shall be submitted within 30 calendar days of receipt of Government comments. Five bound hard copies shall be submitted, and one unbound hard copies with the appropriate SHPO cover page shall be submitted. Two sets of CDs electronic copy of the report with site records in PDF formats shall be submitted on two compact disks neither disk shall be a copy of the other, one disk shall contain the report and site forms and one disk shall contain the GIS data). Note: The pdf file shall have all graphics, maps and appendices included in the file.

6.0 PERFORMANCE REQUIREMENTS SUMMARY

It is intended to ensure that the Government receives the services for which it contracted. The Government will only pay for services received. The Performance Requirement Summary (PRS) determines if the contractor meets the performance standards of the contract, as well as provides guidelines for how and when surveillance will be performed. Government contract quality assurance will be performed at such times and/or places as may be necessary to determine the services conform to contract requirements.

6.1 Performance Requirements Summary Table

These are the criteria against which the performance will be evaluated. Work shall be considered not to have been performed when any one of the following conditions exists in accordance to the Quality Assurance Surveillance Plan. The Performance Requirements Summary Table can be found in Attachment 2.

Deliverable of Service Requirement

Measurement / Metric Surveillance Method

Frequency

Procedures to be taken when performance standards not met

Pre-Field Activities Compliance with requirements to include timeliness, accuracy, quality, consistency, and functionality

Submittal Review

Draft Submittal Final Submittal

a. Contractor revision of submittal at own expense;

b. Poor performance evaluation

Kick-Off Meeting: Compliance with requirements to Submittal Draft and Final a. Contractor revision of

Work Plan & Quality Control Plan include timelines, accuracy, quality consistency functionality

Review (Work Plan) submittal;

b. Poor performance evaluation

Field Survey Compliance with requirements to include timeliness, accuracy, quality, consistency, and functionality

25% fieldwork inspection.

Submittal Review

Monthly Contract Update Reports

a. Contractor revision of submittal at own expense;

b. Poor performance evaluation

Report Compliance with requirements to include timeliness, accuracy, quality, consistency, and functionality

Submittal Review

Draft Submittal Final Submittal

a. Contractor revision of submittal at own expense;

b. Poor performance evaluation

Minutes of all significant conversations and meetings

Compliance with requirements to include timeliness, accuracy, quality, consistency, functionality

Submittal Review

Draft and Final a. Contractor revision of submittal;

b. Poor performance evaluation

Monthly Progress Reports

Compliance with requirements to include timeliness, accuracy, quality, consistency, functionality

Submittal Review

Upon Submission

a. KTR revision of submittal;

b. Delay in payment

Monthly Invoices Compliance with requirements to include timeliness, accuracy, quality, consistency, functionality

Submittal Review

Upon Submission

a. KTR revision of submittal;

b. Poor performance evaluation

Monthly Expenditure Reports

Compliance with requirements to include timeliness, accuracy, quality, consistency, functionality

Submittal Review

Upon Submission

a. KTR revision of submittal

Release of Claims Compliance with requirements to include timeliness, accuracy, quality, consistency, functionality

Submittal Review

Upon Submission

a. KTR revision of submittal;

b. Delay in Final Payment

6.2 Non-compliance

The QAE will notify the COR and the KO of less than acceptable performance. If any of the services do not conform to contract requirements, the Government may require the contractor to perform the services again in conformity with the contact requirements, at no increase in contract amount.

When the defect(s) in services cannot be corrected by re-performance, the Government may:

• Require the contractor to take necessary action to ensure future performance conforms to contract requirements;

• Reduce the contract price to reflect the reduced value of the services performed; or

• If the contractor fails to promptly re-perform the services, or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may:

- By contract or otherwise, perform the services and charge to the contractor any cost incurred by the Government that is directly related to the performance of such service;

- Issue Cure Notice;

- Terminate the contract for Government convenience; or

- Terminate the contract for cause.

6.3 Surveillance

Periodic inspection, 100% inspection and processing of complaints received from project personnel or stakeholders will serve as the surveillance methods under this contract. If the COR discovers deficiencies and/or receives complaints, the COR will pass them on to the contractor's Quality Control Inspector (QCI) for correction.

6.4 Quality Control

The contractor shall develop and maintain an effective quality control program to ensure services are performed in accordance with this PWS. The contractor shall develop and implement procedures to identify and prevent defective services.

6.4.1 Quality Control Program

The contractor’s quality control program (QCP) is the means by which he assures himself that his work complies with the requirement of the contract. In the case of this contract, the QCP is considered to be the contractor’s draft plan detailed in PWS paragraph 5.2.2.

6.4.2 Quality Assurance

The Government shall evaluate the Contractor’s performance under this contract in accordance with the Quality Assurance Surveillance Plan (QASP). This plan is primarily focused on what the Government must do to ensure that the contractor has performed in accordance with performance standards detailed in the Performance Requirements Summary found in PWS paragraph 6.0 and charted in the Performance Requirements Summary Table found in Attachment 2. The QASP defines how the performance standards shall be applied, the frequency of surveillance, and the minimum acceptable defect rate(s).

6.5 Correction of Non-Performance of Work

Contractor shall employ an adequate quantity of personnel to insure that any area found to be not in compliance and therefore not acceptable, shall be made acceptable by the performance or re-performance of the work, where such re-performance is possible, during the first business day after noncompliance has been observed by or reported to and verified by the COR.

6.6 Damages Caused by the Contractor

Contractor shall be held accountable and liable to the Government for any damages to government facilities, fixtures, furnishings, equipment, or grounds caused by the Contractors or their employees.

6.7 Interference with Government Operations

Contractor and their employees shall perform all work in such a way as to not interfere with regularly scheduled Government operational activities.

7.0 TECHNICAL REQUIREMENTS.

The KTR is responsible for gathering the relevant materials and information (i.e., Literature Review) to complete this work. Literature Review includes:

Past archeological reports associated with the project area located at the OR SHPO.

Archeological testing reports, monitoring reports, site and survey records and maps located at OR

SHPO.

Site and survey records available at Corps.

Historical photos, oral histories, historic contexts, and any available information at university libraries, local historic societies, libraries and county offices, and USACE library.

The Secretary of the Interior’s “Standards and Guidelines for Archeology and Historic Preservation” shall be followed in determining qualifications for the Principal Investigator and Crew Leader positions, i.e. 36 CFR Part 61, http://www.cr.nps.gov/local-law/arch_stnds_9.htm.

The KTR shall have experience conducting monitoring work on Pacific Northwest archeological and cultural sites. The KO will provide written approval of resumes prior to contract award, as appropriate.

7.1 Survey, Site Recording, and Reporting Standards.

All cultural resource survey work, site recording, and reporting shall be performed in accordance with the following guidelines, standards and procedures specified unless otherwise directed or clarified in individual tasks.

a) Secretary of Interior’s Standards and Guidelines. On-line versions of the Secretary of Interior’s

Standards and Guidelines are located at the following website address: (http://www.cr.nps.gov/local-law/arch_stnds_0.htm).

b) Oregon State Historic Preservation Office.

i. On-line versions of OR SHPO survey and inventory guidelines are located at the following website addresses:

ii. http://www.oregon.gov/oprd/HCD/ARCH/docs/Master_Final_FieldGuidelines_January2

016.pdf and http://www.oregon.gov/oprd/HCD/SHPO/docs/ORLinearResourcesGuidancev2.pdf.

iii. On-line site forms and instructions are located at the following website address:

http://heritagedata.prd.state.or.us/index.cfm).

iv. OR SHPO Site forms for field use are located at the following website address:

http://www.oregon.gov/oprd/HCD/ARCH/docs/online_site_form_for_field.pdf

v. OR SHPO reporting guidelines are located at the following website address:

http://www.oregon.gov/oprd/HCD/ARCH/docs/Reporting_Guidelines_FINAL.pdf

8.0 SUBMITTALS. The KTR shall provide the following submittals in accordance with the schedule in this

Contract.

8.1 Work Plan. One PDF copy sent via email.

8.2 Contract Management. The following submittals must be provided to the TL:

Draft Report. Submit one copy each of PDF report, GIS data, and site forms on two CDs.

Final Report. Submit five book or hard bound copies, one unbound copies with appropriate SHPO cover sheet, and Site Forms in both hard copy and digital media format on two CDs. Final report shall include a bibliography that lists all reports, studies, articles, and other literature referencing the defined cultural area. Submit final report and associated documents electronically also.

GIS Data. One electronic copy of all GIS generated information (e.g., layers, maps, etc.) shall be submitted along with the draft report for review on two compact discs. The GIS information shall be in ESRI shapefile or ESRI feature class format and shall include metadata. Final GIS data on two compact disks shall be submitted with the final report. Any questions concerning GPS or GIS should be directed to Vanessa van der Borg, (503-808-4684), Vanessa.vanderBorg@usace.army.mil.

8.3 Contract Administration and Accounting.

The KTR shall submit the documents required to support contract administration and accounting requirements to Raymie.P.Briddle@usace.army.mil, TL, and the COR. This shall include:

Monthly Invoices on ENG Form 93.

Monthly Progress Reports.

Monthly Expenditure Reports.

Monthly Exposure (man-hours) Report.

Final Invoice and Release of Claims.

8.4 Anti-Terrorism/Operations Security (AT/OPSEC) Submittals.

The KTR shall submit the documents required to support AT/OPSEC requirements to the TL. This shall include:

Non-US Citizens Employee Submittals.

E-Verify Employees Submittals.

9.0 QUALITY MONITORING AND MEASUREMENT.

The Government will perform quality monitoring and measurement of the services performed under this Contract. Please reference Attachment 1, Quality Assurance Surveillance Plan (QASP).

10.0 PERFORMANCE SCHEDULE.

Interim milestones are expected target dates and changes to these dates may be negotiated during progress review meetings without a modification to this Contract. The scheduled completion date for all work is a firm performance target, requiring modification to the Contract if an adjustment to that date is required.

TASK

PWS

Paragraph

MILESTONE

(Calendar Days after Receipt of Award)

E-Verify Employees Submittal 13.5 3 Work Plan 5.1 7 Kick-Off Meeting 5.2.1 10 Foreign Born Employee Submittals 13.2 10 Naturalized Citizen Submittals 13.2 10 AT Level I Training 13.1 30

Identification of Employees 13.2 15 days prior to start of work iWatch/ CorpsWatch Training 13.3 15 Field Work 5.2.2 Start 30 days after award Draft Report 5.2.4 120 Government Review Comments Provided 5.2.5 160 Final Report Submittal 5.2.5 190 Contract Completion Date - 220 days after award

11.0 COORDINATION REQUIREMENTS.

11.1 General

Coordination of these activities is critical to the successful completion of this Contract. Every effort shall be made to resolve identified issues in a timely manner before they become problems. Communication by telephone and e-mail is strongly encouraged. Regularly scheduled meetings are described below. Other meetings, including additional site visits and telephone conference calls, required to exchange information may be scheduled by mutual agreement, and shall be e-mailed to the POCs.

11.2 Government POCs for This Contract.

The KTR shall provide written records of all significant conversations. The KTR shall be in contact with multiple Government POCs. The KO is the only POC with the authority to direct the KTR to perform services or change the terms of the Contract. The COR is delegated specific authorities with respect to oversight and administration of the Contract. Government POCs under this Contract are as follows:

ASSIGNMENT PERSONNEL PHONE EMAIL

Contracting Officer (KO) Sue Jones 503-808-4632 Sue.Jones@usace.army.mil Contracting Officer’s Rep.

(COR)

Raymie Brindell 541-937-2131 x143

Raymie.P.Briddell@usace.army.

mil

Contract Specialist (CS) Eric Oldenkamp 503-808-4617 Eric.j.oldenkamp@usace.army.mi l

Project Natural Resources Manager

Wendy Jones 541-221-7694 Gwendolyn.A.Jones@usace.army .mil

Technical Lead (TL) / District Archeologist

Sally Bird-Gauvin 503-808-4778 Sally.Bird- Gauvin@usace.army.mil

Invoice Raymie.P.Briddle@usace.army.mil

11.3 Meeting Documentation. At minimum, meeting documentation shall be prepared as follows:

Meeting agendas shall be prepared for each meeting and e-mailed to the TL, COR, including any additional personnel listed on the Product Development Team (PDT) two days prior to each meeting.

The TL will provide the KTR with a list of PDT members and contact information after receipt of award.

A list of action items specific to each meeting participant shall be developed to ensure a record of all discussions and decisions from the previous meeting is maintained. This shall be provided along with the meeting agenda.

The KTR shall e-mail draft meeting notes, to include any updates to the action items, to the TL for distribution to the PDT no later than three calendar days following any meeting.

The PDT comments to the draft notes will be provided to the KTR within five calendar days following receipt of the draft meeting notes.

The KTR shall amend the draft meeting notes within 10 calendar days following the subject meeting.

12.0 GENERAL REQUIREMENTS.

12.1 Metadata. Any data, database(s), and/or geospatial data produced through this Contract must be documented through the preparation of standard metadata (data about data) descriptions. The KTR shall ensure that the metadata delivered is compliant with the International Organization for Standardization (ISO) 19115:2003, North American Profile (NAP). The Standard is available for purchase at:

http://www.webstore.ansi.org.

12.2 Codes and Standards. Work under this Contract shall comply with the latest codes, standards, and regulations applicable to the work requested including USACE Engineering Regulations and Manuals, and Industry Codes and Standards.

12.3 Safety. This paragraph applies to contracts and purchase orders that require the KTR to comply with EM

385-1-1 (e.g., contracts that include the Accident Prevention Clause at FAR 52.236-13 and/or other safety provisions). EM 385-1-1 and its changes are available at http://www.usace.army.mil/CESO/Pages/Home.aspx. EM 385-1-1 states, “Contractors shall comply with the latest version of EM 385-1-1 (including interim changes) that is in effect on the date of solicitation.”

12.4 Additional Services. The KTR shall not perform any services under this Contract that are considered by the

KTR or Government to be a change in work or services required by this agreement without the written approval of the KO.

12.5 Correction of Unsatisfactory Work. The COR maintains the right to reject any work that is found to be in error, incomplete, illegible, or in any way not conforming to the specifications outlined in the Contract. The KTR shall be liable for all costs in connection with correcting such errors. Corrective work may be performed by the Government or by KTR at the discretion of the KO.

12.6 Use of Information. The information developed, gathered, assembled, and reproduced by the KTR or his

Sub-KTRs, or their associates, in fulfillment of the contract requirements as defined in or related to this PWS, shall not be used for any purposes at any time without the written consent of the KO.

13.0 SECURITY.

All KTR and all associated Sub-KTR employees shall comply with applicable facility access and local security policies and procedures. If any of the following requirements have been fulfilled within one year prior to award of this Contract, verification of such shall be provided by the KTR to the TL.

13.1 AT Level I Training. All KTR employees, to include Sub-KTR employees, requiring access to Corps facilities and controlled access areas shall complete AT Level I awareness training with 30 calendar days after contract award date. The KTR shall submit a signed and dated training roster for each affected KTR and Sub-KTR employee to the TL and COR within five calendar days after completion of training by all employees and Sub-KTR personnel. Please contact A/E Contract Coordinator for a copy of the training DVD. Estimated training time is 10 minutes per individual.

13.2 Access and General Protection/Security Policy and Procedures. All KTR and all associated Sub-KTR employees shall comply with applicable facility access and local security policies and procedures. The KTR shall also provide all information required for background checks to meet facility access requirements to be accomplished by the Security Office. The KTR workforce must comply with all personal identity verification requirements as directed by the Department of Defense (DoD), Headquarters Department of Defense (HQDA), and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, shall the Force Protection Condition (FPCON) at any individual facility change; the Government may require changes in KTR security matters or processes.

a) Contractors who do Not Require CAC, but Require Access to a DoD Facility or Installation. The

KTR and all Sub-KTR employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB), applicable installation, facility and area access and local security policies and procedures provided by the Government Representative.

b) Identification of Employees. The KTR shall submit a complete, dated, signed list of all KTR and

Sub-KTR employees and their titles who will be working on the project to the TL within fifteen days prior to the commencement of the work. This listing shall be revised and resubmitted with personnel changes occur. The following information shall be provided:

Name of KTR

Name of Employee

Employee’s birth date

Employee’s place of birth

Employee’s valid identification with photo

Other employee information as needed based on security level

c) Foreign Born Employees. The KTR shall submit photocopies of the green card work permits and/or passports to the TL of all KTR employees who are foreign born and have non-citizen status. Submit photocopies at least 30 calendar days in advance of the commencement of work by the employees. This allows the Portland District Security Office sufficient time to run a security check on these affected personnel. KTR and Sub-KTR personnel who fit the above description of non-citizenship shall not be permitted to work until they pass the security check in addition to other requirements of this contract.

d) Naturalized Citizens. At least one week in advance of the commencement of work by the employees, the KTR shall submit photocopies of Government documentation (i.e., passport) for all naturalized citizens confirming their citizenship to the TL.

13.3 iWATCH and/or CorpsWatch Training. All KTR and all associated Sub-KTRs shall complete the local iWATCH, CorpsWatch, See Something, Say Something program. This local developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the TL. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance. The KTR shall submit a signed and dated training roster for each KTR and Sub-KTR employee to the TL and COR within five calendar days after completion of training. Estimated training time is five minutes per individual. Obtain training DVD from A/E Contract Coordinator.

13.4 Requirement for OPSEC Training. All new KTR employees shall complete Level 1 OPSEC training within 30 calendar days of commencing performance. The KTR shall submit a signed and dated training roster for each KTR and Sub-KTR employee to the TL and COR within five calendar days after completion of training by all employees and Sub-KTR personnel.