am_5.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The Solicitation for FY18 ARNORTH B44 Renovation, JBSA/FSH, San Antonio, Texas is amended as follows.

See SF30 Continuation Sheet(s)

NOTE: Proposal Receipt date has been changed to 14 September 2018 at 2:00 PM Central Time.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

W9126G18B0036

X 9B. DATED (SEE ITEM 11)

09-Aug-2018

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

Sept 7, 2018

CODE

US ARMY ENGINEER DISTRICT, FORT WORTH

ATTN: CESWF-CT

819 TAYLOR ST, ROOM 2A19

P.O. BOX 17300

FORT WORTH TX 76102-0300

W9126G 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9126G18B0036

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

CHANGES TO THE SPECIFICATIONS

1. Replaced Sections: The following section has been updated and replaced in its entirety to the solicitation, bearing the notation “W9126G18B0036-0005”.

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

End of Summary of Changes

FY18 ARNORTH B44 Renovation FSH18ANSRMB44LS

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 73 00 CONTRACT CLAUSES COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK and LIQUIDATED

DAMAGES:

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work, including O&M Manuals and Final Record Drawings , See NTP. 365 $ 898.62

( ) O & M Manuals ** ** None

( ) Final Record Drawings

*** *** None

NOTE: All work on this project shall be completed within the number of calender days stated in Item of Work (1) above, inclusive of all review periods and Government phasing requirements specified. (AM#5) The duration of the project will be increased by 180 days if any or all options are exercised.(/AM#5) If the Government accepts a proposal for a completion period of lesser duration, and such proposal alters the time periods for review and phasing, the Contract shall be read to include the original periods for review and phasing. If a completion period of lesser duration is proposed and accepted by the Government, the accepted completion period will replace the original construction schedule listed above in the Schedule. If an alternate completion period is proposed, the Bid Schedule must reflect pricing information for the alternate proposed completion period. The liquidated damages stated above will be applied for each calendar day the Contractor

SECTION 01 00 00.00 44 Page 1 exceeds the Contract scheduled duration.

** Operation and Maintenance Manuals: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph OPERATION AND MAINTENANCE MANUALS for requirements and withholding amount to ensure completion of O&M Manuals.

*** Record Drawings: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph titled RECORD DRAWINGS for requirements and withholding amount to ensure completion of record drawings.

1.1.1 Testing of Heating and Air-Conditioning Systems

The times stated for completion of this project includes all required testing specified in appropriate specification sections of heating, air conditioning and ventilation systems including HVAC Commissioning.

Exception: boiler combustion efficiency test, boiler full load tests, cooling tower performance tests, and refrigeration equipment full load tests, when specified in the applicable specifications, shall be performed in the appropriate heating/cooling season as determined by the Contracting Officer.

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause FAR 52.249-10 entitled "DEFAULT: (FIXED PRICE CONSTRUCTION)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

SECTION 01 00 00.00 44 Page 2

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

2 3 4 3 4 6 3 4 5 5 5 3

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day.

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

1.3 CONSTRUCTION PHASING

1.4 WORK RESTRICTIONS

1.4.1 Working Hours

Normal working hours are Monday through Friday, 0630 to 1700 hours, unless otherwise indicated at the preconstruction conference. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer.

1.4.2 Security Requirements

1.4.2.1 Installation Entrance Requirements

Entrance requirements to the Installation are specified in Section 01 35

13.01 44 SPECIAL PROJECT PROCEDURES FOR JOINT BASE SAN ANTONIO/FORT SAM

HOUSTON.

For the duration of this Contract, access to Fort Sam Houston will be delayed between 5 minutes to 30 minutes or more due to increased security precautions, including the checking of vehicle occupants' IDs, vehicle manifests, and the searching of all vehicles. Any general or specific threat to the safety of those working or living at the Installation could result in longer waiting times at the access points to the Installation.

The following are the minimum requirements for contractor employees entering Fort Sam Houston:

a. One form of picture ID.

b. A memo from the construction company on their letterhead stating the reason for entry, contract number, and the location at Fort Sam Houston where the jobsite is located.

c. All delivery trucks must have a bill of lading and delivery truck drivers must have a picture ID.

SECTION 01 00 00.00 44 Page 3

1.4.3 Background Checks

Furnish a background check for each employee to the Pass & Badge Office prior to badge issuance. The document shall be as follows:

a. MEMORANDUM FOR: Directorate of Emergency Services, Pass and Badge Branch, Building #367, Fort Sam Houston, Texas 78234

b. Containing the following information:

1) Name of Employee:

2) Signature of Employee:

3) Company Name:

4) Type of Investigation Completed:

5) Date of Investigation:

c. Document shall be done on original company/official letterhead (NO

PHOTO COPIES, NO FAX COPIES).

d. Document shall be signed by authorizing official that is signing CSFS Form 4318-R as authorizing official.

e. CFSF Form 4318-R and all attached documentation must contain original signatures.

f. Point of Contact for this memorandum is Pass and Badge Section, DES Physical Security Division at 210-221-0643 ir 210-221-1393.

1.4.4 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.5 UTILITIES

1.5.1 Payment for Utility Services

Utilitiy availability and Payment For Utility Services are specified in Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROL.

1.5.2 Coordination

For Contractor Telephone And Internet Service, the Contractor shall coordinate with ITBC and the local phone company for contractor telephone and internet service during construction.

SECTION 01 00 00.00 44 Page 4

1.5.3 Outages

The Contractor shall coordinate all requests for utility outages with the Contracting Officer and local utility provider (where applicable) in writing 14 days prior to date of requested outage:

a. Water, gas, steam, and sewer outages shall be held to a maximum duration of 4 hours unless otherwise approved in writing.

b. Electrical outages shall have a maximum duration of 4 hours.

c. All utility outages shall be scheduled only on Saturdays, Sundays, or holidays unless specific approval is otherwise received.

1.6 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. RMS - will be used to the greatest extent practicable. Some items may not be submittable via RMS due to program constraints.

Those items shall use an alternate method. All ENGR 4025’s shall be generated and submitted in RMS.

2. Secure, Password Protected Web-Based System Access must be allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission. Under current conditions, 5 megabytes is the limitation for any single file/e-mail.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product samples, color boards, and any other item not feasible to submit digitally, shall be submitted hard copy. ENGR 4025 shall be submitted digitally always. The Government reserves the right to request hard copy submission on any item, if deemed necessary.

Contractor shall be prepared to provide requested hard copy at any time.

SECTION 01 00 00.00 44 Page 5

1.7 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201 (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $700,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 60 days. Accessing and using CPARS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.csd.disa.mil/. If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

1.8 CONTRACTOR PAYROLL RECORD

Contractor shall be required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor shall maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. The ENG 3180's shall be updated weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, the Contractor shall provide the completed ENG 3180’s to the Contracting Officer's Representatives.

1.9 CONTRACTOR SUPPLY and USE OF ELECTRONIC SOFTWARE FOR PROCESSING WAGE

RATE REQUIREMENTS CERTIFIED LABOR PAYROLLS

(a) The contractor is required to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

(b) The contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with the Wage Rate Requirements statute. When the contractor uses an electronic payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. The contractor shall obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of this construction contract. The access

SECTION 01 00 00.00 44 Page 6 shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

(c) The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the Federal Acquisition Regulation (FAR);

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export in an Excel spreadsheet to be imported into the contractor's Resident Management System (RMS), that in turn shall export payroll data to the Government's RMS;

(5) demonstrated security of data and data entry rights;

(6) ability to produce contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the date/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic payroll processing system shall be provided to the Government during contract closeout.

(d) All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services shall not be a separately bid or reimbursed item under this contract.

1.10 ADDITIONAL CONTRACTOR PAYROLL RECORD

(1) Reference the Special Contract Requirement CONTRACTOR SUPPLY and USE

OF ELECTRONIC SOFTWARE FOR PROCESSING WAGE RATE REQUIREMENTS CERTIFIED

LABOR PAYROLLS. The Fort Worth District requires the contractor and all sub-contractors to use an electronic payroll system meeting the requirements the above referenced requirements and the following.

(a) The Certified Labor Payrolls must be tracked electronically via WEB-based software and all data must be submitted via WEB. Payroll guidelines,"Instructions to Contractors on Contract Labor Requirements, published as "Appendix A, SWFP 1185-1-1" (also known as the Green book), will be provided to advise/inform contractors how these labor provisions will be administered and enforced.

(b) The WEB-based software must be capable of downloading data directly

SECTION 01 00 00.00 44 Page 7 from existing electronic payrolls, track workers to ensure that overtime is being paid when overtime status is reached on Government contracts whether on one or multiple contracts or different sub-contractors. The software must track apprentices and journeyman ratios, create and track SF-1444 "Request for Authorization of Additional Classification and Rate", track workers by name/address/with or without Social Security Numbers, allow automated redaction of information appearing on payroll statements for agency response to Freedom of Information Act (FOIA requests), and provide free online training by the software provider to any user of the software.

(c) The software must allow fringe benefit statement to track fringe benefits "whether cash or into an approved plan, fund, or program. If the fringe benefits are paid into a plan, fund, or program the company's name (receiving benefits), phone number, and address shall be listed on the Statement of Compliance Form (DD Form 879 or WH-347).

(d) Software must provide a method of tracking standard and non-standard deductions such as restitution, alimony, child support, and allow for custom entries. Method of tracking must list the deductions on the statement of compliance or be listed as an attachment.

(e) The Contractor is required to provide the updated 3080's and notify the Contracting Officer's Representatives weekly by email when the current payrolls are complete and ready for inspection/review on the WEB. Before final payment, the Contractor shall provide the completed ENG For 3180's and 3 disks (CD/DVD) which include complete copies of the Contractor and sub-contractor's payrolls/attachments, to the Contracting Officer's Representatives.

(2) Electronic copies of electronically/manually signed forms/memos/letters such as SF 1413 Statement of Acknowledgement (sub-contractor agreement), SF-1444 "Request for Authorization of Additional Classification and Rate", employee deduction authorization, certification of apprentices and trainees shall be provided to the Contracting Officer's Representative as required by FAR.

1.11 STREET CLOSINGS

The Contractor shall coordinate all requests for street closings with the Contracting Officer in writing 21 days prior to date of requested outage:

a. One lane traffic shall be maintained at all times (except that a total closing may be allowed for specific 8-hour periods).

b. The final street repair shall be completed within 21 calendar days after the start of any street crossing. Any part of the street returned to service prior to final repair shall be maintained smooth with hot-mix cold-lay surface course.

c. Open cuts across paved roads and streets for utility crossings will not be allowed. Utility crossings will be accomplished by boring or jacking procedures only.

1.12 Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers

SECTION 01 00 00.00 44 Page 8

(USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veteran Affairs - VOW to Hire Heroes Act http://benefits.va.gov/vow Army Wounded Warrior Program -http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation - Hiring Our Heroes http://www.hiringourheroes.org/ Guide to Hiring Veterans - Reference Material -http://whitehouse.gov/sites/default/files/docs/white_house_business_council_-_guide_to_h

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 00 00.00 44 Page 9