am_1.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The Solicitation for Defense Information Systems Agency (DISA) Building 200 Mechanical Piping and Controls is, is amended as follows:

See SF30 Continuation Sheet(s)

NOTE: Proposal Receipt date is changed to 18 January 2017, 10:00 a.m., Central Time.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

W9126G-16-R-0579

X 9B. DATED (SEE ITEM 11)

06-Dec-2016

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended,X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

05-Jan-2017

CODE

US ARMY ENGINEER DISTRICT, FORT WORTH

ATTN: CESWF-CT

819 TAYLOR ST, ROOM 2A19

P.O. BOX 17300

FORT WORTH TX 76102-0300

W9126G 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9126G-16-R-0579

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

1. 011 00.02 – CONTRACT LINE ITEM SCHEDULE – Section 00 11 00.02 is revised and replaced. See the attached bearing the notation “W9126G-16-R-0579, Amendment No. 0001”.

2. 01 00 00.00 44 – CONSTRUCTION SCHEDULE – Section 01 00 00.00 44 is revised and replaced. See the attached bearing the notation “W9126G-16-R-0579, Amendment No. 0001”.

3. 26 23 00 – LOW-VOLTAGE SWITCHGEAR is removed from this project in its entirety and superseded by Section 26 23 13 – PARALLELING LOW-VOLTAGE SWITCHGEAR.

4. 26 23 13 – PARALLELING LOW-VOLTAGE SWITCHGEAR is added to the solicitation. See the attached bearing the notation “W9126G-16-R-0579, Amendment No. 0001”.

5. Sections 25 08 10 and 25 10 10 are removed and superseded by “DISA INTEGRATED AUTOMATION” provided in ths amendment as part of ATTACHMENT A.

6. Drawings Sheets C101, ED101, ED102, E101, E102, E103 are revised and replaced. See the attached bearing the notation “Amendment No. 1”.

6. ATTACHMENT A – DISA SPECIFICATIONS is added to the solicitation. See the attached bearing the notation “W9126G-16-R-0579, Amendment No. 0001”.

7. ATTACHMENT B – SITE PICTURES is added to the solicitation. See the attached bearing the notation “W9126G-16-R-0579, Amendment No. 0001”.

8. ATTACHMENT C – SITE VISIT SIGN-IN SHEET is added to the solicitation. See the attached bearing the notation “W9126G-16-R-0579, Amendment No. 0001”.

End of Summary of Changes

Estimated Estimated Item No. Description Quantity Unit Unit Price Amount

0001 All Work for the Construction of the Electrical Capacity Upgrades at Building 200 1 JOB $ *** $

<AM001>

0002 Permit Fees (Port of San Antonio) 1 JOB $ *** $

<AM001>

$TOTAL OFFER

Defense Information Systems Agency (DISA) Building 200 Electrical Capacity Upgrade Port San Antonio, Texas

Solicitation No.W9126G-16-R-0579

CLIN SCHEDULE

Section 00 11 00 Page 1

DISA B200 Electrical PSAB200E

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 72 00 CONTRACT CLAUSES COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK and LIQUIDATED

DAMAGES:

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work, including O&M Manuals and Final Record Drawings for DISA Building 200 Electrical Upgrades.

Upon Contractor acknowledgement on Notice to Proceed (NTP).

420 $ 1,103.85

(2) O & M Manuals ** ** None

(3) Final Record Drawings

*** *** None

a. Liquidated damages for individual items of work will not be combined. Only the rate of the affected item of work will be assessed.

b. Liquidated damages are not accumulative for multiple phases of work.

** Operation and Maintenance Manuals: (AM#1) See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph OPERATION AND MAINTENANCE MANUALS01 32 01.00 10 para 3.3.18.2 for requirements and withholding amount to ensure completion of O&M Manuals.

*** Record Drawings: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph titled RECORD DRAWINGS01 32 01.00 10 para 3.3.18.1 for requirements and withholding amount to ensure completion of record drawings. (/AM#1)

SECTION 01 00 00.00 44 Page 1

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause FAR 52.249-10 entitled "DEFAULT: (FIXED PRICE CONSTRUCTION)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

SAN ANTONIO, TX AREA (FORT SAM HOUSTON, KELLY, LACKLAND, BROOKS, AND

RANDOLPH AFB'S AND RESERVE CTRS AT SAN ANTONIO)

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

2 3 4 3 4 6 3 4 5 5 5 3

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day.

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

1.3 WORK RESTRICTIONS

1.3.1 Working Hours

Normal working hours are Monday through Friday, 0630 to 1700 hours, unless otherwise indicated at the preconstruction conference. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for

SECTION 01 00 00.00 44 Page 2 approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer.

1.3.2 Security Requirements

1.3.2.1 Installation Entrance Requirements

For the duration of this Contract, access to the project site will be delayed between 5 minutes to 30 minutes or more due to increased security precautions, including the checking of vehicle occupants' IDs, vehicle manifests, and the searching of all vehicles.

The following are the minimum requirements for contractor employees entering the project site:

a. One form of picture ID.

b. A memo from the construction company on their letterhead stating the reason for entry, contract number.

c. All delivery trucks must have a bill of lading and delivery truck drivers must have a picture ID.

d. All Contractor employees entering Building 200 must be US citizens.

e. No cell phones allowed.

f. No cameras allowed.

1.3.3 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.4 UTILITIES

1.4.1 Payment for Utility Services

Utility availability and Payment For Utility Services are specified in Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROL.

1.4.2 Coordination

For Contractor Telephone And Internet Service, the Contractor shall coordinate with ITBC and the local phone company for contractor telephone and internet service during construction.

1.4.3 Outages

The Contractor shall coordinate all requests for utility outages with the user technical POC through the Contracting Officer and local utility provider (where applicable) in writing 30 days prior to date of requested outage:

SECTION 01 00 00.00 44 Page 3

a. Water, gas, steam, and sewer outages shall be held to a maximum duration of 4 hours unless otherwise approved in writing.

b. Electrical outages are not permitted.

c. Chilled water outages are not permitted.

d. In addition to the thirty (30) days notice, the Contractor shall submit a detailed Method of Procedure (MOP) for all work on critical power and chilled water systems.

1.5 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. QCS/RMS - will be used to the greatest extent practicable. Some items may not be submitted via QCS/RMS due to program constraints.

Those items shall use an alternate method. All ENGR 4025’s shall be generated and submitted in QCS.

2. Secure, Password Protected Web-Based System Access must be allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via QCS/RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission. Under current conditions, 5 megabytes is the limitation for any single file/e-mail.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product samples, color boards, and any other item not feasible to submit digitally, shall be submitted hard copy. ENGR 4025 shall be submitted digitally always. The Government reserves the right to request hard copy submission on any item, if deemed necessary.

Contractor shall be prepared to provide requested hard copy at any time.

1.6 CONTRACTOR PAYROLL RECORD

Contractor shall be required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor shall maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. The ENG 3180's shall be updated

SECTION 01 00 00.00 44 Page 4 weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, the Contractor shall provide the completed ENG 3180’s to the Contracting Officer's Representatives.

1.7 (S-102) CONTRACTOR SUPPLY and USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED LABOR PAYROLLS (April 2011)

The contractor is encouraged to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Davis-Bacon Act as stated in FAR 52.222-8, PAYROLLS AND BASIC RECORDS and FAR 52.222-13, COMPLIANCE

WITH DAVIS-BACON AND RELATED ACT REGULATIONS.

If the contractor elects to use an electronic payroll processing system, then the contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with Davis-Bacon and related Act regulations. When the contractor uses an electronic Davis-Bacon payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. The contractor shall obtain and provide electronic system access to the Government, as required to comply with the Davis-Bacon and related Act regulations over the duration of this construction contract. The access shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria: commercially available; compliant with appropriate Davis Bacon Act payroll provisions in the FAR; able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract; demonstrated security of data and data entry rights; ability to produce contractor-certified electronic versions of weekly payroll data; ability to identify erroneous entries and track the data/time of all versions of the certified Davis Bacon payrolls submitted to the government over the life of the contract; capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic Davis-Bacon payroll processing system shall be provided to the Government during contract closeout.

All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The costs for Davis-Bacon Act compliance using electronic payroll processing services shall not be a separately bid/proposed or reimbursed item under this contract.

1.8 ADDITIONAL CONTRACTOR PAYROLL RECORD

(1) Reference the Special Contract Requirement (S-102) CONTRACTOR SUPPLY

AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED

SECTION 01 00 00.00 44 Page 5

LABOR PAYROLLS. The Fort Worth District encourages the contractor and all sub-contractors to use an electronic payroll system meeting the requirements of S-102 and the following requirements.

(a) The Certified Labor Payrolls must be tracked electronically via WEB-based software and all data must be submitted via WEB. Payroll guidelines, "Instructions to Contractors on Contract Labor Requirements, published as "Appendix A, SWFP 1185-1-1" (also known as the Green book), will be provided to advise/inform contractors how these labor provisions will be administered and enforced.

(b) The WEB-based software must be capable of downloading data directly from existing electronic payrolls, track workers to ensure that overtime is being paid when overtime status is reached on Government contracts whether on one or multiple contracts or different sub-contractors. The software must track apprentices and journeyman ratios, create and track SF-1444 "Request for Authorization of Additional Classification and Rate", track workers by name/address/with or without Social Security Numbers, allow automated redaction of information appearing on payroll statements for agency response to Freedom of Information Act (FOIA requests), and provide free online training by the software provider to any user of the software.

(c) The software must allow fringe benefit statement to track fringe benefits "whether cash or into an approved plan, fund, or program. If the fringe benefits are paid into a plan, fund, or program the company's name (receiving benefits), phone number, and address shall be listed on the Statement of Compliance Form (DD Form 879 or WH-347).

(d) Software must provide a method of tracking standard and non-standard deductions such as restitution, alimony, child support, and allow for custom entries. Method of tracking must list the deductions on the statement of compliance or be listed as an attachment.

(e) The Contractor is required to provide the updated 3080's and notify the Contracting Officer's Representatives weekly by email when the current payrolls are complete and ready for inspection/review on the WEB. Before final payment, the Contractor shall provide the completed ENG For 3180's and 3 disks (CD/DVD) which include complete copies of the Contractor and sub-contractor's payrolls/attachments, to the Contracting Officer's Representatives.

(2) Electronic copies of electronically/manually signed forms/memos/letters such as SF 1413 Statement of Acknowledgement (sub-contractor agreement), SF-1444 "Request for Authorization of Additional Classification and Rate", employee deduction authorization, certification of apprentices and trainees shall be provided to the Contracting Officer's Representative as required by FAR.

1.9 Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are

SECTION 01 00 00.00 44 Page 6 available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veteran Affairs - VOW to Hire Heroes Act http://benefits.va.gov/vow Army Wounded Warrior Program -http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation - Hiring Our Heroes http://www.hiringourheroes.org/ Guide to Hiring Veterans - Reference Material -http://whitehouse.gov/sites/default/files/docs/white_house_business_council_-_guide_to_h

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 00 00.00 44 Page 7

Section 26 23 13 Page 1

SECTION 26 23 13

PARALLELING LOW-VOLTAGE SWITCHGEAR

PART 1 - GENERAL

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.

1.2 SUMMARY

A. This Section includes metal-clad, low-voltage; circuit-breaker switchgear rated 1000 V and less, and associated control systems, for paralleling generators on an isolated bus and for distributing power in ac systems.

B. Related Sections include the following:

1. Section 260913 "Electrical Power Monitoring and Control" for interfacing communication and metering requirements.

1.3 DEFINITIONS

A. ATS: Acceptance Testing Specifications.

B. GFCI: Ground-fault circuit interrupter.

C. HMI: Human machine interface.

1.4 ACTION SUBMITTALS

A. Product Data: For each type of switchgear and related equipment, include the following:

1. Technical data on features, performance, electrical characteristics, ratings, and finishes.

2. Rated capacities, operating characteristics, furnished specialties, and accessories for individual circuit breakers.

3. Features, characteristics, ratings, factory settings, and time-current characteristic curves for individual relays and overcurrent protective devices.

4. Description of sequence of operation for paralleling controls.

B. Shop Drawings: For each type of switchgear and related equipment, include the following:

1. Dimensioned plans, elevations, sections, and details, including required clearances and service space around equipment. Include the following:

a. Tabulation of installed devices with features and ratings.

b. Enclosure types and details.

c. Outline and general arrangement drawing showing dimensions, shipping sections, and weights of each assembled section.

d. Floor plan drawing showing locations for anchor bolts.

e. Bus configuration with current rating, size, and number of conductors in each bus run, including phase, neutral, and ground conductors of main and branch buses.

f. Short-time and short-circuit current rating of switchgear assembly.

g. Features, characteristics, ratings, and factory settings of individual overcurrent protective devices and auxiliary components.

h. Nameplate legends.

i. Mimic-bus diagram.

j. UL listing for series rating of installed devices.

2. Wiring Diagrams: For switchgear, paralleling control system, and related equipment, include the following:

a. Power, signal, and control wiring.

W9126G-16-R-0579, Amendment No. 0001

Section 26 23 13 Page 2

b. Schematic control diagrams.

c. Diagrams showing connections of component devices and equipment.

d. Three-line diagrams of current and future circuits showing device terminal numbers and internal diagrams.

e. Schematic diagrams showing connections to remote devices.

3. Design Calculations: Signed and sealed by a qualified professional engineer. Calculate requirements for selecting seismic restraints.

C. Samples: Representative portion of mimic bus with specified finish.

Manufacturer's color charts showing colors available for mimic bus.

1.5 INFORMATIONAL SUBMITTALS

A. Coordination Drawings: Floor plans showing dimensioned layout, required working clearances, and required area above and around switchgear where pipe and ducts are prohibited. Show switchgear layout and relationships between components and adjacent structural and mechanical elements. Show support locations, type of support, and weight on each support. Indicate field measurements.

B. Manufacturer Seismic Qualification Certification: Submit certification that switchgear, overcurrent protective devices, accessories, and components will withstand seismic forces defined in Section 260548 "Vibration and Seismic Controls for Electrical Systems." Include the following:

1. Basis of Certification: Indicate whether withstand certification is based on actual test of assembled components or on calculation.

a. The term "withstand" means "the unit will remain in place without separation of any parts from the device when subjected to the seismic forces specified."

b. The term "withstand" means "the unit will remain in place without separation of any parts from the device when subjected to the seismic forces specified and the unit will be fully operational after the seismic event."

2. Dimensioned Outline Drawings of Equipment Unit: Identify center of gravity and locate and describe mounting and anchorage provisions.

3. Detailed description of equipment anchorage devices on which the certification is based and their installation requirements.

C. Qualification Data: For testing agency.

D. Source quality-control test reports.

E. Field quality-control test reports.

F. Updated mimic bus diagram reflecting field changes after final switchgear load connections have been made, for record.

1.6 CLOSEOUT SUBMITTALS

A. Operation and Maintenance Data: For switchgear and components to include in emergency, operation, and maintenance manuals. In addition to items specified in Section 017823 "Operation and Maintenance Data," include the following:

1. Manufacturer's written instructions for sequence of operation.

2. Manufacturer's sample system checklists and log sheets.

3. Manufacturer's written instructions for testing and adjusting relays and overcurrent protective devices.

4. Time-current curves, including selectable ranges for each type of relay and overcurrent protective device.

1.7 MAINTENANCE MATERIAL SUBMITTALS

A. Furnish extra materials described below that match products installed and that are packaged with protective covering for storage and identified with labels describing contents.

1. Fuses: Six of each type and rating used. Include spares for control power circuits and fusible devices.

Section 26 23 13 Page 3

2. Touchup Paint: 3 containers of paint matching enclosure finish each 0.5 pint.

B. Maintenance Tools: Furnish tools and miscellaneous items required for switchgear test, inspection, maintenance, and operation. Include the following:

1. Overhead crane and trolley and all other items necessary to remove circuit breaker from housing and transport to remote location.

2. Racking handle to move circuit breaker manually between connected and disconnected positions, and a secondary test coupler to permit testing of circuit breaker without removal from switchgear.

1.8 QUALITY ASSURANCE

A. Testing Agency Qualifications: An independent agency, with the experience and capability to conduct the testing indicated, that is a member company of the InterNational Electrical Testing Association or is a nationally recognized testing laboratory (NRTL) as defined by OSHA in 29 CFR 1910.7, and that is acceptable to authorities having jurisdiction.

1. Testing Agency's Field Supervisor: Person currently certified by the

InterNational Electrical Testing Association or the National Institute for Certification in Engineering Technologies to supervise on-site testing specified in Part 3.

B. Testing Agency Qualifications: An independent agency, with the experience and capability to conduct the testing indicated, that is a nationally recognized testing laboratory (NRTL) as defined by OSHA in 29 CFR 1910.7.

C. Source Limitations: Obtain switchgear through one source from a single manufacturer.

D. Product Options: Drawings indicate size, profiles, and dimensional requirements of switchgear and are based on the specific system indicated.

Refer to Section 016000 "Product Requirements."

E. Electrical Components, Devices, and Accessories: Listed and labeled as defined in NFPA 70, Article 100, by a testing agency acceptable to authorities having jurisdiction, and marked for intended use.

F. Comply with NFPA 70.

1.9 DELIVERY, STORAGE, AND HANDLING

A. Deliver switchgear in sections of lengths that can be moved past obstructions in delivery path.

B. Store switchgear indoors in clean dry space with uniform temperature to prevent condensation. Protect switchgear from exposure to dirt, fumes, water, corrosive substances, and physical damage.

C. If stored in areas subjected to weather, cover switchgear to provide protection from weather, dirt, dust, corrosive substances, and physical damage. Remove loose packing and flammable materials from inside switchgear;

install electric heating (250 W per section) to prevent condensation.

1.10 PROJECT CONDITIONS

A. Installation Pathway: Remove and replace building components and structures to provide pathway for moving switchgear into place.

B. Interruption of Existing Electrical Service: Do not interrupt electrical service to facilities occupied by Owner or others unless permitted under the following conditions and then only after arranging to provide temporary electrical service according to requirements indicated:

1. Notify Owner no fewer than two days in advance of proposed interruption of electrical service.

Section 26 23 13 Page 4

2. Do not proceed with interruption of electrical service without Owner's written permission.

C. Product Selection for Restricted Space: Drawings indicate maximum dimensions for switchgear, including clearances between switchgear and adjacent surfaces and other items. Comply with indicated maximum dimensions.

1. Ambient temperature not exceeding 104 deg. F (40 deg. C).

2. Altitude of 650’above sea level for outdoor installation.

1.11 COORDINATION

A. Coordinate layout and installation of switchgear and components with other construction that penetrates ceilings or is supported by them, including conduit, piping, equipment, and adjacent surfaces. Maintain required clearances for workspace and equipment access doors and panels.

B. Coordinate size and location of concrete bases. Concrete, reinforcement, and formwork requirements are specified with concrete.

PART 2 - PRODUCTS

2.1 MANUFACTURERS

A. In other Part 2 articles where titles below introduce lists, the following requirements apply to product selection:

1. Available Manufacturers: Subject to compliance with requirements, manufacturers offering products that may be incorporated into the Work include, but are not limited to, manufacturers specified.

2. Manufacturers: Subject to compliance with requirements, provide products by one of the manufacturers specified.

2.2 GENERATOR PARALLELING MONITOR AND CONTROL SYSTEM

A. Manufacturers:

1. Caterpillar; Engine Div.

B. Individual Generator Control and Monitoring Panel: Provide each generator with a control and monitoring panel that allows the operator to view status and control operation of respective generator. Provide panel with the following features and characteristics:

1. Generator Metering: 1 percent accuracy class or better.

a. Ammeter, Voltmeter, Frequency Meter, Wattmeter, Kilowatt-Hour Meter, and Power Factor Meter:

1) For three-phase and four-wire systems, indicate line-to-line and line-to-neutral conditions on voltmeter.

2) Provide analog devices for voltmeter and frequency meters.

3) Provide switches or other provisions to allow reading of both generator and bus voltages and frequencies from this metering set.

b. Synchroscope and "Generator Set Synchronized" Indication:

1) Provide lamp or LED indication of synchronization.

2) Provide 360-degree analog movement synchroscope.

c. Engine run-time meter, start counter, rpm meter, and battery voltage meter.

d. Engine oil temperature gage and engine coolant temperature gage.

2. Generator Protective and Control Switches: Provide oil-tight, industrial-grade switches in generator control and monitoring panel.

a. Mode Selector Switch (Run/Off/Auto):

1) "Run" mode to start and accelerate unit to rated speed and voltage, but not close paralleling circuit breaker.

2) "Off" mode to prevent generator from starting or to immediately shutdown generator if running.

3) "Auto" mode to allow generator to start on receipt of remote start signal.

W9126G-16-R-0579, Amendment No. 0001 http://www.specagent.com/LookUp/?ulid=2000&mf=04&mf=95&src=wd&mf=04&src=wd http://www.specagent.com/LookUp/?uid=123456817975&mf=04&src=wd

Section 26 23 13 Page 5

b. Circuit-Breaker Trip/Close Switch: Interlocked with system control so that circuit-breaker closure is impossible unless the following occurs:

1) Mode selector switch is in "Run" position.

2) Generator set is synchronized with system bus.

c. Control/reset push button with flashing lamp to indicate generator is locked out due to fault condition.

d. Lamp test push button to simultaneously test all lamps on panel.

e. Control Panel Illumination: DC lamps to illuminate panel when lighting from surrounding environment is not available.

f. Emergency Stop Push Button: Red mushroom-head switch maintaining its position until manually reset.

g. Voltage and Frequency Raise/Lower Switches:

1) Allow plus/minus 5 percent adjustment when generator set is operating but not paralleled.

3. Generator Protective and Control Devices: Solid-state industrial relays, integrated microprocessor-based control devices, and other accessories and devices located either in generator control and monitoring panel or in switchgear control section to provide the following features and functions:

a. Kilowatt Load Sharing Control:

1) Operates engine governors during synchronizing and provides isochronous load sharing when paralleled.

2) Allows generator set to ramp up to kilowatt load level signaled by system master controller.

b. Load-Demand Governing Control:

1) Causes generator set to ramp down to zero loads when signaled to shut down in load-demand mode.

2) Causes generator set to ramp up to a proportional share of total bus load.

c. Kilovolt Ampere Rating Load Sharing Control:

1) Operates alternator excitation system while generator set is paralleled.

2) Causes sharing of reactive load among all generator sets to within 1 percent of equal levels without voltage drop.

d. Sync-Check and Paralleling Monitor and Control:

1) Monitors and verifies that generator set has reached 90 percent of nominal voltage and frequency before closing to bus.

2) Prevents out-of-phase paralleling if two or more generator sets reach operating conditions simultaneously, by sending "inhibit" signal to sets not designated by system as "first to close to bus."

3) Recognizes failure of "first-to-close" generator set and signals system paralleling to continue.

4) Prevents out-of-phase closure to bus due to errant manual or automatic operation of synchronizer.

e. Synchronizer Control:

1) Adjusts engine governor to match voltage, frequency, and phase angle of paralleling bus.

2) Maintains generator-set voltage within 1 percent of bus voltage, and phase angle within 20 electrical degrees of paralleling bus for 0.5 seconds before circuit-breaker closing.

3) Provides "fail-to-synchronize time delay" adjustable from 10 to 120 seconds; with field selectivity to either initiate alarm or shut down generator set on failure condition.

f. Reverse Power Monitor and Control:

1) Prevents sustained reverse power flow in generator set.

2) Trips generator circuit breaker and initiates generator set shutdown when reverse power condition exceeds 10 percent of generator set kilowatt for three seconds.

g. Phase Rotation Monitor and Control:

Section 26 23 13 Page 6

1) Verifies generator set and paralleling bus phase rotation match prior to closing paralleling circuit breaker.

h. Electronic Alternator Overcurrent Alarm and Shutdown Control:

1) Monitors current flow at generator-set output terminals.

2) Initiates alarm when load current on generator set is more than 110 percent of rated current for more than 60 seconds.

3) Provides overcurrent shutdown function matched to thermal damage curve of alternator. Provide without instantaneous-trip function.

i. Electronic Alternator Short-Circuit Protection:

1) Provides shutdown when load current is more than 175 percent of rated current and combined time/current approaches thermal damage curve of alternator. Provide without instantaneous-trip function.

j. Loss of Excitation Monitor:

1) Initiates alarm when sensing loss of excitation to alternator while paralleled to system bus.

k. Generator-Set Start Contacts: Redundant system, 10 A at 32-V dc.

l. Cool-Down Time-Delay Control: Adjustable, 0 to 600 seconds.

m. Start Time-Delay Control: Adjustable, 0 to 300 seconds.

n. Paralleling Circuit-Breaker Monitor and Control:

1) Monitors circuit-breaker auxiliary contacts.

2) Initiates fault signal if circuit breaker fails to close within adjustable time-delay period (0.5 to 15 seconds).

3) Trips open and locks out paralleling circuit breaker upon paralleling circuit breaker failure to close, until manually reset.

4. Engine Protection and Local Annunciation:

a. Provide annunciation and shutdown control modules for alarms indicated.

b. Provide visual alarm status indicator and alarm horn with silence/acknowledge push button on generator control and monitoring panel.

c. Annunciate the following conditions:

1) Status, Light Only (Non-latching):

a) Generator engine control switch not in auto (red).

b) Generator engine control switch in auto (green).

c) Emergency mode (red).

d) Generator circuit breaker closed (red).

e) Generator circuit breaker open (green).

f) Engine stopped (green).

g) Engine running (red).

h) Engine cool-down (amber).

2) Pre-Alarm, Light and Horn (Non-latching):

a) Pre-high coolant temperature (amber).

b) Pre-low oil pressure (amber).

c) Low coolant temperature (amber).

d) Engine low battery (amber).

e) Engine low fuel (amber).

f) Generator fails to synchronize (amber).

3) Shutdown Alarm, Light and Horn (Latching):

a) Engine over-crank (red).

b) Engine over-speed (red).

c) Engine low oil pressure (red).

d) Engine high coolant temperature (red).

e) Engine low coolant level (red).

f) Engine remote emergency shutdown (red).

g) Generator circuit breaker tripped (red).

h) Generator loss of field (red).

i) Generator reverse power (red).

j) Generator under-voltage (red).

k) Generator overvoltage (red).

l) Generator under-frequency (red).

Section 26 23 13 Page 7

m) Generator over-frequency (red).

C. Master Control System and Monitoring Equipment: Paralleling and monitoring equipment, components, and accessories for multiple generators with the following features and characteristics:

1. Components and devices shall be mounted in the switchgear control section of the switchgear lineup.

2. Paralleled System Metering: 1 percent accuracy class or better to monitor total output of generator bus.

a. Ammeter, voltmeter, frequency meter, wattmeter, kilowatt-hour meter, power factor meter, kilovolt ampere, kilovolt ampere rating, and kilowatt demand meters.

1) For three-phase/four-wire systems, indicate line-to-line and line-to-neutral conditions on voltmeter.

2) Display all functions on the HMI device.

3. Full-Color HMI Device: Touchscreen with minimum viewing area of 60 square inches.

a. Allows operator to monitor and control the complete system of paralleled generator sets.

b. Screens shall include the following:

1) Main Menu: Include date, time, and system status messages with screen push buttons to access one-line diagram, system controls, load controls, alarms, bus metering, and individual generator-set data.

2) One-Line Diagram Screen: Depicting system configuration and system status by screen animation, screen colors, text messages, or pop-up indicators. Indicate the following minimum system conditions:

a) Generator sets, buses, and paralleling circuit breakers energized/de-energized.

b) Generator-set mode (run/off/auto).

c) Generator-set status (normal/warning/shutdown/load-demand stop).

d) Paralleling circuit-breaker status (open/closed/tripped).

e) Bus conditions (energized/de-energized).

f) Provide access to other screens.

3) AC Metering Screen: Displays the following minimum meter data for the paralleling bus:

a) Phase volts and amperes, kilowatt, kilovolt ampere, kilovolt ampere rating, power factor, frequency, kilowatt hour, and kilowatt demand.

b) Real-time trend chart for system kilowatts and volts updated on not less than one-second intervals.

c) A minimum of one historical trend chart for total system loads with intervals no shorter than five minutes and a minimum duration of four hours.

4) Generator-Set Control Screen: Provides control over individual generator sets from master system control panel.

Includes the following minimum functions:

a) Generator manual start/stop control (functional only when generator-set mounted control switch is in "Auto" position).

b) Generator-set alarm reset.

c) Manual paralleling and circuit-breaker controls.

5) Generator-Set Data Display Screen: Provide the following minimum parameters:

a) Engine speed, oil pressure and temperature, coolant temperature, and engine operating hours.

b) Three-phase voltage and current, kilowatt, power factor, and kilowatt hour.

c) Generator control switch position and paralleling circuit-breaker position.

d) All generator-set alarms.

Section 26 23 13 Page 8

6) System Control Screen: Password protected and with the following minimum functions:

a) System Test Modes: Test with load/test without load/normal/retransfer time-delay override.

b) Test with Load: Starts and synchronizes generator sets on paralleling bus; all loads are transferred to bus.

c) Test without Load: Starts and synchronizes generator sets on paralleling bus but does not transfer loads to bus.

d) Time adjustments for retransfer time delay, transfer time delay, system time delay on stopping, and system time delay on starting.

7) Load-Demand Control Screen: Monitors total load on system bus and controls number of generator sets running so that capacity tracks load demand.

a) Load-Demand Control: On/off.

b) Load-Demand Pickup Set Point: Adjustable from 90 to 40 percent in 5 percent increments.

c) Load-Demand Dropout Set Point: Adjustable from 20 to 70 percent in 5 percent increments.

8) Manual Load Control Screen: Allows operator to manually add or delete generator sets from paralleled system in response to system load parameters.

a) Indication of system available in kilowatts and amperes.

b) Control functions allow manual addition/removal of generator sets on system, and activation of load-shed/load-restore functions.

9) Load-Add/Load-Shed Sequence Screen: Password protected and with the following minimum functions:

a) Assigns "load-add sequence priority" to each load control relay with designation for relay operation after a set number of generator sets are online.

b) Assigns "load-shed sequence priority" to each load control relay with designation for relay operation depending on number of generator sets online.

10) Alarm Summary and Run Report Screen:

a) Lists most recent alarm conditions and status changes.

b) Lists a minimum of the most recent 32 alarm conditions by name and time/date; acknowledges alarm conditions with time/date.

c) For each start signal, lists start time and date, stop time and date, maximum kilowatt and ampere load on system during run time, and start and stop times of individual generator sets.

4. Solid-State System Status Panel:

a. Provides visual alarm status indicator and alarm horn with silence/acknowledge push button.

b. Annunciates the following conditions:

1) Status, Light Only:

a) Running Status: Display generator set number and "green" running-status light.

b) Load demand mode (green).

c) Priority Load Status: Display load number and "green" on-status light.

d) System test (green).

e) Remote system start (red).

f) Normal source available (green).

g) Connected to normal (green).

h) Generator source available (green).

i) Connected to generator source (green).

2) Status, Light and Alarm:

a) Load-Shed Level Status: Displays load number and red load-shed, status light.

Section 26 23 13 Page 9

b) Generator Alarm Status: Displays generator number and red "Check Generator" status light.

c) Controller malfunction (red).

d) Check station battery (red).

e) Bus overload (red).

f) System not in auto (red).

D. Description of System Operation:

1. Loss of Normal Power:

a. System receives "start" signal; all generator sets start and achieve rated voltage and frequency.

b. System closes the first generator set achieving 90 percent of rated voltage to paralleling bus.

c. "Priority load add" controls prevent overloading of system.

d. Remaining generator sets switched to synchronizers that control and then allow closure of generator sets to paralleling bus.

e. On closure to paralleling bus, each generator set assumes its proportional share of total load.

2. Failure of a Generator Set to Start or Synchronize:

a. After expiration of over-crank time delay, generator set shuts down and alarm is initiated.

b. Priority controller prevents overload of system bus.

c. Manual override of priority controller at HMI allows addition of low-priority load to bus.

d. Bus overload monitor protects bus from manual overloading.

3. Bus Overload:

a. On bus overload, load-shed control initiates load shedding.

b. If bus does not return to normal frequency within adjustable time period, additional load continues to be shed until bus returns to normal frequency.

c. Loads shed can be reconnected to bus only by manual reset at HMI.

4. Load-Demand Mode:

a. With "load-demand" function activated, controller continuously monitors total bus load.

b. If bus load is below preset limits for 15 minutes, demand controller shuts down generator sets in predetermined order until minimum number of sets are operating.

c. On sensing available bus capacity diminished to set point, controller starts and closes generator sets to bus to accommodate load.

5. Return to Normal Power:

a. Process starts on removal of start signals from system.

b. When no load remains on paralleling bus, all generator breakers open, go through cool-down period, and shut down.

c. If start signal is received during cool-down period, one generator set is reconnected to bus, and system operation follows that of "loss of normal power."

2.3 MANUFACTURED UNITS

A. Description: Factory assembled and tested and complying with IEEE C37.20.1.

B. Ratings: Suitable for application in 3-phase, 60-Hz, solidly grounded neutral system.

C. Indoor Enclosure Material: Steel.

D. Outdoor Enclosure Fabrication Requirements: Galvanized steel, weatherproof;

integral structural-steel base frame with factory-applied asphaltic undercoating.

1. Provide each compartment or group of compartments with the following features:

a. Structural design and anchorage adequate to resist loads imposed by

125-mph (200-km/h) wind.

Section 26 23 13 Page 10

b. Space heater operating at one-half or less of rated voltage, sized to prevent condensation.

c. Louvers equipped with insect and rodent screen and filter; arranged to permit air circulation while excluding insects, rodents, and exterior dust.

d. Hinged front door with locking provisions.

e. Interior light with switch.

f. Weatherproof GFCI duplex receptacle.

g. Power for heaters, lights, and receptacles to be provided by control power transformer or as indicated.

2. Provide weatherproof internal aisle construction with the following features:

a. Common internal aisle of sufficient width to permit protective-device withdrawal, disassembly, and servicing in aisle.

b. Aisle access doors with exterior padlocking provisions and interior panic latches.

c. Aisle space heaters operating at one-half or less of rated voltage thermostatically controlled.

d. Vapor-proof fluorescent aisle lights with low-temperature ballasts, controlled by wall switch at each entrance.

e. GFCI duplex receptacles, a minimum of two, located in aisle.

f. Aisle ventilation louvers equipped with insect and rodent screen and filter; arranged to permit air circulation while excluding insects, rodents, and exterior dust.

E. Access: Fabricate enclosure with hinged, rear cover panels to allow access to rear interior of switchgear.

F. Finish: Manufacturer's standard gray finish over a rust-inhibiting primer on phosphatizing-treated metal surfaces.

G. Phase-, Neutral-, and Ground-Bus Materials: Extend full length of switchgear.

1. Phase Bus: Copper, silver plated at connection points or Copper, tin plated.

2. Ground Bus: Copper, silver or, tin plated; minimum size 1/4 by 2 inches

(6 by 50 mm).

H. Switchgear Components:…