Corrected Final DPG - B4156 New Electrical Service SPECS.pdf

BUILDING 4156 ELECTRICAL UPGRADE

Dugway Proving Ground (DPG), Utah

SPECIFICATION FILE NUMBER 2132

DESIGN FILE NUMBER 181-25-0407

SPECIFICATIONS

US Army Corps of Engineers Sacramento District

MAY 2024

Bldg. 4156 Repair Electrical Service Entrance Specs #2132 Dugway Proving Ground (DPG), UT

PROJECT TABLE OF CONTENTS

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 00 00 08/21, CHG 2: 05/23 GENERAL REQUIREMENTS

01 11 00 08/15 SUMMARY OF WORK

01 14 00 11/22, CHG 1: 02/23 WORK RESTRICTIONS

01 32 01 02/15, CHG 4: 09/22 PROJECT SCHEDULE

01 33 00 08/18, CHG 7: 10/22 SUBMITTAL PROCEDURES

01 35 26 11/20, CHG 5: 09/22 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 02/19, CHG 1: 03/22 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00 11/16, CHG 6: 09/22 QUALITY CONTROL

01 45 00.15 11/16, CHG 3: 9/22 RESIDENT MANAGEMENT SYSTEM CONTRACTOR

MODE (RMS CM)

01 50 00 11/20, CHG 10: 09/22 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 08/16 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 02/19, CHG 3: 11/21 CONSTRUCTION WASTE MANAGEMENT AND

DISPOSAL

01 78 00 05/19, CHG 8: 04/23 CLOSEOUT SUBMITTALS

01 78 23 08/15 OPERATION AND MAINTENANCE DATA

01 78 24 05/18 FACILITY DATA REQUIREMENTS

01 91 00 02/19 TOTAL BUILDING COMMISSIONING

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00 08/22 DEMOLITION

DI VI SI ON 03 - CONCRETE

03 30 00 02/19, CHG 6: 11/23 CAST-IN-PLACE CONCRETE

DI VI SI ON 25 - I NTEGRATED AUTOMATI ON

25 05 11 05/21 CYBERSECURITY FOR FACILITY-RELATED

CONTROL SYSTEMS - ATS/Generator Controls

DI VI SI ON 26 - ELECTRI CAL

26 05 48 11/23 SEISMIC PROTECTION FOR ELECTRICAL

EQUIPMENT

26 05 73 08/23 POWER SYSTEM STUDIES

26 08 00 11/22 APPARATUS INSPECTION AND TESTING

26 12 19.10 05/19, CHG 2: 11/23 THREE-PHASE, LIQUID-FILLED PAD-MOUNTED

TRANSFORMERS

26 20 00 08/23 INTERIOR DISTRIBUTION SYSTEM

26 23 00 05/15, CHG 2: 11/19 LOW-VOLTAGE SWITCHGEAR

26 27 13.10 30 10/07, CHG 2: 08/18 ELECTRIC METERS

26 32 15.00 05/20 ENGINE-GENERATOR SET STATIONARY

15-2500 KW, WITH AUXILIARIES

26 36 23 05/20, CHG 1: 08/21 AUTOMATIC TRANSFER SWITCHES AND

BY-PASS/ISOLATION SWITCH

26 42 13 05/21 GALVANIC (SACRIFICIAL) ANODE CATHODIC

PROTECTION (GACP) SYSTEM

DI VI SI ON 31 - EARTHWORK

31 00 00 08/08, CHG 2: 02/21 EARTHWORK

PROJECT TABLE OF CONTENTS Page 1

DI VI SI ON 33 - UTI LI TI ES

33 08 55 08/19 FUEL DISTRIBUTION SYSTEM START-UP

(NON-HYDRANT)

33 52 10 11/18, CHG 1: 11/20 FUEL SYSTEMS PIPING (SERVICE STATION)

33 52 23.15 11/18 POL SERVICE PIPING WELDING

33 71 01 05/19, CHG 1: 11/19 OVERHEAD TRANSMISSION AND DISTRIBUTION

33 71 02 08/21 UNDERGROUND ELECTRICAL DISTRIBUTION

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 00 00

GENERAL REQUIREMENTS

08/ 21, CHG 2: 05/ 23

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 SCRAP MATERIAL

1.4 WRITTEN GUARANTEES AND GUARANTOR'S LOCAL REPRESENTATIVE

1.5 PRICING OF CONTRACTOR-FURNISHED PROPERTY

1.6 GENERAL SAFETY REQUIREMENTS

1.7 ANTITERRORISM AND OPERATIONAL SECURITY.

1.7.1 General security requirements and guidance:

1.7.2 Antiterrorism (AT) Level I training:

1.7.3 Physical security and access control requirements:

1.7.4 Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something):

1.7.5 Pre-screen candidates using E-Verify Program:

1.8 TEMPORARY ELECTRIC WIRING

1.8.1 Temporary Power and Lighting

1.8.2 Construction Equipment

1.8.3 Circuit Protection

1.9 UTILITIES

1.10 REQUEST TO TURN OFF UTILITIES AND CLOSE ROADWAYS AND PARKING LOTS

1.11 PLANNED UTILITY OUTAGES AND STREET CLOSURES

1.12 EXCAVATION PERMITS

1.13 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.14 SPECIAL MILITARY PROCEDURES

1.14.1 Dugway PG

1.15 AREAS OF RADAR RADIATION HAZARD

1.16 HAZARDOUS NOISE AREA

1.17 COLOR SCHEME FOR CONTRACTOR FACILITIES

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

PART 3 EXECUTION

3.1 AFTER AWARD DOCUMENTS

-- End of Section Table of Contents --

SECTION 01 00 00 Page 1

SECTION 01 00 00

GENERAL REQUIREMENTS

08/ 21, CHG 2: 05/ 23

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this Section to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2023; ERTA 4 2023) National Electrical Code

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety -- Safety and Health Requirements Manual

ER 415-1-15 (1989) Construction Time Extensions for Weather

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

1.3 SCRAP MATERIAL

Materials specified to be removed and become the property of the Contractor are designated as scrap, and the Contractor, by signing this Contract, hereby acknowledges that the Contractor has made due allowance for value of such scrap in the Contract price.

1.4 WRITTEN GUARANTEES AND GUARANTOR'S LOCAL REPRESENTATIVE

Obtain and furnish to the Contracting Officer written guarantees for the equipment and appliances furnished. Furnish with each guarantee: The name, address, and telephone number of the guarantor's representative nearest to the location where the equipment and appliances are installed, who, upon request of the Using Service's representative, will honor the guarantee during the guaranty period and will provide the services prescribed by the terms of the guarantee.

SECTION 01 00 00 Page 2

1.5 PRICING OF CONTRACTOR-FURNISHED PROPERTY

1.6 GENERAL SAFETY REQUIREMENTS

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS.

1.7 ANTITERRORISM AND OPERATIONAL SECURITY.

1.7.1 General security requirements and guidance:

The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts.

The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations.

Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures.

The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel.

The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

1.7.2 Antiterrorism (AT) Level I training:

All contract personnel requiring routine access to Army installations, facilities, and controlled access areas, or requiring network access shall complete initial and annual refresher AT Level I awareness training.

Online AT Level I awareness training is available at https://jko.jten.mil/ (website subject to change).

1.7.3 Physical security and access control requirements:

All contract personnel requiring physical access to a federal installation

SECTION 01 00 00 Page 3 or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-III") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

1.7.4 Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something):

All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

1.7.5 Pre-screen candidates using E-Verify Program:

Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements.

Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/ eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

1.8 TEMPORARY ELECTRIC WIRING

1.8.1 Temporary Power and Lighting

Provide construction power facilities in accordance with the safety requirements of the NFPA 70 and EM 385-1-1 . Enforce the safety requirements of electrical extensions for the work of subcontractors. Work to be accomplished by skilled electrical tradesmen in a workmanlike manner, as approved by the Contracting Officer.In addition contractor shall submit a temporary power design for contracting officer review and approval, refer to SECTION 01 11 00 SUMMARY OF WORK.

1.8.2 Construction Equipment

In addition to the requirements of EM 385-1-1 , install temporary wiring conductors for operation of construction tools and equipment of either Type TW or THW contained in metal raceways, or may be multiconductor cord.

SECTION 01 00 00 Page 4

Temporary wiring to be secured above the ground or floor in a workmanlike manner and cannot present an obstacle to persons or equipment. Open wiring may only be used outside of buildings, and then only in strict accordance with the provisions of the National Electrical Code.

1.8.3 Circuit Protection

In addition to the present requirements in EM 385-1-1 and NFPA 70 , ensure 15-ampere and 20-ampere receptacle outlets used for obtaining power during construction have ground fault circuit interrupters (GFCI) for personnel protection. Block and brick saws to be equipped with GFCI. The Contracting Officer may allow an exception to this requirement for circuits for concrete vibrators or circuits operating at other than 60 Hertz normal (in both cases an assured grounding program as described in the NFPA 70 , except utilizing the daily inspection frequency of the grounding means of such equipment, may be permitted). The assured grounding program cannot be permitted as a substitute for usage of GFCI'S except as described above.

Ensure generator-powered 15- and 20-ampere, 60 Hertz receptacle outlets have GFCI'S, and are to be properly grounded. Provide a testing means which will impose a measured fault of 5 milliamperes, plus or minus 1 milliamperes, and result in tripping the GFCI unit.

1.9 UTILITIES

Immediately notify the Contracting Officer in writing if utilities not shown on the drawings interfere with construction operations, to enable a determination by the Contracting Officer as to the necessity for removal or relocation. If such utilities are removed or relocated as directed by the Contracting Officer, an equitable adjustment in the Contract price to be made pursuant to the Contract Clause CHANGES to cover the cost of additional pertinent work or delay.

1.10 REQUEST TO TURN OFF UTILITIES AND CLOSE ROADWAYS AND PARKING LOTS

Requests to turn off utilities and close roadways and parking lots must be made using the approved DPW Outage Request form.

Work on high voltage distribution systems must include a power outage; hot work is not permitted.

All utility outages must be coordinated through dona.w.curry.civ@army.mil, or designated representative.

Except for emergencies, Outage Requests for the English Village area will be made NLT 21 days prior to the requested outage data.

Outage Requests for areas outside of English Village will be made NLT 35 days prior to the requested date.

Expect outages to be approved for weekends and holidays due to mission requirements.

1.11 PLANNED UTILITY OUTAGES AND STREET CLOSURES

Ensure utility outages and street closures are as short a duration as possible and to be scheduled as far in advance as possible with the Contracting Officer, in no case less than 30 days before the outage or closure. Obtain from the Contracting Officer in writing a statement or

SECTION 01 00 00 Page 5 schedule giving the permissible times of outages or closures for particular installations and the maximum time allowed for each. Strictly observe such schedules.

1.12 EXCAVATION PERMITS

Obtain excavation permits issued from the Directorate of Public Works (DPW), through the Contracting Officer. The appropriate form, for this request, may be obtained from the Contracting Officer. Processing time required is 14 calendar days. Direct questions concerning the excavation permit to the Contracting Officer.

a. Prior to performing excavation at Dugway Proving Ground, obtain a permit for excavation. The permit is to be issued by Dugway Facilities and Services Directorate through the Corps of Engineers.

b. Make application for the permit to the Resident Office by taking the following steps:

(1) Prepare duplicate site drawings or prepared drawings, indicating areas of excavation and the depth and width of excavations.

(2) Prepare a schedule, or show on the site drawings a schedule, indicating the planned dates of excavation.

(3) Staking, in the field, areas indicated on the drawings for excavation.

c. Allow a minimum period of 30 calendar days for completion of the excavation permit process by Dugway. No excavation is permitted until the excavation permit is issued.

d. Dugway regulations require the presence of a Dugway Safety Officer representative at the site during excavation operations. Schedule excavations in advance; unscheduled excavation work is not allowed.

1.13 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather. In order for the Contracting Officer to award a time extension under this clause, satisfy the following conditions:

(1) The weather experienced at the project site during the Contract period is unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather causes a delay to the completion of the project. The delay is beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and constitutes the base line for monthly weather time evaluations. Progress schedule to reflect these anticipated adverse weather delays in weather dependent activities.

SECTION 01 00 00 Page 6

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

STATE

UTAH

INSTALLATION/NOAA STATION

DUGWAY PROVING GROUND/TOOELE

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(20) (16) (14) (08) (05) (03) (02) (02) (02) (05) (13) (21)

c. Upon execution of the Notice to Proceed (NTP), record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Adverse weather delay days prevent work on critical activities for 50 percent or more of the scheduled work day.

Refer to ER 415-1-15 .

1.14 SPECIAL MILITARY PROCEDURES

1.14.1 Dugway PG

a. Work Schedule: Perform the work required on this project within the normal hours of the workweek at Dugway Proving Ground. The workweek at Dugway Proving Ground is Monday through Thursday, with normal hours from 7:00 am to 5:30 pm. Make an evaluation of this required 4 day, 40 hour work week and include this requirement in the preparation of the bid. Progress schedule is to reflect this requirement for a 4 day, 40 hour work week. Do not operate outside of normal working hours.

b. The proposed construction location: The proposed construction is located at the Dugway Proving Grounds (Secure Area). Security procedures for access to the area may have a significant influence on the method and schedule for work performance. The following security procedures may apply to people seeking access to the project site:

(1) Initial and subsequent issue of access badge.

(2) Vehicle passes and vehicle safety inspection by Army personnel.

(3) Denial of access of certain personnel, including foreign nationals.

(4) Attendance at safety briefings by Base prior to entering area.

(5) Issue and maintenance of protective mask (personnel are to be clean shaven to wear masks).

(6) Blood tests. (Red Blood Cell Acetylcholinesterase (RBCche) tests are performed by the Health Clinic. Each employee to have a minimum of three tests, two for a baseline and one upon exit.

Contact the Chemical Surety Office for further information.)

(7) Exchange badge procedure for access to secure area.

(8) Inspection of vehicles and contents upon entering/departing area.

(9) Restrictions on storage of material within secure area.

(10) Required demobilization of construction equipment stored in secure area.

(11) Escorts and restrictions on personnel movements in secure area.

(12) Limitations on guard changes and unscheduled work.

(13) Restrictions on smoking and eating in secure area.

SECTION 01 00 00 Page 7

(14) Mandatory evacuation of area if ordered.

(15) Additional chemical safety procedures required if storage buildings are to be opened or entered.

(16) Inoculations may be required for personnel.

Make an evaluation of the above and include reasonable costs within the bid price for security procedures. Additional information is available from the Security Office at Dugway Proving Ground. Contact the Security Office prior to bid times.

1.15 AREAS OF RADAR RADIATION HAZARD

The work performed may be hazardous at times due to radar radiation.

Construction activities and personnel cannot be allowed within such areas without prior arrangement with and the approval of the Contracting Officer. Coordinate regularly with the Contracting Officer and radar operating personnel.

1.16 HAZARDOUS NOISE AREA

Work area is located within a high noise area and can be hazardous to hearing. Provide adequate ear protection for personnel at the job site.

1.17 COLOR SCHEME FOR CONTRACTOR FACILITIES

Storage and operational facilities including temporary structures, signs and fencing, that remain at the site are to be compatible with the color scheme used on the project signs as directed by the Contracting Officer.

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

The Government will provide an optical disc at the preconstruction conference that contains the materials specified in Section 01 78 00

CLOSEOUT SUBMITTALS

PART 3 EXECUTION

3.1 AFTER AWARD DOCUMENTS

Provide conformed specifications in hard copy reproduced from the PDF Contract Documents. Hard copy drawings consist of sets of ANSI D (22 inches by 34 inches) and sets of half size (11 inches by 17 inches) 3-hole punched and bound with metal posts. Ensure specifications are standard letter (8-1/2 inches by 11 inches), 3-hole punched, and bound with metal posts. Submit specifications and drawings within 5 work days of the receipt of the AWARD documents from the Government .

-- End of Section --

SECTION 01 00 00 Page 8

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 SUBMITTALS

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.3 OCCUPANCY OF PREMISES

1.4 EXISTING WORK

1.5 DRAWINGS

1.6 Temporary Power Plan (EM 385-1-1)

1.6.1 Electrical Temporary Wiring and Lighting.

1.6.2 Electrical Testing

1.7 PROJECT REQUIREMENTS (CLIN DESCRIPTIONS)

1.8 AUTHORITIES

1.9 PRECONSTRUCTION CONFERENCE

1.10 Dugway Proving Ground (DPG) Landfill

1.11 Dugway Proving Ground (DPG) Solid Wastes and Recyclable Materials

1.12 Natural Resources

1.13 Safety

1.14 Fuel / Oil Burning Equipment

1.15 Pollution Prevention

1.16 Cultural Resources

1.17 Fugitive Dust

1.18 Directorate of Public Works Visitor Access Procedures for US

Citizens

1.19 POST-AWARD POINTS OF CONTACT

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals Temporary Power Plan (EM 385-1-1); G

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The Contractor shall provide all labor, materials, supervision, transportation, tools, equipment, design, and construction services necessary for renovation and construction of complete operational facilities for this construction project. Work includes to replace existing electrical service entrance and generator for the building 4156.

The replacement will include the service pad-mounted transformer, main distribution switchboard, meter, generator, automatic transfer switch and related conduits and wiring.

1.2.2 Location

The work is located in Ditto Center (Building 4156) at Dugway Proving Ground (DPG), UT. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Occupancy notifications will be posted in a prominent location in the work area.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as

SECTION 01 11 00 Page 2 approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 DRAWINGS

Dugway Proving Groud, Utah, Building 4156 Service Entry Replacement.PDF

1.6 Temporary Power Plan (EM 385-1-1)

1.6.1 Electrical Temporary Wiring and Lighting.

A sketch of proposed temporary power distribution systems shall be submitted to the GDA and accepted for use before temporary power is installed. The sketch shall indicate the location, voltages, and means of protection of all circuits, including receptacles, disconnecting means, grounding, GFCIs, and lighting circuits.

1.6.2 Electrical Testing

A. Temporary electrical distribution systems and devices shall be checked and found acceptable for polarity, ground continuity, and ground resistance before initial use and before use after modification. GFCI shall be tested monthly.

B. Ground resistance and circuits shall be measured at the time of installation and shall comply with drawings. The measurement shall be recorded and a copy furnished to the GDA.

1.7 PROJECT REQUIREMENTS (CLIN DESCRIPTIONS)

The contractor shall furnish all labor, materials, accessories, transportation, equipment, and supervision necessary to accomplish the work described. Contractor is to coordinate and work closely with the facility, minimizing disruption. The scope of the project is to replace existing electrical service entrance and generator for the building 4156. The replacement will include the service pad-mounted transformer, main distribution switchboard, meter, generator, automatic transfer switch and related concrete enccased ductbanks, conduits and wiring.

1.8 AUTHORITIES

Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

1.9 PRECONSTRUCTION CONFERENCE

Prior to the initiation of work, a meeting will be held with the Contractor, DPG and USACE to discuss matters of mutual interest concerning the contract. General conditions, work schedule, phasing and coordination, security, safety, permits, and other matters pertinent to work accomplishments will be discussed in this meeting.

SECTION 01 11 00 Page 3

1.10 Dugway Proving Ground (DPG) Landfill

The DPG Landfill is permitted to accept ACM waste. Travel Distance is approximately 10 miles from Building 4156. DPG Landfill is available for contractor to utilize at no disposal fees. POC for this action and all solid waste disposal actions is Mr. Jerry Mason (435) 831-3369, email -gerald.l.mason.civ@mail.mil

1.11 Dugway Proving Ground (DPG) Solid Wastes and Recyclable Materials

Proponent will manage solid wastes and recyclable materials in consultation with Dugway's recycling manager.

1.12 Natural Resources

Please notify the Natural Resources office at DPG immediately if any nesting birds are observed on or near structures getting upgraded.

Otherwise, no natural resources issues at this time. Work will take place within previously disturbed cantonment areas.

1.13 Safety

Construction Industry Safety Requirements for work at elevated heights must be followed.

1.14 Fuel / Oil Burning Equipment

No equipment in the design is to be changed to fuel/oil burning equipment without authorization from The USAG (DPG) Director of Public Works

1.15 Pollution Prevention

In the case of a spill of petroleum, oil, or lubricants (POL), hazardous substances or hazardous waste that are beyond the training and clean-up capabilities of test personnel, the DPG Installation Spill Contingency Plan (ISCP) will be implemented. If the spill presents an immediate danger to human health or the environment, the supervisor will evacuate all personnel away from the spill and contact the WDTC Director, the DPG Fire Department, and DPG Environmental Programs Division, providing as much information as possible relating to the spill.

1.16 Cultural Resources

Building 4156, has not been evaluated for NRHP inclusion as it is not 50 years old, nor does it qualify under any Criteria using Consideration G.

1.17 Fugitive Dust

Fugitive dust (PM10 and PM2.5) will be generated from demolition and sawing/cutting. Any activity producing dust must use the Dugway Proving Grounds (DPG) Fugitive Dust Control Plan and associated activity form to document how fugitive dust on-site was minimized to prevent opacities caused by fugitive dust from exceeding 20% on site and 10% at the property boundary. The activities corresponding form must be filled out to track and record dust control minimization activities. Forms 10 and 13 will need to be used for this activity. A logbook entry may also be required to document activity. Please see form for instructions. NEPA REC activity officer will need to record actions and control measures used for dust

SECTION 01 11 00 Page 4 control, and provide the information on the associated form to Boyd Roberts 831-2546, or Kay Rose 831-3375.

1.18 Directorate of Public Works Visitor Access Procedures for US Citizens

1. All visitors coming to Dugway Proving Ground (DPG) must fill out form, 'SITE VISITOR INFORMATION SHEET.PDF', for all individuals. This information is required so we can process your request thru the new pre-registration system. All visitors will have a background check see the News Release, 'Tighter Security Checks for Visitors', in the following pages. Foreign Nationals (non-US Citizens) have separate requirements and will be addressed separately - coordinate with your Contracting Officer's Representative (COR) or Point of Contact (POC).

2. Visitors that will be at DPG for more than six months should fill out the form, 'DPG ACCESS IDENTIFICATION APPLICATION' that will be provided by your COR or POC. Recommend the prime contractor appoint one or two individuals to do all badge requests. DPW will not accept requests from subcontractors.

3. Multiple requests cannot be combined into one document - the individual fields are not unique from page to page and they lose all information except page 1.

4. The preferred method of processing requests is electronic via email.

The form is designed for electronic input with a pull-down menu.

Contact information will be given after award, once COR has been designated by the Contracting Officer.

In sending documentations Via Email:

- Subject Line of the email type: Visitor Access Request, Contract Number/Order).

- Attach the requested information, SITE VISITO INFORMATION SHEET and DPF ACCESS IDENTIFICATION APPLICATION (If applicable), and badge application as appropriate.

- Be sure to Cc your COR, Contract Specialist / Contract Administrator, Contracting Officer, etc.

*NOTE: Do not combine separate applications into one PDF file.

5. Allow up to three days for processing - if that is not possible, visitors can show up at the visitor center and they will run the background check. If it is on a weekend, it may take longer than 30 minutes. Please keep in mind that the only issue is if visitors have an adverse report, they would have made a long trip for nothing.

1.19 POST-AWARD POINTS OF CONTACT

The Administrative US Army COE POC & ACO will be designated at the time of award. They will be responsible for verifying that the Contractors' performance and completion of work is in accordance with applicable requirements.

SECTION 01 11 00 Page 5

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 11 00 Page 6

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00

WORK RESTRICTIONS

11/ 22, CHG 1: 02/ 23

PART 1 GENERAL

1.1 SUBMITTALS

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

1.2.1.1 Subcontractors and Personnel Contacts

1.2.1.2 No Smoking Policy

1.2.2 Working Hours

1.2.3 Work Outside Regular Hours

1.2.4 Occupied Building

1.3 SECURITY REQUIREMENTS

1.3.1 Physical Security

1.3.2 Anti-Terrorism (AT) and Operations Security (OPSEC):

1.3.2.1 AT Level I Training

1.3.2.2 Access and General Protection / Security Policy and

Procedures

1.3.2.2.1 Contractors requiring Common Access Card (CAC)

1.3.2.2.2 Contractors that do not require CAC,

1.3.2.2.3 iWatch Training

1.3.2.2.4 Contractor Employees Who Require Access to Government

Information Systems (IS).

1.3.3 OPSEC Standing Operating Procedure (SOP) / Plan

1.3.4 OPSEC Training

1.3.5 Contractor Access to DPG

1.3.5.1 Personnel Security

1.3.5.1.1 Security Badge Requirements

1.3.6 Entry Procedures to Controlled / Restricted Areas

1.3.7 Contractor Sponsored Foreign Nationals

1.3.8 Reporting Requirements:

1.3.9 Drivers

1.3.10 Additional Security Requirements:

1.3.11 REAL ID Act - 5 Jan 2016

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 14 00 Page 1

SECTION 01 14 00

WORK RESTRICTIONS

11/ 22, CHG 1: 02/ 23

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for information only. When used, a code following the "G" classification identifies the office that will review the submittal for the Government.

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Ensure all Contractor equipment, include delivery vehicles, are clearly identified with their company name.

1.2.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.2.1.2 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.2.2 Working Hours

Regular working hours are Monday through Thursday except US Federal Holidays. Workers typically work ten (10) hours per day, 40 hours per week. Core hours of work are from 0700 to 1730 daily. All employees are expected to be available during core hours.

SECTION 01 14 00 Page 2

1.2.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer.

1.2.4 Occupied Building

The Contractor shall be working around existing buildings which are occupied. Do not enter the building without prior approval of the Contracting Officer.

The existing buildings and their contents must be kept secure at all times. Provide temporary closures as required to maintain security as directed by the Contracting Officer.

1.3 SECURITY REQUIREMENTS

The following paragraphs provide information on security requirements associated with this contract.

1.3.1 Physical Security

The Contractor shall be responsible for safeguarding all Government equipment, information and property provided for Contractor use. At the close of each work period, Government facilities shall be secured. The Contractor shall ensure that its employees entering Army-controlled installations or facilities have obtained access badges and passes IAW facility regulations and that these badges and passes are obtained in advance so as not to delay the accomplishment of contracted services (see Security Badge Requirements for additional information). Delay caused by contractor failure to obtain badges and passes in advance will not be a basis for claim by the Contractor.

The Contractor shall return all issued US Government Common Access Cards (CAC), Installation badges, and/or access passes to the COR when the contract is completed or when a Contractor employee no longer requires access to the Installation or facility. The Contractor shall demonstrate compliance with all personnel identity verification procedures. If the COR determines that the Contractor is not ensuring all access cards, badges, etc., are being returned as required under this section, the KO may take action against the Contractor to the extent allowed under the FAR and applicable supplements. Actions taken against the Contractor for their failure to comply with this requirement shall not relieve them of their duties associated with this contract. Force Protection Condition (FPCON) impact on work levels: During FPCONs Charlie and Delta, services are discontinued. Services shall resume when the FPCON level is reduced to level Bravo or lower. Procedures for complying with requirements addressed herein shall be included in the Contractor's Quality Control Plan (CQCP).

The Contractor shall establish and implement methods of making sure all

SECTION 01 14 00 Page 3 keys/key cards issued to the Contractor by the Government are not lost or misplaced and are not used by unauthorized persons. All references to keys include key cards. No keys issued to the Contractor by the Government shall be duplicated. The Contractor shall develop procedures covering key control that shall be included in the CQCP. Such procedures shall include turn-in of any issued keys by personnel who no longer require access to locked areas. The Contractor shall immediately report any occurrences of lost or duplicate keys/key cards to the KO. In the event keys, other than master keys, are lost or duplicated, the Contractor shall, upon direction of the KO, re-key or replace the affected lock or locks; however, the Government, at its option, may replace the affected lock or locks or perform re-keying. When the replacement of locks or re-keying is performed by the Government, the total cost of re-keying or the replacement of the lock or locks shall be deducted from the monthly payment due the Contractor. In the event a master key is lost or duplicated, all locks and keys for that system shall be replaced by the Government and the total cost deducted from the monthly payment due the Contractor. The Contractor shall prohibit the use of Government issued keys/key cards by any persons other than the Contractor's employees. The Contractor shall prohibit the opening of locked areas by Contractor employees to permit entrance of persons other than Contractor employees engaged in the performance of assigned work in those areas, or personnel authorized entrance by the KO. The Contractor shall establish and implement methods of ensuring that all lock combinations are not revealed to unauthorized persons.

1.3.2 Anti-Terrorism (AT) and Operations Security (OPSEC):

The following sections provide applicable AT / OPSEC requirements, unless otherwise noted.

1.3.2.1 AT Level I Training

All Contractor employees, to include subcontractor employees, requiring access to Army Installations, facilities, and controlled access areas shall complete AT Level I Training within 14 days after contract start date. Employees hired after contract start date have 14 days from hire date to complete the training. The Contractor shall submit certificates of completion for each affected Contractor employee and subcontractor employee to the COR within 14 days after completion of training by all employees and subcontractor personnel. AT Level I Training is available at the following website: CAC Holders; Error! Hyperlink reference not valid. NON-CAC Holders; Error! Hyperlink reference not valid..

1.3.2.2 Access and General Protection / Security Policy and Procedures

Contractor and all associated sub-contractor employees shall comply with applicable installation, facility, and area commander Installation/facility access and local security policies and procedures (provided by Government representative). The Contractor shall also provide all information required for background checks to meet Installation access requirements to be accomplished by Director of Emergency Services (DES), and/or Security Office (SO). Contractor workforce must comply with all personal identity verification requirements (FAR Clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DoD, Headquarters Department of the Army (HQDA), and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON at any individual facility or Installation change, the Government may require changes in

SECTION 01 14 00 Page 4

Contractor security matters or processes.

1.3.2.2.1 Contractors requiring Common Access Card (CAC)

NOT USED

1.3.2.2.2 Contractors that do not require CAC, Contractors that do not require CAC, but require access to a DoD facility or installation. The Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

1.3.2.2.3 iWatch Training

The Contractor and all associated sub-contractors shall brief all employees on the local iWatch program (training standards provided by the requiring activity Anti-terrorism Officer (ATO)). This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. This training shall be completed within 14 days of contract award and within 14 days of new employees commencing performance on this contract. Results shall be reported to the COR NLT 14 days after completion of the training required as stated above.

1.3.2.2.4 Contractor Employees Who Require Access to Government Information Systems (IS).

All Contractor employees with access to a Government information system must be registered in the Army Training Certification Tracking System (ATCTS) at the commencement of services, and must successfully complete the DoD Information Assurance Awareness training. prior to access to the information systems and annually thereafter.

1.3.3 OPSEC Standing Operating Procedure (SOP) / Plan

The Contractor shall develop an OPSEC SOP/Plan and submit for review and approval to the Government prior to end of the Phase-In period per Army Regulation (AR) 530-1 Operations Security. In addition, the Contractor shall identify an individual who shall be an OPSEC Coordinator. The Contractor shall ensure this individual becomes OPSEC Level II certified per AR 530-1 NLT the end of the Phase-In period.

1.3.4 OPSEC Training

All contractor employees shall complete Level I OPSEC training per AR 530-1 within 30 days of the approved OPSEC SOP/Plan. Thereafter, new Contractor employees must complete Level I OPSEC training within 30 days of their reporting for duty. All Contractor employees must complete annual OPSEC training. The Contractor shall submit certificates of completion for each affected Contractor employee and subcontractor employee to the COR within 14 days after completion of training.

SECTION 01 14 00 Page 5

1.3.5 Contractor Access to DPG

Access to DPG requires that Contractor employees voluntarily submit personal data (e.g. Name, Driver License Number, Date of birth, Active CAC; Y or N, Email address, Company Name, and Citizenship) when applying for a DPG Identification Card. When applying for a Temporary Access Pass (contractor shall submit the personal data a minimum of 72 hours in advance) the following personal data is required (same as above plus date of arrival, date of departure, reason for visit, and areas to be visited). This information is routinely used by DPG Law Enforcement and Security personnel to conduct driver's license and criminal history/background checks. Adverse information revealed by such checks (e.g. outstanding criminal warrants, criminal history indicating a potential risk to DPG Installation security, or similar negative information indicating a potential security and/or law enforcement risk to DPG) may result in denial of access and/or re-entry to DPG. Delays caused by any adverse employee information do not constitute a basis for claim by the Contractor. It is the Contractor's responsibility to assure all personnel scheduled to work on the installation have acceptable backgrounds.

1.3.5.1 Personnel Security

The Contractor shall appoint a Facility Security Officer (FSO). The FSO shall provide employees with training required by DoD 5220.22-M Industrial Security Manual, DoD 5220.22-R, Army security directives and local security directives. Some of the work required by this contract may require access to restricted areas. Occasional delays in obtaining authorization for access to these areas or escort to a work site may be anticipated. The Contractor's personnel requiring unescorted entry to restricted or other sensitive areas designated by the Installation Commander shall comply with AR 25-2 and AR 380-67 Personnel Security Program.

The Contractor shall request from the Defense Industrial Security Clearance Office (DISCO), P.O. Box 2499, Columbus, OH 43216-5006, and security clearances (e.g., locksmiths, alarm technicians) for personnel requiring access to classified information within 15 days after contract award. The Contractor shall provide the security information to the DPG Intelligence Office prior to the end of the phase-in period and when any changes occur during the term of the contract.

The Counter Intelligence Office (CIO) processes National Agency Checks (NAC) for Contractor employees who require access to restricted areas or have access to sensitive information or equipment. The Contractor shall request a waiver through the servicing CIO to process employees for an NAC that requires access to restricted areas and who do not already have a security background investigation. In DPG cleared facilities, Performing Activities shall comply with the National Industrial Security Program (NISPOM) controlled area requirements. The CIO shall approve the establishment, the construction, and the modification of all designated controlled areas before they may be used for the storage of classified materials.

1.3.5.1.1 Security Badge Requirements

The Contractor is responsible for security badges issued to their employees and/or employees of their subcontractors. A designated

SECTION 01 14 00 Page 6 representative (being an officer or supervisor of the Contractor) shall co-sign for each individual when obtaining the required item(s).

Additionally, the Contractor shall provide to the KO a list of employees needing badges under the awarded contract prior to initiation of work.

The Contractor shall submit, to the KO with his monthly billing, a "certificate of return for all badges from the cognizant office(s) before approval for payment will be considered.

The cost for lost items will be deducted from the Contractor's monthly billing (during the month of discovery) for item(s) not returned or lost, or the Contractor will be billed in cases where the replacement cost of lost items exceeds the amount due the Contractor. The Contractor shall be required to have security badges issued to their personnel by DPG Visitor Control Center Bldg. 5910. DPG IDs shall be visible at all times while West of Access Control Point 2. The Government will be responsible for the issuance of security badges required by DoD 5220.22-R Industrial Security Regulation. Additionally, all Contractor employees shall obtain and maintain a Government issued Common Access Card.

1.3.6 Entry Procedures to Controlled / Restricted Areas

The Contractor shall coordinate with Range Control at phone number 435-831-5141 for access to DPG Range Areas. If contractor needs access to Buildings 4153, 4156, 4165, and 8027 it shall be initiated via use of the phone located at the turnstile at each buildings entry location. The Contractors personnel requiring unescorted entry to restricted or other sensitive areas designated by the Installation Commander shall comply with AR 380-67 and AR 25-2.

1.3.7 Contractor Sponsored Foreign Nationals

All foreign national personnel (including guests) that need access past Access Control Point 2 will require a DPG affiliated U.S. citizen escort.

If a sensitive…