A07.01_SF1442__MOTCO_19R0078_B606_Substation_&_Switchgear.pdf.pdf

W62N6M90948838

Project Title: MOTCO Building 606 Electrical Substation & Sw itchgear Upgrade

Military Ocean Terminal at Concord, CA (MOTCO) is undergoing modernization and is looking to upgrade the electrical infrastructure. This project w ill upgrade the existing substation to accommodate future loads at MOTCO. The existing transformer shall be demolished and replaced w ith a new larger capacity transformer to accommodate the maximum future electrical load at MOTCO. Upgrade the existing sw itchgear by modifying it or replacing it to provide tw o circuits. Demolish the existing primary 4-point 15 KV junctions in the manhole and replace w ith an above grade 6-point junction cabinet to feed all the existing loads other than the Tidal circuit. Provide all necessary modif ications to manhole and underground conduits required to accomplish moving the loads to the new above grade junction cabinet.

In accordance w ith FAR 36.204(f) the Disclosure of Magnitude of this project is betw een $1M and $5M.

This solicitation w ill proceed as a small business set-aside.

DEANNA C ZEMOVICH 916-557-7027

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

07-Aug-2019

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________450 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________3 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________06 Sep 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CORPS OF ENGINEERS, SACRAMENTO

CONTRACTING DIVISION

1325 J STREET

SACRAMENTO CA 95814-2922

W91238

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W9123819R0078 45

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W9123819R0078

Section 00 01 10 - Table of Contents

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 01 Price Schedule 2 Attachment 02 MOTCO B606 Substation

Drawings

Attachment 03 Specifications 616 15-APR-2019 Attachment 04 DB Wage Determination 122 26-JUL-2019 Attachment 05 Pre-Award Survey 3 Attachment 06 Past Performance

Questionnaire

Attachment 07 Site Visit Instructions 2

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Upgrade Transformer and Switchgear

FFP

B606 Substation Upgrade Transformer & Switchgear FOB: Destination

PURCHASE REQUEST NUMBER: W62N6M90948838

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job Repair Existing Inland Service Switch

FFP

Repairs to Existing Inland Service Switch

PURCHASE REQUEST NUMBER: W62N6M90948838

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 450 dys. ANP 1 MOTCO RESIDENT OFFICE

CHELAN SCHREIFELS

410 NORMAN AVENUE, BLDG 901

CONCORD CA 94520

916-557-6684

W91238

0002 450 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

W91238

Section 00 21 00 - Instructions

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.236-28 Preparation of Proposals--Construction OCT 1997 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.215-7008 Only One Offer OCT 2013

CLAUSES INCORPORATED BY FULL TEXT

52.215-1 INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2017)

(a) Definitions. As used in this provision--

“Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal.

“In writing or written” means any worded or numbered expression which can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

“Proposal modification” is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

“Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

“Time”, if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals. (1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror.

Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show--

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, or revision, of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications, or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall--

(1) Mark the title page with the following legend: This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed--in whole or in part--for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of--or in connection with-- the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend: Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award.

(1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government's interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government's best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm, fixed-price contract resulting from this solicitation.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

U.S. Army Corps of Engineers, Sacramento District ATTN: Construction Contracting Officer, DeAnna Mannel, Room 878 1325 J Street Sacramento, CA 95814-2922

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- August 22, 2019 at 13:00 Local time.

(c) Participants will meet at-- See site visit instructions Atch 7, and additional site visit information.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

NONE

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Department of Defense FAR Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

http://farsite.hill.af.mil/

Section 00 21 16 - Instructions to Proposers

INSTRUCTIONS, CONDITIONS

INSTRUCTIONS, CONDITIONS & NOTICES TO OFFERORS SUBMITTAL INFORMATION FOR

OFFERORS (RFPS):

The following documents must be returned with your quote, bid, or offer.

--The completed Standard Form 1442 with continuation pages, duly executed with an original signature by an official authorized to bind the company. Ensure that the firm’s DUNS or DUNS+4 Number is entered in the block with its name and address.

--Your acknowledgement of any and all Amendments to the solicitation in accordance with the instructions on the Standard Form 30 Amendment.

Note: If the SF 1442 and/or the pricing schedule was changed by amendment, be sure to use the amended pages when submitting your quote, bid, or offer.

--The completed CLIN Bid Schedule with your proposed contract line item prices inserted in the appropriate spaces. Prices must be proposed for all contract line items and priced sub-line items. Unit prices are to be extended to the actual “dollar and cents” amounts (i.e., to two decimal places). Do not round off extended prices to the nearest dollar. Check your pricing submission very carefully for mathematical and clerical errors prior to submission.

--Your completed Representations, Certifications, and Other Statements of Bidders/Offerors (Section 00 45 00).

--Your Offer Guarantee (e.g., Standard Form 24, “Bid Bond”)

DIRECTIONS FOR SUBMITTING OFFERS:

Proposals must be submitted by land mail or air courier to the address below. Hard copy submissions need to include four (4) copies of the Technical Proposal (One original and three copies) and one (1) original hard copy Price Proposal and be accompanied by a compact disk of both proposals in CD format. The hard copies and CD proposals must be received by the date and time listed in block 13(A) of the SF1442.

Envelopes/packages containing offers must be sealed, marked and addressed as follows:

MARK ENVELOPES/PACKAGES: Solicitation Number: W9123819R0078

ADDRESS ENVELOPES/PACKAGES TO:

U..S. Army Corps of Engineers Sacramento Contracting Division ATTN: Deanna C. Zemovich 1325 J Street, Suite 878 Sacramento, CA 95814-2922

SPECIAL INSTRUCTION PERTAINING TO HAND-CARRIED OFFERS:

Hand-carried offers must be delivered to: The Building Lobby at 1325 J Street, CA. Have Security call the Contract Specialist, Deanna C. Zemovich, at 916-557-7027 or Procurement Technician at 916-557-5226.

Due to security precautions, offerors may no longer hand-carry their offers directly to Contracting Division. Offers may NOT be turned-in at the Security Desk or left unattended elsewhere in the Lobby. Additionally, offers are advised that there is no public parking in the Building.

PROPOSAL SUBMISSIONS:

The preferred method for assembling proposals is a method that enables the rapid insertio or deletion of pages such as three ring binders. Ensure recommended capacity is not exceeded and that pages turn freely. Do not use spring clamps, spiral binding systems, or heat binding systems.

Do not include exceptions to the terms and conditions of the solicitation in either the technical or bid price submissions. Inclusion of any standard company terms and conditions that conflict with the terms and conditions of the solicitation may result in a determination that the proposal/bid is unacceptable and thus ineligible for award.

Resolve questions about the terms and conditions or technical requirements of the solicitation prior to submission of the proposal/bid; see “Inquiries”, located in this Section 00 21 16, for points of contact. Notwithstanding the above, the bidder must clearly describe in the proposal cover sheet submitted with the bid price submission, any exceptions, within the proposal/bid, to the contractual and/or technical terms and conditions of the solicitation.

CONTRACTOR RESPONSIBILITY, PREAWARD SURVEY:

In order to determine a contractor's responsibility for purposes of contract award in accordance with FAR Part 9, the contractor is required to provide a statement regarding previous experience and past performance in performing comparable work, information related to the business organization, financial resources, and/or plant to be used in performing the work (see Attachments, Pre-award Survey). All offerors will complete and return the Preaward Survey as part of the Price/Cost proposal. Failure to submit the Pre-award Survey in conjunction with the price proposal will not of itself render the offer unacceptable. In order to be determined to be responsible a prospective contractor must be determined responsible in accordance with FAR 9.104-1. In section IV of the Pre-award Survey, list most recent projects at or above $900,000.00.

The Pre-award Survey as a tool used by the Government in determining responsibility of the offeror is submitted as part of the Price/Cost proposal and is separate from the technical proposal's response to the technical evaluation criteria found later in this section. Some of the information required from the offeror for completion of the Preaward Survey and the technical proposal may be duplicative but it is necessary that the information be provided in full in both places and that the Price/Cost proposal and the Technical proposal be separate documents. DO NOT state, for example, in the technical proposal, "See Price/Cost proposal for past performance information".

AVAILABILITY OF CORPS OF ENGINEERS PUBLICATIONS DESCRIPTIONS:

a. The internet URL for Corps of Engineers publications is:

http://www.publications.usace.army.mil/

b. Construction Criteria Base (CCB). The Construction Criteria Base (CCB) system available through the National Institute of Building Sciences includes copies of Corps of Engineers methods and specifications. Information about the CCB can be obtained from:

http://www.wbdg.org/ccb/ccb.php

PERFORMANCE AND PAYMENT BONDS:

The bidder/offeror whose bid/offer is accepted will, within the time established in the contract, furnish performance and payment bonds in accordance with FAR 52.228-15.

ACCEPTANCE OF OFFERS:

A written award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party.

System for Award Management (SAM) Registration:

http://www.publications.usace.army.mil/ http://www.wbdg.org/ccb/ccb.php

It is a requirement that any and all contractors that intend to do business with the government must be registered in the System for Award Management (SAM) database. No contract may be awarded by the government to any contractor who is not registered in SAM. If your company is not registered in SAM, you must register in order to be eligible for any government award.

The following link provides access to the SAM website: https://www.sam.gov/portal/public/SAM/ If you have difficulties with or questions regarding the SAM registration, the following link has been set up by the Defense Logistics Agency (DLA) to assist contractors registering for CAGE codes for enrollment and navigation within SAM:

https://www.logisticsinformationservice.dla.mil/CAGETier3/

BASIS OF AWARD:

The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror’s initial proposal should contain the offeror’s best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

INQUIRIES:

Prospective offerors should submit inquiries related to this solicitation in accordance with the following (collect calls will not be accepted):

a. For information related to amendments, and the dates set for receipt of proposals, please check http://www.fedbizopps.gov

b. Contractual and Technical inquiries and questions relating to proposal procedures are to be submitted via Bidder Inquiry in ProjNet at https://www.projnet.org/projnet.

1. To submit and review bid inquiry items, offerors will need to be a current registered user or self-register into the system. To self-register go to the aforementioned web page and click on the QUICK ADD link. Select agency as USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your e-mail address, and then click continue. Fill in all required information and click Add User.

2. From this page you may view all bidder inquiries or add an inquiry.

3. Bidders will receive an acknowledgement of their question via e-mail, followed by an answer to their question after it has been processed.

4. The Solicitation Number is: W9123819R0078

The Bidder Inquiry Key is: 8JXBMB-V9SRK2

c. The Bidder Inquiry System will be unavailable for new inquiries 10 days prior to proposal submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation, if necessary.

d. Offerors are requested to review the specification in its entirety, and review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

e. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

f. Offers will NOT be publicly opened. Information concerning the status of the evaluation and/or award will NOT be available after receipt of proposals.

g. The point of contact for this solicitation is:

http://www.sam.gov/portal/public/SAM/ http://www.sam.gov/portal/public/SAM/ http://www.logisticsinformationservice.dla.mil/CAGETier3/ http://www.logisticsinformationservice.dla.mil/CAGETier3/ http://www.fedbizopps.gov/ http://www.projnet.org/projnet http://www.projnet.org/projnet http://www.projnet.org/projnet

Contract Specialist: Deanna C. Zemovich, Contract Specialist Telephone: (916) 557-7027 E-MAIL: Deanna.C.Zemovich@usace.army.mil mailto:Deanna.C.Zemovich@usace.army.mil

Section 00 22 00 - Supplementary Instructions

SUPPLEMENTAL INSTRUCTIONS

INSTRUCTIONS TO OFFERORS

1. OVERVIEW

This is a "Best Value" solicitation for the construction of MOTCO B606 Electrical Substation Upgrade. The Contracting Officer will award a firm fixed-price contract to that responsible Offeror whom the Source Selection Authority determined conforms to the solicitation, is fair and reasonable, and offers the best overall value to the Government, considering all non-price factors described herein, and price.

2. BASIS OF AWARD

2.1 ELIGIBILITY FOR CONTRACT AWARD

In accordance with the requirements of Part 9 of the Federal Acquisition Regulation (FAR), no contract shall be entered into unless the Contracting Officer ensures that all requirements of law, executive orders, regulations, and all other applicable procedures, including clearances and approvals, have been met. This includes the FAR requirement that no award shall be made unless the Contracting Officer makes an affirmative determination of responsibility. To be determined responsible, a prospective contractor must meet the general standards in FAR Part 9 and any special standards set forth in the solicitation.

2.2 SOURCE SELECTION USING THE LOWEST PRICE

TECHNICALLY ACCEPTABLE(LPTA) PROCESS

Lowest Price Technically Acceptable is a process used in competitive negotiated contracting where the best value is expected to result from selection of the technically acceptable proposal with the lowest evaluated price. See FAR 15.101-2.

a. After the due date/time for receipt of proposals, the Government will open proposals to identify the lowest priced offer.

b. Beginning with the lowest priced offer, the Government will evaluate the offeror’s technical proposal against the evaluation criteria contained herein in order to determine the proposal’s technical acceptability.

c. This process will continue until a technically acceptable proposal is identified. Once a technically acceptable proposal is identified, proposal evaluation will cease; and the Government will proceed to evaluate the technical acceptable offeror’s price proposal and upon the contracting officer’s affirmative determination of responsibility, the Government will proceed to award the contract.

2.3 EVALUATION OF THE PRICE PROPOSAL

a. Price will be evaluated and considered but will not be scored or combined with other aspects of the proposal evaluation. The proposed price will be analyzed for reasonableness. Additionally, to the extent proposal evaluation is necessary, offers will be analyzed for unbalanced pricing.

b. Information required to be submitted in the Price Proposal volume in addition to the executed SF 1442 with acknowledgement of amendments and the completed CLIN schedule will be used to determine the offeror’s eligibility for contract award in accordance with paragraph 2.1 above. The Government may enter into exchanges with offerors about such information without it constituting discussions, subject to applicable FAR limitations, including FAR 15.306, Exchanges with offerors after receipt of proposals.

2.4 TECHNICAL EVALUATION FACTORS

The evaluation factors correlate directly to the main organizational tabs identified in the proposal submission instructions.

Technical Proposal

1) Factor 1: Experience and Capability

2) Factor 2: Past Performance

2.5 GENERAL TECHNICAL EVALUATION CRITERIA

a. This Solicitation sets forth requirements for the proposals which include certain submissions and formatting. The offeror’s conformance with the specified format and submission requirements will be considered during the technical evaluation. Failure to comply with the formatting and/or submission requirements may support a contracting officer’s decision to reject a non-conforming proposal. However, in accordance with FAR 52.215-1, the Government may waive informalities and minor irregularities in proposals within reasonable discretion.

b. Technical proposals which do not provide the specified information in the specified location in accordance with the submission instructions may be considered Unacceptable. An offeror has the obligation to affirmatively demonstrate that its proposal will meet the Government’s needs, where required to do so. The Government is under no obligation to search for information that is not in the specified location.

c. The Government cannot make award based on a deficient offer. Therefore, a rating of

“Unacceptable” under any factor will render the proposal ineligible for award, unless the Government elects to enter into discussions with that offeror and all deficiencies are remedied in a revised proposal.

d. Teaming agreements are required if example projects were completed by other-than- the-prime offeror on the instant procurement (e.g., Subcontractor, JV Partner, etc.) in order to meet the technically acceptable standard for experience and capability. Accordingly, to the extent that a teaming agreement is necessary to meet the standard for Technically Acceptable for Factor 1 (Experience and Capability), as a basis for award, the awardee shall maintain the team until contract completion unless otherwise stated in writing by the contracting officer.

3 GENERAL SUBMISSION REQUIREMENTS AND INSTRUCTIONS.

3.1 GENERAL INSTRUCTIONS.

3.1.1 Media, Page Size, Margins, Fonts, and Page Limitations.

Submit only the hard-copy paper documents and electronic files specifically authorized elsewhere in this section. Do not submit excess information, to include audio-visual materials, electronic media, etc. Do not include links to information on websites in lieu of incorporating the information physically into the proposal. Except where another size is specifically authorized for a specific submission, use only 8 1/2” x 11” paper. Use at least 1 inch margins, which may include headers and footers. Do not justify the right margin. Ensure that all text and graphics are clearly legible. Do not use a font size smaller than 10, unusual font styles such as script, or condensed fonts. For submissions with page limitations, the pages will be counted as follows: One side of the paper is one page;

information on both the back and front of one sheet of paper will be counted as two pages. Where authorized, a foldout sheet will count as one page. Pages furnished for organizational purposes only, such as a “Table of Contents” or divider tabs, are excluded from page limitations.

3.1.2 Proposal Binding.

The preferred method for assembling proposals is a method that enables the rapid insertion or deletion of pages such as three ring binders. Ensure recommended capacity is not exceeded and that pages turn freely. Do not use spring clamps, spiral binding systems, or heat binding systems.

3.1.3 Conditioning of Offer.

Do not include exceptions to the terms and conditions of the solicitation in either the technical or price proposal volumes. Inclusion of any standard company terms and conditions that conflict with the terms and conditions of the solicitation may result in a determination that the offer is unacceptable and thus ineligible for award. Resolve questions about the terms and conditions or technical requirements of the solicitation prior to submission of the offer; see “Inquiries”, located in Section 00 21 16, for points of contact. Notwithstanding the above, the offeror must clearly describe in the proposal cover sheet submitted with the volume any exceptions, within the offer, to the contractual and/or technical terms and conditions of the solicitation.

3.1.4 Restrictions on Offeror-Provided Information.

“Confidential” projects cannot be submitted to demonstrate capability unless all of the information required for evaluation as specified herein can nonetheless be provided to the Government as part of the offeror’s technical proposal. Offerors that include in their proposals information that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, must clearly mark the information in accordance with FAR 52.215-1, “Instructions to Offeror – Competitive Acquisition”, paragraph (e), “Restriction on disclosure and use of data”. Files shall not contain classified data.

3.2 REQUIREMENT FOR SEPARATE PRICE AND TECHNICAL PROPOSAL VOLUMES.

Each offeror must submit both a “price proposal” volume and a “technical proposal” volume. The price proposal includes the signed offer and the offeror’s proposed prices. The technical proposal includes all required information relating to the “non-cost” evaluation factors. The two volumes must be submitted as separate, physically distinct volumes. Both volumes must be received at the location shown in Block 8 of Standard Form 1442, not later than the date and time specified in Block 13 of Standard Form 1442. The information in the two volumes is evaluated separately and independently. Therefore, all information intended by the offeror to be evaluated as part of the price proposal must be submitted as part of the price proposal. All information intended by the offeror to be evaluated as part of the technical proposal must be submitted as part of the technical proposal. Do not merely cross-reference similar material between the technical and price proposals. Information in the price proposal will not be considered in the technical evaluation, and vice versa.

3.2.1 Marking of Proposal Volumes.

Mark each volume as either the “Price Proposal” or the “Technical Proposal”. Additionally, mark the outside front cover of each volume with the project title and location, solicitation number, name and address of the offeror, and volume copy number. (Markings which identify the offeror are not required on either the back cover or on the spine/binding.)

3.2.2 Tabbing of Proposal Volumes.

Offers are to be formatted and tabbed in accordance with the instructions that follow for each proposal volume.

3.2.3 Table of Contents.

Include a table of contents for each proposal volume.

4 PRICE PROPOSAL VOLUME.

4.1 NUMBER OF SETS OF THE PRICE PROPOSAL.

Submit the original (hard copy) of the price proposal volume. Also, submit an electronic copy on a Compact Disc (CD) in PDF.

4.2 FORMAT, CONTENTS, AND LIST OF TABS FOR THE PRICE PROPOSAL.

There are no page limits for the price proposal; however, limit responses to required information. Excess information will not be evaluated. Organize your price proposal as indicated below.

TAB CONTENTS OF THE PRICE PROPOSAL

1. Proposal Cover Sheet

2. SF 1442; Acknowledgement of Amendments; (Joint Venture Agreement (if applicable))

3. CLIN Schedule

4. Representations and Certifications

5. Offer Guarantee

6. Pre-Award Survey Information

4.3 DETAILED SUBMISSION REQUIREMENTS FOR THE

PRICE PROPOSAL. Tab 1 of the Price Proposal:

Proposal Cover Sheet.

The proposal cover sheet is required by FAR 52.215-1 (c)(2). This provision, titled “Instructions to Offerors – Competitive Acquisition” is provided in full text in Section 00 21 00. The format and content for the proposal cover sheet follows:

PROPOSAL COVER SHEET

1. Solicitation Number:

2. The name, address, DUNS number, telephone numbers and email addresses of the offeror.

3. A statement specifying the extent of agreement with all terms, conditions, and provisions included in the Solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item.

4. Names, titles, email addresses, and telephone numbers of persons authorized to negotiate on the offeror’s behalf with the Government in connection with this solicitation:

5. Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent’s authority.

(End of Proposal Cover Sheet)

Tab 2 of the Price Proposal: SF 1442; Acknowledgement of Amendments; Joint Venture Agreement.

The Standard Form (SF) 1442 must be completed by the offeror and duly executed with an original signature by the official(s) identified in the proposal cover sheet as authorized to bind the offeror in accordance with FAR 4.102, which includes specific instructions pertaining to individuals, partnerships, corporations, Joint Venture participants, and agents. Include the offeror’s DUNS number in block 14 of the SF 1442, along with the offeror’s address. All amendments must be acknowledged in accordance with the instructions on the Standard Form 30, Amendment. If the offeror is a Joint Venture (JV), include a copy of the JV agreement and indicate its status. (Note: It is preferred, but not requiredthat you use a document protector in lieu of punching holes in the

SF1442.)

Tab 3 of the Price Proposal: CLIN Schedule.

Submit the completed CLIN Schedule with the offeror’s proposed contract prices inserted in the appropriate spaces. Prices must be proposed for all contract line items. Unit prices must be extended to the actual “dollar and cents” amounts (i.e., to two decimal places). Do not round off the extended prices to the nearest dollar. Check your pricing submission very carefully for mathematical and clerical errors prior to submission. Any qualification or caveat of pricing may render the proposal unacceptable and therefore not eligible for award. (Note: It is preferred, but not required, that you use a document protector in lieu of punching holes in the completed “original” CLIN schedule.)

Tab 4 of the Price Proposal: Representations and Certifications.

The offeror must have electronically completed the annual representations and certifications on the System for Award Management (SAM) website in accordance with FAR 52.204-8. The offeror is responsible for ensuring that these on-line Representations and Certifications are updated as necessary to reflect changes, but at least annually to ensure that they are kept current, accurate and complete. Additionally, the offeror must also complete and return the “Representations, Certifications, and Other Statements of Offerors” included in Section 00 45 00 of the solicitation.

Tab 5 of the Price Proposal: Offer Guarantee.

All offerors must submit an Offer guarantee (e.g., Standard Form 24, Bid Bond) which complies with the requirements of FAR 28.101 Bid Guarantees, and any Defense and Army supplements thereto.

Tab 6 of the Price Proposal: Pre-Award Survey Information.

a. The Contracting Officer is required to make an affirmative pre-award determination of the prospective contractor’s responsibility in accordance with the mandatory requirements of Part 9 of the Federal Acquisition Regulation (FAR) and its supplements. The Contracting Officer must have sufficient information available to determine that a prospective contractor meets these minimum standards. Therefore, the offeror is requested to provide the pre-award survey information described below with its price proposal:

(1) The completed Construction Contractor Data Form with Supplemental Schedules A-C (see format which follows). If the offeror is a large multi-segmented business concerns, the data provided on the supplemental schedules may be limited to information that directly pertains to the specific segment of the business concern (e.g., the division, group, unit, etc.) proposed to perform work under the prospective contract with its own work force. If the offer is being submitted by a Joint Venture, submit a separate form for each Joint Venture participant. The offeror may submit pre-award survey information in another format, provided that the information furnished is substantially the same as that which would be furnished on the Construction Contractor Data Form and its supplemental schedules.

(2) Current financial statements. If the financial statement is more than 60 days old, submit a certificate stating that the firm's financial condition is substantially the same, or, if not the same, state the changes that have taken place. If a Joint Venture, provide this information for each participant in the Joint Venture.

(3) Banking information. Provide letters from banks or other financial institutions with which the contractor conducts business. The letters should contain information about your firm's accounts, loans, lines of credit, etc. The Government is interested in financial stability, timely payments, the length and nature of the relationship between the firm and the financial institution, and the firm's financial ability to perform the contract. The letters should also provide the name and telephone number of the bank representative the Government may contact. If a Joint Venture, provide this information for each Joint Venture participant.

b. The Government will treat the pre-award survey information submitted by the offeror as proprietary. See Table of

Contents for Attachment.

5 TECHNICAL PROPOSAL VOLUME

5.1 NUMBER OF SETS OF THE TECHNICAL PROPOSAL

The Technical Proposal is to be submitted in one original (hard copy) and three copies.