Atch_1_SOW_MOTCO_Repairs_to_Bridges_T-1,_T-2,_T-5_and_T-6.pdf

Attachment 1 June 6, 2018

STATEMENT OF WORK

Repairs to Bridges T-1, T-2, T-5 and T-6 Military Ocean Terminal, Concord, CA

1. SUMMARY

The objective of this Contract is to repair bridges T-1, T-2, T-5 and T-6 at Military Ocean Terminal, Concord, California, as described in this Solicitation (RFP) and to meet the operational requirements of the Army. The total period of performance is up to 365 calendar days.

Options 7 and 8 are defined in Section 7 below.

Contractor is encouraged to attend the proposal conference and visit the site before submitting their proposal.

2. SCOPE OF WORK

Contractor shall provide all labor, materials, tools and equipment necessary for construction of this project titled Repairs to Bridges T-1, T-2, T-5 and T-6, Military Ocean Terminal, Concord, CA. Work includes repairs to the subject bridges as indicated in this Request for Proposal (RFP).

See project specifications and drawings for more details.

3. SAFETY REQUIREMENTS

In addition to Section 01 35 26 of the specifications, all installation safety regulations shall be followed. Comply with the most current edition of USACE EM 385-1-1, and all applicable federal, state, and local laws, ordinances, criteria, rules and regulations including but not limited to 29 CFR 1910 and 29 CFR 1926.

4. AUTHORITIES STATEMENT

Only a warranted Contracting Officer acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

5. PROJECT SCHEDULE

Overall project construction should be scheduled to take place during regular business hours (Mon-Fri, 0730-1600 except federal holidays).

Contractor shall hold Periodic Schedule Update Meetings and Weekly Progress Meetings in accordance with Specification 01 32 01 PROJECT SCHEDULE.

6. CONTRACTOR MANPOWER REPORTING

Attachment 1 June 6, 2018

The contractor shall report ALL contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract for USACE. The contractor is required to completely fill in all required data fields using the following web address: http://www.ecmra.mil/.

Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year. Contractors may direct questions to the help desk at help desk at: http://www.ecmra.mil.

7. UNSCHEDULED INTERRUPTIONS

Work operations are subject to delay by unscheduled interruptions and contractor personnel may be required to immediately leave the designated work area or be denied access due to security operations. Mission requirements may necessitate suspension or cancellation of custodial operations for a period of 10 days or 45 days, dependent on which delay option in this contract is exercised. All incomplete work shall be rescheduled for completion at a later time and date mutually agreed upon by the ACO, COR, POC, QA personnel, and the Contractor. The Period of Performance will also be adjusted accordingly.

8. SECURITY

Contractor is responsible for maintaining the site and all other Contractor controlled areas in such a manner as to minimize the risk of injury or accident to site personnel or others who may be in the area. Contractor is also responsible for furnishing an identification badge/card to each individual working on the site.

See project specifications for more details regarding security requirements.

9. LIQUIDATED DAMAGES

The liquidated damages for this contract are $2,090 per calendar day for each day of delay.

10. POST-AWARD POINTS OF CONTACT

The Administrative US Army COE POC & ACO will be designated at the time of award. They will be responsible for verifying that the Contractors’ performance and completion of work is in accordance with applicable requirements.

APPENDICES

Appendix 1 – Specifications Appendix 2 – Drawings http://www.ecmra.mil/ http://www.ecmra.mil/