Atch_2_Supplemental_Contract_Requirements_(005).pdf

W91238-17-R-0070 Attachment 4 – Acknowledgement Statement Small Business Set Aside July 10, 2017

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to FAR 52.211-10, Commencement, Prosecution, And Completion of Work. The time duration of performance period is 120 calendar days after Notice to Proceed date.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction.

Liquidated damages for this work is $2,341.00 for each day of delay.

3. Authorities. Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer. The Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision Number: CA170009 05/12/2017 CA9 (Heavy Building), Yuba County, Ca, or its most current modification at the time of award is hereby applicable to work performed under this contract. The most current decisions or their modifications can be found by clicking on hyperlink http://www.wdol.gov/dba.aspx for such information.

5. Time Extensions For Unusually Severe Weather. Refer to FAR 52.249-10, Default (Fixed- Priced Construction). All weather delays will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(20) (16) (14) (08) (05) (03) (02) (02) (02) (05) (13) (21)