Atch 2 Task Order Supplemental Contract Requirements for San Pablo.pdf

Attachment 2 July 8, 2010

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to contract section 00700, page 12, FAR 52.211-10. The performance period for the work stated above shall be 45 calendar days .

2. Liquidated Damages. Refer to contract section 00700, page 13, FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work is $1507.00.00 for each day of delay.

3. Authorities. No person other than the Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision No. CA100029 07/02/2010, or its most current modification at the time of award is hereby applicable to work performed under this task order.

The most current decision or its modification can be found at http://www.wdol.gov/, with input of Contra Costa County and Building as the construction type.

5. Time Extensions For Unusually Severe Weather.

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with CONTRACT CLAUSE, Section 00700, entitled “DEFAULT (FIXED-PRICED CONSTRUCTION)”. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(B) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

TO BE ESTABLISHED FOR EACH TASK ORDER

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Attachment 2 July 8, 2010

OAKLAND AB/RICHMOND

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(06) (05) (05) (04) (01) (00) (00) (00) (01) (02) (05) (06)

(C) Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day.

(ER 415-1-15, 31 OCT 89)