Pricing Breakout.pdf

PRICING BREAKOUT

CLIN 0001 – Attic Insulation in Building 235 1 Job Lump Sum _____________

CLIN 0002 – Attic Insulation R-19 in Buildings: 1 Job Lump Sum _____________ 354, 356, 358, 359, 364, 261, 268, 233, and 267

CLIN 0003 – Attic Insulation R-30 in Buildings: 1 Job Lump Sum _____________ 209, 210, 211, 212, 213, 214, 215, 216, 218, 450, 451, 452, 453, 220, 273, 274, 275, 276, 204, 205, 206, 207, 219, 254, 257, 263, 272, 277, 278, 324, 339, 340, 454, 517, 343, 221, 660, 838, 208, 228, 230, 325, and 518

CLIN 0004 – Insulation in Suspended Ceiling R-11 1 Job Lump Sum _____________ in Building 630

CLIN 0005 – Remove Raccoons 5* each at ________ = _____________

SUB TOTAL BASE PRICE $________________________

(Line Items 0001 thru 0005)

Option Item – 1

CLIN 0006 – Insulation in Suspended Ceiling R-19 1 Job Lump Sum _____________ in Buildings: 631, 632, 633, 634, 635, 636, 637, 619, 621, 623, 610, 848, 616, 617, 830, 834, 422, 418, 420, 824, 0620A, and 627

TOTAL ESTIMATED PRICE $________________________

(Line Items 0001 thru 0006)

* QUANTITY IS AN ESTIMATED AMOUNT. SEE SECTION 00700, FAR 52.211-18, FOR VARIATION IN

ESTIMATED QUANTITY CONTRACT CLAUSE.

The successful bidder/offeror grants the options listed in the Pricing Schedule to the Government. This option may be exercised any time up to 150 days after receipt of Notice to Proceed. Exercise of the option occurs upon mailing of written notice to the Contractor. Exercise will be made by the Contracting

Officer. The price for exercise of the option includes all work and effort associated with the scope of that item. No additional time for contract completion will be allowed when an option is exercised. The given contract completion time was formulated to include time necessary to perform all option work.

52.211-18 Variation in Estimated Quantity (Apr 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

(End of Clause)