A.01.38 - Summary of Work for Norfolk District Project - Bellwood Club.pdf

COE-N - Repair Building 42 DLA 2130170

SECTION 01 11 00.00 50

SUMMARY OF WORK FOR NORFOLK DISTRICT PROJECTS

PART 1 TITLE

1.1 DEFINITIONS

a. Facility: The facility is:

Building 42, Bellwood Club Defense Logistics Agency - Aviation DSCR, Richmond, Virginia

CO: Contracting Officer or his authorized representative.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes the interior renovation and repair of the existing building to include new floor, wall, and ceiling finishes. the restrooms fixtures will be replaced along with the restroom accessories. The scope of work also includes providing a new HVAC System, new plumbing fixtures and new lighting.

All work shall be performed in accordance with NESHAP Asbestos Regulations, 40 CFR 61 subpart M, and OSHA regulations 29 CFR 1910 and 1926.

Building 42, Bellwood Club, is a registered historical building;

therefore, all work to the interior and exterior of the historical building must be performed in a method to maintain the historical accuracy of the building as approved by the historic authorities.

The existing sprinkler system will be replaced and heads shall be adjusted to fit within the center of the new suspended ceiling panels. Sand, prime and paint all wainscoting, wood columns, wood beams, stair rails, windows, doors, wood fireplace surrounds and mantels, and trim unless otherwise noted. The cabinetry in the upstairs kitchenette shall be removed and new cabinetry installed. The exterior front porch shall be modified to bring it back to its original design. The basement door to the north exterior stairs will be removed and the areaway will be infilled. The shingle roof on the historical building shall be removed down to the existing roof deck. All damaged roof deck shall be replaced in kind. A new cricket shall be installed adjacent to the existing chimneys and a new standing seam roof over 30# felt over ice-and-water shield, shall be installed on the historical building. Flashing shall be installed around the existing chimneys and the exterior painted surfaces shall be scraped, primed, and painted. The walls at the scullery and near the first floor fire place shall be removed and rebuilt.

All materials noted on drawings shall be assumed new unless specifically noted as existing (E). All materials noted as existing shall remain unless specifically noted to the removed.

Contractor shall verify all existing dimensions and conditions in the

SECTION 01 11 00.00 50 Page 1 field prior to starting demolition and new work. Contractor shall notify the government if, after demolition, conditions are found which may be damaged or code deviant. Deviations shall be brought to the attention of the government prior to commencing work.

**All kitchen drain piping shall be jet cleaned out to the grease interceptors and a video through the drains provided to confirm the cleanliness and to identify any potential issues.

1.2.2 Location

The work shall be located at the DSCR where shown on the drawings.

1.3 PERSONNEL RESTRICTIONS

Personnel are limited to the immediate site areas and shall not enter buildings or facilities not involved in the work. All employees of the Contractor will be subject to all rules and regulations of the Facility which pertain to personnel. The Contractor shall erect fences and signs as specified and be responsible for the restrictions of all personnel. The Contractor's plans for restricting personnel access to the project site shall be submitted for approval as a part of the Safety Plan (Accident Prevention Plan). Facility access shall be restricted. Contractor shall comply with current security requirements. All vehicles shall be registered with the military police.

1.3.1 Security Requirements Defense Supply Center Richmond (DSCR)

No employee or representative of the Contractor will be admitted to the work site unless he furnishes satisfactory proof that he is a citizen of the United States or has proper identification to work in the United States.

a. Personnel Information - All authorized non-military personnel utilizing the base are required to have in their possession at all times a Base Visitor Pass or Base Identification. This pass is issued by the DSCR Visitors Center located at the North Gate. Proof of identity is required to obtain a visitor pass or Base Identification. The Visitors Center is open Monday through Friday except Federal holidays from 7:00 a.m. to 3:00 p.m. A minimum of 14 working days prior to start of work, the Contractor shall furnish to the Defense Supply Center Richmond (DSCR), Richmond, VA, Security Department, via the Contracting Officer, the following information for Contractor and subcontractor personnel required to enter the Station:

(1) Contract Number

(2) Beginning Date (Month, Day, Year)

(3) Ending Date (Month, Day, Year)

(4) Name of the company (The Prime Contractor and Sub Contractor)

(5) Full Name of the employee (First, Middle and Last)

(6) Address of Current (Employee's) Residence (Bldg#, Street, City, State, Zip or City and Country)

SECTION 01 11 00.00 50 Page 2

(7) Social Security Number (SS#)

(8) US Citizen (Yes / No)

(9) Gender (Male/Female)

(10) Race (American Indian or Alaska Native, Asian, Black or African American, Native Hawaiian or Other Pacific Islander, and White)

(11) Date of Birth (Month, Day, Year)

(12) Place of Birth (City, State, Country)

b. The DSCR Security Department will run a criminal history check on Contractor employees as a condition of employment. Official proof of identity or naturalization papers may be required, which will be returned once entered into the security computer system. Based on the results of the criminal history check, the Security Officer will or will not grant entry to the Station. If entry is denied, the Contractor will be immediately notified. DSCR Security may require updating or rechecking criminal history based on the duration of the contract. NOTE: DSCR Security has been denying entry to persons whose police record checks are positive. Failure to obtain entry approval will not affect the contract price or time of completion.

c. Proof of Identity -Official identification can consist of copies of birth certificates, valid federal identification, valid state identification, or valid naturalization papers. Examples of official identification are valid state issued driver's license, military ID card, military dependent ID card, green card, etc. Expired identification is not valid.

d. Base Entry Passes - Contractor base entry passes will be valid for each entry aboard DSCR from 6:00 a.m. to 6:00 p.m., Monday through Friday except for Federal holidays, unless prior arrangements have been made with the Contracting Officer, and DSCR Security has been notified. The passes are the property of the base and are to be returned to Visitors Control at the North Gate upon completion of the contract or termination of employment. Replacement passes must be requested in writing and be accomplished by written authorization from the Contracting Officer.

Compliance with this requirement is mandatory and certification thereof to the Contracting Officer is required prior to submitting final invoices. Failure to return badges will hold up Contractor's final payment.

e. Contractor Responsibility for Employees - The Contractor is responsible for employees under his employment. Ensure that employees are familiar with and obey station traffic, safety, and security regulations.

f. Unofficial photography, cameras, or photographs are prohibited on DSCR property. When official photographs are required, submit a written approval request containing specific justification and details to the Contracting Officer 5 days prior.

SECTION 01 11 00.00 50 Page 3

g. Firearms, Weapons, Alcoholic Beverages, Illegal Drugs, and Contraband are prohibited on DSCR property. Violators may be prosecuted. State issued/authorized concealed weapons permits are not valid on Federal (DSCR) property.

h. Motor Vehicle Operation - Ingress and egress of personnel will be subject to the DSCR security regulations.

(1) All personnel must be made aware of the base speed limits:

25 mph (unless otherwise posted) Speed limits are enforced and violators will be ticketed. DSCR traffic violations are processed through the federal court system.

(2) Seat belts are MANDATORY.

(3) Parking is in designated areas only, between two white lines. No parking is permitted in fire lanes, on seeded areas, in reserved parking slots, or assigned handicapped parking. Any equipment or vehicle that does not fit within a standard parking space must contact the Contracting Officer to determine a designated area for parking such equipment or vehicle.

Contractor employees shall park vehicles (Commercial or Private) in areas designated by the Contracting Officer. This area may or may not necessarily be within reasonable walking distance of the construction site. The contractor shall provide transportation between the parking area and the construction site. Contractor employee parking shall not interfere with existing and established parking requirements of the Base.

(4) Traffic accidents shall be reported immediately to the DSCR Emergency Dispatch by calling 911 or (804) 279-4888.

(5) All personnel entering the installation are subject to random vehicle inspections/searches at any time while on the base. The purpose of these inspections is to detect the theft of Government and private property, firearms, weapons, alcoholic beverages, illegal drugs, or contraband.

(6) Information required for Vehicle Passes- Driver's are required to bring the vehicle, contract number, vehicle registration, copy of vehicle insurance policy, valid state inspection documentation, and valid driver's license to the Visitor Control Center at the North Gate. Vehicles without passes will not be allowed entry to base.

i. Commercially Owned Vehicles - All commercial Vehicles are to clearly display the authorized company name or logo on both sides of the vehicle.

ii. Privately Owned Vehicles - No Privately-Owned Vehicles will be allowed within the Defense Distribution Depot, Richmond, VA (DDRV) area or any other secure/controlled industrial area located on DSCR.

iii. Rental Vehicles - The driver is to show all paper work from the rental company showing that the driver is authorized to

SECTION 01 11 00.00 50 Page 4 operate the subject vehicle. Rental vehicles will not be allowed in secure/controlled industrial areas located on DSCR unless the rental vehicle clearly displays the authorized operating company name or logo on both sides of the vehicle.

i. Access to Restricted Areas - Base entry passes allow access to designated areas on the installation only. Entries into secure/controlled industrial areas are prohibited unless the contract requires it.

j. Current Information - Contractors will be responsible for keeping the vehicle and employee lists current, and for securing and returning identification cards belonging to terminated employees to the DSCR Security Department.

k. Providing Information to Subcontractors - Prime Contractors shall be responsible for ensuring that subcontractors receive security information. Failure to comply with the specified requirements will result in prime contractors and subcontractors being denied access to the construction site.

l. DSCR is not responsible for job site security. Removal of material from job-site and base are subject to security checks.

Contractor is to notify DSCR security of any special measures (watchmen, alarm, etc), security concerns, security problems, or unusual activities within the job site.

1.4 TRANSPORTATION FACILITIES

The Facility is served by an all-weather surfaced road network. Road(s) within the Facility proposed to be used by the Contractor shall be subject to prior approval of the Facility authorities and such roads, if used, shall be maintained throughout construction and shall be restored to as good condition as existed prior to their use. The Contractor shall also construct, subject to approval, such temporary haul roads and bridges as may be necessary for conducting his work. Any such temporary construction shall be removed and the affected area restored to its original condition. All costs for the use of existing transportation facilities, for the construction of temporary facilities, and for maintenance, repair, removal and restoration shall be borne by the Contractor.

1.4.1 Use of Roads

Hard-surfaced roads from major and primary municipal roads serve the Facility. The movement of all vehicles within the Facility shall be confined to the roads designated and shall comply with traffic regulations within the Facility. The Contractor shall keep all roads clear of all obstructions and free of mud and other foreign materials resulting from operations. The Contractor's vehicles shall at no time follow a vehicle closer than 50 feet, and all vehicles shall pull off the road and come to a complete stop when meeting emergency vehicles, or vehicles with flashing lights. Facility speed limits and traffic controls shall be observed.

1.4.2 Road Restrictions

The movement of all vehicles within the Facility shall be confined to the roads designated and shall comply with traffic regulations within the Facility. Other roads may be used only with the approval of the CO.

SECTION 01 11 00.00 50 Page 5

1.4.3 Cleated Vehicles

Cleated vehicles shall not be moved over surfaced roads except at the immediate site of the area where they are to be used.

1.5 SPECIAL CONTRACTOR REQUIREMENTS

1.5.1 COORDINATION IN WORK AREAS

1.5.1.1 Occupied Work Area

The area where work is to be accomplished will be occupied during the work. Activities of the occupants of the scheduled work area shall not be interrupted or hampered in any way without prior written approval of the Contracting Officer.

1.5.1.2 Unoccupied Work Area

The area where the Contractor is scheduled to perform the work will not be occupied during the work, however, the Contractors work activities may affect other area(s) that are occupied. All work shall be in accordance with the Contractor's work plan.

1.5.1.3 Maintenance of Utilities

Any active utilities, including but not limited to electricity, gas, water, sewer, heating, air conditioning, or any like service, that will require interruption or replacement in any occupied area affected as a result of the Contractors scheduled work activities, shall be temporarily provided by the Contractor at his own expense until the affected service is fully and permanently restored. All temporary method(s) of service replacement the Contractor proposes for use on this contract shall be approved by the CO prior to commencing the work.

1.5.1.4 Hours of Work

The normal work hours for construction shall be from 8:00 a.m. to 4:30 p.m. Monday through Friday of each week. Any request to change these hours shall be made in writing to the Contracting Officer at least two calendar days prior to the desired day on which the change is to go into effect. The changed hours shall not go into effect until written permission has been received from the Contracting Officer.

1.5.1.5 Existing Utility Location

Existing utilities must be located before doing any digging work on Facility. The Contractor shall be responsible to contact USACE and DSCR through DSCR Chief of Utilities, obtain all necessary existing utility locations, which may be necessary to accomplish his work, and mark any utility lines in the immediate vicinity of his work. It shall be the responsibility of the Contractor to contact USACE and DSCR through DSCR Chief of Utilities for locating commercial utilities 48 hours prior to digging operations. The contractor shall be responsible for maintaining marked utilities

1.5.1.6 Personnel Escort

An authorized Contractor representative must escort all personnel

SECTION 01 11 00.00 50 Page 6 attempting to obtain a badge to Security. The representative shall sign documentation that the employee meets Security criteria and is suitable for a badge to be issued.

1.6 TIME EXTENSION FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled "Default: (Fixed Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

1.6.1 Sub Title

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS

BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV

DEC DSCR 10 9 9 6 8 7 8 7 6 5

7 9

1.6.2 Reports

Upon acknowledgement of the Notice to Proceed and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

1.6.3 Impacted Days

The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in the schedule of monthly anticipated adverse weather delays, above, the contracting officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the Contract Clauses entitled "Default (Fixed Price Construction)".

SECTION 01 11 00.00 50 Page 7

1.7 EXSITING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.8 PHYSICAL DATA

The physical conditions indicated on the drawings and in the specifications are the result of site visits, surveys, and borings. See civil drawings.

1.9 SITE CONTAMINATION

This site is designated a Category II site and is defined as a current or former industrial site or other hazard producing activity site which is perceived to be a clean location; however, due to former industrial or other activities within or near the site, it has the potential for contamination.

1.9.1 Contamination Removal

In the event that contamination beyond that shown or specified is encountered, the Contracting Officer shall be advised immediately. The contamination shall be removed as directed and replaced with satisfactory material. Payment therefore will be made in conformance with the CHANGES clause of the CONTRACT CLAUSES.

1.9.2 Compliance Requirements

The Contractor shall comply with applicable Federal, state and local laws, codes, ordinances and regulations (including the obtaining of licenses and permits) in connection with any hazardous material, substance or waste.

1.9.3 Requirements

The requirements of this clause and any act or failure to act by the Government shall not relieve the Contractor of any responsibility or liability for the safety of Government, Contractor or subcontractor personnel or property.

1.10 INTERRUPTIONS OF UTILITIES

1.10.1 Approval

Utility services shall be interrupted by the Contractor to relocate, make connections, or interrupt for any purpose, without written approval of the

CO.

SECTION 01 11 00.00 50 Page 8

1.10.2 Request

Request for permission to shut down services shall be submitted in writing to the CO not less than 10 calendar days prior to date of proposed interruption. The request shall give the following information:

a. Nature of Utility (Gas, L.P. or H.P., Water, Electrical, Communications, Fire Alarm Systems, Security Systems)

b. Size of line and location of shutoff.

c. Buildings and services affected.

d. Hours and date of shutoff.

e. Estimated length of time service will be interrupted.

1.10.3 Service Interruptions

Services shall not be shut off until receipt of approval of the proposed hours and date from the Contracting Officer.

1.10.4 Timely Disconnections

Shutoffs which will cause interruption of Government work operations as determined by the Contracting Officer shall be accomplished during regular non-work hours or non-work days of the Using Agency without any additional cost to the Government.

1.10.5 Utilities Operation

Operation of valves on water mains will be by Government personnel.

Where shutoff of water lines interrupts service to fire hydrants or fire sprinkler systems, the Facility Fire Department shall be notified by the Contractor in writing 72 hours prior to the proposed interruption. The Contractor shall arrange his operations and have sufficient material and personnel available to complete the work without undue delay and shall restore service without delay in event of emergency.

1.10.6 Gas

Flow in gas mains which have been shut off shall not be restored until the Government inspector has determined that all items serviced by the gas line have been hsut off.

1.11 HISTORICAL AND ARCHAEOLOGICAL FINDS

Federal legislation provides for the protection, preservation, and collection of scientific, prehistoric, historical, and archaeological data, including relics and specimens which might otherwise be lost due to alteration of the terrain or building features as a result of any Federal construction project. Should the Contractor, or any of the Contractor's employees, or parties operating or associated with the Contractor, in the performance of this contract discover evidence of possible scientific, prehistoric, historical, or archaeological data, the Contractor shall immediately cease work at that location, avoid further disturbance, and notify the Contracting Officer, giving the location and nature of the findings. The Contractor shall forward written confirmation to the Contracting Officer as directed. The Contractor shall exercise care so

SECTION 01 11 00.00 50 Page 9 as not to disturb or damage artifacts or fossils uncovered during excavation operations, and shall provide such cooperation and assistance as may be necessary to preserve the findings for removal or other disposition. Any person who, without permission, injures, destroys, excavates, appropriates, or removes any historical or prehistoric artifact, object of antiquity, or archaeological resource on the public lands of the United States is subject to arrest and penalty of law.

Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance or changes in the work, or both.

If such delays or changes are ordered, an equitable adjustment will be made in the contract in accordance with the applicable clauses of the contract.

1.12 SUBCONTRACTS AND WORK COORDINATION

Contract Clauses "SUBCONTRACTS", "PERMITS AND RESPONSIBILITIES", and "MATERIAL AND WORKMANSHIP" are supplemented as follows:

a. Divisions or sections of specifications are not intended to control the Contractor in dividing the work among subcontractor, or to limit work performed by any trade.

b. Contractor shall be responsible for coordination of the work of the trades, subcontractors, and materials.

c. The Government or its representative will not undertake to settle any difference between the Contractor and Contractor's subcontractors, or between subcontractors.

d. The Government reserves the right to refuse to permit employment on the work or require dismissal from the work of any subcontractor who, by reason of previous unsatisfactory work on Corps of Engineers projects, or for any other reason is considered by the Contracting Officer to be incompetent or otherwise objectionable.

1.13 CONSTRUCTION MANPOWER AND EQUIPMENT REPORT

The Contractor shall submit executed CENAO Form 987, Construction Manpower and Equipment Report daily. The report shall include manpower and equipment for the general and subcontractors. Forms are available from the Contracting Officer.

1.14 PURCHASE ORDERS

To ensure proper expediting of orders the Contractor and his subcontractors shall furnish to the Contracting Officer, one copy of each purchase order covering supplies or services required for performance of the work. Each purchase order shall clearly indicate the date of placement, the date delivery is required in order to avoid delay in the scheduled progress of the work, and the date delivery is promised by the supplier or producer.

Copies of purchase orders shall be forwarded on the date issued.

1.15 PROFIT

1.15.1 Weighted Guidelines

Weighted guidelines method of determining profit shall be used on any

SECTION 01 11 00.00 50 Page 10 equitable adjustment change order or modification issued under this contract. The profit factors shall be as follows:

Factor Rate Weight Value Degree of Risk 20 Relative difficulty of work 15 Size of Job 15 Period of performance 15

Factor Contractor's investment Rate Weight Assistance by Government 05 Subcontracting 25

1.15.2 Value

Based on the circumstances of each procurement action, each of the above factors shall be weighted from .03 to .12 as indicated below. The value shall be obtained by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

1.15.2.1 Degree of Risk

Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12. Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider: the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

1.15.2.2 Period of Performance

The period of performance shall be 30 days from the issuance of notice to proceed.

1.16 BLASTING

Blasting will not be permitted.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used.

-- End of Section --

SECTION 01 11 00.00 50 Page 11