AMENDMENT W911XK20B0014 0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

St. Louis River AOC Azcon/DSPA Slip Sediment Remediation.

The purpose for this amendment is to:

1. Delete Option 1 Line Item 11 from the Bid Schedule.

2. Specification - Changed to updated version.

3. Plans/Draw ings - Changed to updated version.

4. Section 00 21 13 - Basis of Selection of Aw ard - Deleted paragraph (b).

5. Section 00 21 13 - Instruction to Bidders- Intent - Revised language.

6. Clause 52.211-10 - Commencement, Prosecution and Completion of Work Alternate I - Deleted language in second paragraph.

7. Clause 52.217-5 - Evaluation of Options is deleted.

Note: Site visit sign-in sheet is available at beta.sam.gov. Reference changes on the follow ing pages. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 25-Jun-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W911XK20B0014

X 9B. DATED (SEE ITEM 11)

10-Jun-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

25-Jun-2020

CODE

U.S.ARMY ENGINEER DISTRICT, DETROIT

477 MICHIGAN AVENUE, 7TH FLOOR

DETROIT MI 48226-4523

W911XK 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911XK20B0014

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0002

1. Bid Schedule Revised:

Deleted - Option 1 – Line Item 11.

Added - New Bid Schedule without Option.

2. Specification Revised:

Deleted – Specification.

Added – Updated Version of Specification.

3. Plans Revised:

Deleted – Plans.

Added – Updated Version of Plans/Drawings.

4. Section 00 21 13 – Instruction to Bidders – Basis of Selection of Award:

Deleted –Paragraph (b) In accordance with FAR Provision 52.217-5, the Government intends to evaluate bids for award purposes by adding the total price to the total price for the basic requirement.

5. Section 00 21 13 – Instruction to Bidders - Intent:

Revised language– The intent of this solicitation is to award one (1) firm fixed-price construction contract for the Howards Bay Remedial Dredging.

Replace with language - The intent of this solicitation is to award one (1) firm fixed-price contract for St.

Louis River AOC Azcon/DSPA Slip Sediment Remediation.

6. Clause 52.211-10 – Commencement, Prosecution and Completion of Work (APR 1984) -

ALTERNATE I (APR 1984):

Deleted - Language in second paragraph (Work associated with any Option work item shall exercise not later than (NLT) 30 calendar days after the contract award; no additional time shall be granted).

7. Clause 52.217-5 – Evaluation of Options (JUL 1919):

Delete – Clause 52.217-5.

SECTION 00 10 00 - SOLICITATION

The following have been modified:

BID SCHEDULE

St. Louis River AOC Azcon/DSPA Slip Sediment Remediation

ITEM SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE TOTAL

0001 Mobilization & Demobilization 1 JOB $___________ $_____________

0002 Turbidity Curtain Installation & 1 JOB $___________ $_____________

Maintenance, Azcon/DSPA Slip

0003 Slip Dredging, Azcon/DSPA Slip 1 JOB $___________ $_____________

0004 Pilot Test, Azcon/DSPA Slip 1 JOB $___________ $_____________

0005 Subaqueous Cap Layer A 1 JOB $___________ $_____________ Construction - Areas A, B, C, D, E Transition Area & Cap Apron Area, Azcon/DSPA Slip

0006 Subaqueous Cap 2-inch Diameter 1 JOB $___________ $_____________ Stone Armor Layer Construction - Areas A, B, C, D, E Transition Area & Cap Apron Area, Azcon/DSPA Slip

0007 Subaqueous Cap 4-inch Diameter 1 JOB $___________ $_____________ Stone Armor Layer Construction - Area C, Azcon/DSPA Slip

0008 Dewatering Sediment, Azcon/DSPA Slip 1 JOB $___________ $_____________

0009 Landfill Disposal of Dewatered 1 JOB $___________ $_____________ Sediment, Azcon/DSPA Slip

0010 Debris Removal and Disposal, 1 JOB $___________ $_____________ Azcon/DSPA Slip

TOTAL AMOUNT OF BID $ ___________________

SECTION 00 21 13 - INSTRUCTIONS TO BIDDERS

The following have been deleted:

52.217-5 Evaluation Of Options JUL 1990

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 October 2020. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 14 August 2020. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)