Amendment_0002_-_W911XK-17-B-0005.pdf

W56MES63517205

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

FY17 Gallow ay Creek Ecosystem Restoration, Rochester Hills, Michigan

The requirements for this solicitation are changed as follow s and as indicated on the follow ing pages:

1. The BID DUE DATE and BID OPENING are hereby changed from August 15, 2017 to August 22, 2017, at 2:00 p.m. Eastern Time.

2. The RFI submittal period is hereby extended to Tuesday, August 15, 2017, at 2:00 p.m.

3. The applicable Construction Wage Determination update for this contract is hereby changed to MI170069 (MI69), Modification 8, dated 07/28/2017.

4. Clauses, Specifications, and Draw ings are hereby changed as indicated on the follow ing pages.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 10-Aug-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W911XK-17-B-0005

X 9B. DATED (SEE ITEM 11)

07-Jul-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

09-Aug-2017

CODE

CONTRACTING BRANCH

USACE DETROIT DISTRICT

477 MICHIGAN AVENUE, 7TH FLOOR

DETROIT MI 48226-4523

W911XK 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911XK-17-B-0005

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The following have been added by full text:

AMENDMENT NO. 0002

The following changes are hereby incorporated into the Solicitation and ensuing contract.

CHANGES TO THE SOLICITATION DOCUMENT

Bid Schedule

ADD:

Item 0004 – Option 1 Vegetation Establishment Period

Section 00700 – Contract Clauses

REPLACE:

Clause 52.211-10, Alternate I, from the orginal solicitation.

WITH:

Revised Clause 52.211-10, Alternate I, as indicated on the following pages. The required completion dates are hereby changed for the Construction and Establishment periods of the contract.

Section 00800 – Special Contract Requirements

REPLACE:

Time Extensions for Unusually Severe Weather requirement from the original solicitation.

WITH:

Revised Time Extensions for Unusually Severe Weather requirement as indicated on the following pages. The work week is hereby changed from a seven-day week to a five-day week, and the number of allowable weather delay dates has been changed for each month.

CHANGES TO THE SPECIFICATIONS

Section 01 14 00 Work Restrictions, Paragraph 1.2.4 Exclusionary Period, First Sentence

REPLACE TEXT:

“February 15, 2017”

WITH TEXT:

“February 15, 2018”

CHANGES TO THE DRAWINGS

Drawing Sheet C009, Table 7, “Spacing” Column Text

REPLACE TEXT:

“TREES ARE SPACED EVERY 25’ – 50’ AT LOCATIONS STAKED IN THE FIELD ON THE SOUTH /

EAST FLOODPLAIN. THE FIRST ROW IS 10’ BACK FROM THE TOP OF BANK (BANKFULL). “

WITH TEXT:

“TREES ARE SPACED EVERY 25’ – 50’ ON THE SOUTH / EAST FLOODPLAIN. THE FIRST ROW IS 10’

BACK FROM THE TOP OF BANK (BANKFULL). “

Drawing Sheets C101, C102, C103, C104 and C104A

DELETE NOTE 2:

“A DIGITAL CADD FILE WITH THE PROPOSED CHANNEL THALWEG ALIGNMENT (TANGENTS,

PCS, PTS, RADIUS OF CURVATURE, ETC.), BANKFULL LIMITS, AND PROPOSED FEATURES (IN-

STREAM STRUCTURES, CULVERTS, OFF-CHANNEL FEATURES, ACCESS ROADS, ETC.) WILL BE

AVAILABLE TO THE CONTRACTOR TO ASSIST WITH PROJECT STAKEOUT.”

Drawing Sheets C310, C311, C312, C313, C314, C315, C316, and C317

REPLACE

Drawings C310, C311, C312, C313, C314, C315, C316, and C317 from the original solicitation

WITH:

Revised Drawings C310, C311, C312, C313, C314, C315, C316, and C317 as provided in attached file, “Revised Drawings C310 through C317 – Amendment 0002.pdf” The graphic bar scales have been revised.

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 15-Aug-2017 02:00 PM to 22-Aug-2017 02:00 PM.

The following have been modified:

BID SCHEDULE

Base Bid

Item Supplies/Services Quantity Unit Line Total

0001 Required Work – Reaches 2 and 3 1 Job $

0002 Vegetation Establishment Period 1 Job $

BASE BID TOTAL (Item 0001 Plus Item 0002) $

Option 1

0003 Reach 4 1 Job $

0004 Option 1 Vegetation Establishment Period 1 Job $

OPTION TOTAL (Item 0003 Plus Item 0004) $

TOTAL BID (Base Plus Option, All Items: 0001, 0002, 0003, and 0004) $

Notes:

1. Pricing shown is United States dollars.

2. Price includes all permits, taxes, and delivery costs as may be applicable.

3. Option 1, if exercised, will not change the contract completion date.

SECTION 00700 - CONTRACT CLAUSES

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within TEN (10) calendar days after the date the Contractor receives the Notice to Proceed, (b) prosecute the work diligently, and (c) complete the work according to the following schedule:

Project Phase Description Completion Date

Initial Construction All work excluding establishment of plantings and vegetation October 31, 2018

Establishment Establishment of plantings and vegetation October 31, 2019

The time stated for completion at each phase shall include cleanup of the premises.

Exercise of available contract(s) option shall not change the required completion date(s).

The completion date is based on the assumption that the successful offeror will receive the Notice to Proceed by August 25, 2017. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

TIME EXTENSIONS FOR WEATHER

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 89)

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with Contract Clause 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION).” In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON FIVE (5) DAY WORK WEEK

JAN

FEB

MAR

APR

MAY

JUN

JUL

AUG

SEP

OCT

NOV

DEC

c. Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC Report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for fifty percent (50%) or more of the contractor’s scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather days exceeds the number of days anticipated in Subparagraph (b) above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the CONTRACT CLAUSE entitled “DEFAULT (FIXED PRICE

CONSTRUCTION)”.

End of Requirement

The following have been added by full text:

WAGE DETERMINATION - AMD 0002

The following Wage Determination applies to the work of this contract.

General Decision Number: MI170069 07/28/2017 MI69

Superseded General Decision Number: MI20160069

State: Michigan

Construction Type: Heavy

County: Oakland County in Michigan.

Heavy, Includes Water, Sewer Lines and Excavation (Excludes Hazardous Waste Removal; Coal, Oil, Gas, Duct and other similar Pipeline Construction)

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.20 for calendar year 2017 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.20 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2017. The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2017 1 02/03/2017 2 02/10/2017 3 04/21/2017 4 06/23/2017 5 06/30/2017 6 07/14/2017 7 07/21/2017 8 07/28/2017

BOIL0169-003 01/01/2016

Rates Fringes

BOILERMAKER......................$ 33.88 30.39

* CARP0687-008 06/01/2017

Rates Fringes

CARPENTER, Includes Form Work....$ 31.86 27.05

PILEDRIVERMAN....................$ 31.86 26.93

ELEC0017-001 06/05/2017

Remainder of County Rates Fringes

LINE CONSTRUCTION:

Linemen/Cable Splicer............$ 38.38 6.10+28.5%

ELEC0058-007 07/03/2016

Rates Fringes

ELECTRICIAN......................$ 38.73 22.05

ELEC0876-003 06/06/2016

Township of Holly Rates Fringes

LINE CONSTRUCTION

Cable Splicer...............$ 41.03 5.25+29% Lineman.....................$ 39.40 5.25+29%

ENGI0325-019 06/01/2016

POWER EQUIPMENT OPERATORS: Underground Construction (Including Sewer)

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 31.58 22.85

GROUP 2.....................$ 26.85 22.85

GROUP 3.....................$ 26.12 22.85

GROUP 4.....................$ 25.55 22.85

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Backhoe/ Excavator, Boring Machine, Bulldozer, Crane, Grader/ Blade, Loader, Roller, Scraper, Trencher (over 8 ft. digging capacity)

GROUP 2: Trencher (8-ft digging capacity and smaller)

GROUP 3: Boom Truck (non-swinging, non- powered type boom)

GROUP 4: Broom/ Sweeper, Fork Truck, Tractor, Bobcat/ Skid Steer /Skid Loader

ENGI0326-008 06/01/2017

EXCLUDES UNDERGROUND CONSTRUCTION

Rates Fringes OPERATOR: Power Equipment

GROUP 1....................$ 39.89 23.40

GROUP 2....................$ 38.39 23.40

GROUP 3....................$ 36.89 23.40

GROUP 4....................$ 36.59 23.40

GROUP 5....................$ 35.77 23.40

GROUP 6....................$ 34.91 23.40

GROUP 7....................$ 33.94 23.40

GROUP 8....................$ 32.23 23.40

GROUP 9....................$ 23.89 23.40

FOOTNOTES: Tower cranes: to be paid the crane operator rate determined by the combined length of the mast and the boom.

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Crane with boom & jib or leads 400' or longer

GROUP 2: Crane with boom & jib or leads 300' or longer

GROUP 3: Crane with boom & jib or leads 220' or longer

GROUP 4: Crane with boom & jib or leads 140' or longer

GROUP 5: Crane with boom & jib or leads 120' or longer

GROUP 6: Regular crane operator

GROUP 7: Backhoe/Excavator, Bobcat/Skid Loader, Boring Machine, Broom/Sweeper, Bulldozer, Grader/Blade, Loader, Roller, Scraper, Tractor, Trencher

GROUP 8: Forklift

GROUP 9: Oiler

IRON0025-006 06/01/2015

Rates Fringes

IRONWORKER

Reinforcing.................$ 28.30 24.60 Structural..................$ 33.78 27.84

LABO0334-009 06/01/2017

EXCLUDES OPEN CUT CONSTRUCTION

Rates Fringes Landscape Laborer

GROUP 1.....................$ 20.32 6.80

GROUP 2.....................$ 18.32 6.80

LANDSCAPE LABORER CLASSIFICATIONS

GROUP 1: Landscape specialist, including air, gas and diesel equipment operator, lawn sprinkler installer and skidsteer (or equivalent)

GROUP 2: Landscape laborer: small power tool operator, material mover, truck driver and lawn sprinkler installer tender

LABO0334-021 09/01/2014

SCOPE OF WORK:

OPEN CUT CONSTRUCTION: Excavation of earth and sewer, utilities, and improvements, including underground piping/conduit (including inspection, cleaning, restoration, and relining)

Rates Fringes

LABORER

(1) Common or General.......$ 21.42 16.28

(2) Mason Tender- Cement/Concrete.............$ 21.53 16.28

(4) Grade Checker...........$ 21.66 16.28

(5) Pipelayer...............$ 21.72 16.28

(7) Landscape...............$ 15.79 16.28

LABO1076-008 06/01/2017

EXCLUDES OPEN CUT CONSTRUCTION

Rates Fringes

LABORER

Common or General; Grade Checker; Mason Tender - Cement/Concrete; Pipelayer..$ 24.35 20.42

PAIN0022-005 07/01/2008

Rates Fringes

PAINTER

Brush & Roller..............$ 25.06 14.75 Spray.......................$ 25.86 14.75

PLAS0067-002 04/01/2014

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 30.63 14.07

PLUM0098-005 06/05/2017

Rates Fringes

PLUMBER..........................$ 39.77 27.32

PLUM0636-002 06/06/2016

Rates Fringes

PIPEFITTER.......................$ 39.91 27.15

* TEAM0007-006 06/01/2017

Rates Fringes

TRUCK DRIVER

Dump Truck under 8 cu.

yds.; Tractor Haul Truck....$ 24.90 .50 + a+b Dump Truck, 8 cu. yds. and over........................$ 25.00 .50 + a+b Lowboy/Semi-Trailer Truck...$ 25.15 .50 + a+b

FOOTNOTE:

a. $455.00 per week.

b. $64.40 daily.

SUMI2010-067 11/09/2010

Rates Fringes TRUCK DRIVER: Off the Road Truck............................$ 20.82 3.69

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

(End of Summary of Changes)