SOLICITATION_AMENDMENT_01-_W911SG19B0003.pdf

SEE SCHEDULE

This is an “Invitation for Bids” Project Title: FY 19 WSMR ROOFING PROJECTS

A bid guarantee is required (see clause at FAR 52.228-1). All bid bonds must be originals; photocopies w ill not be accepted. Performance and payment bonds are required (see clause at FAR 52.228-15)

This is a 100% competitive set-aside for Service Disabled Veteran Ow ned Small Business (SDVOSB) under NAICS 238160 w ith a small business size standard of $15 Million

The estimated magnitude of construction for this project is betw een $1,000,000 and $5,000,000

Applicable New Mexico Gross Receipts Tax Rate for Dona Ana County is 6.75% and Otero County is 6.3125% as of the date of solicitation.

The aw ardee of this contract w ill be required to provide a Superintendent at all times w ork is being performed on the project (see clause at FAR 52.236-6). The Superintendent is considered a key position. This position SHALL NOT be subcontracted and must w ork directly for the prime contractor.

Bid opening address: MICC-Fort Bliss, RM 218 111 Pershing Rd, Fort Bliss, TX 79916

Bidders are required to provide a CD copy of their bid documents w ith their IFB submission Resulting contract w ill be Firm-Fixed-Price (FFP)

X

CHRISTOPHER HERRERA 915-569-7659

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

02-Aug-2019

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______5 calendar days and complete it w ithin ________300 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________11 Sep 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

MICC-FT BLISS W911SG

111 PERSHING RD

FT BLISS TX 79916

W911SG

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: (915) 569-7657 TEL: FAX:

W911SG19B0003 96

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W911SG19B0003

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

REPAIR/REPLACE ROOFS 1546

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 1546 per the SOW specifications, and drawings attached herein.

FOB: Destination

PURCHASE REQUEST NUMBER: 0011316429

PSC CD: Z2JB

NET AMT

0002 1 Job

REPAIR/REPLACE ROOFS 1848

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 1848 per the SOW specifications, and drawings attached herein.

FOB: Destination

0003 1 Job

REPAIR/REPLACE ROOFS 1858

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 1858 per the SOW specifications, and drawings attached herein.

FOB: Destination

0004 1 Job

REPAIR/REPLACE ROOFS 21290

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract.The project consists of removing and replacing the roof on building 21290 per the SOW specifications, and drawings attached herein.

FOB: Destination

0005 1 Job

REPAIR/REPLACE ROOFS 23480

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 23480 per the SOW specifications, and drawings attached herein.

FOB: Destination

0006 1 Job

REPAIR/REPLACE ROOFS 23656

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 23656 per the SOW specifications, and drawings attached herein.

FOB: Destination

0007 1 Job

REPAIR/REPLACE ROOFS 23660

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 23660 per the SOW specifications, and drawings attached herein.

FOB: Destination

0008 1 Job

REPAIR/REPLACE ROOFS 26132

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 26132 per the SOW specifications, and drawings attached herein.

FOB: Destination

0009 1 Job

REPAIR/REPLACE ROOFS 26192

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 26192 per the SOW specifications, and drawings attached herein.

FOB: Destination

0010 1 Job

REPAIR/REPLACE ROOFS 26199

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 26199 per the SOW specifications, and drawings attached herein.

FOB: Destination

0011 1 Job

REPAIR/REPLACE ROOFS 128

FFP

The contractor shall furnish all labor, material, equipment, tools, transportation, performance and payment bonds, and supplies necessary to complete the work according to the contract. The project consists of removing and replacing the roof on building 128 per the SOW specifications, and drawings attached herein.

FOB: Destination

PURCHASE REQUEST NUMBER: 0011316429-0001

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 0010 Destination Government Destination Government 0011 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 300 dys. ANP 1 W91VB1

LOWELL AESCHLIMAN

W6CJ USAG WHITE SANDS BLDG 1870

ABERDEEN

WHITE SANDS NM 88002-500

575-678-2768 FOB: Destination

W91VB1

0002 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0004 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0005 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0006 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0007 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0008 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0009 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0010 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0011 300 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO BIDDERS

INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

1. Description of the Project:

The Directorate of Public Works (DPW) White Sands Missile Range (WSMR), has a new requirement that consists of removing and replacing the roofs on buildings 1546, 1848, 1858, 21290, 23480, 23656, 23660, 26132, 26192, 26199 and 128 in White Sands Missile Range, NM

2. Instructions to Bidders:

2.1. You are invited to submit a bid in response to our Invitation for Bids (IFB)

W911SG-19-B-0003 FY19 WSMR ROOFING PROJECTS, at 1:00 PM MST 11 September 2019 at Ft.

Bliss TX Bldg 111 Room 218.

2.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price.

2.3. This solicitation is set-aside 100% for Service Disabled Veteran Owned Small Businesses (SDVOSB).

3. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

3.1. A pre-bid conference will be conducted on 20 August 2019 at 8:30 AM MST for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at the parking lot of BLDG 102 White Sands Missile Range, NM. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

3.2. The conference/site visit is limited to a maximum of two (2) attendees per company. Contractor representatives should be prepared to furnish identification if requested.

Email the following information for all attendees to Christopher Herrera at christopher.herrera1.civ@mail.mil

Company Name POC Name and position title Telephone Number

Individual or group questions will not be answered during the site visit. Potential bidders may submit written questions in accordance with section 4 (below) of this instructions to bidders section.

3.3. Potential bidders are not allowed to take pictures at the site visit. If pictures are required, the bidder may ask the designated Government representative to take any pictures requested. Pictures will subsequently be cleared by the WSMR Security Office and then incorporated into the solicitation as an amendment.

3.4. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

3.5. A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.fbo.gov.

4. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

4.1. Submit all questions in the format shown below by email to the contracting office at the address shown below. Do NOT contact DPW directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W911SG-19-B-0003 Email: christopher.herrera1.civ@mail.mil

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

4.1. Any explanation desired by bidder regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

4.2. All questions and requests for information (RFI) must be received NOT LATER THAN 27 August 2019 at 1:00 P.M. MST. An amendment will then be issued with all questions and answers. BIDDERS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS EARLY IN THIS PROCESS. **After the due date no additional RFI’s will be answered**

4.3. Any changes to the drawings, specifications, etc. will be issued in the form of an amendment.

However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on FBO at http://www.fbo.gov

4.4. Receipt by the bidder must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

4.5. All technical data related to this solicitation will be distributed using the Federal Business Opportunities (FedBizOpps.gov or fbo.gov) system. FedBizOpps is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with FedBizOpps before accessing the system.

4.5.1. Amendments, if/when issued will be posted to https://www.fbo.gov/ for electronic downloading.

This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible due to various reasons.

5. SUBMISSION OF BIDS: ELECTRONIC SUBMISSION OF BIDS, TO INCLUDE E-MAIL AND

FACSIMILE TRANSMISSIONS, IS NOT AUTHORIZED.

5.1. The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids on its behalf as indicated below. Bids shall not be addressed to any specific person. Any bids hand-delivered between 12:00 PM and 1:00 PM MST on the due date shall only be delivered to the bid opening room at:

MICC-Fort Bliss, Room 218 111 Pershing Rd Fort Bliss, TX 79916

*Note: Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer shall declare the bid “late” in accordance with FAR 14.304.

All bids must be clearly identified with the bidder’s name and address. To ensure timely and proper handling, the lower left corner of the outermost wrapper should indicate the following:

Invitation for Bid No: W911SG-19-B-0003 Due Date of Bids: 11 September 2019 Time by which Bids are due: 1:00 P.M. (Mountain Standard Time) Title of Project: FY19 WSMR ROOFING PROJECTS

Bidders submission shall consist of one (1) volume, physically separated with detachable parts, and individually title (to include one CD/DVD submitted). Please note no thumb drives will be accepted.

TAB TITLE ORIGINAL

(HARD COPY)

CD/DVD

COPIES

A COVER SHEET 1 1

B SF 1442/

AMENDMENTS

1 1

C TOTAL CONTRACT

PRICE

1 1

D LETTER FROM

BONDING COMPANY

1 1

E BID BOND

GUARANTEE

1 1

F SUBCONTRACTOR

LIST

1 1

G WORK EXPERIENCE 1 1

H REPS & CERTS 1 1

Bids delivered before bid opening must be delivered only by mail, including, Federal Express or United Parcel Service to the address as indicated below. The date and time of delivery established by these carriers is not the official time of receipt by the Government. Bidders are responsible for allowing sufficient time for the bid to be processed for receipt and are cautioned that sufficient time may be as much as 24 hours prior to the date and time designated for receipt of bids. Bids sent by Federal Express and United Parcel Service are required to be sent to:

MICC – Fort Bliss Attention: Christopher Herrera Contract Specialist

W911SG-19-B-0003

Bldg 111 Pershing Road Fort Bliss, TX 79916

*Note the mailing address differs from the bid opening location.

Bidders must allow sufficient time to complete security screening to gain admittance to Fort Bliss, TX. The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids on its behalf. Bidders are responsible for ensuring bids are submitted so as to reach the location designated for receipt of bids.

6. PUBLIC BID OPENING:

The bid opening will occur at the time and date specified in Block 13 of the SF1442:

MICC-Fort Bliss, Room 218 111 Pershing Rd Fort Bliss, TX 79916

7. WAGE DETERMINATION:

Construction Wage Rates are applicable to this project are __2019-NM-011__ as shown in Section 00800.

8. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS:

This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

9. CLAUSES:

Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements there to are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

10. SYSTEM FOR AWARD MANAGEMENT (SAM):

Bidder must be registered in the database IAW FAR 52.204-7 in order to be awarded a contract and have the applicable NAICS code listed in FAR 52.219-1(c), Small Business Program Representations (Alternate I), Representations.

11. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids including the bid bond.

12. BID CONTENT/OFFERORS QUALIFICATIONS: (See section 00800 for Contracting Officer Determination of Responsibility)

IFB DOCUMENTS. Contract shall be awarded to the responsive/responsible prospective contractor considering only price. Before award, to be determined responsive, a prospective contractor must furnish the following information with their bid:

a. TAB A: Cover Sheet. Coversheet shall be on company letterhead and must contain your DUNS number, CAGE code, Tax ID, and authorized representative(s) who can obligate your company contractually, sign the bid, and sign, other contract actions; include telephone number with area code and complete email address for each authorized representative. Failure to provide all of the above requirements shall render your bid nonresponsive.

b. TAB B: Signed and completed SF 1442 along with any amendments. The SF1442 shall be submitted fully completed. The Contractor shall acknowledge any amendments to the IFB in accordance with the instructions on the SF1442. All bidders are cautioned to complete blocks 20a-20c with an original signature in block 20b. Failure to provide all of the above requirements shall render your bid nonresponsive.

c. TAB C: CLIN Price and Total Contract Amount . The Bidders shall provide pages 3-8 of the solicitation pricing each CLIN individually and include the OVERALL contract price.

d. TAB D: Letter from Bonding Company. Letter must indicate the bidder’s ability to obtain performance and payment bonds in the amount of their bid. Failure to provide this letter shall render your bid as nonresponsive.

e. TAB E: Bid Bond Guarantee. Per FAR 52.228-1, failure to provide a bid bond guarantee per FAR 52.228-1 shall render your bid nonresponsive.

f. TAB F: Subcontract List. Bidders shall submit a list of proposed subcontractors as an attachment to their bid. If bidder does not intend on utilizing subcontractors (self-perform), Bidder shall state so in their bid.

Failure to provide this listing or statement will render the bid nonresponsive and eliminate the offer from further consideration for award.

g. TAB G: Work Experience. The prime contractor shall demonstrate that it possesses general construction contract management by providing at least two examples of relevant work experience in an awarded contract similar to the requirements stated in this solicitation. Documentation shall be submitted with the bid and include the contract number, the date of contract award, the customer's name and contact information, the awarded dollar value, a description of all work elements included in the contract, the number and type of specialty trades needed to complete the contract, and the period of time allocated for completion of the work. The Government will accept work experience from Federal, State, and institutional and commercial contracts. Failure to provide this documentation will render the bid/offer non-responsive and no further consideration will be given to that bidder for award of this contract.

h. TAB H: REPRESENTATIONS, CERTIFICATIONS. The bidder shall ensure that their business has completed an online Representations and Certifications at the System and Awards Management (SAM) website, which may be found at https://www.sam.gov/portal/public/SAM//. It is the bidder’s responsibility to ensure that the information provided in each representation and certification is completed truthfully and completely. A bidder’s failure to complete the online representations and certifications prior to the close of the Solicitation (to include listing of the applicable NAICS code and applicable size standards) will result in their bid being deemed non-responsive and eliminated from further consideration. Bidders shall submit the representations and certifications listed in Section 00600 or provide a printed version of the documents from their corporate SAM profile. Bidder must be registered in the database IAW FAR 52.204-7 in order to be awarded a contract and have the applicable NAICS code listed in FAR 52.219-1(c), Small Business Program Representations (Alternate I), Representations.

Section 00600 - Representations & Certifications

CLAUSES INCORPORATED BY REFERENCE

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238160.

(2) The small business size standard is $15,000,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 238160- assigned to contract number TBD.

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JUN 2019)

Substitute the following paragraphs (b), (d) and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at FAR 52.204-7, System for Award Management, is included in this solicitation, paragraph

(e) of this provision applies.

(2) If the provision at FAR 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

__ (i) Paragraph (e) applies.

__ (ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(viii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00700 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-2 Security Requirements AUG 1996 52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2018 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

JUN 2016

52.204-22 Alternative Line Item Proposal JAN 2017 52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-13 Notice of Set-Aside of Orders NOV 2011 52.219-14 (Dev) Limitations on Subcontracting (DEVIATION 2019-O0003). JAN 2019

52.219-27 (Dev) Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (DEVIATION 2019-O0003).

JAN 2019

52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action…