11148559_-_ROD041687P-_Amendment_0001_Solicitation_-_W911SG-18-R-0072.pdf

W911SG18R0072

0011148559

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to complete the follow ing:

1. Include revised SOW dated 13 August 2018 w ith the follow ing additions:

a. Section 1.1 TMDE Room- Panel MDP 3

b. Section 1.1.1.1 Rodent droppings on kitchen area.

2. Include revised Plans and Draw ings w ith additions for Panel MDP 3.

All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 27

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 15-Aug-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W911SG18R0072

X 9B. DATED (SEE ITEM 11)

02-Aug-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

15-Aug-2018

CODE

MICC- FT BLISS

ISSUING OFFICE

FORT BLISS TX 79916-6812

W911SG 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Title File Drawing No.

11148559 - ROD041687P- Revised Plans and Drawings - W911SG-18-R-0072 11148559 - ROD041687P- Specifications - W911SG-18-R-0072

(End of clause)

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

The following have been modified:

STATEMENT OF WORK

SCOPE OF WORK

August 13, 2018

ROD041687P and Main, Sub Panel, and Dry Type Transformer Replacement for

Building 22886

White Sands Missile Range, NM

Information contained in this document regarding commercial products or firms may not be used for advertising or promotional purposes and is not an endorsement of any product or firm by the

Directorate of Public Works, White Sands Missile Range or the U.S. Army.

PROJECT NAME: ROD041687P and Main, Sub Panel, and Dry Type Transformer Replacement DATE: August 13, 2018 Page 1

Table of Contents

Part 1 – Project Description and Location

1.1 General Description of Work

1.2 Project Location

1.3 Contract Discrepancies

1.4 Period of Performance (POP)

1.5 Pre-Construction Meeting

1.6 Progress Meetings

1.7 Temporary Utilities

Part 2 – Installation Access and Security

2.1 Installation access

2.2 Contractor’s Responsibilities

2.3 Removal of Personnel

2.4 Photography

2.5 Working Hours

2.6 Entry Restrictions/Roadblocks

Part 3 – Safety Compliance

3.1 Safety Compliance

3.2 Coordination With Sub-Contractors

3.3 Site Specific Safety Plan

3.4 Internal Job Site Safety Inspections

3.5 Hazard Analysis

3.6 Accident Reporting Requirements

3.7 Safety Meetings

3.8 Display of Safety Information

3.9 Work in Confined Spaces

3.10 Safety Data Sheets for Hazardous Materials

3.11 Radiation Permits and Authorizations

3.12 Hot Work Permits

Part 4 – Environmental Quality Program

4.1 Cleanup and Disposal of Waste Materials

4.2 Waste Hauler Requirements

DATE: August 13, 2018 Page 2

4.3 Waste Disposal

4.4 Prohibitions

4.5 Air Pollution Prevention

4.6 Dust Control

4.7 Water Pollution Prevention

4.8 Sanitary Facilities

Part 5 – Contractor Quality Control

5.1 Quality Control Plan

5.2 Contractor Daily Reports

5.3 Construction Phasing

5.4 Work Area Maintenance

5.5 Utilities Clearances and Outages

5.6 Emergency Suspension of Work

5.7 Government Witness

5.8 Documentation

Part 6 – Product Requirements

6.1 General Information

6.2 Delivery, Storage, and Handling

6.3 Installation

6.4 Product Data

Part 7 – Required Employee Training

7.1 Employee Training

Part 8 – Project Submittals

8.1 Submittals

8.2 Submittal Requirements

8.3 List and Timeline of Submittals

8.4 Government Review of Submittals

8.5 Training

8.6 Equipment Manuals, Shop Drawings, and Product Data Manuals

8.7 As-Built Drawings

Note: Project Engineer shall indicate if As-Builts are required or not for a particular project

8.8 ................................................................................................... Operation and Maintenance Manual.

DATE: August 13, 2018 Page 3

8.9 Warranties

Part 9 – Construction Schedules

9.3 Construction Schedule

Part 10 – Hazardous Building Materials Abatement

10.3 GENERAL

Part 11-Narrative of Specific Work Requirements

11.3 Specific Work

Part 12 – Construction Drawings (Separate Attachments)

12.1 GENERAL

Part 13-Applicable Codes/Standards

Part 14-Specifications

DATE: August 13, 2018 Page 4

Part 1 – Project Description and Location

1.1 General Description of Work:

All work shall comply with State, local and Federal laws and regulations, industry and construction codes and standards, manufacturer’s specifications and recommendations, and all contract special provisions, terms and conditions. The Contractor shall be responsible for obtaining all required licenses and permits to perform construction work on a Federal installation, be properly bonded and insured in accordance with Federal Acquisition Regulation (FAR) requirements. The intent of the contract is to provide for the construction and completion of the work described. The precise details of performing the work are not stipulated except as considered essential for the successful completion of the work. The Contractor shall furnish all labor, material, equipment, tools, transportation, and supplies necessary to complete the work according to the contract.

Evaluate and correct according to NEC 2017Code, all found/discovered electrical deficiencies within the electrical interior of B-22886 known as Dry Site. These panels and transformer have exceeded their life expectancy and are not safe to operate and protect the tenants at building 22886 from Arc Flash and electrocution.

Replace/Upgrade Federal Pacific Main Power Panel and sub Panels MDP3, PP,L, L, LA, MDP 2, P/1, lighting contactor, and dry type transformer with new Power Panels, Sq. “D” or equivalent with new branch circuit breakers along with new dry type transformer NEMA 1. New equipment shall comply with the National Electric Code (NEC) 2017 and all new panels shall have copper bus along with bolt on breakers and dry type transformer shall have copper windings and ground bus. Existing branch circuits (conductors) in panels shall be transferred to the new panels to the correct breaker size along with splicing of the conductor section 300.14 NEC 2017 as needed. Remove feeder conductors and install new conductors to each panel and dry type transforme sized to the correct load. Contractor shall match AIC ratings to the new circuit breakers that shall protect existing equipment.

Replace existing indoor Dry type Transformer, 112.5 KVA, 3 Phase, 480 V-120/208V, Delta- Wye connected primary, located in kitchen, with a new Dry Type, 112.5 KVA TX (include secondary disconnect switch with fuses-heavy duty), 3 phase, Delta- Wye, 4W, Secondary, to be located to the Electrical room east of the building.

1) The new source of power, for the 112.5 KVA Transformer, primary conductors should be in RIGID conduit both primary and secondary, the properly sized conductors shall be pulled from the existing Power source Panel “MPD-3” located inside the electrical room east of building and to the new Panel “PP” NEMA 1, 208 V, 3 phase located in the kitchen using existing conduit.

2) Purchase and install new Main Power Panel, "PP", 3 phase, AIC- 22000A minimum.

a. Main Power Circuit Breaker, 3Phase, National Electric Code (NEC) 2017 approved I (current), rating, V,(voltage) rating, Arc Flash rating, with the required number of circuit breakers, NEMA 1 rating, Ground Bus and Neutral Bus. Brand Name, Square "D" required. Type of mounting; Flush, Line Feed, Top or Bottom, Bus bars-Copper only. There shall be Bolt-on circuit breakers, Lighting circuits shall have special NEC 2017 approved lighting circuit breakers.

DATE: August 13, 2018 Page 5

b. Provide proper Main feeder lugs sized according to NEC 2017, Main conductor size based upon the existing load. All Circuits shall be ‘chased out’, labeled and listed on the panel door card.

c. Branch circuit Breakers; Provide three pole, bolt-on circuit breakers, sized, I/V rated for the subpanel connected. (Evaluate, bring up to NEC 2017 code all existing electrical discrepancies in the existing branch circuits)

3) Break Area Panel "PP", sub panel. Provide new Square "D" circuit breaker panel, new Main Circuit Breaker, new replacement circuit breakers, Type CBRs: bolt-on. Installed according to NEC 2017 grounding, neutral bus and circuit labeling, circuits as determined by circuit tracing and verification, as described on the door card. Correct door card to correspond with new traced circuits.

4) Mechanical Room Panel "P/1". Provide new Square "D" circuit breaker panel, with Main Circuit Breaker, and new replacement bolt-on circuit breakers. Install according to NEC 2017 grounding, neutral bus and circuit labeling with corrected circuits as determined by circuit tracing and verification, and described on the door card.

5) Mechanical Room, Panel “MDP-2”. Provide new Square "D" circuit breaker panel, new Main Circuit Breaker, new replacement bolt-on circuit breakers. Install according to NEC 2017 grounding, neutral bus and circuit labeling with corrected circuits as determined by circuit tracing and verification, as described on the door card.

6). TMDE Room- Panel L, Provide new Square "D" circuit breaker panel, with main lugs, and new replacement bolt-on circuit breakers, Install according to NEC 2017 grounding, neutral bus and circuit labeling with corrected circuits as determined by circuit tracing and verified, described on the door card.

7). TMDE Room, Panel "LA”, Provide new Square "D" circuit breaker panel, with main lugs, and new replacement bolt-on circuit breakers and a new lighting contactor control. Install according to NEC 2017 grounding, neutral bus and circuit labeling with corrected circuits as determined by circuit tracing and verification, as described on the door card.

8) TMDE Room- Panel MDP 3- Provide new Square "D" circuit breaker panel, new Main Circuit Breaker, new replacement bolt-on circuit breakers. Install according to NEC 2017 grounding, neutral bus and circuit labeling with corrected circuits as determined by circuit tracing and verification, as described on the door card. Include 8 new contactors (4 for exhaust fan and 4 for evap coolers ).

New panels and dry type transformer shall satisfy Institute of Electrical and Electronic Engineers 1584 Guide to Performing Arc Flash, IEEE 142-2007 Recommended Practice for Grounding of Industrial, National Electric Code 2017, and Commercial Power Systems, National Fire Protection Association 70E, and Occupational Safety and Health Administration standards.

Contactor shall work with the government to schedule outages for performing the work in the following order:

1) Panel MDP 3(with 8 contactors), Panels “L” and “LA” (Includes Lighting Contactor)

2) Panel “PP” and Relocating and Installing New Dry Type Transformer

3) Panels “P/1” and “MDP-2”.

DATE: August 13, 2018 Page 6

Government shall move their property for the areas where work will be performed (electrical room-shelves with items on it and mechanical room-McDonnel Boiler Water Control) for the contractor prior to them mobilizing so they can begin work when they arrive.

1.1.1 RODENT DROPPINGS:

1.1.1.1 The terminal compartment of the existing 500 kVA pad mounted transformer and above ceiling tiles in kitchen is contaminated with rodent droppings. Rodents on White Sands Missile Range may carry the Hantavirus. Hantavirus Survey No. 18-RF-666-97, conducted by U.S. Army Center for Health Promotion and Preventive Medicine on White Sands Missile Range 4-8 April 1997, identified the rodent species, Peromyscus Boylii (common name: Brush Mouse) as a carrier of the Hantavirus.

The Hantavirus may be transmitted to humans when exposed to infected rodents. Exposures may include: breathing in the virus. This may happen when rodent urine and droppings containing Hantavirus are stirred up into the air. Touching eyes, nose or mouth after touching rodent droppings, urine, or nesting materials that contain the virus. A bite from an infected rodent.

Persons infected with the Hantavirus may develop Hantavirus Pulmonary Syndrome (HPS). HPS is a severe, sometimes fatal, respiratory disease. Anyone who comes into contact with rodents or rodent contaminated materials that carry Hantavirus, without proper protection, are at risk of developing HPS.

HPS is not spread from person to person.

Based on the rodent droppings remediation specification (provided as a separate attachment), provide rodent dropping remediation work including the handling and control of rodent contaminated materials and the resultant procedures and equipment required to protect workers, the environment and occupants of the building or area, or both, from contact with rodent dropping products. The work also includes the disposal of any rodent droppings and contaminated materials generated by the work. The rodent dropping removal work includes the disinfection or sanitizing of surfaces contaminated by rodent droppings and contaminated materials. Provide containment and engineering control techniques as outlined in the rodent droppings specification. All rodent dropping and contaminated materials removal work shall be supervised by a biohazard remediation supervisor as specified in the specification.

1.1.1.2 See the rodent droppings remediation specification for all requirements. Specification to be provided as a separate attachment.

1.1.1.3 Contractor shall ensure that the Government provides the rodent droppings specification before submitting a cost proposal.

1.2 Project Location:

Work is located at 22886 at Dry Site, White Sands Missile Range (WSMR), and New Mexico in Dona Ana.

1.3 Contract Discrepancies:

Contractor shall become thoroughly familiar with the existing conditions, analyze the components of the project, take the necessary equipment, and make any necessary calculations to achieve the project requested. The contractor shall notify the Contracting Officer Representative (COR) immediately of any

DATE: August 13, 2018 Page 7 errors, omissions, and other discrepancies in contract documents for all work covered in this Scope of Work (SOW).

1.4 Period of Performance (POP):

All work shall be completed according to the awarded contract period of performance of no later than 120 calendar days after the notice to proceed is issued by the Contracting Officer (KO). The POP includes time required to process any coordination with any Government office or the COR on as needed basis for example traffic control, dig permit coordination, utility outage requests, submittals in accordance with (IAW) Section 8.3, etc.

1.5 Pre-Construction Meeting:

The contractor shall attend a pre-construction meeting held by the government prior to construction.

Construction shall NOT begin until this meeting is held. This meeting serves to answer any questions from the contractor and to discuss building issues such as storage, security, access, working hours, etc.

1.6 Progress Meetings:

The project coordinator and the superintendent from the contractor shall attend any progress meetings held by the government on a scheduled or unscheduled basis (with 48 hour notice), or on dates determined by the government. This meeting is for the contractor to discuss their current progress, to discuss schedule, and to discuss and resolve any other project related issues.

1.7 Temporary Utilities:

If required to complete the requirements of this contract, temporary utilities may be available from the Government.

1.7.1 Water Service. The Contractor may use water from the Government's existing water system.

When connecting to the Government’s water system, including attaching water hoses to spigots, the contractor must install a back flow prevention device that is approved by WSMR Water Plant manager, 575-678-1917.

1.7.2 Electric Power Service. The Contractor may use electric power from the Government’s existing electrical system. If a temporary service is required, the Contractor shall inform the KO prior to contract award so equipment and demarcation can be negotiated.

Part 2 – Installation Access and Security

2.1 Installation access:

The Contractor and all associated sub-contractors employees shall provide all information required (to the COR or as required by the WSMR Visitor Control Program) for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause

DATE: August 13, 2018 Page 8 of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes. Contractors requiring up-range access shall comply with the requirements of WSMR Visitor Control Program (May 2017). The Government is not responsible for work delays or additional costs associated with and / or contractor’s failure to obtain clearances for their employees.

2.2 Contractor’s Responsibilities.

The Contractor shall ensure that all employees carry their Installation access authorization with them during working hours and show them upon request. The Government will periodically verify passes from the contractor employees with their personal identification. The Contractor shall also ensure that all passes are current, and are originals and not copies. If an employee is terminated the Contractor shall ensure that Installation access passes, badges, or other access credentials are turned in to the COR within 1 (one) working day.

2.3 Removal of Personnel.

The Government has the right to remove any Contractor employee at any time during the duration of the contract if that employee fails to meet the Installation Security Requirements. In such case, the Contractor shall ensure that Installation access passes, badges, or other access credentials are turned in to the COR immediately. The Contractor shall submit the name and qualifications of a replacement within 5 (five) working days of the removal to the COR.

2.4 Photography:

Under no circumstances shall the Contractor or any of their subcontractors take photographs of any type while on the installation. Failure to comply with this requirement will result in employee being barred from entering the installation. Photographs may be taken by the government COR and provided to the Contractor upon security review and approval.

2.5 Working Hours:

White Sands operates on a compressed work schedule with an off day every other Friday (RDO) and observes Federal Holidays. Normal working hours for the installation are from 07:00 AM to 4:30 PM. The KO may authorize the Contractor to perform work outside of normal working hours and days. If the Contractor desires to work during periods other than the days and hours listed above, a written request must be made to the KO within 4 (four) calendar days of their intention.

2.6 Entry Restrictions/Roadblocks:

Contractor and all associated sub-contractors employees may be required to work in areas subject to entry restrictions, evacuations, and roadblocks. Roadblocks on public highways are normally set for a duration of at least one (1) hour. Internal roadblocks are normally set for a duration of at least two (2) Hours. However, on occasion the duration may be all day. Prime Contractor is responsible for scheduling

DATE: August 13, 2018 Page 9 operations to avoid unnecessary delays and missed services. Range and roadblock status may be obtained by calling 678-1178 or 678-2222. Roadblocks time and duration are subject to change without prior notification.

Part 3 – Safety Compliance

3.1 Safety Compliance:

Army construction contracts fall within the purview of the US Army Corps of Engineers Safety and Health Requirements Manual, Engineer Manual (EM) 385-1-1, and Occupational Safety and Health Administration (OSHA) Title 29 Part 1910 and 1926. The version in effect at time of contract award will be used. OSHA 29 CFR 1910 Safety and Health Regulations as well as 29 CFR 1926 Safety and Health Regulations for Construction are available online at:

3.1.1 http://www.osha.gov/

3.1.2 EM-385-1-1 is available online at: http://www.publications.usace.army.mil/USACE-

Publications/Engineer-Manuals/

3.2 Coordination With Sub-Contractors

The prime contractor is the "controlling authority" and is responsible for all work site safety and health conditions including those of the subcontractors. The prime contractor shall be responsible for informing their subcontractors of the safety provisions under the terms of the contract and the penalties for noncompliance, coordinating the work to prevent one task from interfering with or creating hazardous working conditions for other tasks, and inspecting subcontractor operations to ensure that accident prevention responsibilities are being carried out.

3.3 Site Specific Safety Plan.

Construction contracts shall include a site and project specific safety plan. EM 385-1-1 refers to a safety plan as an Accident Prevention Plan (APP). The safety plan will be tailored to the project, based on the size and complexity of the construction to be accomplished and shall include a fall protection and prevention program. A typical safety plan will address such issues as, but will not be limited to:

3.3.1 The company’s safety and health policy.

3.3.2 Company safety inspections of the job site.

3.3.3 Use of personnel protective equipment (PPE).

3.3.4 Safety rules and penalties associated with not following the rules.

3.3.5 Safety training and frequency (identifying hazards, explaining precautions and proper use of equipment/machinery, and the PPE required for the job including how to use and maintain PPE).

3.3.6 The steps to be followed to report unsafe working conditions and practices.

3.3.7 Special hazards.

3.3.8 Hazardous materials.

3.3.9 Confined spaces, i.e. entry procedures and ventilation requirements, etc.

3.3.10 Lockout tag procedures.

DATE: August 13, 2018 Page 10

3.3.11 Instruction concerning safe operations and appropriate emergency action in the event of accidental exposure.

3.3.12 Emergency procedures.

3.3.13 Identifying personnel on site who have had first aid training.

3.3.14 Identify where communication devices (such as phones, radios or other approved communication devices) are located with appropriate phone numbers posted.

3.3.15 Post how to exit the work area in an expeditious and safe manner.

3.3.16 The plan will identify the person with lead responsibility for safety, where protective equipment may be obtained and the procedures for reporting a safety hazard.

The person identified as the lead responsible for Safety may also perform Contractor Quality Control upon approval by the KO.

See section 8.3 for deliverable requirements.

Approval of the Safety Plan does not relieve the contractor of complying will all applicable safety requirements.

3.4 Internal Job Site Safety Inspections.

Frequent and regular contractor internal job site inspections shall focus on identifying and removing hazards. The Contractor’s Safety Plan will explain the disciplinary process that will be followed when the contractor job inspections find violations to the safety rules. The disciplinary process shall be included in the employee’s training and reviewed during regular safety briefings. The Government will review the Contractor’s Safety Plan for adequacy, completeness and compliance with OSHA and EM 385-1-1 requirements. The Contractor shall review and amend the safety plan, as necessary, throughout the life of the contract. Amended safety plans shall be submitted to the COR for approval. The Contractor shall incorporate unusual or high-hazard activities not identified in the original safety plan as they are discovered.

3.5 Hazard Analysis.

Before beginning each work activity involving a type of work presenting hazards not experienced in previous project operations or where a new work crew or subcontractor is to perform the work, the contractor(s) performing that work activity shall prepare an Activity Hazard Analysis (AHA) (sometimes called a job hazard analysis).

See section 8.3 for deliverable requirements.

Approval of the Activity Hazard Analysis does not relieve the contractor of complying will all applicable safety requirements.

3.6 Accident Reporting Requirements.

DATE: August 13, 2018 Page 11

Contractors shall immediately report all accidents or injuries to the COR or his/her designee. If COR or Project Representative is not available, report accidents or injuries to the Installation Safety Office (ISO) Director (575-678-8234). Forward a written report through the COR using contractor’s format or similar IAW DAPAM 385-40 to the Installation Safety Office (ISO) within seven (7) calendar days of occurrence.

Damage to Army property. This includes Government furnished material, property, or equipment provided to a contractor. Contractor must complete DA Form 285 or 285-AB-R (available at http://armypubs.army.mil/), when damage to Army property is equal to or greater than $5,000.00. If Contractor has an issued Common Access Card (CAC), Contractor is required to complete the report through REPORT IT, the Army's online accident reporting system (https://safety.army.mil/). If contractor has not been issued a CAC, the forms identified in DA PAM 385-40 must be utilized and provided to the ISO Director or designated representative within seven (7) calendar days of occurrence.

The COR shall: Immediately notify the ISO of a contractor accident or injury and ensure a written accident report is sent to the ISO within seven (7) calendar days of occurrence.

Contractors shall report to the local OSHA office accidents and injuries in accordance with OSHA reporting requirements (https://www.osha.gov/oshdir/nm.html).

3.7 Safety Meetings.

The contractor shall conduct and document meetings as required by EM 385-1-1. Attach minutes showing contract title, signatures of attendees and a list of topics discussed to the contractor's daily report.

3.8 Display of Safety Information.

The contractor shall erect a safety bulletin board at the job site at least one calendar day prior to commencement of work. Where size, duration, or logistics of project do not facilitate a bulletin board, an alternative method, acceptable to the COR, that is accessible and includes all mandatory information for employee and visitor review, shall be deemed as meeting the requirement for a bulletin board.

Include and maintain information on safety bulletin board as required by EM 385-1-1, section 01.A.06.

3.9 Work in Confined Spaces.

Comply with the requirements in Section 34 of USACE EM 385-1-1, OSHA 29 CFR 1910.146, and OSHA 29 CFR 1926.21(b)(6). Any potential for a hazard in the confined space requires a permit system to be used.

WSMR Fire Department issues permits for confined space entry. Please call 575-678-0470/4187 to obtain a permit. Permits shall be requested no later than two (2) working days in advance of the work to be performed. The Contractor shall coordinate with the COR to submit the permit request.

3.10 Safety Data Sheets for Hazardous Materials.

The Contractor shall submit a List of Hazardous Materials (LHM) and Safety Data Sheets (SDS) IAW the requirements of paragraph e of the clause at FAR 52.223-3 Alternate 1, “Hazardous Materials

DATE: August 13, 2018 Page 12

Identification and Safety Data.” The information shall be submitted as outlined in section 8.3 List of Submittals.

3.11 Radiation Permits and Authorizations.

Civilian contractors bringing radioactive devices (e.g. nuclear soil density meters) onto the Installation must have approval from the Installation Radiation Safety Officer, 575-678-8726. Contractor shall prepare and submit an application (DA Form 3337, http://armypubs.army.mil) to bring in radiation devices at least seven (7) calendar days prior to anticipated use. Applications shall be submitted through the COR. Contractor shall not bring in any devices without a government approved application.

3.12 Hot Work Permits.

The contractor shall obtain a hot work permit for any activity that requires an open flame or involves activities such as welding, burning, brazing, soldering, cutting and grinding materials. Hot work permits can be obtained from the WSMR Fire Department. Please call 575-678-0470/4187 to obtain a permit.

Permits shall be requested no later than two (2) working days hours in advance.

Part 4 – Environmental Quality Program

4.1 Cleanup and Disposal of Waste Materials.

The contractor shall be responsible for the cleanup and disposal of waste and debris generated during and at the completion of this project. The Contractor shall be responsible for the payment of all disposal costs, fees for obtaining permits and licenses, and transportation costs. In addition, the Contractor shall pay, at no additional cost to the Government, all fines and clean-up costs due to improper disposal or due to spills, leaks, or releases. In general, the waste and debris shall be disposed of IAW all applicable federal, State, and Local laws and regulations. Specifically, the waste and debris shall be disposed of IAW the jurisdiction having authority, including, any disposal site outside the State of New Mexico. The Contractor shall ensure that all waste and debris is containerized IAW the U.S. Department of Transportation and the jurisdiction having authority laws and regulations. The Contractor shall ensure that all waste is containerized in a manner to prevent uncontrolled and improper spills, leaks, and releases.

4.2 Waste Hauler Requirements:

All waste haulers shall be licensed IAW the requirements specified in the appropriate New Mexico Administrative Code (NMAC) for the type of waste to be disposed of. In addition, all waste haulers are responsible for obtaining all required licenses and permits for jurisdictions outside of the State of New Mexico if crossing state lines to dispose of the waste.

4.3 Waste Disposal.

The contractor shall dispose of all waste and debris as follows:

DATE: August 13, 2018 Page 13

4.3.1 Construction waste and debris: All construction waste, as defined by the New Mexico Environment Department (NMED) Solid Waste Bureau (SWB) shall be disposed of at an off-site location that has been permitted, by the jurisdiction having authority, to accept and dispose of construction waste and debris.

4.3.2 Municipal solid waste: All municipal type waste and debris, as defined by the NMED

SWB shall be disposed of at an off-site location that has been permitted, by the jurisdiction having authority, to accept and dispose of municipal solid waste.

4.3.3 Hazardous Waste, Universal Waste, and Polychlorinated Biphenyl (PCBs): All hazardous/universal waste and PCBs shall be disposed of through the WSMR Hazardous Waste Management Center (HWMC), 575-678-4641. The COR will coordinate with the HWMC to determine if the contractor is responsible for disposing of the waste directly or if the waste is to be turned over to the HWMC for disposal. The contractor is responsible for containerizing and transporting the waste in accordance with the U.S.

Department of Transportation (USDOT) and the jurisdiction having authority regulations for the transportation of hazardous materials. In addition, the contractor shall be responsible for completing and managing the waste manifest whenever transporting hazardous waste/universal waste and PCBs.

4.3.4 Ozone Depleting Refrigerants: Ozone depleting refrigerants shall be disposed of through the WSMR Logistics Readiness Center, 575-678-5957. The contractor is responsible for containerizing and transporting the refrigerants in accordance with USDOT and the jurisdiction having authority regulations for the transportation of refrigerants.

4.3.5 Asbestos Waste and Debris: All asbestos waste and debris shall be disposed of at an off-site location that has been permitted, by the jurisdiction having authority, to accept and dispose of the asbestos waste and debris. The Contractor shall ensure that all asbestos waste and debris is containerized and transported in accordance with the USDOT and the jurisdiction have authority regulations. In addition, containers such as roll-offs and trailers shall have rigid sides, bottoms, and tops to transport asbestos waste and debris. Containers with soft covers (e.g. tarps) are prohibited. The contractor shall be responsible for completing and managing the asbestos waste shipment record in accordance with EPA regulation 40 CFR Part 61 and the State of New Mexico Environment Department Solid Waste Regulations.

4.3.6 Liquid, semisolid, and sludge waste: All liquid, semisolid, and sludge waste shall be disposed of at an off-site location that has been permitted, by the jurisdiction having authority, accept and dispose of the waste.

4.3.7 Waste from Portable Latrines (“Port-a-Potties”): All waste from portable latrines shall be disposed of at an off-site location that has been permitted, by the jurisdiction having authority to accept and dispose of the waste.

DATE: August 13, 2018 Page 14

4.3.8 Scrap Metal: To the extent possible or if required as part of this project, scrap metal, including electrical wiring, shall be disposed of at the WSMR Metal Scrap Yard (575-678- 3160 or 575-640-8522). All glass shall be removed from metal windows and metal doors before transporting the scrap metal to the Metal Scrap Yard.

4.3.9 All other waste and debris not specifically noted: Dispose of all other waste and debris

IAW the laws and regulations of the jurisdiction having authority.

4.4 Prohibitions:

4.4.1 On-site Burning or incineration of waste and debris.

4.4.2 On-site burial.

4.4.3 Dumping at locations not permitted, by the jurisdiction having authority, to accept and dispose of the waste and debris.

4.4.4 Use of unlicensed waste haulers.

4.4.5 Using containers that are not appropriate for the disposal of waste and debris.

4.5 Air Pollution Prevention.

The contractor shall comply with applicable Federal, State, and local laws and regulations concerning the prevention and control of air pollution. The Contractor shall utilize such methods and devices as are reasonably available to prevent, control, and otherwise minimize atmospheric emissions or discharges of air contaminants. For examples, equipment and vehicles that show excessive emissions of exhaust gases shall not be operated until corrective repairs or adjustments reduce such emissions to acceptable levels.

4.6 Dust Control

During the performance of work required, the Contractor shall comply with applicable Federal, State, and local laws and regulations regarding the prevention, control, and abatement of dust pollution. Materials other than water used for dust control shall be approved by the WSMR Environmental Division. The Contractor shall be responsible for all damages resulting from dust originating from Contractor operations IAW the clause at FAR 52.236-07 entitled “Permits and Responsibilities.” The Contractor shall provide all labor, equipment, and materials, and shall use efficient, methods wherever and whenever required to prevent, dust nuisance or damage to persons, property, or activities, including, but not limited to crops, orchards, cultivated fields, wildlife habitats, traffic, and similar conditions.

4.7 Water Pollution Prevention

Contractor shall control point source discharges by use of sediment and erosion controls; wastewater and storm water management controls; construction site management practices; best management practices (BMP); and other controls; including Federal, State, and local control requirements.

4.8 Sanitary Facilities

DATE: August 13, 2018 Page 15

Contractor is responsible to provide a portable latrine for Contractor use. The designated restroom(s) must be properly maintained and all contractor debris removed. The facility must be kept reasonable clean. All liquid and solid waste from portable latrines shall be disposed at an approved off site location.

Part 5 – Contractor Quality Control

5.1 Quality Control Plan

The Contractor shall prepare a Quality Control Plan describing the actions the Contractor will take to ensure the work meets contract requirements. The Quality Control Plan shall also include the name of the Contractor Quality Control (CQC). If specific experience or qualification requirements are called for in the SOW, Plans, or Specifications, (e.g., welder qualification certificate) the Quality Control Plan will document how these requirements are to be met by the Contractor. During the actual work activities, a CQC shall be on site at all times who is an employee of the prime contractor and has authority to make decision on behalf of the prime contractor. The QCQ shall be responsible for ensuring that all work performed meets the requirements of the contract SOW, plans, and specifications. The person identified as the CQC may also be the lead responsible for Safety upon approval by the KO.

5.2 Contractor Daily Reports.

The Contractor shall submit a daily report to the COR, showing the contractor inspections and tests, on the first workday following the date covered by the report. Work quality shall be the responsibility of the contractor. The Contractor shall inspect and test work often enough to ensure that quality of materials, workmanship, construction, finish, and functional performance is in compliance with applicable standards.

5.3 Construction Phasing.

Government will maintain use of the adjacent access areas during construction activities. The contractor will be provided with reasonable access and staging areas during construction in the vicinity of the construction. The Contractor shall be responsible for maintaining the construction area and storage facilities and repairing damage caused during construction activities prior to substantial completion and final payment. The Contractor shall remove all stored materials and equipment no later than 5 (five) days after final acceptance of the work.

5.4 Work Area Maintenance.

All areas disturbed by the Contractor’s operation shall be kept reasonably clean by the contractor. During the course of the work, the Contractor shall periodically, or as directed by the COR, remove and dispose of all surplus construction materials and debris and keep the project area clean. Upon completion of the work, the Contractor shall remove temporary construction facilities, debris, and unused materials, leaving the project site in a neat and clean condition no later than 5 (five) days after final acceptance of the work.

5.5 Utilities Clearances and Outages.

DATE: August 13, 2018 Page 16

The Contractor shall obtain utility clearances before digging, boring, burrowing, tunneling, excavating and any other penetrations that may damage underground utilities. The Contractor shall request the clearances through the COR. The Contractor shall notify the COR in writing no more than seven (7) work days advance and no earlier than three (3) work days in advance prior to excavation to request the clearances. The Contractor shall white mark all proposed excavation locations prior to requesting utility locates. Utility outages shall be requested in writing at least one week in advance. The following utility clearances shall be required before the start of construction:

5.5.1 Communications Line

5.5.2 Electrical Line.

5.5.3 Gas Line.

5.5.4 Water Line.

5.5.5 Waste Water Line.

5.5.6 PNM Gas Lines.

5.5.7 Comcast Cable.

5.6 Emergency Suspension of Work.

When the Contractor is notified by the COR of noncompliance with the safety provisions of the Contract, the Contractor shall immediately, unless otherwise instructed, correct the unsafe or unhealthy condition. Additionally, the WSMR Safety Office and the WSMR Fire Department have the authority to suspend work under impending emergency situations (Risk of immediate loss of life or serious health issue).

5.6.1 If the Contractor fails to comply promptly, all or part of the Work will be stopped by notice from the KO or the KO through the COR.

5.6.2 When, in the opinion of and by written notice given by the KO or the COR, satisfactory corrective action has been taken by the Contractor, work shall resume.

5.6.3 The Contractor shall not be allowed any extension of time or compensation for damages in connection with a work stoppage for an unsafe or unhealthy condition.

5.7 Government Witness.

All inspections and tests are required to verify documented contract assumptions, to establish work accomplishment, or to certify performance attainment shall be witnessed by the COR and coordinated through the Quality Control Plan (QCP). The contractor shall notify the COR in writing at least five (5) work days prior to conducting inspections and tests.

5.8 Documentation:

The Contractor shall provide two (2) copies of documents containing all test reports/findings to the COR.

Test results shall typically include: item/system tested, location, date of test, test parameters/measured data, date of last calibration done in the equipment, Contractor Inspector/Government witness, test

DATE: August 13, 2018 Page 17 equipment description and measurement technique. When complete, the inspections/tests documents shall be turned over to the COR within three (3) days.

Part 6 – Product Requirements

6.1 General Information.

References to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, submit for approval a variance for any equipment, material, article, or process that, in the judgment of the COR in conjunction with the Government Project Engineer, is equal to that named in the specifications, unless otherwise specified. The Contractor shall provide data or assurance that the product is equal.

6.2 Delivery, Storage, and Handling.

The Contractor shall transport and handle manufactured products IAW manufacturer's instructions. The Contractor shall store and protect all products and materials IAW manufacturer's instructions including temperature and environmental conditions. The Contractor shall remove and replace damaged items with new items.

6.3 Installation.

The Contractor shall install products IAW manufacturer’s recommendations unless otherwise specified.

6.4 Product Data.

Product data to be included on material submittals shall include all data that indicates the product meets or exceeds the contract requirements and specifications. The product data shall also include any specific installation procedures, requirements, or restrictions if such information is provided by the manufacturer.

Part 7 – Required Employee Training

7.1 Employee Training:

All persons entering WSMR as part of the contract shall complete the following training. Proof of completion of training shall be submitted to the COR at least five (5) days prior to the start of any work.

7.1.1 Unexploded Ordnance Training. Prior to the start of any work on the installation, all Contractor and sub-contractor employees are required to watch the Installation Unexploded Ordnance Briefing Video (approximately 6 minutes). All employees are required to read Policy Letter #24 and complete the Record of Organizational Training on Unexploded Ordnance Range Hazards. The video and policy letters are available for download at http://www.wsmr.army.mil/ux/Pages/default.aspx.

DATE: August 13, 2018 Page 18

7.1.2 Wildlife-Vehicle Accident Prevention information video. This video is available at http://www.wsmr.army.mil/gar/dir/Safety/Pages/RSB.aspx. The video is approximately 4 minutes long.

7.1.3 AT Level-1 Training. All Contractor and subcontractor employees, requiring access to Army installations, facilities and controlled access areas shall complete AT Level I awareness training within seven (7) calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. This training takes approximately two (2) hours and is individual computer based training, not group training. The Contractor shall submit certificates of completion for each contractor employee and subcontractor employee, to the COR or to the KO, if a COR is not assigned, within seven (7) calendar days after completion of training by all employees and subcontractor personnel. AT level I awareness training is available at the following website: http://jko.jten.mil.

7.1.4 iWATCH Training. The Contractor and all associated sub-contractors shall brief all employees on the local iWATCH program (training standards provided by the requiring activity ATO). This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the appropriate personnel. This training will be provided electronically by the COR and takes approximately 10 minutes. This training shall be completed within 30 calendar days of contract award and within 15 calendar days of new employees commencing performance with the results reported to the COR NLT 45 calendar days after contract award.

Part 8 – Project Submittals

8.1 Submittals.

The contractor shall furnish all submittals and perform all work required for furnishing submittals to the Government, within 15 calendar days after contract award, IAW the clause at FAR 52.236-21, and the requirements in the provisions, clauses, and paragraphs of these specifications.

8.2 Submittal Requirements.

Contractor shall provide one (1) electronic copy of all submittals to the COR with a courtesy copy forwarded to the Contract Specialist (KS). TRADOC Form 928-R-E, January 2002 version shall be used for the submittals. All Forms shall be electronically fillable.

8.3 List and Timeline of Submittals.

No later than fourteen (14) days after award of the contract, at a minimum the following submittals shall be provided by the contractor to the COR with a courtesy copy to the KS:

8.3.1 List of subcontractors (SF-1413) per 48 CFR 52.222-11.

8.3.2 Site Specific Safety Plan per Section 3.3.

8.3.3 Activity Hazard…