PWS.pdf

1PERFORMANCE WORK STATEMENT (PWS)

Maintenance of Water Treatment Systems

Army Research Laboratory (ARL), Spesutie Island and Graces Quarters, Aberdeen Proving Ground (APG), MD

08 January 2026

C.1 BACKGROUND:

In 2002, water treatment systems were installed at ARL APG, Spesutie Island, MD, which maintained by ARL’s Department of Public Works (DPW). DPW also provided maintenance of the water treatment systems, which was included with the system installation. The service performed by DPW for maintenance was stopped in approximately 2008. In 2022, a FFP contract was awarded for the maintenance program for the filtration of undesirable contaminants in the water systems on Spesutie Island, ARL, APG, MD and Graces Quarters, Middle River, ARL, MD.

C.2 OBJECTIVE:

ARL requires continuance of a maintenance program for the filtration of undesirable contaminants in the water systems utilized for personal, as well as laboratory purposes, on

Spesutie Island (ARL, APG, MD), and Graces Quarters, (9 Lace Road, Middle River, ARL, MD)

(sixteen (16) locations) The current water has been certified as “potable” for human use, but due to certain contaminants, especially iron, quarterly maintenance is required to ensure that damage to highly specialized equipment used in experimental operations does not occur.

C.3 REQUIREMENTS:

Base Year Maintenance:

C.3.1 The Contractor shall perform a Quarterly Site Visit on all existing water treatment systems and applicable control units located in Buildings on Spesutie Island The Quarterly Site Visit shall include the following maintenance and testing:

C.3.1.1 The Contractor shall ensure maintenance on each water treatment system is performed at the end of each quarter in order to meet drinking water standards set by U.S. Environmental Protection Agency (EPA) Safe Drinking Water Act

(SDWA), based on routine usage at each site, estimated at twenty (20) to thirty (30) gallons per day. Maintenance shall include all of the following:

C.3.1.1.1 All required chemicals, feeder fills, filter changes, resin cleaning, rebedding of filters, and salts to operate the water treatment systems compatible with Culligan Water Conditioners and Automatic Water Filter (Medallist Series)the original equipment manufacturers (OEM), standards of the water treatment systems (16 systems)

C.3.1.1.2 Mixing of chlorine solution and blow down of retention tanks of dissolved impurities.

C.3.1.1.3 Conditioning of the water using a Medallist Series automatic water conditioner

C. 3.1.2 The Contractor shall perform water testing at each Quarterly Site Visit and make any adjustments necessary to maintain the water standards listed in Section C.3.1.1.

C.3.1.3 The Contractor shall test the 30 or 55 gallon contact/retention tanks, depending on which unit is being serviced, to ensure that they remain fully functional in accordance with the OEM standards.

C.3.2 The Contractor shall record all of the results of the Quarterly Site Visit to include service conducted, test results, and recommendations for repair or replacement and provide the results in writing to the COR no later than five (5) business days after each visit.

C.3.3 Service Regulations

The Contractor shall ensure that all disposals, installations, repair, and/or replacements of water treatment systems and parts are in accordance with Federal, State and local requirements.

C.3.4 Hours of Operation

Contractor personnel shall perform work during the hours of 8:00 am to 4:00 pm, Monday through Friday, excluding Federal holidays. Contractor personnel shall coordinate work schedules with the COR and work on-site at a time and date approved by the COR. To meet an emergency system or part failure, it may be necessary, from time to time, for Contractor personnel to work outside the normal hours during the course of the year.

C.3.5 OPTION Base Year Maintenance (CLIN 0001):

The Contractor shall perform quarterly maintenance in accordance with Sections C.3.1 to C.3.5

C.3.6 OPTION Year One (1) Maintenance (CLIN 0002):

C.3.7 OPTION Year Two (2) Maintenance (CLIN 0003):

C.3.8 OPTION Year Three (3) Maintenance (CLIN 0004):

C.3.9 OPTION Year Four (4) Maintenance (CLIN 0005):

C.4 SECURITY CONSIDERATIONS

C.4.1 Installation Access. All vehicles and personnel are subject to search and seizure of contraband or unauthorized Government property according to AR 190-13.

C.4.2 The Contractor shall safeguard Government resources according to AR 11-2. The

Contractor shall be responsible for maintaining proper conduct and good discipline within contractor occupied work areas.

C.4.3 APG Unescorted Access. Employee must be able to obtain a favorable background investigation to have unescorted access to the restricted area. Unescorted access into restricted areas of APG shall be granted to contractor personnel who currently possess a security clearance or who have obtained a favorable National Agency Check (NAC) or Federal Bureau of

Investigation (FBI) Check. The contractor shall complete IMAP Form 1199, Application for

Security Badge/Camera Pass, and FD 258, Application Fingerprint Card, for all contractor employees. Processing time for the FBI check is approximately four (4) to six (6) weeks.

Before beginning work on this contract, the Contractor shall obtain required forms from the COR and return the completed forms to the COR within ten (10) working days. The Contractor shall advise employees that this information will be used to review criminal history records. Adverse information may result in an individual being denied security area access. The Contractor shall be responsible for delays in the progress or completion of the contract because of the Contractor employees' disqualification for security badges. Such delays will not be deemed excusable under the Default Clause and further, may be subject to the Liquidated Damages provision of this contract, if applicable. Until the FBI check is completed or a security clearance is granted, contractor personnel shall be continually escorted, into, out of, and within the restricted areas by other contractor personnel possessing a photographic security badge.

C.4.4 Contractor employees and all associated sub-contractor employees requiring access to

Army installations, facilities, and controlled access areas shall complete AT Level I awareness training within 14 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. The Contractor shall submit certificates of completion for e4ach affected contractor employee and subcontractor employee, to the COR or the Contracting Officer, if a COR is not assigned, within 7 calendar days after completion of training by all employees and subcontractor personnel. This includes new contractor employees as they are assigned. AT Level 1 Awareness Training is available at the following website:

http://jko.jten.mil.

C.4.5 Contractor employees and all associated sub-contractors employees requiring access to

Army installations, facilities, and controlled access areas shall provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office.

Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

C.4.6 Contractor employees and all associated sub-contractor employees that do not require

CAC, but require access to a DoD facility or installation shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification

Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-

13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

C.4.7 Contractor employees and all associated sub-contractors requiring access to Army installations, facilities, and controlled access areas shall brief all employees on the local iWATCH program (training standards provided by the requiring activity ATO). This local developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. This training shall be completed within 14 calendar days of contract award and within 7 calendar days of new employees http://jko.jten.mil/ commencing performance with the results reported to the COR NLT 20 calendar days after contract award.

C.4.8 Contractor employees with Security Clearances, per AR 381-2, para 2-4b; Threat

Awareness and Reporting Program (TARP), must receive annual TARP training by a CI agent or other trainer as specified in 2-4b. Please see below information for making report.

iSALUTE: https://ww.inscom.army.mil/isalute iWATCH: https://www.myarmyonesource.com

Spy Hotline: 1-800-CALL-SPY

C.5. PERSONAL/CONTRACTOR-OWNED PROPERTY

The Contractor shall ensure that personal property or contractor-owned property brought on any

ARL installation is clearly marked as such to preclude misidentification as Government property.

Additionally, the Contractor shall ensure that personal property or Contractor-owned property meets safety specifications as set forth by Occupational Safety and Health Administration

(OSHA), MOSH, and the U.S. Army. The Contractor shall ensure that all personal property or

Contractor-owned property is removed from all ARL installations at the end of the period of performance.

3/11/2026

X Swati Jain

Contracting Officer

Signed by: USA https://ww.inscom.army.mil/isalute https://www.myarmyonesource.com/