W911KB22B0003-0002.pdf

NIL003

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to incorporate the follow ing changes:

1.The follow ing revised documents shall be substituted for the superseded documents. The identifier “AM1” appears before and after new and/or revised material:

•Section 00 11 01 – CLIN Schedule, deleted CLINs No. 0004, 0011, 0017, 0023. Updated Note 1.

•Section 00 73 00.00 29, replace pages 1-9. Paragraphs 1.2.7 and 1.2.8 deleted.

•Section 01 22 00.00 10, replace pages 1-4. Revised paragraphs 1.1.2, 1.1.2.1, 1.1.2.2, and 1.2.1.1.

2.Responses to 14 bidder inquiries.

The point of contact for this amendment is Jennifer Gosh at Jennifer.Gosh@usace.army.mil.

1. CONTRACT ID CODE PAGE OF PAGES

1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 15-Feb-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W911KB22B0003

X 9B. DATED (SEE ITEM 11)

24-Jan-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

11-Feb-2022

CODE

U.S. ARMY ENGINEER DISTRICT, AK

CEPOA-CT (W911KB)

2204 TALLEY AVENUE

JBER AK 99506-0898

W911KB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911KB22B0003

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 11 01 - CLIN SCHEDULE

The following have been modified:

CLIN SCHEDULE

(End of Summary of Changes)

Section 00 11 01 – CLIN SCHEDULE

BID/CLIN SCHEDULE

NINILCHIK HARBOR REVETMENT REPLACEMENT

NINILCHIK, ALASKA

Item No. Description Qty Unit Unit Price Total Amount

BASE ITEMS (STA 10+00 to STA 15+00 and STA 21+50 to STA 22+00)

0001 Mobilization and Demobilization for First Year Work, complete 1 Job $___________ $___________

0002 Demolish and Remove Existing Revetment STA 10+00 to STA 15+00 and STA 21+50 to 22+00, complete AM1… 1 Job $___________ $___________

…AM1

0003 Excavation and Embankment Preparation STA 10+00 to STA 15+00 and STA 21+50 to 22+00, complete 12,725 CY $___________ $___________

AM2… deleted CLIN 0004 …AM2

0005 Construct C Rock STA 10+00 to STA 15+00 and STA 21+50 to 22+00, complete 2,650 CY $___________ $___________

0006 Construct B Rock STA 10+00 to STA 15+00 and STA 21+50 to 22+00, complete 4,000 CY $___________ $___________

0007 Construct A Rock STA 10+00 to STA 15+00 and STA 21+50 to 22+00, complete 4,150 CY $___________ $___________

0008 Pre- and Post-Construction Surveys for First Year Work, complete 2 EA $___________ $___________

Total of Base Items 0001 through 0008: $___________

Item No. Description Qty Unit Unit Price Total Amount

OPTION 1 ITEMS (STA 15+00 to STA 17+00)

0009 Demolish and Remove Existing Revetment STA 15+00 to STA 17+00, complete AM1… 1 Job $___________ $___________

…AM1

0010 Excavation and Embankment Preparation STA 15+00 to STA 17+00, complete 4,200 CY $___________ $___________

AM2… deleted CLIN 0011 …AM2

0012 Construct C Rock STA 15+00 to STA 17+00, complete 950 CY $___________ $___________

0013 Construct B Rock STA 15+00 to STA 17+00, complete 1,400 CY $___________ $___________

0014 Construct A Rock STA 15+00 to STA 17+00, complete 1,500 CY $___________ $___________

Total of Option 1 Items 0009 through 0014: $___________

Item No. Description Qty Unit Unit Price Total Amount

OPTION 2 ITEMS (STA 17+00 to STA 19+00)

0015 Demolish and Remove Existing Revetment STA 17+00 to STA 19+00, complete AM1… 1 Job $___________ $___________

…AM1

0016 Excavation and Embankment Preparation STA 17+00 to STA 19+00, complete 4,000 CY $___________ $___________

AM2… deleted CLIN 0017 …AM2

0018 Construct C Rock STA 17+00 to STA 19+00, complete 950 CY $___________ $___________

0019 Construct B Rock STA 17+00 to STA 19+00, complete 1,400 CY $___________ $___________

0020 Construct A Rock STA 17+00 to STA 19+00, complete 1,500 CY $___________ $___________

Total of Option 2 Items 0015 through 0020: $___________

OPTION 3 ITEMS (STA 19+00 to STA 21+50)

0021 Demolish and Remove Existing Revetment STA 19+00 to STA 21+50, complete AM1… 1 Job $___________ $___________

…AM1

0022 Excavation and Embankment Preparation STA 19+00 to STA 21+50, complete 5,600 CY $___________ $___________

AM2… deleted CLIN 0023 …AM2

0024 Construct C Rock STA 19+00 to STA 21+50, complete 1,175 CY $___________ $___________

0025 Construct B Rock STA 19+00 to STA 21+50, complete 1,750 CY $___________ $___________

0026 Construct A Rock STA 19+00 to STA 21+50, complete 1,875 CY $___________ $___________

Total of Option 3 Items 0021 through 0026: $___________

OPTION 4 ITEMS

0027 Mobilization and Demobilization For Second Year Option Item Work, complete 1 Job $___________ $___________

0028 Pre- and Post-Construction Surveys for Second Year Work, complete 2 EA $___________ $___________

0029 Deconstruct First Year Work From STA 21+50 to 22+00 and Prepare Transition For Second Year Work, complete 1 Job $___________ $___________

Total of Option 4 Items 0027 through 0029: $___________

Total of All Items 0001 through 0029: $___________

NOTES:

1. ESTIMATED VOLUMES: The volumes shown in the “Qty” column for all unit priced items measured by the cubic yard (CY) above are estimated quantities. Actual quantities may vary. Offerers shall reference the following:

FAR 52.217-7 Option for Increased Quantity – Separately Priced Line Item FAR 52.211-18 Variation in Estimated Quantity AM2… deleted text …AM2

2. EXERCISE OF OPTIONS: The Government intends to award, subject to availability of funds, the base and option items in order to construct the entire project from STA 10+00 to STA 22+00 in the first year utilizing only one mobilization and demobilization. If full funding is not available at time of award, then the Government may exercise a second year of construction to complete any remaining work subject to availability of funds. Offerers shall reference the following:

FAR 52.211-10 Commencement, Prosecution, and Completion of Work FAR 52.211-12 Liquidated Damages – Construction FAR 52.217-5 Evaluation of Options

FAR 52.217-7 Option for Increased Quantity – Separately Priced Line Item FAR 52.232-18 Availability of Funds

EVALUATION OF BIDS:

1. AWARD: Award shall be made to the low, responsive, responsible bidder as determined in accordance with 52.217-5 Evaluation of Options. Evaluation and acceptance of options will not obligate the Government to exercise the options.

2. INCOMPLETE BIDS: Failure to submit a bid on all items in the bid/CLIN schedule will result in an incomplete bid and the bid shall be rejected. Job or unit prices must be shown for each item within the schedule.

3. ARITHMETIC DISCREPANCIES:

(A) For the purpose of initial evaluation of bids, the following shall be utilized in resolving arithmetic discrepancies found on the face of bid/CLIN schedules as submitted by the bidder:

I. Obviously misplaced decimal points shall be corrected;

II. Discrepancy between unit price and extended price, the unit price shall govern;

III. Apparent errors in extension of unit prices shall be corrected;

IV. Apparent errors in addition of job and extended unit prices shall be corrected.

(B) For the purpose of bid evaluation, the Government shall proceed on the assumption that the bidder intends their bid to be evaluated on the basis of unit prices, the total arrived at by resolution of arithmetic discrepancies as provided above, and the bid shall be so reflected on the abstract of bids.

(C) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

4. SPECIAL OFFER CONDITION: If a modification to a bid based on unit prices is submitted which provides for a lump sum adjustment to the total bid price, the application of the lump sum adjustment to each unit price in the bid/CLIN schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the bid/CLIN schedule.

-- END OF BID/CLIN SCHEDULE --

AM2

SPECIFICATIONS

US Army Corps of Engineers Alaska District

NIL003

(P2 No. 476878)

NINILCHIK HARBOR REVETMENT

REPLACEMENT

NINILCHIK, ALASKA

AM1… W911KB-22-B-0003 …AM1

AM2… February 10, 2022 …AM2

(INTENTIONALLY LEFT BLANK)

AM2 NINILCHIK HARBOR REVETMENT REPLACEMENT NIL003

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 73 00.00 29

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

1.2 GENERAL SCR'S

1.2.1 SCR-GE030 Certificates Of Compliance And Lab Test Report:

1.2.2 SCR-GE070 Requirements For Contractors Performance Evaluation:

1.2.3 SCR-GE104 Veterans Employment Emphasis for USACE Contracts

1.2.4 SCR-GE112 Equipment Ownership and Operating Expense Schedule

(MAR 1995)

1.2.5 SCR-GE113 Payment for Materials Delivered Off-Site

1.2.6 SCR-GE115 Basis For Settlement Of Proposals

1.3 SAFETY/SITE/SECURITY SCR'S

1.3.1 SCR-SS010 Safety And Health Requirements Manual:

1.3.2 SCR-SS020 Signal Lights:

1.3.3 SCR-SS030 Communication Security:

1.3.4 SCR-SS040 Haul Roads:

1.3.5 SCR-SS060 Preservation Of Historical, Archaeological & Cultural

Resources:

1.3.6 SCR-SS070 Time Extensions For Unusually Severe Weather (ER

415-1-15, 31 OCT 89):

1.4 CIVIL WORKS SCR'S

1.4.1 SCR-CW010 Damage To Work:

1.4.2 SCR-CW060 Environmental Litigation:

1.4.3 SCR-CW070 CorpsWatch/iWatch Training

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

DOCUMENT 00 73 00.00 29 Page 1

SECTION 00 73 00.00 29

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

33 CFR 81 Navigation and Navigable Waters (International Navigation)

33 CFR 84 Navigation and Navigable Waters (Inland Navigation)

33 CFR 89 Navigation and Navigable Waters (Inland Navigation)

1.2 GENERAL SCR'S

1.2.1 SCR-GE030 Certificates Of Compliance And Lab Test Report:

SEE SECTION 01 33 00: SUBMITTAL PROCEDURES. Any certificates required for demonstrating proof of compliance of materials with specification requirements shall be executed in 3 copies. Each certificate shall be signed by an official authorized to certify on behalf of the manufacturing company and shall contain the name and address of the Contractor, the project name and location, and the quantity and date or dates of shipment or delivery to which the certificates apply. Copies of laboratory test reports submitted with certificates shall contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies. Certification shall not be construed as relieving the Contractor from furnishing satisfactory material, if, after tests are performed on selected samples, the material is found not to meet the specific requirements.

1.2.2 SCR-GE070 Requirements For Contractors Performance Evaluation:

The Government will evaluate the contractor's performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), a web-based system (https://www.cpars.gov/). After an evaluation (interim or final) is generated by the Government, the contractor will only have the ability to access, review and comment on the evaluation for a period of 60 days. Contractors are highly encouraged to review soonest upon notice of a rated assessment from CPARS. If the Contractor fails to review and or comment on the evaluation within the

DOCUMENT 00 73 00.00 29 Page 2

60-day period, the evaluation returns to the Government. The Government then finalizes the evaluation without any Contractor comments. CPARS User Manual and other useful tools for Contractors/Entities are available at https://www.cpars.gov/help.htm. The contractor shall provide the Contacting Officer the primary contact name and email address in order to receive the initial email and to access the system.

1.2.3 SCR-GE104 Veterans Employment Emphasis for USACE Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal employment information for Veterans (FEDSHIREVETS) at https://www.fedshirevets.gov/ Department of Labor Veterans Employment & Training Services https://www.dol.gov/agencies/vets/ Department of Veterans Affairs-Veterans Opportunity to Work (VOW) to Hire Heros Act of 2011 https://benefits.va.gov/vow/ Army Wounded Warrior Program -https://wtc.army.mil/modules/employers/el-hireOurSoldiers.html U.S. Chamber of Commerce Foundation-Hiring Our Heros https://www.uschamberfoundation.org/hiring-our-heroes Employer Guide to Hiring Veterans - Reference Material https://www.dol.gov/veterans/hireaveteran/ pdf/Employer-Guide-to-Hire-Veterans-June-2018.pdf (not a clickable link)

1.2.4 SCR-GE112 Equipment Ownership and Operating Expense Schedule (MAR 1995)

(a) This clause does not apply to terminations. See SCR-GE115 of this section and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region IX. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was

DOCUMENT 00 73 00.00 29 Page 3 performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

1.2.5 SCR-GE113 Payment for Materials Delivered Off-Site

(a) Pursuant to FAR 52.232-5, Payments Under Fixed Price Construction Contracts, materials delivered to the contractor at locations other than the site of the work may be taken into consideration in making payments if included in payment estimates and if all the conditions of the General Provisions are fulfilled. Payment for items delivered to locations other than the work site shall be limited to:

(1) Materials required by the technical provisions; or

(2) Materials that have been fabricated to the point where they are identifiable to an item of work required under this contract; or

(3) Items specifically listed below.

Payment for rock produced and stored at the quarry will be made only after passing all rock quality and gradation tests in SECTION 35 31 19; this includes materials to be used for A Rock, B Rock and C Rock. These materials shall be stored in separate stockpiles for each gradation of material. Payment may be made for up to 35% of the value of the contract line item for gradation of material.

Payment for materials delivered off-site shall be made only after receipt of paid invoices listing the value of material and labor incorporated in the items along with a canceled check showing the prime contractor's title to the items delivered off site. Payment for materials delivered off-site shall be limited to the following items: Items approved for payment by the Contracting Officer, or their representative.

1.2.6 SCR-GE115 Basis For Settlement Of Proposals

Actual costs will be used to determine equipment costs for a settlement proposal submitted on the total cost basis under FAR 49.206-2(b). In evaluating a terminations settlement proposal using the total cost basis, the following principles will be applied to determine allowable equipment costs:

(1) Actual costs for each piece of equipment, or groups of similar serial or series equipment, need not be available in the contractor's accounting records to determine total actual equipment costs.

(2) If equipment costs have been allocated to a contract using

DOCUMENT 00 73 00.00 29 Page 4 predetermined rates, those charges will be adjusted to actual costs.

(3) Recorded job costs adjusted for unallowable expenses will be used to determine equipment operating expenses.

(4) Ownership costs (depreciation) will be determined using the contractor's depreciation schedule (subject to the provisions of FAR 31.205-11).

(5) License, taxes, storage and insurance costs are normally recovered as an indirect expense and unless the contractor charges these costs directly to contracts, they will be recovered through the indirect expense rate.

AM2... deleted paragraphs 1.2.7 and 1.2.8 ...AM2

1.3 SAFETY/SITE/SECURITY SCR'S

1.3.1 SCR-SS010 Safety And Health Requirements Manual:

EM 385-1-1 and its changes are available at https://www.usace.army.mil/Missions/Safety-and-Occupational-Health/.

The Contractor shall be responsible for complying with the current edition and all changes posted on the web (see web address above) as of the effective date of this solicitation and shall comply with the version in effect on the contract award date. This EM 385-1-1 shall remain in effect throughout the life of the contract.

1.3.2 SCR-SS020 Signal Lights:

The Contractor shall display signal lights and conduct its operations in accordance with the General Regulations of the Department of the Army and of the Coast Guard governing lights and day signals to be displayed by towing vessels with tows on which no signals can be displayed; vessels working on wrecks, dredges, and vessels engaged in laying cables or pipe or in submarine or bank protection operations, lights to be displayed on dredge pipe lines, and day signals to be displayed by vessels of more than 65 feet in length moored or anchored in a fairway or channel, and the passing by other vessels of floating plant working in navigable channels, as set forth in Commandant U.S. Coast Guard Instruction M16672.2, Navigation Rules: International-inland (COMDTINST M16672.2) of 33 CFR 81 Appendix A (International) and 33 CFR 84 through 33 CFR 89 (Inland) as applicable.

1.3.3 SCR-SS030 Communication Security:

All communications with DOD organizations are subject to COMSEC review.

Contractor personnel shall be aware that telecommunications networks are continually subject to intercept by unfriendly intelligence organizations.

The DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls originating from or terminating at DOD organizations. Therefore, civilian Contractor personnel are advised that any time they place a call to or receive a call from Alaska District offices or Resident Engineer offices located on military installations, they are subject to COMSEC procedures. The Contractor will assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with official DOD information.

DOCUMENT 00 73 00.00 29 Page 5

1.3.4 SCR-SS040 Haul Roads:

Whenever practical, one-way haul roads shall be used on this contract.

Haul roads built and maintained for this work shall comply with the following:

1. One-way haul roads for off-the-road equipment; e.g., belly dumps, scrapers, and off-the-road trucks shall have a minimum usable width of 25 feet. One-way haul roads for over-the-road haulage equipment only (e.g., dump trucks, etc.) may be reduced to a usable width of 15 feet.

When the Contracting Officer determines that it is impractical to obtain the required width for one-way haul roads (e.g., a road on top of a levee), a usable width of not less than 10 feet may be approved by the Contracting Officer, provided a positive means of traffic control is implemented. Such positive means shall be signs, signals, and/or signalman and effective means of speed control.

2. Two-way haul roads for off-the-road haulage equipment shall have a usable width of 60 feet. Two-way haul-roads for over-the-road haulage equipment only may be reduced to a usable width of 30 feet.

3. Haul roads shall be graded and otherwise maintained to keep the surface free from potholes, ruts, and similar conditions that could result in unsafe operation.

4. Grades and curves shall allow a minimum sight distance of 200 feet for one-way roads and 300 feet for two-way roads. Sight distance is defined as the centerline distance an equipment operator (4.5 feet above the road surface) can see an object 4.5 feet above the road surface. When conditions make it impractical to obtain the required sight distance (e.g., ramp over levees), a positive means of traffic control shall be implemented.

5. Dust abatement shall permit observation of objects on the roadway at a minimum distance of 300 feet.

6. Haul roads shall have the edges of the usable portion marked with posts at intervals of 50 feet on curves and 200 feet maximum elsewhere. Such markers shall extend 6 feet above the road surface and, for nighttime haulage, be provided with reflectors in both directions.

1.3.5 SCR-SS060 Preservation Of Historical, Archaeological & Cultural Resources:

A. No known historical, archeological and cultural resources have been identified within the Contractor's construction boundary as designated on the contract drawings.

B. If, during construction activities, the Contractor observes items that might have historical or archeological value, such observations shall be reported immediately to the Contracting Officer so that the appropriate authorities may be notified and a determination can be made as to their significance and what, if any, special disposition of the finds should be made. The Contractor shall cease all activities that may result in the

DOCUMENT 00 73 00.00 29 Page 6 destruction of these resources and shall prevent its employees from trespassing on, removing, or otherwise damaging such resources.

1.3.6 SCR-SS070 Time Extensions For Unusually Severe Weather (ER 415-1-15, 31 OCT 89):

A. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled "DEFAULT (FIXED PRICE CONSTRUCTION)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

1. The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

2. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

B. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay Work Days Based on a 5-Day Work Week

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

19 17 13 12 19 10 9 14 18 20 17 17

C. Upon acknowledgement of the Notice to Proceed and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and the resultant impact to normally scheduled work. Actual adverse weather delays days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather days exceeds the number of days anticipated in Paragraph B, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a modification in accordance with the Contract Clause entitled "DEFAULT (FIXED-PRICE CONSTRUCTION)".

1.4 CIVIL WORKS SCR'S

1.4.1 SCR-CW010 Damage To Work:

The responsibility for damage to any part of the permanent work shall be as set forth in the clause of the contract entitled "Permits and Responsibilities". However, if, in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood or earthquake, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound

DOCUMENT 00 73 00.00 29 Page 7 engineering and construction practices in the conduct of the work, the Contractor shall make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or lump sum prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or lump sum prices applicable to any part of such work an equitable adjustment pursuant to Clause, "Changes", of the contract, will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except, as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

1.4.2 SCR-CW060 Environmental Litigation:

A. If the performance of all or part of the work is suspended, delayed, or interrupted due to an order of a court of competent jurisdiction as a result of environmental litigation, as defined below, the Contracting Officer, at the request of the Contractor, shall determine whether the order is due in any part to the acts or omissions of the Contractor or subcontractor at any tier not required by the terms of this contract. If it is determined that the order is not due in any part to acts or omissions of the Contractor or a subcontractor at any tier other than as required by the terms of this contract, such suspension, delay, or interruption shall be considered as if ordered by the Contracting Officer in the administration of this contract under the terms of the "Suspension of Work" clause of this contract. The period of such suspension, delay or interruption shall be considered unreasonable, and an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) as provided in that clause, subject to all the provisions thereof.

B. The term "environmental litigation", as used herein, means a lawsuit alleging that the work will have an adverse effect on the environment or that the Government has not duly considered, either substantively or procedurally, the effect of the work on the environment.

1.4.3 SCR-CW070 CorpsWatch/iWatch Training

The contractor and all associated sub-contractors shall receive a brief/training on the local suspicious activity reporting program, Corps Watch. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the Contracting Officer's Representative (COR) NLT 5 calendar days after the completion of the training. Information regarding the Corps Watch program is available at: https://www.poa.usace.army.mil/Portals/34/docs/AKdistrict/iWatchUSACE Contractors28April16.pdf

PART 2 PRODUCTS

Not Used

DOCUMENT 00 73 00.00 29 Page 8

PART 3 EXECUTION

Not Used

-- End of Section --

DOCUMENT 00 73 00.00 29 Page 9

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00.00 10

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 SINGLE JOB PAYMENT ITEMS

1.1.1 Mobilization and Demobilization

1.1.1.1 Payment

1.1.1.2 Unit of Measure

1.1.2 Demolish and Remove Existing Revetment

1.1.2.1 Payment

1.1.2.2 Unit of Measure

1.2 UNIT PRICE PAYMENT ITEMS

1.2.1 Excavation and Embankment Preparation

1.2.1.1 Payment

1.2.1.2 Measurement

1.2.1.3 Unit of Measure

1.2.2 Construct C Rock, B Rock, or A Rock

1.2.2.1 Payment

1.2.2.2 Measurement

1.2.2.3 Unit of Measure

1.2.3 Construction Surveys

1.2.3.1 Payment

1.2.3.2 Unit of Measure

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 22 00.00 10 Page 1

SECTION 01 22 00.00 10

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 SINGLE JOB PAYMENT ITEMS

Payment items for the work of this contract for which contract job payments will be made are listed in the BID/CLIN SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.1.1 Mobilization and Demobilization

1.1.1.1 Payment

Payment will be made for costs associated with mobilization and demobilization, as defined in SECTION 00 72 00 Contract Clause 252.236-7004

PAYMENT FOR MOBILIZATION AND DEMOBILIZATION.

1.1.1.2 Unit of Measure

Unit of measure: Job.

AM2... 1.1.2 Demolish and Remove Existing Revetment

1.1.2.1 Payment

Payment will be made for costs to demolish and remove the existing revetment and groins within the construction boundary. This includes surveying, excavating, transporting, and disposing of the revetment and groin components and all other incidentals necessary to complete this work in accordance with the specifications and drawings.

1.1.2.2 Unit of Measure

Unit of measure: Job. ...AM2

1.2 UNIT PRICE PAYMENT ITEMS

Payment items for the work of this contract on which the contract unit price payments will be made are listed in the BID/CLIN SCHEDULE and described below. The unit price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price

SECTION 01 22 00.00 10 Page 2 items. Work paid for under one item will not be paid for under any other item.

1.2.1 Excavation and Embankment Preparation

1.2.1.1 Payment

AM2... Payment will be made for costs to prepare the embankment for placement of filter rock and rip rap after the existing revetment has been removed. This includes surveying, excavating, transporting, and placing of classified materials, defined in Section 31 00 00 EARTHWORK, and all other incidentals associated with preparing the embankment slope in accordance with the specifications and drawings. Deviation in the actual quantity, either above or below the estimated quantity shown, shall not be made a basis for a claim for adjustment in the contract unit price, except as otherwise specified in SECTION 00 72 00 Contract Clauses FAR 52.211-18 Variation in Estimated Quantity. ...AM2

1.2.1.2 Measurement

Measurement by the cubic yard for excavation and embankment preparation within the construction boundary shall be computed by comparing surveys and calculating the net volume of material removed and placed as specified in SECTION 31 09 13.00 29 SURVEYS (Civil Works).

1.2.1.3 Unit of Measure

Unit of measure: Cubic yard (CY).

1.2.2 Construct C Rock, B Rock, or A Rock

1.2.2.1 Payment

Payment will be made for costs to produce, transport, and place C, B, or A rock on the revetment between the stations (STA) 10+00 and 22+00 and to the design tolerance specified. This includes rock quality testing, site surveying, and all other incidentals associated with these features of work in accordance with the specifications and drawings. Deviation in the actual quantity, either above or below the estimated quantities shown, shall not be made a basis for a claim for adjustment in the contract unit price, except as otherwise specified in Section 00 72 00 Contract Clause FAR 52.211-18 Variations in Estimated Quantities.

1.2.2.2 Measurement

Measurement by the cubic yard for C, B and A rock within the construction boundary shall be computed by comparing surveys and calculating the net volume of material placed as specified in Section 31 09 13.00 29 SURVEYS (Civil Works).

1.2.2.3 Unit of Measure

Unit of measure: Cubic yard (CY).

1.2.3 Construction Surveys

1.2.3.1 Payment

Payment will be made at the contract unit price for each survey and shall

SECTION 01 22 00.00 10 Page 3 constitute full compensation for performing the pre-construction and post-construction surveys as specified in Section 31 09 13.00 29 SURVEYS (Civil Works). Under no circumstances will any payment be made for a survey until all requirements of Section 31 09 13.00 29, applicable to that survey, have been met.

1.2.3.2 Unit of Measure

Unit of measure: each (EA).

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 22 00.00 10 Page 4

Controlled Unclassified Information (CUI) Only

Bid Inquiry Contractor Report All Inquiries Resolved Between 15-Feb-22 and 15-Feb-22

Project: Ninilchik Harbor, Ninilchik, AK Review: W911KB22B0003 (00001) (sorted by CommentID ) Displaying 14 inquiries.

Id Discipline Sheet Detail Spec

9588689 General 00 21 00 4. Bid Guarantee

Comment Classification: Controlled Unclassified Information (CUI)

Please clarify if the Bid Bond only applies to the Base Bid at this time or should also include any/all Options.

On: Feb 04 2022.

Government Response. . The bid guarantee covers the entire bid price (total price of the base plus options). On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9592785 Specifications NA NA Section 00 73 00 (1.2.7)

Comment Classification: Controlled Unclassified Information (CUI)

Specification Section 00 73 00 (1.2.7) references Evaluation of Subdivided Items that contain item numbers that are not part of the CLIN schedule. Would you please clarify what item numbers will be evaluated for this project?

On: Feb 08 2022.

Government Response. . Specs will be amended to remove reference to subdivided items On: Feb 15

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594441 Civil Page 39 Clause 52.211-10

Comment Classification: Controlled Unclassified Information (CUI)

Table lists CLIN 1 thru 8 to be completed by 12-31-23, is this correct?

On: Feb 09 2022.

Government Response. . correct On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594454 Civil Page 39 Clause 52.211-10

Comment Classification: Controlled Unclassified Information (CUI)

Table lists 44 CLIN items, CLIN table lists 29, please clarify.

On: Feb 09 2022.

Government Response. . Amendment 1 to solicitation specs removes the additional CLINS in clause 52.211-10 On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594458 Civil 1.4.3 Corps Watch Training

Comment Classification: Controlled Unclassified Information (CUI)

Could not find information at website referenced. Please advise.

On: Feb 09 2022.

Government Response. . Copy/pasted link from specs and it worked for me. See attached pdf - this contains 25 slides. You will need to use a supported browser (Chrome works for me)to view the video links found in the pdf On: Feb 15 2022

Page 1 of 3ProjNet: Logged In User

2/15/2022https://www.projnet.org/projnet/binKornHome/index.cfm

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594460 Civil 1.4.3 Corps Watch Training

Comment Classification: Controlled Unclassified Information (CUI)

Approximately how long does the Corps Watch training last?

On: Feb 09 2022.

Government Response. . When using the link found in the specs (need to use a supported browser - Chrome worked for me) you will get a pdf with 25 slides. Within those slides are 3 videos totaling 9 minutes 11 seconds On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594462 Civil C-101

Comment Classification: Controlled Unclassified Information (CUI)

Can the Contractor shut down the beach on the Cove side during construction?

On: Feb 09 2022.

Government Response. . No, contractor can't shut down the beach entirely. Reference Section 01 19

40.00 29, 1.9 Scheduling of work and 1.15 Coordination of Work. Also reference Section 01 50 00 Temporary Construction Facilities and Controls, and Section 01 57 20.01 29 Environmental Protection 1.9, j.

On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594480 Civil C-101 01 45 00.00 10 3.4.1

Comment Classification: Controlled Unclassified Information (CUI)

Is the contractor required to have a QC Representative at the Quarry Continuously during production?

On: Feb 09 2022.

Government Response. . CQC staff is not required to be continuously present at the quarry during production. However, administration of the CQC system and plan will cover both onsite and offsite work and a sufficient number of CQC staff are required to ensure safety and contract compliance – Section 01 45

00.00 10-3.3. Also note rock testing requirements in Section 35 31 19. On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594482 Civil C-101

Comment Classification: Controlled Unclassified Information (CUI)

Will the contractor be required to build a haul road on the beach?

On: Feb 09 2022.

Government Response. . Contractor will not be required to build a haul road on the beach. Haul road requirements can be found in Section 00 73 00.00 29 Special Contract Requirements SCR-SS040 Haul Roads, Section 01 19 40.00 29 Special Items Civil Works-1.17. Also note that tracked and wheeled vehicles are prohibited in the flowing waters of Ninilchik River from 16 May to 30 November – Section 01 57 20.01 29 Environmental Protection. On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594490 Civil 01 19 40.00 29 Par 1.12

Comment Classification: Controlled Unclassified Information (CUI)

What is the furthest distance the government quarters can be from the job site?

On: Feb 09 2022.

Government Response. . Quarters within the surrounding community, so the Government representative can drive to project site in a reasonable amount of time On: Feb 15 2022

Page 2 of 3ProjNet: Logged In User

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594499 Civil 52.236-27 b

Comment Classification: Controlled Unclassified Information (CUI)

Contractor had technical issues attending the pre-bid conference call. Is there a recording of the call available?

On: Feb 09 2022.

Government Response. . Agenda and meeting minutes are available in amendment 1 of the solicitation specs On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594501 Civil C-101

Comment Classification: Controlled Unclassified Information (CUI)

12. Can contractor work from the beach at low tide?

On: Feb 09 2022.

Government Response. . Construction activities must take place above +10 feet MLLW to comply with Special Area Permit requirements concerning Clam Gulch Critical Habitat. On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9594503 Civil C-101

Comment Classification: Controlled Unclassified Information (CUI)

Can Contractor off load material on beach?

On: Feb 09 2022.

Government Response. . Offloading material from the beach is permitted. Offloading must take place above +10 feet MLLW. Also reference Section 01 57 20.01 29-1.9,j - "rock fill and construction demo debris shall be temporarily stored/stockpiled on the existing roadway above +18.4 feet MLLW or immediately removed from the construction boundary to the max extent possible." On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

9599124 Civil C301 C301

Comment Classification: Controlled Unclassified Information (CUI)

Do the Design Elevations listed in the plan correlate directly to the Tidal Elevations given in published charts and tide books? If not, what is the correction factor needed to correlate the two datums.

On: Feb 11 2022.

Government Response. . Design is referenced to MLLW as shown in the plans so there isn't any adjustment needed. On: Feb 15 2022

Current Request Status: Request Closed

Information for this report is procurement sensitive.

Report Complete

Controlled Unclassified Information (CUI) Only Patent 11/892,984 ProjNet property of ERDC since 2004.

Page 3 of 3ProjNet: Logged In User

Unclassified

ARMY iWATCH

Always Ready. Always Alert.

Because someone is depending on you.

1Unclassified iWATCH Because

Boston Marathon Bombing

Always Ready. Always Alert.

Because someone is depending on you.Unclassified

Boston Marathon Bombing

- RAND May 13th, 2013, Crowd-sourcing Our Security by Brian Michael Jenkins

The investigation of the Boston Marathon bombing highlighted growing public participation in protecting communities against terrorism Shocked by the attack Bostonians were eager toterrorism. Shocked by the attack, Bostonians were eager to assist authorities in running the bombers down before they could strike again. Spectators provided police with their videos of the event. They assisted in identifying the bombers. They obeyed the controversial order to stay off the streets. It was a citizen's tip that led to the capture of the second suspect.

Always Ready. Always Alert.

Because someone is depending on you.Unclassified p p p

2010 Times Square Bombing Attempt

The SUV was parked near a theater where the musical “The Lion King” was p g being performed. The bomb inside it had cheap-looking alarm clocks connected to a 16-ounce can filled with fireworks, which were apparently intended to detonate gas cans and set off propane tanks in a chain reaction “to cause mayhem to create casualties ” police Commissioner Raymond Kelly

“Hundreds of lives” may have been saved Saturday night by the quick action of di iti d l f t th iti h th ki SUV cause mayhem, to create casualties,” police Commissioner Raymond Kelly said.

Always Ready. Always Alert.

Because someone is depending on you.Unclassified ordinary citizens and law enforcement authorities who saw the smoking SUV parked in Times Square.” -- President Barack H. Obama

Citizens Reporting

Citizen tips in the previous two vignettes played a critical roll.

“Citizen tips to local law enforcement are what the fight against domestic terrorism is built on. Local police are one of the best tools Uncle Sam has to thwart home-grown terrorists…the feet on the street ”street.”

FBI Director Robert Mueller III in a 2006 speech

Always Ready. Always Alert.

Are we Safer Now then 2001?

Unclassified/FOUO

The leaders of the House and Senate Intelligence itt id S d D b 1st 2013 th t t i tcommittees said Sunday December 1st, 2013, that terrorists have gained ground in the past two years and that the United States is not any safer than it was at the outset of 2011.

Several dozen suspected terrorist bomb makers includingSeveral dozen suspected terrorist bomb makers, including some believed to have targeted American troops, may have mistakenly been allowed to move to the United States as war refugees, according to FBI agents investigating the remnants of roadside bombs recovered from Iraq and Afghanistan. –ABC News November 20th, 2013

Always Ready. Always Alert.

Because someone is depending on you.Unclassified

Afghanistan. ABC News November 20 , 2013

Army iWATCHy

Please view Army iWATCH video at this link: http://youtu.be/MwJE2GsXHNgp y g

Always Ready. Always Alert.

What is iWATCH

An Education and Reporting Program p g g that is endorsed by police chiefs across the U S which teaches people how tothe U.S. which teaches people how to detect suspicious behavior and encourages them to report itencourages them to report it.

Always Ready. Always Alert.

iWATCH Began

IWATCH was first developed by the Los Angeles PoliceIWATCH was first developed by the Los Angeles Police Department to encourage and enable members of the community to help protect their community by identifying d ti i i b h i k t b i t dand reporting suspicious behavior known to be associated with terrorist activities.

According to the San Jose Mercury News June 3 edition, when iWATCH was first revealed in October 2009, then- LAPD P li Chi f Willi B tt id it "i t d d tLAPD Police Chief William Bratton said it was "intended to be the next evolution of keeping America safe…”

Always Ready. Always Alert.

iWATCH Evolves iWATCH quickly spread across the united states and the q y p concept was adopted by the federal government and law enforcement agencies a crossed the country. The United States Army was no exceptionArmy was no exception.

This nationwide campaign creates partnerships between military and civilian organizations. Particularly in informationmilitary and civilian organizations. Particularly in information sharing. Such information or cooperation may reveal a piece of the puzzle that thwarts a terrorist plot.

Consequently, iWatch empowers Soldiers, civilian employees, contractors, their family members, as well as civilian visitors with protecting places where they live work and…