Amendment_1_package.pdf

W911KB-17-R-0001

EIE376

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

PROJECT TITLE/LOCATION: EIE376 F-35 Hangar Propulsion MX/Dispatch, Eielson AFB Alaska

a. This amendment provides changes to the solicitation as indicated on the continuation pages of this document.

b. PROPOSAL DUE DATE REMAINS 20 April 2017 at 1400 hours ALASKA TIME. Proposals shall be submitted in accordance w ith Section 00 21 00, paragraph 1.12, Proposal Submittals.

c. YOU ARE REQUIRED TO ACKNOWLEDGE RECEIPT OF THIS AMENDMENT ON THE REVERSE SIDE OF THE STANDARD FORM 1442.

1. CONTRACT ID CODE PAGE OF PAGES

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 10-Apr-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W911KB-17-R-0001

X 9B. DATED (SEE ITEM 11)

16-Mar-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

10-Apr-2017

CODE

U.S. ARMY ENGINEER DISTRICT, AK

CEPOA-CT (W911KB)

PO BOX 6898

JBER AK 99506-0898

W911KB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

a. The following drawings are substituted for the superseded documents/sections:

A-101, A-102, A-103, A-104, G-101, G-102, C-003, C-103, C-125, C-300, E-005

b. The following revised documents/sections are substituted for the superseded documents/sections. The identifier “AM 01” appears before and after new and/or revised materials, except as noted below.

REQUEST FOR PROPOSAL TABLE OF CONTENTS

Replace entire section

SECTION 00 11 00 – CLIN SCHEDULE

Replace entire section

SECTION 00 73 46 – WAGE DETERMINATIONS SCHEDULES

Replaced with AK170001 dated 04/07/2017

Section 01 78 00 Replace entire section

Section 07 22 00

Section 08 81 00

NOTE: Revisions within the following documents do not contain the above referenced identifiers:

NONE

c. The following sections are deleted:

d. The following documents are added:

SECTION 00 22 11 – PROPOSAL SUBMISSION REQUIREMENTS EVALUATION CRITERIA AND

BASIS OF AWARD ONE STEP - - BEST VALUE

Attachments 1 through 7

SECTION 31 00 00 – EARTHWORK

Attachment 2 – Revised Final Geotechnical Data Report

e. The following revisions are incorporated:

f. Other:

(End of Summary of Changes)

ALL OTHER TERMS AND CONDITIONS SHALL REMAIN THE SAME.

AM#1

F-35A Hangar/Propulsion MX/Dispatch W911KB-17-R-0001

EIE376 RTA

i

REQUEST FOR PROPOSAL

TABLE OF CONTENTS

GENERAL REQUIREMENTS AND TECHNICAL PROVISIONS

DIVISION 01 – GENERAL REQUIREMENTS

01 19 30.00 29 SPECIAL ITEMS FOR EIELSON AFB PROJECTS

01 22 00.00 10 PRICE AND PAYMENT PROCEDURES

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 33 29 SUSTAINABILITY REPORTING

AM#1… DELETED TEXT …AM#1

01 35 26 GOVERNMENT SAFETY REQUIREMENTS

01 36 00.00 29 RADIOACTIVE MATERIALS PROCEDURES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 04.00 29 CONTRACTOR QUALITY CONTROL

01 50 0.04 29 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS FOR EIELSON

AFB PROJECTS

01 57 20.01 29 ENVIRONMENTAL PROTECTION

01 57 34.00 29 STORM WATER POLLUTION PREVENTION MEASURES

01 58 00 PROJECT IDENTIFICATION

01 74 19. CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 91 00. COMMISSIONING

DIVISION 02 – EXISTING CONDITIONS

02 41 00 DEMOLITION

02 61 13 EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL

02 83 13.00 20 LEAD IN CONSTRUCTION

DIVISION 03 – CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

EIE376 RTA

ii

DIVISION 04 – MASONRY

04 20 00 MASONRY

04 22 53 MORTARLESS MASONRY VENEER

DIVISION 05 – METALS

05 12 00 STRUCTURAL STEEL

05 21 00 STEEL JOIST FRAMING

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 51 00 METAL STAIRS

05 51 33 METAL LADDERS

05 52 00 METAL RAILINGS

DIVISION 06 – WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 20 00 FINISH CARPENTRY

06 61 16 SOLID POLYMER (SOLID SURFACING) FABRICATIONS

DIVISION 07 – THERMAL AND MOISTURE PROTECTION

07 21 13 BOARD AND BLOCK INSULATION

07 22 00 ROOF AND DECK INSULATION

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 42 13 METAL WALL PANELS

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 61 14.00 20 STEEL STANDING SEAM ROOFING

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

07 95 00 EXPANSION CONTROL

DIVISION 08 – OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 33 23 OVERHEAD COILING DOORS

08 34 16.20 VERTICAL LIFT FABRIC DOORS

08 36 13 SECTIONAL OVERHEAD DOORS

08 51 13 ALUMINUM WINDOWS

08 60 45 TRANSLUCENT PANELS

08 71 00 DOOR HARDWARE

Attachment 1 – Hangar Hardware Sets iii

08 81 00 GLAZING

DIVISION 09 – FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 62 38 STATIC-CONTROL FLOORING

09 65 00 RESILIENT FLOORING

09 67 23.16 FUEL RESISTIVE RESINOUS FLOORING, 5-COAT SYSTEM

09 68 00 CARPETING

09 90 00 PAINTS AND COATINGS

DIVISION 10 – SPECIALTIES

10 14 00.20 INTERIOR AND EXTERIOR SIGNAGE

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

10 51 13 METAL LOCKERS

DIVISION 12 – FURNISHINGS

12 24 13 ROLLER WINDOW SHADES

12 36 00 COUNTERTOPS

12 48 13 ENTRANCE FLOOR MATS AND FRAMES

12 93 00 SITE FURNISHINGS

DIVISION 13 – SPECIAL CONSTRUCTION

13 48 00 SEISMIC PROTECTION FOR MISCELLANEOUS EQUIPMENT

13 48 00.00 10 SEISMIC PROTECTION FOR MECHANICAL EQUIPMENT

DIVISION 21 – FIRE SUPPRESSION

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

21 13 17.00 10 DRY PIPE SPRINKLER SYSTEM, FIRE PROTECTION

21 13 18.00 10 PREACTION AND DELUGE SPRINKLER SYSTEMS, FIRE PROTECTION

Attachment 1 - UFC 4-211-01

21 13 20.00 20 LOW-LEVEL HIGH EXPANSION FOAM FIRE EXTINGUISHING FOR

AIRCRAFT HANGARS

Attachment 1 - UFC 4-211-01 iv

21 30 00 FIRE PUMPS

DIVISION 22 – PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 15 14.00 40 GENERAL SERVICE COMPRESSED-AIR SYSTEMS, LOW PRESSURE

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 00 99 AIRCRAFT COOLING UNITS

23 05 15 COMMON PIPING FOR HVAC

23 05 48.00 40 VIBRATION AND SEISMIC CONTROLS FOR HVAC PIPING AND

EQUIPMENT

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 23.00 29 DIRECT DIGITAL CONTROL FOR HVAC, BACNET, CEPOA SPECIFIC

23 21 13.00 20 LOW TEMPERATURE WATER (LTW) HEATING SYSTEM

23 22 13.35 40 STEAM TRAPS

23 22 23.00 40 STEAM CONDENSATE PUMPS

23 22 25.00 40 STEAM VALVES

23 31 13.00 40 METAL DUCTS

23 35 00.00 10 OVERHEAD VEHICLE TAILPIPE EXHAUST REMOVAL SYSTEM(S)

23 37 13.00 40 DIFFUSERS, REGISTERS, AND GRILLS

23 73 13.00 40 MODULAR INDOOR CENTRAL-STATION AIR-HANDLING UNITS

DIVISION 26 – ELECTRICAL

26 05 00.00 50 COMMON WORK RESULTS FOR ELECTRICAL - HEADBOLT OUTLET

INSTALLATION

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 08 00 APPARATUS INSPECTION AND TESTING

26 12 19.10 THREE-PHASE PAD-MOUNTED TRANSFORMERS

26 13 01 PAD-MOUNTED DEAD-FRONT AIR INSULATED SWITCHGEAR

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 13 SWITCHBOARDS

26 27 14.00 20 ELECTRICITY METERING

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 29 23 VARIABLE FREQUENCY DRIVE SYSTEMS UNDER 600 VOLTS

26 35 44 270 VDC SOLID STATE GROUND POWER UNIT

26 41 00 LIGHTNING PROTECTION SYSTEM

v

26 51 00 INTERIOR LIGHTING

DIVISION 27 – COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 10 05 ELECTRONIC SECURITY SYSTEMS (ESS)

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

Attachment 1 - UFC 4-211-01

DIVISION 31 – EARTHWORK

31 00 00 EARTHWORK

Attachment 1 - EIE376 F35A Hangar Propulsion MX Dispatch Data Report

AM#1… Attachment 2 – Revised Final Geotechnical Data Report, EIE379, F35A

Hangar/Squad Ops/AMU …AM#1

31 05 19 GEOTEXTILE

31 09 20.00 29 FIELD SCREEN TESTING OF SOILS FOR CHEMICAL CONTAMINATION

31 11 00 CLEARING AND GRUBBING

31 23 29 GROUND THAWING

31 23 30 DEEP DYNAMIC SOIL IMPROVEMENT

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 05 33 LANDSCAPE ESTABLISHMENT

32 11 23 AGGREGATE BASE COURSE

32 12 10 BITUMINOUS TACK COAT

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 11 CONCRETE PAVEMENT FOR AIRFIELDS AND OTHER HEAVY-DUTY

PAVEMENTS

32 13 73 COMPRESSION JOINT SEALS FOR EXTERIOR CONCRETE PAVEMENTS

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 17 23 PAVEMENT MARKINGS

32 31 13 CHAIN LINK FENCES AND GATES

32 92 19 SEEDING

DIVISION 33 – UTILITIES

33 05 29.00 29 WATER DISTRIBUTION SYSTEMS IN UTILIDORS

33 05 33.00 29 SEWERS IN UTILIDORS

EIE376 RTA

vi

33 05 37.00 29 HEAT DISTRIBUTION SYSTEMS IN UTILIDORS AND MANHOLES

33 05 41.00 29 UTILIDOR SYSTEM

33 11 00 WATER DISTRIBUTION

33 32 16 PACKAGED UTILITY WASTEWATER PUMPING STATIONS

33 40 00 STORM DRAINAGE UTILITIES

33 71 01 OVERHEAD TRANSMISSION AND DISTRIBUTION

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

DIVISION 41 – MATERIAL PROCESSING AND HANDLING EQUIPMENT

41 22 13.14 BRIDGE CRANES, OVERHEAD ELECTRIC, TOP RUNNING

- - End of Project Table of Contents - -

PROPOSAL SCHEDULE

F-35A HANGAR/PROPULSION/DISPATCH

EIELSON AFB, ALASKA

AM#1…

BASE ITEMS

Item No.

Description Estimated Quantity

Unit Unit Price Amount

0001 Construct F-35A Hangar/Propulsion/Dispatch within the building 5-foot lines, Complete

1 Job $_________ $_________

0002 Construct site work and utilities beyond the building 5-foot lines, Complete

1 Job $_________ $_________

0003 Provide Temporary Heating independent of existing central steam heating system, Complete

1 Job $_________ $_________

AM#1…

…AM#1

AM#1…Provide construction related sustainability documentation to verify achievement of ISWG Guiding Principles Validation, per spec section 01 33 29, Complete** …AM#1

1 Job $_________ $_________

AM#1…Total of Base Items 0001 thru 0003 & 0011…AM#1 $_________

OPTION ITEMS

Item No.

Description Estimated Quantity

Unit Unit Price Amount

0004 Clear, Excavate and Perform Ground Improvements under the EIE379 Hangar/Squad Ops/AMU facility, Complete **

1 Job $_________ $_________

0005 Remove, Sample and stockpile 1000 Cubic Yards of potentially POL contaminated soil, including construction of Holding Cells, Complete

1000 CY $_________ $_________

0006 Construct North row of parking, including paving, striping and headbolt heaters, Complete **

1 Job $_________ $_________

0007 Construct West access road and parking area for EIE379, including paving, curb and gutter, striping, sidewalk, headbolt heaters and site lighting, and all site work such as drainage, clearing and seeding, Complete **

Item No.

Description Estimated Quantity

Unit Unit Price Amount

0008 Install Standing Seam Metal Roof System (SSMRS) in lieu of SBS Membrane, Complete **

1 Job $_________ $_________

0009 Purchase ACA-1 and ACA-3 avionics cooling units and deliver to site, Complete

1 Job $_________ $_________

0010 Install ACA-1 and ACA-3 avionics Cooling Units, at locations shown on drawings, Complete. If CLIN 0009 is not awarded, ACA-1 and ACA-3 will be Government Furnished, Contractor Installed. ****

AM#1…DELETED TEXT …AM#1

0012 Provide manhole sump pumps, level control, horn/strobe annunciation panels and all associated controls, wiring, and branch circuits, per design drawings, Complete**

1 Job $_________ $_________

0013 Sample, Test and Remove Asbestos Containing Material (ACM), including packaging, storing and transporting, per spec section 01 57 20.01 29, Complete

100 LF $_________ $_________

0014 Sample, Test and Remove lead base paint material, including packaging, storing and transporting, per spec section 02 83 13.00 20, Complete ***

100 SF $_________ $_________

0015 Purchase and deliver to site ACA-2 and ACA-4 avionics cooling units, Complete

1 Job $_________ $_________

0016 Install ACA-2 and ACA-4 avionics cooling units at locations shown on drawings, Complete. If CLIN 0015 is not awarded, ACA-2 and ACA-4 will be Government Furnished, Contractor Installed ****

AM#1…Total of Optional Items 0004 thru 0010 & 0012 thru 016 …AM#1 $_________

TOTALS

Total of Base and Optional Items 0001 thru 0016 $_________

Proposed Contract Duration: ______________

* Work on CLIN 0005 shall be the cost for work identified in Specs 02 61 13 “Excavation and Handling of Contaminated Material” and Section 01 57 20.01 29 “Environmental Protection” that is additional to the requirements of the normal project excavation and the field screening identified in Section 31 09

20.00 29 “Field Screen Testing of Soils for POL Contamination”. For CLIN 0005, the Contractor shall keep a record of the amount of contaminated soil being excavated and disposed of. If the amount of contaminated soil being excavated & disposed of is above 115% or below 85% of the estimated quantity, the equitable adjustment will be in accordance with FAR CLAUSE 52.211-18, VARIATION IN ESTIMATED QUANTITY. This option can be awarded at any time during the Construction Contract period

AM#1…** For CLINs 0004, 0006, 0007, 0008, and 0012, these options items can be awarded up to 30 days following NTP. …AM#1

*** For CLINs 0013 and 0014, the Contractor shall keep a record of the amount of material being removed and disposed of. If the amount of material being removed and disposed of is above 115% or below 85% of the estimated quantity, the equitable adjustment will be in accordance with FAR CLAUSE 52.211-18, VARIATION IN ESTIMATED QUANTITY. These options can be awarded at any time during the Construction Contract period.

**** For CLINs 0009, 0010, 0015, and 0016, these options can be awarded at any time during the Construction Contract period."

EVALUATION OF OFFERS.

1. AWARD: Award will be made in accordance with Section 00 22 11 - EVALUATION FACTORS

FOR AWARD.

2. INCOMPLETE OFFERS: Failure to submit an offer on all items in the schedule constitutes an incomplete offer. Incomplete offers may be rejected. Lump sum or unit prices must be shown for each item within the schedule.

3. EXTENSIONS: All extensions of the unit prices shown will be subject to verification by the Government. In case of variation between the unit price and the extension, the unit price will be considered to be the offer.

4. SPECIAL CONDITION: If a modification to an offer based on unit prices is submitted which provides for a lump sum adjustment to the total estimated cost, the application of the lump sum adjustment to each unit price in the proposal schedule must be stated. If it is not stated, the offeror agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the proposal schedule.

-- END OF PROPOSAL SCHEDULE --

AM#1…

General Decision Number: AK170001 04/07/2017 AK1

Superseded General Decision Number: AK20160001

State: Alaska

Construction Types: Building and Heavy

Counties: Alaska Statewide.

BUILDING AND HEAVY CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories)

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.20 for calendar year 2017 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.20 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2017.

The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2017 1 01/20/2017 2 01/27/2017 3 02/17/2017 4 03/17/2017 5 03/31/2017 6 04/07/2017

ASBE0097-001 01/01/2017

Rates Fringes

Asbestos Workers/Insulator (includes application of all insulating materials protective coverings, coatings and finishings to all types of mechanical systems).........................$ 38.68 20.07

HAZARDOUS MATERIAL HANDLER

(includes preparation, wetting, stripping, removal scrapping, vacuming, bagging, and disposing of all insulation materials, whether they contain asbestos or not, from mechanical systems).........$ 37.38 19.55

* BOIL0502-002 08/01/2016

Rates Fringes

BOILERMAKER......................$ 44.26 28.41

BRAK0001-002 07/01/2016

Rates Fringes

Bricklayer, Blocklayer, Stonemason, Marble Mason, Tile Setter, Terrazzo Worker.....$ 40.81 19.15 Tile & Terrazzo Finisher.........$ 34.79 19.15

CARP1501-001 09/01/2014

Rates Fringes

MILLWRIGHT.......................$ 35.74 21.29

CARP2520-003 09/01/2014

Rates Fringes

Diver Stand-by....................$ 41.65 23.34 Tender......................$ 40.65 23.34 Working.....................$ 81.45 23.34 Piledriver Carpenter...................$ 37.34 23.34 Piledriver; Skiff Operator and Rigger..................$ 37.34 23.34 Sheet Stabber...............$ 36.59 22.59 Welder......................$ 42.90 23.34

DEPTH PAY PREMIUM FOR DIVERS BELOW WATER SURFACE:

50-100 feet $1.00 per foot 101 feet and deeper $2.00 per foot

ENCLOSURE PAY PREMIUM WITH NO VERTICAL ASCENT:

5-50 FEET $1.00 PER FOOT/DAY

51-100 FEET $2.00 PER FOOT/DAY

101 FEET AND ABOVE $3.00 PER FOOT/DAY

SATURATION DIVING:

The standby rate applies until saturation starts. The saturation diving rate applies when divers are under pressure continuously until work task and decompression are complete. the diver rate shall be paid for all saturation hours.

WORK IN COMBINATION OF CLASSIFICATIONS:

Employees working in any combination of classifications within the diving crew (except dive supervisor) in a shift are paid in the classification with the highest rate for that shift.

CARP4059-001 09/01/2014

Rates Fringes

CARPENTER

Carpenter...................$ 37.34 23.34 Lather/Drywall Applicator...$ 36.59 22.59

* ELEC1547-004 04/01/2017

Rates Fringes

CABLE SPLICER....................$ 39.82 3%+25.44

ELECTRICIAN......................$ 39.49 3%+25.69

* ELEC1547-005 04/01/2017

Line Construction

Rates Fringes

CABLE SPLICER....................$ 52.57 3%+30.81

Linemen (Including Equipment Operators, Technician)...........$ 50.52 3%+30.81 Powderman........................$ 48.52 3%+30.81

TREE TRIMMER.....................$ 35.84 3%+22.56

ELEV0019-002 01/01/2017

Rates Fringes

ELEVATOR MECHANIC................$ 53.76 31.585+a+b

FOOTNOTE: a. Employer contributes 8% of the basic hourly rate for over 5 year's service and 6% of the basic hourly rate for 6 months to 5 years' of service as vacation paid credit. b. Eight paid holidays:

New Year's Day; Memorial Day; Independence Day;

Labor Day; Veteran's Day; Thanksgiving Day; Friday after Thanksgiving, and Christmas Day

ENGI0302-002 01/01/2017

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 40.28 22.65

GROUP 1A....................$ 42.04 22.65

GROUP 2.....................$ 39.51 22.65

GROUP 3.....................$ 38.79 22.65

GROUP 4.....................$ 32.58 22.65

TUNNEL WORK

GROUP 1....................$ 44.31 22.65

GROUP 1A...................$ 46.24 22.65

GROUP 2....................$ 43.46 22.65

GROUP 3....................$ 42.67 22.65

GROUP 4....................$ 35.84 22.65

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Asphalt Roller: Breakdown, Intermediate, and Finish; Back Filler; Barrier Machine (Zipper); Beltcrete with power pack and similar conveyors; Bending Machine;

Boat Coxwains; Bulldozers; Cableways, Highlines and Cablecars; Cleaning Machine; Coating Machine; Concrete Hydro Blaster; Cranes-45 tons and under or 150 foot boom and under (including jib and attachments): (a) Hydralifts or Transporters, all track or truck type,(b) Derricks;

Crushers; Deck Winches-Double Drum; Ditching or Trenching Machine (16 inch or over); Drilling Machines, core, cable, rotary and exploration; Finishing Machine Operator, Concrete Paving, Laser Screed, Sidewalk, Curb and Gutter Machine; Helicopters; Hover Craft, Flex Craft, Loadmaster, Air Cushion, All Terrain Vehicle, Rollagon, Bargecable, Nodwell, and Snow Cat; Hydro Ax: Feller Buncher and similar; Loaders (2 1/2 yards through 5 yards, including all attachments): Forklifts with telescopic boom and swing attachment, Overhead and front end, 2 1/2 yards through 5 yards, Loaders with forks or pipe clamps; Loaders, elevating belt type, Euclid and similar types; Mechanics, Bodyman; Micro Tunneling Machine; Mixers: Mobile type w/hoist combination; Motor Patrol Grader; Mucking Machines:

Mole, Tunnel Drill, Horizontal/Directional Drill Operator, and/or Shield; Operator on Dredges; Piledriver Engineers, L. B. Foster, Puller or similar Paving Breaker; Power Plant, Turbine Operator, 200 k.w. and over (power plants or combination of power units over 300 k.w.); Scrapers-through 40 yards; Service Oiler/Service Engineer; Sidebooms-under 45 tons; Shot Blast Machine; Shovels, Backhoes, Excavators with all attachments, and Gradealls (3 yards and under), Spreaders, Blaw Knox, Cedarapids, Barber Greene, Slurry Machine; Sub-grader (Gurries, Reclaimer, and similar types); Tack tractor; Truck mounted Concrete Pumps, Conveyor, Creter; Water Kote Machine; Unlicensed off road hauler

GROUP 1A: Camera/Tool/Video Operator (Slipline), Cranes-over 45 tons or 150 foot (including jib and attachments): (a) Clamshells and Draglines (over 3 yards),

(b) Tower cranes; Licensed Water/Waste Water Treatment Operator; Loaders over 5 yds.; Certified Welder, Electrical Mechanic, Camp Maintenance Engineer, Mechanic (over 10,000 hours); Motor Patrol Grader, Dozer, Grade Tractor, Roto-mill/Profiler (finish: when finishing to final grade and/or to hubs, or for asphalt); Power Plants: 1000 k.w.

and over; Quad; Screed; Shovels, Backhoes, Excavators with all attachments (over 3 yards), Sidebooms over 45 tons;

Slip Form Paver, C.M.I. and similar types; Scrapers over 40 yards;

GROUP 2: Boiler-fireman; Cement Hog and Concrete Pump

Operator; Conveyors (except as listed in group 1); Hoist on steel erection; Towermobiles and Air Tuggers;

Horizontal/Directional Drill Locator;Licensed Grade Technician; Loaders, (i.e., Elevating Grader and Material Transfer Vehicle); Locomotives: rod and geared engines;

Mixers; Screening, Washing Plant; Sideboom (cradling rock drill regardless of size); Skidder; Trencing Machine under 16 inches; Waste/ Waste Water Treatment Operator.

GROUP 3: "A" Frame Trucks, Deck Winches: single power drum;

Bombardier (tack or tow rig); Boring Machine; Brooms-power;

Bump Cutter; Compressor; Farm tractor; Forklift, industrial type; Gin Truck or Winch Truck with poles when used for hoisting; Grade Checker and Stake Hopper; Hoist, Air Tuggers, Elevators; Loaders: (a) Elevating-Athey, Barber Green and similar types (b) Forklifts or Lumber Carrier (on construction job site) (c) Forklifts with Tower (d) Overhead and Front-end, under 2 1/2 yds. Locomotives:Dinkey (air, steam, gas and electric) Speeders; Mechanics (light duty); Oil, Blower Distribution; Post Hole Diggers, mechanical; Pot Fireman (power agitated); Power Plant, Turbine Operator, under 200 k.w.; Pumps-water; Roller-other than Plantmix; Saws, concrete; Skid Steer with all attachments; Straightening Machine; Tow Tractor

GROUP 4: Rig Oiler/Crane Assistant Engineer;Parts and Equipment Coordinator; Swamper (on trenching machines or shovel type equipment); Spotter; Steam Cleaner; Drill Helper.

FOOTNOTE: Groups 1-4 receive 10% premium while performing tunnel or underground work. Rig Oiler/Crane Assistant Engineer shall be required on cranes over 85 tons or over 100 feet of boom.

IRON0751-003 07/01/2015

Rates Fringes

Ironworkers:

BRIDGE, STRUCTURAL,

ORNAMENTAL, REINFORCING

MACHINERY MOVER, RIGGER,

SHEETER, STAGE RIGGER,

BENDER OPERATOR.............$ 36.25 28.05

FENCE, BARRIER INSTALLER....$ 32.75 28.05

GUARDRAIL INSTALLERS........$ 33.75 28.05

GUARDRAIL LAYOUT MAN........$ 33.49 28.05

HELICOPTER, TOWER...........$ 37.25 28.05

LABO0341-005 04/01/2016

Rates Fringes

Laborers: South of the 63rd Parallel & West of Longitude

138 Degrees

GROUP 1.....................$ 30.00 26.17

GROUP 2.....................$ 31.00 26.17

GROUP 3.....................$ 31.90 26.17

GROUP 3A....................$ 35.18 26.17

GROUP 3B....................$ 38.72 23.46

GROUP 4.....................$ 19.57 26.17

TUNNELS, SHAFTS, AND RAISES

GROUP 1....................$ 33.00 26.17

GROUP 2....................$ 34.10 26.17

GROUP 3....................$ 35.09 26.17

GROUP 3A...................$ 38.70 26.17

GROUP 3B...................$ 42.59 23.46

LABORERS CLASSIFICATIONS

GROUP 1: Asphalt Workers (shovelman, plant crew); Brush Cutters; Camp Maintenance Laborer; Carpenter Tenders; Choke Setters, Hook Tender, Rigger, Signalman; Concrete Laborer(curb and gutter, chute handler, grouting, curing, screeding); Crusher Plant Laborer; Demolition Laborer;

Ditch Diggers; Dump Man; Environmental Laborer (asbestos (limited to nonmechanical systems), hazardous and toxic waste, oil spill); Fence Installer; Fire Watch Laborer;

Flagman; Form Strippers; General Laborer; Guardrail Laborer, Bridge Rail Installers; Hydro-Seeder Nozzleman;

Laborers (building); Landscape or Planter; Laying of Decorative Block (retaining walls, flowered decorative block 4 feet and below); Material Handlers; Pneumatic or Power Tools; Portable or Chemical Toilet Serviceman; Pump Man or Mixer Man; Railroad Track Laborer; Sandblast, Pot Tender; Saw Tenders; Scaffold Building and Erecting; Slurry Work; Stake Hopper; Steam Point or Water Jet Operator;

Steam Cleaner Operator; Tank Cleaning; Utiliwalk, Utilidor Laborer and Conduit Installer; Watchman (construction projects); Window Cleaner

GROUP 2: Burning and Cutting Torch; Cement or Lime Dumper or Handler (sack or bulk); Choker Splicer; Chucktender (wagon, airtrack and hydraulic drills); Concrete Laborers (power buggy, concrete saws, pumpcrete nozzleman, vibratorman);

Culvert Pipe Laborer; Cured in place Pipelayer;

Environmental Laborer (marine work, oil spill skimmer operator, small boat operator); Foam Gun or Foam Machine Operator; Green Cutter (dam work); Gunnite Operator; Hod Carriers; Jackhammer or Pavement Breakers (more than 45 pounds);Laying of Decorative Block (retaining walls, flowered decorative block above 4 feet); Mason Tender and Mud Mixer (sewer work); Pilot Car; Plasterer, Bricklayer and Cement Finisher Tenders; Power Saw Operator; Railroad Switch Layout Laborer; Sandblaster; Sewer Caulkers; Sewer Plant Maintenance Man; Thermal Plastic Applicator; Timber Faller, chain saw operator, filer; Timberman

GROUP 3: Alarm Installer; Bit Grinder; Guardrail Machine Operator; High Rigger and tree topper; High Scaler;

Multiplate; Slurry Seal Squeegee Man

GROUP 3A: Asphalt Raker, Asphalt Belly dump lay down; Drill Doctor (in the field); Drillers (including, but not limited to, wagon drills, air track drills; hydraulic drills);

Powderman; Pioneer Drilling and Drilling Off Tugger (all type drills); Pipelayers

GROUP 3B: Grade checker (setting or transfering of grade marks, line and grade)

GROUP 4: Final Building Cleanup

TUNNELS, SHAFTS, AND RAISES CLASSIFICATIONS

GROUP 1: Brakeman; Muckers; Nippers; Topman and Bull Gang;

Tunnel Track Laborer

GROUP 2: Burning and Cutting Torch; Concrete Laborers;

Jackhammers; Nozzleman, Pumpcrete or Shotcrete.

GROUP 3: Miner; Retimberman

GROUP 3A: Asphalt Raker, Asphalt Belly dump lay down; Drill Doctor (in the field); Drillers (including, but not limited to, wagon drills, air track drills; hydraulic drills);

Powderman; Pioneer Drilling and Drilling Off Tugger (all type drills); Pipelayers.

GROUP 3B: Grade checker (setting or transfering of grade marks, line and grade)

Tunnel shaft and raise rates only apply to workers regularly employed inside a tunnel portal or shaft collar.

LABO0942-001 04/01/2016

Rates Fringes

Laborers: North of the 63rd Parallel & East of Longitude 138 Degrees

GROUP 1.....................$ 30.00 26.17

GROUP 2.....................$ 31.00 26.17

GROUP 3.....................$ 31.90 26.17

GROUP 3A....................$ 35.18 26.17

GROUP 3B....................$ 38.72 23.46

GROUP 4.....................$ 19.57 26.17

TUNNELS, SHAFTS, AND RAISES

GROUP 1....................$ 33.00 26.17

GROUP 2....................$ 34.10 26.17

GROUP 3....................$ 35.09 26.17

GROUP 3A...................$ 38.70 26.17

GROUP 3B...................$ 42.59 23.46

LABORERS CLASSIFICATIONS

GROUP 1: Asphalt Workers (shovelman, plant crew); Brush Cutters; Camp Maintenance Laborer; Carpenter Tenders; Choke Setters, Hook Tender, Rigger, Signalman; Concrete Laborer(curb and gutter, chute handler, grouting, curing, screeding); Crusher Plant Laborer; Demolition Laborer;

Ditch Diggers; Dump Man; Environmental Laborer (asbestos (limited to nonmechanical systems), hazardous and toxic waste, oil spill); Fence Installer; Fire Watch Laborer;

Flagman; Form Strippers; General Laborer; Guardrail Laborer, Bridge Rail Installers; Hydro-Seeder Nozzleman;

Laborers (building); Landscape or Planter; Laying of Decorative Block (retaining walls, flowered decorative block 4 feet and below); Material Handlers; Pneumatic or Power Tools; Portable or Chemical Toilet Serviceman; Pump Man or Mixer Man; Railroad Track Laborer; Sandblast, Pot Tender; Saw Tenders; Scaffold Building and Erecting; Slurry Work; Stake Hopper; Steam Point or Water Jet Operator;

Steam Cleaner Operator; Tank Cleaning; Utiliwalk, Utilidor Laborer and Conduit Installer; Watchman (construction projects); Window Cleaner

GROUP 2: Burning and Cutting Torch; Cement or Lime Dumper or Handler (sack or bulk); Choker Splicer; Chucktender (wagon, airtrack and hydraulic drills); Concrete Laborers (power buggy, concrete saws, pumpcrete nozzleman, vibratorman);

Culvert Pipe Laborer; Cured in place Pipelayer;

Environmental Laborer (marine work, oil spill skimmer operator, small boat operator); Foam Gun or Foam Machine Operator; Green Cutter (dam work); Gunnite Operator; Hod Carriers; Jackhammer or Pavement Breakers (more than 45 pounds);Laying of Decorative Block (retaining walls, flowered decorative block above 4 feet); Mason Tender and Mud Mixer (sewer work); Pilot Car; Plasterer, Bricklayer and Cement Finisher Tenders; Power Saw Operator; Railroad Switch Layout Laborer; Sandblaster; Sewer Caulkers; Sewer Plant Maintenance Man; Thermal Plastic Applicator; Timber Faller, chain saw operator, filer; Timberman

GROUP 3: Alarm Installer; Bit Grinder; Guardrail Machine Operator; High Rigger and tree topper; High Scaler;

Multiplate; Slurry Seal Squeegee Man

GROUP 3A: Asphalt Raker, Asphalt Belly dump lay down; Drill Doctor (in the field); Drillers (including, but not limited to, wagon drills, air track drills; hydraulic drills);

Powderman; Pioneer Drilling and Drilling Off Tugger (all type drills); Pipelayers

GROUP 3B: Grade checker (setting or transfering of grade marks, line and grade)

GROUP 4: Final Building Cleanup

TUNNELS, SHAFTS, AND RAISES CLASSIFICATIONS

GROUP 1: Brakeman; Muckers; Nippers; Topman and Bull Gang;

Tunnel Track Laborer

GROUP 2: Burning and Cutting Torch; Concrete Laborers;

Jackhammers; Nozzleman, Pumpcrete or Shotcrete.

GROUP 3: Miner; Retimberman

GROUP 3A: Asphalt Raker, Asphalt Belly dump lay down; Drill Doctor (in the field); Drillers (including, but not limited to, wagon drills, air track drills; hydraulic drills);

Powderman; Pioneer Drilling and Drilling Off Tugger (all type drills); Pipelayers.

GROUP 3B: Grade checker (setting or transfering of grade marks, line and grade)

Tunnel shaft and raise rates only apply to workers regularly employed inside a tunnel portal or shaft collar.

PAIN1959-001 09/01/2015

NORTH OF THE 63RD PARALLEL

Rates Fringes

PAINTER

BRUSH/ROLLER PAINT OR WALL

COVERER.....................$ 32.07 20.01

TAPING, TEXTURING,

STRUCTURAL PAINTING,

SANDBLASTING, POT TENDER,

FINISH METAL, SPRAY,

BUFFER OPERATOR, RADON

MITIGATION, LEAD BASED

PAINT ABATEMENT, HAZARDOUS

MATERIAL HANDLER............$ 32.59 20.01

PAIN1959-002 02/01/2016

SOUTH OF THE 63RD PARALLEL

Rates Fringes

PAINTER

Brush, Roller, Sign, Paper and Vinyl, Swing Stage, Hand Taper/Drywall, Structural Steel, and Commercial Spray............$ 30.31 19.76 Machine Taper/Drywall.......$ 31.56 19.76 Spray-Sand/Blast, Epoxy and Tar Applicator..........$ 31.66 19.76

PAIN1959-003 01/01/2017

NORTH OF THE 63RD PARALLEL

GLAZIER..........................$ 38.63 21.54

PAIN1959-004 07/01/2012

Rates Fringes

FLOOR LAYER: Carpet.............$ 30.09 13.02

PAIN1959-006 01/01/2017

SOUTH OF THE 63RD PARALLEL

Rates Fringes

GLAZIER..........................$ 38.63 20.82

PLAS0867-001 02/01/2016

Rates Fringes

PLASTERER

North of the 63rd parallel..$ 37.25 20.41 South of the 63rd parallel..$ 37.00 20.41

PLAS0867-004 02/01/2016

Rates Fringes

CEMENT MASON/CONCRETE FINISHER

North of the 63rd parallel..$ 37.25 20.41 South of the 63rd parallel..$ 37.00 20.41

* PLUM0262-002 01/01/2017

East of the 141st Meridian

Rates Fringes

Plumber; Steamfitter.............$ 38.02 26.72

PLUM0367-002 07/01/2016

South of the 63rd Parallel

Rates Fringes

Plumber; Steamfitter.............$ 39.85 22.85

PLUM0375-002 07/01/2016

North of the 63rd Parallel

Plumber; Steamfitter.............$ 40.81 24.25

PLUM0669-002 01/01/2015

Rates Fringes

SPRINKLER FITTER.................$ 43.75 22.57

ROOF0189-006 04/01/2016

Rates Fringes

ROOFER...........................$ 42.62 15.50

SHEE0023-003 07/01/2015

South of the 63rd Parallel

Rates Fringes

SHEET METAL WORKER...............$ 40.79 22.38

SHEE0023-004 07/01/2015

North of the 63rd Parallel

Rates Fringes

SHEET METAL WORKER...............$ 45.93 21.44

TEAM0959-003 09/01/2016

Rates Fringes

TRUCK DRIVER

GROUP 1.....................$ 39.59 21.17

GROUP 1A....................$ 40.86 21.17

GROUP 2.....................$ 38.33 21.17

GROUP 3.....................$ 37.51 21.17

GROUP 4.....................$ 36.93 21.17

GROUP 5.....................$ 36.17 21.17

GROUP 1: Semi with Double Box Mixer; Dump Trucks (including rockbuggy and trucks with pups) over 40 yards up to and including 60 yards; Deltas, Commanders, Rollogans and similar equipment when pulling sleds, trailers or similar equipment; Boat Coxswain; Lowboys including attached trailers and jeeps, up to and including 12 axles; Ready-mix over 12 yards up to and including 15 yards); Water Wagon (250 Bbls and above); Tireman, Heavy Duty/Fueler

GROUP 1A: Dump Trucks (including Rockbuggy and Trucks with pups) over 60 yards up to and including 100 yards; Jeeps (driver under load)

GROUP 2: Turn-O-Wagon or DW-10 not self-loading; All Deltas, Commanders, Rollogans, and similar equipment; Mechanics;

Dump Trucks (including Rockbuggy and Trucks with pups) over

20 yards up to and including 40 yards; Lowboys including attached trailers and jeeps up to and including 8 axles;

Super vac truck/cacasco truck/heat stress truck; Ready-mix over 7 yards up to and including 12 yards; Partsman;

Stringing Truck

GROUP 3: Dump Trucks (including Rockbuggy and Trucks with pups) over 10 yards up to and including 20 yards; batch trucks 8 yards and up; Oil distributor drivers; Oil Distributor Drivers; Trucks/Jeeps (push or pull); Traffic Control Technician

GROUP 4: Buggymobile; Semi or Truck and trailer; Dumpster;

Tireman (light duty); Dump Trucks (including Rockbuggy and Truck with pups) up to and including 10 yards; Track Truck Equipment; Grease Truck; Flat Beds, dual rear axle; Hyster Operators (handling bulk aggregate); Lumber Carrier; Water Wagon, semi; Water Truck, dual axle; Gin Pole Truck, Winch Truck, Wrecker, Truck Mounted "A" Frame manufactured rating over 5 tons; Bull Lifts and Fork Lifts with Power Boom and Swing attachments, over 5 tons; Front End Loader with Forks; Bus Operator over 30 passengers; All Terrain Vehicles; Boom Truck/Knuckle Truck over 5 tons; Foam Distributor Truck/dual axle; Hydro-seeders, dual axle;

Vacuum Trucks, Truck Vacuum Sweepers; Loadmaster (air and water); Air Cushion or similar type vehicle; Fire Truck/Ambulance Driver; Combination Truck-fuel and grease;

Compactor (when pulled by rubber tired equipment); Rigger (air/water/oilfield); Ready Mix, up to and including 7 yards;

GROUP 5: Gravel Spreader Box Operator on Truck; Flat Beds, single rear axle; Boom Truck/Knuckle Truck up to and including 5 tons; Pickups (Pilot Cars and all light duty vehicles); Water Wagon (Below 250 Bbls); Gin Pole Truck, Winch Truck, Wrecker, Truck Mounted "A" Frame, manufactured rating 5 tons and under; Bull Lifts and Fork Lifts (fork lifts with power broom and swing attachments up to and including 5 tons); Buffer Truck; Tack Truck; Farm type Rubber Tired Tractor (when material handling or pulling wagons on a construction project); Foam Distributor, single axle; Hydro-Seeders, single axle; Team Drivers (horses, mules and similar equipment); Fuel Handler (station/bulk attendant); Batch Truck, up to and including 7 yards;

Gear/Supply Truck; Bus Operator, Up to 30 Passengers;

Rigger/Swamper

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

AM#1 F-35A HANGAR / PROPULSION MX / DISPATCH EIE376

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 78 00

CLOSEOUT SUBMITTALS

PART 1 GENERAL

1.1 REFERENCES

1.2 DEFINITIONS

1.2.1 As-Built Drawings

1.2.2 Record Drawings

1.3 SOURCE DRAWING FILES

1.3.1 Terms and Conditions

1.4 SUBMITTALS

1.5 SPARE PARTS DATA

1.6 QUALITY CONTROL

1.7 WARRANTY MANAGEMENT

1.7.1 Warranty Management Plan

1.7.2 Performance Bond

1.7.3 Pre-Warranty Conference

1.7.4 Contractor's Response to Construction Warranty Service

Requirements

1.7.5 Warranty Tags

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

2.2 SYSTEM DESCRIPTION

2.2.1 Additional Drawings

2.2.1.1 Sheet Numbers and File Names

2.3 CERTIFICATION OF EPA DESIGNATED ITEMS

PART 3 EXECUTION

3.1 AS-BUILT DRAWINGS

3.1.1 Markup Guidelines

3.1.2 As-Built Drawings Content

3.2 RECORD DRAWING FILES

3.3 RECORD DRAWINGS

3.3.1 Final Record Drawing Package

3.4 FINAL APPROVED SHOP DRAWINGS

3.5 CONSTRUCTION CONTRACT SPECIFICATIONS

3.6 AS-BUILT RECORD OF EQUIPMENT AND MATERIALS

3.7 OPERATION AND MAINTENANCE MANUALS

3.8 CLEANUP

-- End of Section Table of Contents --

Section 01 78 00 Page 1

SECTION 01 78 00

CLOSEOUT SUBMITTALS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

ERDC/ITL TR-12-1 (2012) CAD Drafting Standard

ERDC/ITL TR-12-6 (2012) A/E/C CAD Standard - Release 5.0

1.2 DEFINITIONS

1.2.1 As-Built Drawings

As-built drawings are developed and maintained by the Contractor and depict actual conditions, including deviations from the Contract Documents. These deviations and additions may result from coordination required by, but not limited to: contract modifications; official responses to Contractor submitted Requests for Information; direction from the Contracting Officer;

designs which are the responsibility of the Contractor, and differing site conditions. Maintain the as-builts throughout construction as red-lined hard copies on site and or red-lined PDF files. These files serve as the basis for the creation of the record drawings.

1.2.2 Record Drawings

The record drawings are the final compilation of actual conditions reflected in the as-built drawings.

1.3 SOURCE DRAWING FILES

Request the full set of electronic drawings, in the source format, for Record Drawing preparation, after award and at least 30 days prior to required use.

1.3.1 Terms and Conditions

Data contained on these electronic files must not be used for any purpose other than as a convenience in the preparation of construction drawings and data for the referenced project. Any other use or reuse shall be at the sole risk of the Contractor and without liability or legal exposure to the Government. The Contractor must make no claim and waives to the fullest extent permitted by law, any claim or cause of action of any nature against the Government, its agents or sub consultants that may arise out of or in connection with the use of these electronic files. The Contractor must, to the fullest extent permitted by law, indemnify and hold the Government harmless against all damages, liabilities or costs, including reasonable attorney's fees and defense costs, arising out of or resulting from the use

Section 01 78 00 Page 2 of these electronic files.

These electronic CAD drawing files are not construction documents.

Differences may exist between the CAD files and the corresponding construction documents. The Government makes no representation regarding the accuracy or completeness of the electronic CAD files, nor does it make representation to the compatibility of these files with the Contractor hardware or software. In the event that a conflict arises between the signed and sealed construction documents prepared by the Government and the furnished Source drawing files, the signed and sealed construction documents govern. The Contractor is responsible for determining if any conflict exists. Use of these Source Drawing files does not relieve the Contractor of duty to fully comply with the contract documents, including and without limitation, the need to check, confirm and coordinate the work of all contractors for the project. If the Contractor uses, duplicates or modifies these electronic source drawing files for use in producing construction drawings and data related to this contract, remove all previous indicia of ownership (seals, logos, signatures, initials and dates).

1.4 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only.