W51AA125R0004 DRAFT.pdf

W25G1V42540100

See Section J for list of Attachments.

DEAN BERKOVICS 570-615-6627

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED (RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. ( Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442- 101 STANDARD FORM 1442 (REV. 4-85)

Presc ribed by GSA

FAR (48 CFR) 53.236-1( e)

11. The Contractor shall begin perf ormance w ithin _______10 calendar days and complete it w ithin ________485 calendar days after receiving aw ard, X notice to proceed. This per formance per iod is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to per form the w ork required are due at the place specified in Item 8 by ___________ local time ______________ (date). If this is a sealed bid solicitation, of fers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in f ull text or by reference.

D. Off ers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

ACC-APG TOBYHANNA D IVISI ON (W51AA1)

11 HAP ARNOLD BLVD

TOBYHANNA PA 18466

W51AA1

PAGE OF PAGES

1 OF

CODE

(Ti tle, identi fying no., date):

12B. CALENDAR DAYS

(hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W51AA125R0004 27

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to per form the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this off er is accepted by the Government in w riting w ithin ________ calendar days after the date off ers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required perf ormance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The of feror acknowledges receipt of amendments to the solicit ation -- give number and dat e of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or pr int)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherw ise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. ( Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Cont ractor is not required to sign this document. ) document and return _______ copies t o issuing office.) Cont ractor agrees Y our of f er on t his solicit ation, is hereby accept ed as t o t he items listed. This award con-t o f urnish and deliv er all item s or perf orm all work, requisitions identif ied sum mates the contract , which consists of (a) the Gov ernm ent solicit ation and on this f orm and any continuation sheet s f or t he consideration st ated in this y our of f er , and (b) this cont ract award. No f urther contractual document is cont ract. The rights and obligat ions of t he parties to this cont ract shall be necessary.

gov erned by (a) t his contract award, (b) t he solicitat ion, and (c) the clauses, representat ions, cer tif icat ions, and specif ications or incorporated by ref er-ence in or at tached to t his contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W51AA125R0004

Section A - Solicitation/Contract Form

ADDENDUM

1. This Solicitation is in accordance with FAR Part 36 and FAR Subpart 19.502.2, as applicable. This requirement is a Total 100% Small Business Set-Aside. The NAICS Code for this requirement is 238210.

2. MAGNITUDE OF CONSTRUCTION PROJECT: Pursuant to FAR 36.204, the estimated magnitude of construction is: Between $250,0000 to $500,000,000.

3. SITE VISIT: IAW FAR Clause 52.236-27, a single site visit will be conducted. The site visit will be held on on XXXX, XXX XX, 2024 @ 1:00PM EST. Attendance is recommended for Offerors. The meeting location will be Building 20 (Guard Shack/Security). Attendees are encouraged to arrive 15 minutes early to check in. If visitors do not possess a TYAD issued Contractor badge, they will be required to present a valid, Government issued photo I.D.

to gain access to the base (vehicle registration and insurance may also be required). Information provided at each site visit, as well as answers to any general questions, shall not affect the terms and conditions of the solicitation and/or specifications. Terms remain unchanged unless the solicitation is amended in writing. Please refer to clause 52.236-27 for Site Visit information.

4. QUESTIONS AND ANSWERS: Offerors are advised to submit any questions regarding this solicitation in writing to both the Contract Specialist, Dean Berkovics, via email only at DEAN.M.BERKOVICS.CIV@ARMY.MIL and the Contracting Officer, Stephanie Coleman, via email only at STEPHANIE.M.COLEMAN17.CIV@ARMY.MIL. Answers will be consolidated in the form of Questions and Answers and emailed to all vendors. If an Questions and Answers impact the SOW then an Amendment will be created where applicable, and posted in the same manner as the Solicitation.*QUESTIONS MUST BE RECEIVED NO LATER THAN THREE (3) DAYS AFTER SITE VISIT. NO QUESTIONS WILL BE ACCEPTED AFTER THIS TIME* Questions received after this time will not be answered.

5. PROPOSAL DUE DATE: Proposals shall be submitted no later than XXXXX, XXXX X, 2024 by 10:00 AM EST via email to the Contract Specialist, DEAN.M.BERKOVICS.CIV@ARMY.MIL. It is the responsibility of the offeror to confirm the proposal was received by this above date/time. Proposals received after the offer due date/time will not be considered for award. The Government shall not be held responsible for any technical issues that may arise.

6. The minimum acceptance period for offers is sixty (60) days from the proposal due date specified in this Solicitation.

7. Any resultant award will be a Firm Fixed Price Contract.

8. BASIS OF AWARD: The Government will award a Firm-Fixed-Price contract resulting from this solicitation to the responsible offeror whose offer, conforming to the solicitation, will be the best value to the Government. Three

(3) evaluation factors: Technical, Price, and Past Performance will be used. Refer to Section L, Instructions to Offerors and Section M, Evaluation of Proposals for detailed information. The Government reserves the right to award to other than the lowest priced offer.

9. WAGE DETERMINATION: Department of Labor (DOL) Davis Bacon Act (DBA) Wage Determination No.

PA20240098, Modification Number 06, Dated: 06/07/2024 is currently applicable and provided as Attachment 2.

10. DISCUSSIONS: The Government intends to award without discussions. Offerors should provide their best, complete proposal upon initial submission. The Government reserves the right to hold discussions if deemed necessary by the Contracting Officer.

11. PERFORMANCE AND PAYMENT BONDS: Performance and Payment Bonds: In accordance with (IAW) FAR Clause 52.228-15 – Performance and Payment Bonds – Construction, offerors are to note that Performance and Payment Bonds are required for contracts over $150,000. All bonds are due no later than ten (10) days after award.

12. CONTRACTOR RESPONSIBILITY: In order to be considered for award, offerors must be found to be responsible IAW FAR Part 9.1. The Government may, at its discretion, require an offeror to submit additional information in order to determine Contractor responsibility. If an offeror is deemed to be NOT responsible IAW FAR 9.104-1, they may not be considered for award.

13. PROPOSAL REQUIREMENTS: In order to be considered for award, offerors must submit, at a minimum, the following:

a. Completed/Signed SF 1442

b. All signed Amendments

c. Three (3) Past Performance References (FAR 52.212-2)

d. Attachment 3: Proposed Price Schedule

e. Technical Proposal Submission IAW Attachment 1, Statement of Work

f. Minimum 60 day offer acceptance period

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot

PAD-MOUNTED SWITCHGEAR REPLACEMENT

FFP

The objective of this effort is to remove and replace three (3) Brand Name S&C Electric Company Vista Medium Voltage Pad-Mounted Switchgear due to deterioration/corrosion and age of equipment. The work includes that described in the accompanying Statement of Work listed herein.

See Attachment 1 - Statement of Work for further details.

FOB: Destination

NSN: AASSVC42540100

MILSTRIP: W25G1V42540100

PURCHASE REQUEST NUMBER: W25G1V42540100

PSC CD: N061

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 485 dys. ADC 1 SEE BELOW FOR SEPARATE SHIPPING

INSTRUCT

XXX

XXX PA 00000

FOB: Destination

W25G1V

Section G - Contract Administration Data

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232- 7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

_____________________CONSTRUCTION PAY INVOICE_______________________________

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

______N/A________

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC HQ0303

Issue By DoDAAC W51AA1

Admin DoDAAC** W51AA1

Inspect By DoDAAC ____

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) W25G1V

Service Acceptor (DoDAAC) W25G1V

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

WAWF Acceptor: Sean Tufano sean.p.tufano.civ@army.mil

Contract Specialist: dean.m.berkovics.civ@army.mil

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

David.k.kern2.civ@army.mil

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section I - Contract Clauses

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-17 Contractor Employee Whistleblower Rights NOV 2023 52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities

DEC 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.204-27 Prohibition on a ByteDance Covered Application JUN 2023 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-5 Material Requirements AUG 2000 52.211-13 Time Extensions SEP 2000 52.215-2 Audit and Records--Negotiation JUN 2020 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.219-8 (Dev) Utilization of Small Business Concerns (DEVIATION 2024-

O0002)

FEB 2024

52.219-28 Post-Award Small Business Program Rerepresentation FEB 2024 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-12 Contract Termination-Debarment MAY 2014

52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021 52.222-54 Employment Eligibility Verification MAY 2022 52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-16 Progress Payments NOV 2021 52.232-17 Interest MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.243-4 Changes JUN 2007

52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-2 Termination For Convenience Of The Government (Fixed- Price)

APR 2012

52.249-2 Alt I Termination for Convenience of the Government (Fixed- Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

JAN 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.203-7003 Agency Office of the Inspector General AUG 2019 252.203-7004 Display of Hotline Posters JAN 2023 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

MAY 2024

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

JAN 2023

252.219-7011 Notification to Delay Performance JUN 1998 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7012 Preference For Certain Domestic Commodities APR 2022 252.225-7048 Export-Controlled Items JUN 2013 252.226-7003 Drug-Free Work Force AUG 2024 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.247-7023 Transportation of Supplies by Sea JAN 2023

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 485 days after notice to proceed. The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $690.12 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section J - List of Documents, Exhibits and Other Attachments

ATTACHMENTS

Attachment 1: Statement of Work (SOW) Atttachment 2: Wage Determination Attachment 3: Proposed Price Schedule Attachment 4: ACWS Transition Information for Offerors

Section K - Representations, Certifications and Other Statements of Offerors

52.204-17 Ownership or Control of Offeror AUG 2020 52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-7 Information Regarding Responsibility Matters OCT 2018 52.215-6 Place of Performance OCT 1997 52.236-28 Preparation of Proposals--Construction OCT 1997 252.204-7016 Covered Defense Telecommunications Equipment or Services

-- Representation

DEC 2019

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services -- Representation

MAY 2021

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2024)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238210.

(2) The small business size standard is $19,000,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] Paragraph (d) applies.

[ ] Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.)

This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph

(d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ___ ] will, [ ___ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT

2020)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representations.

(1) The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

Section L - Instructions, Conditions and Notices to Bidders

INSTRUCTIONS TO OFFEROR

1. PROPOSAL SUBMISSION REQUIREMENTS:

(a). Only electronic proposals will be accepted. No hardcopy proposals will be accepted. Electronic offers shall be submitted via e-mail to the Contract Specialist at dean.m.berkovics.civ@army.mil. The Offeror’s responses shall clearly address each factor listed below. Failure to address these factors, or to properly complete and submit a proposal, may result in the Offeror being rated unacceptable and being removed from consideration. Therefore, Offerors are urged to follow instructions and contact the Contract Specialist if instructions are not understood.

Offerors are cautioned to put forth their best efforts, and to furnish all information clearly in order to allow the Government to properly evaluate proposals. Offerors should not assume that they will have an opportunity to clarify or correct anything in their proposal after submission. Therefore, proposals should be submitted on the most favorable terms that the Offeror can submit to the Government.

The Offeror’s proposal shall include the following factors. These factors shall be clearly identified and labeled.

1. Technical Proposals: Offerors shall submit technical proposals, to include a complete description of how the Offeror will meet the Government’s SOW, Attachment 1. Offerors must not simply parrot the Government’s requirement. Any exceptions to any terms and conditions must be included in proposal and agreed upon by both parties before any award.

2. Price Proposals: Price Proposals shall include:

(a). Completed SF 1442 - Solicitation, Offer and Award. Offerors shall submit a completed SF1442, signed by an individual authorized to contractually bind the firm. All solicitation amendments must be acknowledged on SF 1442. The completed SF 1442 shall include the total proposed price in CLIN 0001. The price shall be Firm Fixed- Price. The Offeror shall take care not to include remarks that take exception to the Government’s SOW or pricing requirements, or otherwise preclude the Government from evaluating the offer, which will render the offer unacceptable.

(b). Completed Attachment 3 - Proposed Price Schedule, including all applicable data. This completed price schedule will be used in determination of price reasonableness. The Contractor shall provide a complete breakdown of item pricing with its offer including labor categories, hourly labor rates, number of labor hours, materials, supplies, equipment, other direct costs (quantity and unit price), profit, and indirect costs in sufficient detail to provide thorough evaluation per Federal Acquisition Regulation (FAR) clause 52.215-20 Alt I in electronic Excel spreadsheet format (submitted as separate attachment). When subcontractors are used, provide evidence of competitive award; if subcontract is not competitively awarded provide subcontractor’s detailed pricing as previously described. Lump Sum pricing is unacceptable.

3. Past Performance: Offeror shall include three references of past performance performed within the past three years, along with a point of contact and their contact information. Offeror’s submission shall include at a minimum:

(a). Project title, description, and location (physical address).

(b). Description of the scope of work, to include the work performed as the prime contractor.

(c). Start and completion dates (original vs actual) and a brief narrative for any differences between original and actual. Explain the steps the contractor took to successfully complete the project on time and with minimal impact to the customer.

(d). Project cost (original vs actual) and brief narrative for any differences between original and actual.

Other sources of past performance history shall be considered, such as information available from CPARS, PPIRS, FAPIIS, and OSHA.

2. SOLICITATION, OFFER AND AWARD DOCUMENT:

(a). Section A – Standard Form 1442 (SF 1442), Solicitation, Offer and Award - An authorized official of the firm shall sign the SF 1442 and all certifications requiring original signature. An Acrobat PDF file shall be created to capture the signatures for submission. All Amendments must be acknowledged on SF 1442.

(b). Bid Guarantee for Pad-Mounted Switchgear Replacement must be included with proposal.

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.215-1 Instructions to Offerors--Competitive Acquisition NOV 2021

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting…