W519TC-23-R-2045.pdf

The United States Army Contracting Command - Rock Island (ACC-RI) request a proposal for the Repair Roofing - Building 250 on the Rock Island Arsenal, Rock Island, IL.

All w ork is to be done in accordance w ith (IAW) the Scope of Work (SOW) for Project 2019-4428, attached specif ications and draw ings. See

DFARS 252.236-7001.

This Request for Proposal (RFP) is issued as a total 100% Small Business Set-Aside.

This RFP contains one base bid.

IAW FAR 36.204(e), the magnitude of this project is betw een $500,000.00 and $1,000,000.00.

Performance and Payment Bonds are required.

Please see Executive Summary for further requirements.

LINDSAY P. PARK

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

26-Apr-2023

(RFP)

(IFB)

X

CALL:

Building 250 Roof Repair

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______45 calendar days and complete it w ithin ________180 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________Exec Summary

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________26 May 2023 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

ARMY CONTRACTING COMMAND - ROCK ISLAND

3055 RODMAN AVE

ROCK ISLAND IL 61299

W519TC

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

2019-4428

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W519TC23R2045 38

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W519TC23R2045

Section SF 30 - Block 14 Continuation Page (SF 30)

EXECUTIVE SUMMARY

1. The United States Army Contracting Command – Rock Island (ACC-RI) requests a proposal on behalf of Rock Island Garrison (USAG – RIA) consisting of furnishing labor, material, and equipment to repair by replacement of an existing 4,800 square feet low-slope single-ply Ethylene Propylene Diene Monomer (EPDM) roof with a new EPDM roofing system on Building 250 located at the US Army Garrison, Rock Island Arsenal, Rock Island, Illinois. All work is to be done in accordance with the Scope of Work (SOW) for project 2019-4428.

2. This period of performance for this project is 180 calendar days from the date of the Notice to Proceed. Calendar days will be tracked by the Contracting Officer Representative (COR). See Section 1.3 Base Bid of the Scope of Work as stated below –

1.3 The Base Bid consists of furnishing all labor and material as necessary to complete the installation of a new roofing system on Building 250 as shown on the attached drawings. Work includes, but is not limited to, removal of existing EPDM roofing, insulation, roof drains and associated material. The Base Bid completion date shall be 180 calendar days after award of the contract.

This project shall be a calendar day contract. The contractor is allowed 180 calendar days to complete the project.

Failure in completing the project in the allotted 180 calendar days will result in a deduction at the liquidated damages rate of $1,000.00 (one thousand dollars) per working day until the project is completed.

3. This requirement will be competed on SAM.gov at https://www.sam.gov/SAM/ as a 100% Small Business Set Aside.

4. The North American Industry Classification System (NAICS) code is 238160, Roofing Contractors. The Product Service Code is Z2QA, Repair or Alteration of Restoration of Real Property (Public or Private)

5. All Offerors MUST be registered in the System for Award Management (SAM) database in accordance with Federal Acquisition Regulation (FAR) 52.204-7 and Defense Federal Acquisition Regulation Supplement (DFARS) 252.204-7004 when submitting an offer, and shall continue to be registered until time of award, during performance, and through final payment of any contract resulting from this solicitation. Lack of registration in SAM will make an Offeror ineligible for award. Contractors may obtain information on registration and annual confirmation requirements via the SAM website at https://www.sam.gov/SAM/ or by calling 866-606-8220.

6. The Government will award a single Firm-Fixed Price (FFP) contract from this solicitation to the responsive, responsible Offeror with the lowest price and an acceptable past performance rating as outlined in paragraph 7. This Request for Proposal (RFP) contains one contract line-item number, CLIN 0001 which represents one firm-fixed price base bid. Contractor is to provide: a firm-fixed price to execute all work associated with CLIN 0001.

7. The contractor shall submit a total of three past performance references for similar projects that are within the last five years and may include subcontractor references.

a. Each reference shall include the information bulleted below:

Contracting agency/company and technical points of contact with their phone numbers.

Electronic-mail addresses, and titles.

Contract number and delivery/task order number, as applicable.

The original contract award date (for the base period of performance) and the completion (or estimated completion) date (shall reflect all option periods).

Contract value (value of each performance period shall be identified).

Scope of work.

b. If applicable, the submittal in this section shall also list any contract or purchase order under which either a cure notice or show cause letter was received, or any contract or purchase order that was terminated for cause by the Government within the past three years. The contractor must briefly explain the facts and circumstances in each such instance.

The Government will evaluate past performance as acceptable/unacceptable. The Government will contact all contract references provided and conduct research into Government Databases on past performance (PPIRs, CPARs, etc.) to determine past performance to be relevant and recent and to determine that past performance to be acceptable.

Relevant past performance efforts involve similar scope and magnitude of effort and complexities this RFP requires.

Recent past performance is within the past 5 years.

Past Performance Acceptable/Unacceptable Rating Method is as follows:

Adjectival Rating Description Acceptable Based on the offeror’s performance record, the

Government has a reasonable expectation that the offeror will successfully perform the required effort, or the offeror’s performance record is unknown (See note below).

Unacceptable Based on the offeror’s performance record, the Government does not have a reasonable expectation that the offeror will be able to successfully perform the required effort.

In the case of an offeror without a record of recent/relevant past performance no meaningful confidence assessment rating can be reasonably assigned. The Offeror will be given an acceptable rating.

8. The Government anticipates price competition, therefore, certified cost or pricing data is not required to be submitted with the Offeror’s proposal. However, the Government reserves the right to request certified cost or pricing data in the event price competition does not exist.

9. A Notice to Proceed (NTP) will be issued at time of contract award and the awardee shall prepare and submit a practicable schedule and Quality Control Plan (QCP) to the Contracting Officer for approval within 15 days. The remaining pre-submittals are due within 30 days after issuance of the NTP, with commencement of physical work to begin 45 days after NTP. Per allowance provided within FAR Clause 52.236-15, titled “Schedules for Construction Contracts (APR 1984)”, the Contracting Officer has authorized a revision to paragraph (a) of the clause. FAR clause 52.236-15 as revised is included in its entirety below.

52.236-15 SCHEDULES for CONSTRUCTION CONTRACTS (APR 1984)

(a) The Contractor shall, within 15 days after issuance of the notice to proceed, submit three copies of a practicable schedule to the Contracting Officer and Contracting Officer Representative for approval. The schedule shall show the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified within the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

10. The Government reserves the right to reject any or all proposals and make no award if such action is in the best interest of the Government.

11. Notice to potential Offerors: In order to align with current requirements of Department of Defense (DoD) DFARS 201.304 and Army Federal Acquisition Regulations Supplemental (AFARS) 5101.304 there has been a change to the format of ACC-RI solicitations (and resultants contracts). This notice is to inform you of that format change and to advise you to review the entire solicitation thoroughly.

12. There will be a site visit held on Monday, May 08, 2023 at 10:00 a.m. CST. All site visit attendees will meet at the gate between Building 250 and 254 located on Flagler Street on the Rock Island Arsenal, Rock Island, IL. Please see Attachment 0009, Site Visit Map.

****** PLEASE READ CAREFULLY FOR IMPORTANT SITE VISIT INFORMATION **********

ALL ATTENDEES MUST ACCESS THE ISLAND THROUGH THE MOLINE GATE AND STOP

AT BUILDING 23, VISITOR CONTROL CENTER, TO GAIN ACCESS TO THE ISLAND

UNLESS YOU HAVE AN EXISTING BADGE TO GAIN ACCESS. YOU WILL NEED TO SHOW

A VALID DRIVERS LICENSE. PLEASE ALLOW 60 MINUTES PRIOR TO THE SITE VISIT FOR

PROCESSING.

PLEASE EMAIL THE NAMES OF THE ATTENDEES FROM YOUR COMPANY TO

lindsay.p.park.civ@army.mil.

13. Offerors are cautioned to ensure their proposals are fully complete, including fill-ins and blanks in the solicitation. Any Offeror submitting a proposal agrees by submission that their proposal and the prices contained therein will be valid for 60 days after receipt of final proposals.

14. This solicitation is subject to availability of funds; therefore, this solicitation is currently unfunded. The Government reserves the right to not fund any work listed in the solicitation. See FAR clause 52.232-18.

15. Offerors should note the provision at FAR 52.215-1, titled “Instructions to Offerors – Competitive Acquisition”. The Government intends to award a contract resulting from this solicitation without discussions with Offerors (except clarifications described in FAR 15.306(a)). Therefore, Offeror’s initial proposals should contain the best terms. The Government does however, reserve the right to conduct discussions if determined necessary by the Contracting Officer.

16. The prevailing Wage Rate Requirements (Construction) will be incorporated into the resultant contract and will be in effect for the entire period of performance of the resultant contract. The most recent wage rates can be found online at: www.sam.gov or see Attachments 0007, Davis Bacon Wage Determination of this solicitation.

17. Contractor questions regarding this solicitation and work contained within the SOW are due to the solicitation point of contact (POC) no later than 10:00 a.m. CST on Thursday, May 18th, 2023, in order to ensure all questions can be answered and posted for all Offerors’ knowledge prior to solicitation closing date and time reflected in box 13 of this document. All questions should be directed in writing by email to Lindsay Park, lindsay.p.park.civ@army.mil and Kathleen Ward at kathleen.m.ward.civ@army.mil providing SOLICITATION number W519TC-23-R-2045 in the subject line.

18. Proposal submission deadline is listed in Block 13 of this solicitation. Proposal must be sent electronically to lindsay.p.park.civ@army.mil. No hard copies will be accepted.

- Offerors shall reference solicitation W519TC-23-R-2045 and company name in the proposal email subject line.

- In email body, please request receipt to confirm delivery and also include the Bid Bond Package / Envelope tracking information (see Bid Bond submission instructions in paragraph 19).

- There is no drop-box system for proposal submittal.

- Our email system standard is an estimated limit of ten (10) megabytes per incoming email.

- Please be aware that large files may require extra time to be delivered into our email system. All proposal documents must be fully delivered into the email system and time-stamped by the Government server no later than the time shown in Block 13 of this document.

19. Contractor Bid Bonds are required to be submitted via both mail and electronic mail. See instructions below:

Original Contractor Bid Bonds shall be mailed to the address below. In-person delivery Bid Bonds will not be accepted.

MAILING ADDRESS:

Army Contract Command – Rock Island Attention: Lindsay Park 3055 Rodman Avenue, Building 60 3rd Floor Rock Island, IL 61299

Additionally, a scanned copy of the Bid Bonds shall be sent via electronic mail along with the proposal submission. Bid Bond Package/Envelope tracking information shall be submitted at time of electronic proposal submission.

20. This executive summary is provided as an administrative convenience and is not intended to alter the terms and conditions of the solicitation in any way. Any inconsistencies between this executive summary and other solicitation provisions shall be resolved in favor or the other solicitation provisions.

21. Clauses and provisions from the FAR and supplements thereto are incorporated into this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were included in full text.

22. This solicitation should not be discussed with any Government employee except the Contracting Officer, Ms. Kathleen Ward, or the Contract Specialist, Ms. Lindsay Park. Failure to adhere to this restriction may be grounds to declare your firm ineligible for consideration of any award resulting from this competitive acquisition.

23. The Government representative for this acquisition is Lindsay Park, lindsay.p.park.civ@army.mil.

Comments or questions should be directed in writing to Lindsay Park by email, providing the solicitation number W519TC-23-R-2045 in the subject line.

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Repair Roof Building 250

FFP

All work is to be done in accordance with the Scope of Work for Project 2019- FOB: Destination

PSC CD: Z2QA

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

Section 00 21 00 - Instructions

CLAUSES INCORPORATED BY REFERENCE

52.215-1 Instructions to Offerors--Competitive Acquisition NOV 2021 52.236-28 Preparation of Proposals--Construction OCT 1997 252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023

CLAUSES INCORPORATED BY FULL TEXT

52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS--

REPRESENTATION (DEC 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard.

(2) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program.

(c) If the Offeror checked ``does'' in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:

(End of provision)

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

Funds are not presently available for this contract. The Government's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from kathleen.m.ward20.civ@army.mil.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for Monday, May 08, 2023 at 10:00 CST. All site visit attendees will meet at the gate between Building 250 and 254 located on Flagler Street on the Rock Island Arsenal, Rock Island, IL. Please see Executive Summary, paragraph 11 for further information to obtain entrance on the Rock Island Arsenal.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov

Section 00 45 00 - Representations and Certifications

52.204-7 System for Award Management OCT 2018 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2023)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238160.

(2) The small business size standard is $19,000.000.00.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.)

This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(C) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

JUN 2020

52.204-2 Alt II Security Requirements (MAR 2021) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.215-2 Audit and Records--Negotiation JUN 2020 52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.219-8 Utilization of Small Business Concerns OCT 2022 52.219-14 Limitations On Subcontracting OCT 2022 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021

52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021 52.222-54 Employment Eligibility Verification MAY 2022 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds DEC 2022 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

MAR 2023

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-1 Changes--Fixed Price AUG 1987 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Products and Commercial

Services

MAR 2023

52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2020 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

JAN 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

JAN 2023

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.225-7001 Buy American And Balance Of Payments Program--Basic JAN 2023 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7008 Contract Prices-Bidding Schedules DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.247-7022 Representation of Extent of Transportation by Sea JUN 2019 252.247-7023 Transportation of Supplies by Sea JAN 2023

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 45 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 days after the Contractor receives the Notice to Proceed. Contractor submission of all closeout documentation is also included within this timeline. The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,000.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAR 2023)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph

(d) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all…