W50S83-21-B-0001-U0001.pdf

FKNN182011

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is as follow s:

A) Correct a clerical error in Section 00100 Part 2 from 17MAR21 at 9 a.m. EST to the correct site visit date and time of 23MAR21 at 1 p.m.

B) CLIN 0003 is hereby added for Communications equipment, installation and testing at B518 IAW sections 271513 & 271523 of B-3 Final Submittal dated 16 November 2020 C) Period of Performance is hereby changed from 365 days after NTP to 10 months after NTP

All other terms and conditons remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 19-Mar-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W50S8321B0001

X 9B. DATED (SEE ITEM 11)

09-Mar-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Mar-2021

CODE

USPFO ME 101 MISSION SUPPORT CONTRACTING

101 MAINEIAC AVENUE, STE 505

BANGOR ME 04401-3055

W50S83 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W50S8321B0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The contractor period of performance end date has decreased by 61 days from 365 days to 304 days.

CLIN 0003 is added as follows:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0003 1 Job Communications - Building 518

FFP

Provide all plant, labor, transportation, materials, tools, equipment, appliances and supervision necessary for communications equipment, installation and testing at Building 518 persuant to sections 271513 & 271523 of B-3 Final Submittal specifications and drawings dated 16 November 2020.

FOB: Destination

PSC CD: Y1JZ

NET AMT

DELIVERIES AND PERFORMANCE

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

365 dys. ANP 1 101 ARW/CE

DANIEL TREMBLEY

CIVIL ENGINEERS - F7QJCE

106 ASHLEY AVENUE

SUITE 486

BANGOR ME 04401-8029

207-404-7567

F7QJCE

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

10 mths. ANP 1 101 ARW/CE

DANIEL TREMBLEY

CIVIL ENGINEERS - F7QJCE

106 ASHLEY AVENUE

SUITE 486

BANGOR ME 04401-8029

207-404-7567

The following Delivery Schedule for CLIN 0003 has been added:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

10 mths. ANP 1 101 ARW/CE

DANIEL TREMBLEY

CIVIL ENGINEERS - F7QJCE

106 ASHLEY AVENUE

SUITE 486

BANGOR ME 04401-8029

207-404-7567

INSPECTION AND ACCEPTANCE

The following Acceptance/Inspection Schedule was added for CLIN 0003:

INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

Destination Government Destination Government

The following Technical Office was added for CLIN 0003:

101 ARW/CE

DANIEL TREMBLEY

CIVIL ENGINEERS - F7QJCE

106 ASHLEY AVENUE

SUITE 486

BANGOR ME 04401-8029

SECTION 00100 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

The following have been modified:

SECTION 00100

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

Description of the Project: The intent of this project is to renovate bbuildings 518 & 515 for the G-ASNT equipment.

The scope of the work includes, but not limited to:

Provide all plant, labor, transportation, materials, tools, equipment, appliances and supervision necessary for the Construction of repairing and renovating the existing building 518 and 515. Existing Building 515 houses vehicles used for snow removal and de-icing operations. Work includes provisions for a rooftop antenna platform on Building 518, renovation to approximately 1,500 square feet of existing office areas in Building 518, and renovations to approximately 400 square feet in Building 515 to provide necessary equipment storage space for transportable G-ASNT equipment.

1. Instructions to Bidders:

1.1. You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled W50S83-21-B-0001 entitled G-ASNT Add/Alter Buildings 518 & 515, Project Number FKNN182011, at Bangor ANGB, ME 04401.

1.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price.

1.3. This solicitation is set-aside 100% for small businesses.

2. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

2.1. A pre-bid conference will be conducted on 23 March 2021 at 1300 hours for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at the Maine Air National Guard Base, 101st Civil Engineering Squadron Classroom, Bangor, ME 0440. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

2.2. Due to security conditions, all offerors must register to attend this conference and site visit. A MEANG

Form 4 BACKGROUND REQUEST, 20190801 shall filled out for all attendees and e-mailed to Maj. Daniel Trembley and SrA Tyler Field at the following addresses: daniel.trembley@us.af.mil and tyler.field@us.af.mil.

2.3. This information must be provided in advance, 5 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

2.4. Visitors must pick up their passes at the Installation’s Main Entry Gate prior to arrival. Visitors should plan to arrive approximately 30 minutes prior to the start of the conference or site visit to avoid processing delays. You will be required to present the following information upon arrival: (1) Vehicle Registration, (2) Valid Drivers License, (3) Proof of Insurance for Vehicle, (4) Safety Inspection and Car Rental agreement if applicable. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

2.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

2.6. A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.fbo.gov. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

3.1. Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W50S83-21-B-0001 Email: 101.MSG.MSC.Contracting@us.af.mil

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

4.1. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

4.2. All questions and requests for information (RFI) must be received NOT LATER THAN the fifth working day prior to bid opening. OFFERORS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS

EARLY IN THIS PROCESS.

4.3. Any changes to the drawings, specifications, etc. will be issued in the form of an amendment.

However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on FBO at http://www.fbo.gov

4.4. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

4.5. For security reasons, all technical and engineering data related to this solicitation will be distributed using the Federal Business Opportunities (FedBizOpps.gov or fbo.gov) system. Plans and specifications are locked on FBO and require Contractors to request explicit access from the Contracting Officer OR export controlled access through DLA. See complete instructions on FBO. FedBizOpps is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with FedBizOpps before accessing the system.

4.5.1. Amendments, if/when issued will be posted to https://beta.sam.gov/ for electronic downloading.

This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible due to various reasons.

4. BID REPOSITORY AND BID OPENING:

4.1. A bid repository is provided for hand carried bids and is located at Maine Air National Guard Base, 101

Maineiac Ave., STE 505, Bangor, ME 04401. Hand carried bids must be deposited in the repository prior to the time established for opening of bids. Bidders are cautioned that they will be required to sign-in and obtain a visitor’s pass to enter the facility and should allow time to accomplish this. See instructions for obtain access to the base in the Site Visit instruction. Follow the same instruction for obtaining entry to hand carry bid. Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304.

4.2. The bid opening will occur at the time and date specified in Block 13 of the SF1442 at Maine Air

National Guard Base, 101 Maineiac Ave., STE 505, Bangor, ME 04401. All interested offerors and their major subcontractors are encouraged to attend the bid opening.

5. WAGE DETERMINATION:

5.1. Construction Wage Rates are applicable to this project are General Decision Number: ME20210017

01/01/2021 as shown in Section 00800.

6. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS: This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

7. CLAUSES:

7.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

8. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids including the bid bond.

9. OFFERORS QUALIFICATIONS:

To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

10. N/A

11. List of Brand Name or Sole Source Justifications posted on https://beta.sam.gov.

(End of Summary of Changes)