USAGM High Voltage Transformer Regeneration - Philippines.docx

TRANSFORMER OIL REGENERATION OF 2-UNITS POWER TRANSFORMER, 10 MVA, 230kV-13.8kV

TABLE OF CONTENTS

Section 1 - The Schedule

• SF 1449 Cover Letter

• Continuation to SF-1449, FAC-24-229-01 Prices, Block 23

• Continuation to SF-1449, FAC-24-229-01, Schedule of Supplies/Services Block 20 Description/Specifications/Work Statement

• Price / Cost

• Description/Specifications/Performance Work Statement

Section 2 - Contract Clauses

• Contract Clauses

• Addendum to Contract Clauses - FAR and DOSAR Clauses not Prescribed in Part 12

Section 3 - Solicitation Provisions

• Solicitation Provisions

• Addendum to Solicitation Provisions - FAR and DOSAR Provisions not Prescribed in Part 12

Section 4 - Evaluation Factors

• Evaluation Factors

• Addendum to Evaluation Factors - FAR and DOSAR Provisions not Prescribed in Part 12

Section 5 - Representations and Certifications

• Offeror Representations and Certifications

• Addendum to Offeror Representations and Certifications - FAR and DOSAR Provisions not Prescribed in Part 12

Section 6 - Additional Instructions, Conditions and Notices to Offerors

• Offeror Representations and Certifications

• Requirement Checklist

SECTION 1 - THE SCHEDULE

PRICE/COSTS

I. PRICES AND PERIOD OF PERFORMANCE

A. The contractor shall perform Transformer Oil Regenerations of 2 Units, 230 kV-13.8 kV, 10 MVA Power Transformers at the US Agency for Global Media (USAGM), Radio Transmitting Station Site at Tinang, Concepcion, Tarlac, Philippines. The price listed below shall include all labor, materials, insurance (see FAR 52.228-3 and 52.228-5), overhead, and profit.

B. The Government will pay the Contractor the fixed price for standard services that have been satisfactorily performed.

I.1 OFFERS AND PAYMENT IN U.S. DOLLARS

U.S. firms are eligible to be paid in U.S. dollars. U.S. firms desiring to be paid in U.S. dollars should submit their offers in U.S. dollars. A U.S. firm is defined as a company which operates as a corporation incorporated under the laws of a state within the United States.

I.2 FOREIGN FIRMS

Any firm, which is not a U.S. firm, is a foreign firm. Any firm that does not meet the above definition of U.S. firm shall submit its prices and receive payment in local currency in Philippines Pesos.

I.3 VALUE ADDED TAX

The Government will not reimburse the Contractor for VAT under this contract. The Contractor shall not include a line for VAT on Invoices as the U.S. Embassy has a tax exemption certificate with the host government.

I.4 FIRM-FIXED PRICE TOTAL:

All offerors’ price shall be submitted in Philippines Pesos although if the offeror is a U.S. firm, the firm may submit the price in U.S Dollars in addition to the price in the Philippines Pesos.

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

I. GENERAL INFORMATION:

The purpose of this firm fixed price purchase order is to acquire professional services necessary to perform preventive maintenance services for Two of facility’s Power Transformers.

II. PROJECT REQUIREMENTS:

The Contractor shall perform preventive maintenances as described in the statement of work. The objective of the oil regeneration is to achieve condition improvement and maintain effectiveness of transformers.

III. SCOPE OF WORK:

1. Site visit is a must to familiarize with the area and establish special requirement to execute the task provision of convenient means of mobilization of machine and personnel to site and to different areas where transformers are located prior to implementation of contract. USAGM Tinang facility have 2 feeder lines, each supplied by the 2 units power transformers. Transformer oil regeneration shall be done in 2 stages, one for each transformer for continued operation of the facility.

2. The contractor shall provide plans and methodologies for systematic and safe oil regeneration of the power transformers and submit to COR for approval.

3. The contractor shall inspect, profile parameters and do initial testing needed before regeneration of transformer oil of the power transformers. The contractor shall record as found data of the power transformers.

4. The contractor shall deploy sufficient manpower, tools, equipment, measuring instrument, etc. as required for the work.

5. The Contractor shall provide all necessary filtration/regeneration machines, generator set, and other related machinery. The contractor shall also supply up to Eight (200L) drum of high voltage transformer mineral oil.

6. The contractor shall provide proper materials, equipment, and containers for safe handling and containing spillage of transformer oil and waste during the regeneration process.

7. The contractor shall perform transformer electrical test, Dissolved Gas Analysis (DGA) and oil quality test, winding insulation test, PCB content test, and all necessary tests for the power transformers before re-commissioning. The contractor shall provide all test data before and after the regeneration process.

8. The contractor shall clean the work area and take possession of all waste, used oil, oil containers used on this contract. The contractor shall dispose these materials in accordance with all local and international environmental laws.

9. The contractor shall ensure that no damage is done to other equipment /instruments / item on nearby areas. Any loss or damage done to aforesaid items shall be recovered from contractor.

IV. GENERAL INSTRUCTIONS:

All personnel working in the vicinity shall wear and /or use appropriate safety protection while all work is performed. Strict adherence to NFPA70E and applicable OSHA standards must be maintained at all times. Regular safety meetings shall be held among on-site contractor personnel and local Employed staff assisting. Material Safety Data Sheets (MSDS) for all HAZMAT shall be submitted by the Contractor for all HAZMAT materials. Copies shall be provided to the COR for approval.

Prior to beginning any site work, the Contractor must submit to the COR or LE Staff representative a standard operating procedure (SOP) and schedule to reflect the planned work and sequence. The contractor must obtain approval from the Station Manager noting the planned servicing schedule, and all required generator transfers, tiebreaker switching, or outages.

If any discrepancies are found with the transformer that are not covered under this scope of work, then the Contractor shall provide the detailed report noting the discrepancy found.

IV.1 SAFETY INSTRUCTIONS:

1. Use appropriate personal protective equipment (PPE) when performing work.

2. Contractor shall provide a lead safety person prior to the start of work.

3. Check all work areas, tools, and equipment to ensure unsafe conditions are eliminated or guarded against.

4. Follow site safety procedures.

5. Follow approved lockout/tag out procedures.

6. Remove lockout/tag out in accordance with appropriate procedures.

7. Report all incidents and near miss incidents to COR and assist as requested in the investigation and corrective action.

8. Personnel must be certified for performing maintenance on high voltage equipment.

9. All personnel shall wear the mandatory PPE at all times and ensure use of other relevant PPE depending on the nature of work and condition of the work site.

IV.2 NOTES:

· Contractor shall submit to the COR for review, work sheet/checklist that will be used for performing maintenance service.

· A discrepancy report shall be submitted to the COR immediately upon discovery of any condition that could result in equipment failure.

· Test and inspection report shall be submitted to the COR within seven days of completing work.

· Laboratory report for all chemicals (oil, coolant or fuel analysis) shall be submitted to the COR within 30 days from date of service.

V. DEFINITIONS:

1. The term “Contracting Officer’s Representative” as used throughout the Contract Documents means an individual authorized by the “Contracting Officer” to administer the Project.

2. Outage - A temporary disruption of normal operation or use of utilities, sidewalks, parking areas, driveways or facility access.

3. Utility - Any service provided by an outside source or manufactured in house (gas, water, electricity, fire suppression water, telecommunications, data systems, building automation systems, fire alarm systems, etc.) which facilitates building operations.

VI. QUALITY ASSURANCE:

All work shall be performed in a quality manner as described herein and to the technical standards referenced below. All materials shall be handled and stored in accordance with the manufacturer’s recommendations.

All elements of this project shall be constructed to meet or exceed the criteria set forth in the following Codes, Standards and Publications. In the event of conflicts between these documents, or between these documents and specific requirements noted elsewhere, the more stringent requirements shall govern.

1 – American Standards and Testing Materials (ASTM)

2 – National Electrical Safety Code (NESC)

3 – Underwriters Laboratories (UL)

4 – USA and Philippines National Electric Code. (NEC/PEC)

5 – National Fire protection Association Codes and Standards. (NFPA)

6 – Institute of Electrical and Electronics Engineers (IEEE Standards)

7 – National Electrical Manufacturers Association (NEMA Standards)

8 – Reclamation Safety and Health Standards (RSHS)

VII. NOTICE OF DELAY:

If the Contractor becomes unable to complete the contract work at the time(s) specified because of technical difficulties, notwithstanding the exercise of good faith and diligent efforts in the performance of the work called for hereunder, the Contractor shall give the Contracting Officer written notice of the anticipated delay and the reasons there-for. Such notice and reasons shall be delivered promptly after the condition creating the anticipated delay becomes known to the Contractor. When notice is so required, the Contracting Officer may extend the time specified in the Schedule for such period as deemed advisable.

VIII. SUBMISSION OF INVOICES:

The Contractor shall submit invoices in an original and three (3) copies to the COR at the following address:

US Agency for Global Media, Tinang, Concepcion, Tarlac, Philippines

b) The Contractor agrees that the Government shall not be responsible for personal injuries or for damages to any property of the contractor, its officers, agents and employees, or any other person, arising from an incident to the contractor’s performance of this contract. The Contractor shall hold harmless and indemnify the Government from and all claims arising there from, except in the instance of gross negligence on the part of the Government.

IX.2 CONTRACTOR’S MOBILIZATION AREA

a) The Contractor is permitted to use the area identified by the Contracting Officer’s Representative for operation. The Contractor is cautioned that it shall be responsible for security within the contract limits. On completion of the contract, all facilities shall be removed from the mobilization area by the Contractor. The site shall be cleared of construction debris and other materials and the area restored to its final grade. The Contractor shall provide all utilities required to make the site self-sufficient.

b) The Contractor shall be responsible for the physical security of all material, supplies, and equipment in the Contractor's possession or located in the Contractor's on-site and off-site mobilization and work areas.

c) The Contractor shall control the movements and activities of its employees to protect the physical security of USAGM property.

IX.3 WORKING HOURS

The Contractor shall perform its site construction work during normal USAGM business hours, currently between 8:00 a.m. to 4:30 p.m. except on Philippine and American holidays. Any on-site work by the Contractor outside of these hours must be coordinated in advance and approved by the Contracting Officer.

IX.4 SAFETY REQUIREMENTS AND SUBMITTALS

b) Accident Reporting - A copy of each "Accident Report", which the Contractor or subcontractor submits to its insurance carriers, shall be forwarded to the Contracting Officer as soon as practicable, but in no event later than 7 calendar days after the date an accident occurs. Copies of each such report shall also be provided to the Contracting Officer within the above-stated time limitations. All lost-time injuries to Contractor or subcontractor personnel during project construction require the Contractor to submit an Accident Report as stated above.

IX.5 ON SITE PERSONNEL & SUPERVISION

a) At all times when any work is being performed on site, the Contractor shall have a Supervisor present and in charge of the work who has the capability of communicating in the English language, as well as the language of those performing the work. At any time the supervisor temporarily leaves the area of the work he shall designate an Acting Supervisor. The objective of this requirement is to have a designated person in charge of the work present at all times.

b) All work under this contract shall be performed in a skillful and workmanlike manner. All workmen shall wear shoes and proper clothing while accomplishing the work. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

c) There shall be no drugs, liquor, firearms, or explosives on the work site at any time. All departing Contractor vehicles and employees are subject to search.

IX.6 STANDARDS OF CONDUCT

a) The Contractor shall maintain satisfactory standards of employee competency, conduct, cleanliness, appearance and integrity and shall be responsible for taking such disciplinary action with respect to employees as may be necessary. Each contractor employee is expected to adhere to standard of conduct that reflects credit on themselves, their employer, and the United States Government. The Government reserves the right to direct the contractor to remove an employee from the work site for failure to comply with the standards of conduct.

b) Disorderly conduct, use of abusive or offensive language, quarreling, intimidation by words, actions, or fighting shall not be condoned. Also included is participation in disruptive activities, which interfere with normal and efficient Government operations.

c) Intoxicants and Narcotics. The Contractor shall not allow its employees while on duty to possess, sell, consume, or be under the influence of intoxicants, drugs or substances which produce similar effects.

IX.7 SITE SECURITY

a) The Contractor shall provide the names of all of its personnel working on-site to the Contracting Officer within 5 workdays after issuance of the Notice-To-Proceed by the Government.

b) The Contractor shall be fully responsible for site security of its materials and work from theft, fire, and vandalism.

IX.8 CONTRACTOR'S USE OF USAGM SITE

a) USAGM will occupy and conduct normal business operations at the site during the entire contract performance period. Any work by the Contractor that could cause a disruption of normal operations must be coordinated with and approved by the Contracting Officer.

b) The Contractor's use of the USAGM managed premises shall be limited to the immediate areas where the work is being performed and reasonable access routes to these areas. Use of toilet facilities, canteens, etc., at the existing station shall be as approved by the Contracting Officer.

c) During the contract performance period there may be other projects and Contractors working on these sites. Interface with such projects and Contractors shall be coordinated with the Contracting Officer.

d) The contractor shall coordinate hookup of temporary and new utilities with the Contracting Officer. Also, all required utility outages must be coordinated in writing at least 24 hours in advanc

END OF STATEMENT OF WORK

SECTION 2 - CONTRACT CLAUSES

52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS

(NOV 2021) IS INCORPORATED BY REFERENCE. (SEE SF-1449,

BLOCK 27A)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS—COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

(SEP 2023)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] __ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) ( 41 U.S.C. 4704 and 10 U.S.C. 4655).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

X (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

X (9) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) ( 31 U.S.C. 6101 note).

__ (10) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) ( 41 U.S.C. 2313).

__ (11) [Reserved].

__ (12) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) ( 15 U.S.C. 657a).

__ (13) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a).

__ (14) [Reserved] __ (15)

(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-6.

__ (16)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-7.

__ (17) 52.219-8, Utilization of Small Business Concerns (SEP 2023) ( 15 U.S.C. 637(d)(2) and (3)).

__ (18)

(i) 52.219-9, Small Business Subcontracting Plan (SEP 2023) ( 15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (NOV 2016) of 52.219-9.

__ (iii) Alternate II (NOV 2016) of 52.219-9.

__ (iv) Alternate III (JUN 2020) of 52.219-9.

__ (v) Alternate IV (SEP 2023) of 52.219-9.

__ (19)

(i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) ( 15 U.S.C. 644(r)).

__ (ii) Alternate I (MAR 2020) of 52.219-13.

__ (20) 52.219-14, Limitations on Subcontracting (OCT 2022) ( 15 U.S.C. 637s).

__ (21) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) ( 15 U.S.C. 637(d)(4)(F)(i)).

__ (22) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (OCT 2022) ( 15 U.S.C. 657f).

__ (23)

(i) 52.219-28, Post Award Small Business Program Rerepresentation (SEP 2023)( 15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (MAR 2020) of 52.219-28.

__ (24) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (OCT 2022) ( 15 U.S.C. 637(m)).

__ (25) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) ( 15 U.S.C. 637(m)).

__ (26) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) ( 15 U.S.C. 644(r)).

__ (27) 52.219-33, Nonmanufacturer Rule (SEP 2021) ( 15U.S.C. 637(a)(17)).

__ (28) 52.222-3, Convict Labor (JUN 2003) (E.O.11755).

X (29) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (DEC 2022) (E.O.13126).

__ (30) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

__ (31)

(i) 52.222-26, Equal Opportunity (SEP 2016) (E.O.11246).

__ (ii) Alternate I (FEB 1999) of 52.222-26.

__ (32)

(i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (ii) Alternate I (JUL 2014) of 52.222-35.

__ (33)

(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

__ (ii) Alternate I (JUL 2014) of 52.222-36.

__ (34) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (35) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

X (36)

(i) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (37) 52.222-54, Employment Eligibility Verification (MAY 2022) (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__ (38)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (MAY 2008) of 52.223-9 ( 42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (39) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

__ (40) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

__ (41)

(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (OCT 2015) of 52.223-13.

__ (42)

(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun2014) of 52.223-14.

__ (43) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) ( 42 U.S.C. 8259b).

__ (44)

(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (JUN 2014) of 52.223-16.

X (45) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O. 13513).

__ (46) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

__ (47) 52.223-21, Foams (Jun2016) (E.O. 13693).

__ (48)

(i) 52.224-3 Privacy Training (JAN 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (JAN 2017) of 52.224-3.

__ (49)

(i) 52.225-1, Buy American-Supplies (OCT 2022) ( 41 U.S.C. chapter 83).

__ (ii) Alternate I (OCT 2022) of 52.225-1.

__ (50)

(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (DEC 2022) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (DEC 2022) of 52.225-3.

__ (iv) Alternate III (JAN 2021) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (51) 52.225-5, Trade Agreements (DEC 2022) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X (52) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (53) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

__ (54) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) ( 42 U.S.C. 5150).

__ (55) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov2007) ( 42 U.S.C. 5150).

__ (56) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

X (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

__ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

X (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (OCT2018) ( 31 U.S.C. 3332).

__ (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) ( 31 U.S.C. 3332).

__ (61) 52.232-36, Payment by Third Party (MAY 2014) ( 31 U.S.C. 3332).

__ (62) 52.239-1, Privacy or Security Safeguards (AUG 1996) ( 5 U.S.C. 552a).

__ (63) 52.242-5, Payments to Small Business Subcontractors (JAN 2017) ( 15 U.S.C. 637(d)(13)).

__ (64)

(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631).

__ (ii) Alternate I (APR 2003) of 52.247-64.

__ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] __ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter67).

__ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

__ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

__ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

__ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

__ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) ( 42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(iv) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(v) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

(vi) 52.219-8, Utilization of Small Business Concerns (SEP 2023) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(viii) 52.222-26, Equal Opportunity (SEP 2015) (E.O.11246).

(ix) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

(x) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

(xi) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xiii) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter 67).

(xiv)

(A) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O 13627).

(B) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(xv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

(xvi) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

(xvii) 52.222-54, Employment Eligibility Verification (MAY 2022) (E.O. 12989).

(xviii) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

(xix) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

(xx)

(A) 52.224-3, Privacy Training (Jan 2017) ( 5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) ( 42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxiv) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

Alternate I (FEB 2000). As prescribed in 12.301 (b)(4)(i), delete paragraph (d) from the basic clause, redesignate paragraph (e) as paragraph (d), and revise the reference to "paragraphs (a), (b), (c), or (d) of this clause" in the redesignated paragraph (d) to read "paragraphs (a), (b), and (c) of this clause".

Alternate II (SEP 2023). As prescribed in 12.301 (b)(4)(ii), substitute the following paragraphs (d)(1) and (e)(1) for paragraphs (d)(1) and (e)(1) of the basic clause as follows:

(d)(1) The Comptroller General of the United States, an appropriate Inspector General appointed under section 3 or 8 G of the Inspector General Act of 1978 ( 5 U.S.C. App.), or an authorized representative of either of the foregoing officials shall have access to and right to—

(i) Examine any of the Contractor’s or any subcontractors’ records that pertain to, and involve transactions relating to, this contract; and

(ii) Interview any officer or employee regarding such transactions.

(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), and (c), of this clause, the Contractor is not required to flow down any FAR clause in a subcontract for commercial products or commercial services, other than—

(i) Paragraph (d) of this clause. This paragraph flows down to all subcontracts, except the authority of the Inspector General under paragraph (d)(1)(ii) does not flow down; and

(ii) Those clauses listed in this paragraph (e)(1). Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(A) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509).

(B) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5).

(C) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(D) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(E) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

(F) 52.219-8, Utilization of Small Business Concerns (SEP 2023) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(G) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(H) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

(I) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

(J) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

(K) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40

(L) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter 67).

(M) __ (1) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O 13627).

__ (2) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(N) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

(O) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

(P) 52.222-54, Employment Eligibility Verification (MAY 2022) (Executive Order 12989).

(Q) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

(R) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

(S)__ (1) 52.224-3, Privacy Training (JAN 2017) ( 5 U.S.C. 552a).

__ (2) Alternate I (JAN 2017) of 52.224-3.

(T) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(U) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (JUN 2020) ( 42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(V) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(W) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

ADDENDUM TO CONTRACT CLAUSES

FAR AND DOSAR CLAUSES NOT PRESCRIBED IN PART 12

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. In addition, the full text of a clause may be accessed electronically at: Acquisition.gov this address is subject to change.

If the Federal Acquisition Regulation (FAR) is not available at the location indicated above, use the Department of State Acquisition website at e-CFR to see the links to the FAR. You may also use an Internet “search engine” (for example, Google, Yahoo or Excite) to obtain the latest location of the most current FAR.

THE FOLLOWING FEDERAL ACQUISITION REGULATIONS (FAR) CLAUSES ARE INCORPORATED BY REFERENCE:

CLAUSE TITLE AND DATE

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE

MAINTENANCE (AUG 2020)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

52.228-4 WORKER’S COMPENSATION AND WAR-HAZARD INSURANCE OVERSEAS (APR 1984)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.229-6 FOREIGN FIXED PRICE CONTRACTS (FEB 2013)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUNE 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (MAR 2023)

52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (SEP 2023)

THE FOLLOWING FAR CLAUSES ARE PROVIDED IN FULL TEXT:

52.211-6 BRAND NAME OR EQUAL (AUG 1999)

(a) If an item in this solicitation is identified as "brand name or equal," the purchase description reflects the characteristics and level of quality that will satisfy the Government’s needs. The salient physical, functional, or performance characteristics that "equal" products must meet are specified in the solicitation.

(b) To be considered for award, offers of "equal" products, including "equal" products of the brand name manufacturer, must-

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by-

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate "equal" products on the basis of information furnished by the offeror or identified in the offer and reasonably available to the Contracting Officer. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

(d) Unless the offeror clearly indicates in its offer that the product being offered is an "equal" product, the offeror shall provide the brand name product referenced in the solicitation.

(End of provision)

THE FOLLOWING DOSAR CLAUSES ARE PROVIDED IN FULL TEXT:

CONTRACTOR IDENTIFICATION (JULY 2008)

Contract performance may require contractor personnel to attend meetings with government personnel and the public, work within government offices, and/or utilize government email.

Contractor personnel must take the following actions to identify themselves as non-federal employees:

1. Use an email signature block that shows name, the office being supported and company affiliation (e.g. “John Smith, Office of Human Resources, ACME Corporation Support Contractor”);

1. Clearly identify themselves and their contractor affiliation in meetings;

1. Identify their contractor affiliation in Departmental e-mail and phone listings whenever contractor personnel are included in those listings; and

1. Contractor personnel may not utilize Department of State logos or indicia on business cards.

(End of clause)

652.215-70 EXAMINATION OF RECORDS

(a) With respect to matters related to this contract or a subcontract hereunder, the Department of State Office of the Inspector General, or an authorized representative, shall have upon request:

(1) Complete, prompt, and free access to all Contractor and Subcontractor files (in any format), documents, records, data, premises, and employees, except as limited by law; and

(2) The right to interview any current Contractor and Subcontractor personnel, individually and directly, with respect to such matters.

(b) This clause may not be construed to require the contractor or any subcontractor to create or maintain any record that the contractor or subcontractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(c) The Contractor shall insert a clause containing all the terms of this clause, including this paragraph (c), in all subcontracts under this contract other than acquisitions described in Federal Acquisition Regulation 15.209(b)(1).

652.229-70 EXCISE TAX EXEMPTION STATEMENT FOR CONTRACTORS WITHIN THE UNITED STATES (JUL 1988) This is to certify that the item(s) covered by this contract is/are for export solely for the use of the U.S. Foreign Service Post identified in the contract schedule.

The Contractor shall use a photocopy of this contract as evidence of intent to export. Final proof of exportation may be obtained from the agent handling the shipment. Such proof shall be accepted in lieu of payment of excise tax.

652.232-70 PAYMENT SCHEDULE AND INVOICE SUBMISSION (FIXED-PRICE) (AUG 1999)

(a) General. The Government shall pay the Contractor as full compensation for all work required, performed, and accepted under this contract the firm fixed-price stated in this contract.

(b) Invoice Submission. The Contractor shall submit invoices to the office identified in Block 18b of the SF-1449. To constitute a proper invoice, the invoice shall include all the items required by FAR 32.905(e).

The Contractor shall send invoices to USAGM Philippines Procurement’s electronic inbox only: adminprocurement_philippines@usagm.gov

(c) Contractor Remittance Address. The Government will make payment to the contractor’s address stated on the cover page of this contract, unless a separate remittance address is shown below:

652.237-72 OBSERVANCE OF LEGAL HOLIDAYS AND ADMINISTRATIVE LEAVE

(FEB 2015)

(a) The Department of State observes the following days as holidays:

Any other day designated by Federal law, Executive Order, or Presidential Proclamation.

(b) When New Year’s Day, Independence Day, Veterans Day or Christmas Day falls on a Sunday, the following Monday is observed; if it falls on Saturday the preceding Friday is observed. Observance of such days by Government personnel shall not be cause for additional period of performance or entitlement to compensation except as set forth in the contract. If the contractor’s personnel work on a holiday, no form of holiday or other premium compensation will be reimbursed either as a direct or indirect cost, unless authorized pursuant to an overtime clause elsewhere in this contract.

(c) When the Department of State grants administrative leave to its Government employees, assigned contractor personnel in Government facilities shall also be dismissed. However, the contractor agrees to continue to provide sufficient personnel to perform round-the-clock requirements of critical tasks already in operation or scheduled, and shall be guided by the instructions issued by the contracting officer or his/her duly authorized representative.

(d) For fixed-price contracts, if services are not required or provided because the building is closed due to inclement weather, unanticipated holidays declared by the President, failure of Congress to appropriate funds, or similar reasons, deductions will be computed as follows:

(1) The deduction rate in dollars per day will be equal to the per month contract price divided by 21 days per month.

(2) The deduction rate in dollars per day will be multiplied by the number of days services are not required or provided.

If services are provided for portions of days, appropriate adjustment will be made by the contracting officer to ensure that the contractor is compensated for services provided.

(e) If administrative leave is granted to contractor personnel as a result of conditions stipulated in any “Excusable Delays” clause of this contract, it will be without loss to the contractor. The cost of salaries and wages to the contractor for the period of any such excused absence shall be a reimbursable item of direct cost hereunder for employees whose regular time is normally charged, and a reimbursable item of indirect cost for employees whose time is normally charged indirectly in accordance with the contractors accounting policy.

652.242-70 CONTRACTING OFFICER'S REPRESENTATIVE (COR) AUG 1999)

1. The Contracting Officer may designate in writing one or more Government employees, by name or position title, to take action for the Contracting Officer under this contract.