SV0212-26 Baler Solicitation Text C and P.pdf

Unicor, SV0212-26

Vertical Baler

Solicitation posted on SAM.gov: 5/6/2026

Deadline for quotes: 5/22/2026, 2PM EST.

SOLICITATION: Issued as Request for Quote (RFQ) for a Firm-Fixed-Price, Definite Delivery-Definite Quantity.

Set Aside: This is a 100% small business set-aside.

Timeline: We require this baler to be delivered and installed within 30 days of Award.

Buy American: This requirement must meet the Buy American Statute.

Requirement: Federal Prison Industries (FPI) is seeking to purchase one vertical baler, shipped FBO Destination, and installed at:

Unicor Lompoc Recycling

3901 Kline Blvd

Lompoc, CA 93436

SALIENT CHARACTERISTICS / WORK DESCRIPTION:

The baler shall meet or exceed the following minimum specifications:

• Type: Vertical downstroke hydraulic baler

• Motor: Minimum 20 HP

• Cycle Time: Maximum 60 seconds per cycle

• Platen Force: Minimum 80,000 lbs compression force

• Cylinder Rod: Minimum 4 inches

• Bale Size (Approximate):

o Width: ~60 inches o Depth: ~30 inches o Height: ~48 inches

• Bale Weight: Capable of producing bales between 1,000–1,600 lbs or greater

• Electrical Requirements: 208/230/460V, 3-phase

• Safety Features:

o Interlocked safety doors o Multi-point safety switch system o Emergency stop controls

The quote should include the baler, shipping FOB DST to Unicor in Lompoc, and installation and testing to ensure proper operation.

Questions for this solicitation will be addressed in writing to: wesley.newell2@usdoj.gov.

AWARD METHODOLOGY: This acquisition will be procured in accordance with FAR Part 12 – Acquisition of Commercial Items and Part 13 – Simplified Acquisition Procedures. The Government intends to evaluate quotes and award a contract that is the best overall value to the government, in accordance with FAR 52.212-1(g). Evaluation factors are price, technical capabilities, warranty and lead time.

The Government reserves the right to require the quoter to submit additional information as necessary to support a pre-award determination of responsibility.

PERIOD OF PERFORMANCE: UNICOR’s desired delivery is as soon as possible. Vendors are required to provide their best delivery time for evaluation. Delivery schedule will be established at time of award.

OFFERS: Signed and dated offers are submitted by email to: wesley.newell2@usdoj.gov

The date and time for receipt of quotes is:

Friday, May 8, 2026, at 2:00 p.m. EASTERN STANDARD TIME (EST).

Do not send offers via U.S. mail. OMB Clearance 1103-0018.

Offer must indicate Solicitation No. SV0212-26, time specified for receipt of offer, name, address, telephone number of offeror, technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation, terms of any expressed warranty, price and any discount terms. Offer must include acknowledgment of all amendments, if any.

THE FOLLOWING INFORMATION IS REQUIRED TO BE COMPLETED BY THE OFFEROR:

SAM UNIQUE ENTITY IDENTIFIER (UEI): _______________________________________

VENDOR POINT OF CONTACT: _____________________________________

VENDOR TELEPHONE & FAX NUMBER: _____________________________

VENDOR EMAIL ADDRESS: ________________________________________

mailto:wesley.newell2@usdoj.gov

VENDOR BUSINESS SIZE FOR NAICS CODE 333998: Small Business (Y or N): _____________

By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a quote, during performance and through final payment of any contract resulting from this solicitation.

The Contracting Officer is Wesley Newell at wesley.newell2@usdoj.gov.

PART I: INFORMATION

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. The solicitation number is SV0212-26 and this solicitation is issued as a Request For Quote (RFQ). The North American Industry Classification System code is 333998, All Other Miscellaneous General Purpose Machinery Manufacturing (small business size 700). This requirement is 100% set-aside for small business.

This solicitation should result in a Purchase Order. It will not be an ongoing contract.

NOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:

In the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Contracting Officer at UNICOR in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.

INVOICES ARE TO BE EMAILED TO:

Accounts.payable@usdoj.gov mailto:Accounts.payable@usdoj.gov

PART II: FAR CLAUSES

52.203-19: Prohibition on Requiring Certain Internal Confidentiality Agreements.

52.204-13: System for Award Management Maintenance

52.209-10: Prohibition on Contracting with Inverted Domestic Corporations.

52.212-4, Terms and Conditions—Commercial Products and Commercial Services As prescribed in 12.205(b)(3), insert the following clause:

Terms and Conditions—Commercial Products and Commercial Services (Deviation Date)

(a) Definitions. The clause at Federal Acquisition Regulation (FAR) 52.202-1, Definitions, is incorporated by reference.

(b) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance.

The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post acceptance rights—

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(c) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(d) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(e) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes.

Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal, or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause FAR 52.233-1, Disputes, which is incorporated in this contract by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence. Examples of occurrences include acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. When an excusable delay occurs, the Contractor shall—

(1) Notify the Contracting Officer in writing as soon as possible;

(2) Remedy the delay as quickly as possible; and

(3) Notify the Contracting Officer when the occurrence is over.

(g) Invoice. The Government will handle invoices according to the Prompt Payment

Act (31 U.S.C. 3903) and 5 CFR part 1315. The Contractor shall submit invoices to the address designated in the contract to receive invoices. An invoice must include the information required by 5 CFR part 1315.9(b).

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees, and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark, or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment—

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the

Prompt Payment Act ( 31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315.

(3) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date that appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(4) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable;

(D) Contractor point of contact; and

(ii) Provide a copy of the remittance and supporting documentation to the Contracting

Officer.

(5) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3903&num=0&edition=prelim

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by FAR part 33 if–

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see FAR part 32).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a termination for cause.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures for interest credits prescribed in FAR part 32 in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon—

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work and shall immediately cause any and all of its suppliers and subcontractors to cease work.

Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the

Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. The Government will send a cure notice to the Contractor, unless the reason for the termination is late delivery. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered under this contract are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 49 U.S.C. 40118, Government-financed air transportation; and 41 U.S.C. chapter 21 relating to procurement integrity.

(r) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services;

(2) The Disputes, Payments, Invoice, Compliance with Laws Unique to Government

Contracts, and Unauthorized Obligations paragraphs of this clause;

(3) Other contract clauses incorporated in the solicitation or contract;

(4) Addenda to this solicitation or contract;

(5) Solicitation provisions incorporated in the solicitation;

(6) Other paragraphs of this clause;

(7) Other documents, exhibits, and attachments; and

(8) The specification.

(s) Unauthorized obligations.

(1) Except as stated in paragraph (s)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government-authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (s)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(t) Comptroller General examination of record. This paragraph applies if this contract was awarded using other than sealed bid procedures and is in excess of the simplified acquisition threshold on the date of award of this contract.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices, at all reasonable times, the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR part 4, longer period required by statute, or periods specified in other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This clause does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(u) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of clause)

52.219-6: Notice of Total Small Business Set-Aside (If this was competed only among small businesses).

52.219-33: Nonmanufacturer Rule

52.222-3: Convict Labor

(a) Except as provided in paragraph (b) of this clause, the Contractor must not employ in the performance of this contract any person undergoing a sentence of imprisonment imposed by any court of a State, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, or the U.S. Virgin Islands.

(b) The Contractor is not prohibited from employing persons—

(1) On parole or probation to work at paid employment during the term of their sentence;

(2) Who have been pardoned or who have served their terms; or

(3) Confined for violation of the laws of any of the States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, or the U.S. Virgin Islands who are authorized to work at paid employment in the community under the laws of such jurisdiction, if-

(i) The worker is paid or is in an approved work training program on a voluntary basis;

(ii) Representatives of local union central bodies or similar labor union organizations have been consulted;

(iii) Such paid employment will not result in the displacement of employed workers, or be applied in skills, crafts, or trades in which there is a surplus of available gainful labor in the locality, or impair existing contracts for services;

(iv) The rates of pay and other conditions of employment will not be less than those paid or provided for work of a similar nature in the locality in which the work is being performed; and

(v) The Attorney General of the United States has certified that the work-release laws or regulations of the jurisdiction involved are in conformity with the requirements of Executive Order11755, as amended by Executive Orders 12608 and 12943.

(End of clause)

52.222-19: Child Labor—Cooperation with Authorities.

52.222-50: Combating Trafficking in Persons.

52.223-23: Sustainable Products and Services (Balers often involve recycled content or energy efficiency).

52.225-1 Buy American—Supplies (Oct 2022)

(a) Definitions. As used in this clause—

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

https://www.acquisition.gov/far/2.101#FAR_2_101 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title46-section40102(4)&num=0&edition=prelim

Component means an article, material, or supply incorporated directly into an end product.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph

(1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105 .

Domestic end product means—

(1) For an end product that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured end product mined or produced in the United States;

(ii) An end product manufactured in the United States, if-

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Components of unknown origin are treated as foreign. Scrap generated, collected, and prepared for processing in the United States is considered domestic; or

(B) The end product is a COTS item; or

(2) For an end product that consists wholly or predominantly of iron or steel or a combination of both, an end product manufactured in the United States, if the cost https://www.acquisition.gov/far/25.105#FAR_25_105 of foreign iron and steel constitutes less than 5 percent of the cost of all the components used in the end product. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the end product and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the end product contains multiple components, the cost of all the materials used in such end product is calculated in accordance with the definition of "cost of components".

End product means those articles, materials, and supplies to be acquired under the contract for public use.

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign end product means an end product other than a domestic end product.

Foreign iron and steel means iron or steel products not produced in the United States.

Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) 41 U.S.C. chapter 83, Buy American, provides a preference for domestic end products for supplies acquired for use in the United States. In accordance with 41 U.S.C.

1907, the domestic content test of the Buy American statute is waived for an end product that is a COTS item (see 12.505(a)(1)), except that for an end product that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the end product, excluding COTS fasteners.

http://uscode.house.gov/view.xhtml?req=granuleid%3AUSC-prelim-title41-chapter83&saved=%7CZ3JhbnVsZWlkOlVTQy1wcmVsaW0tdGl0bGU0MC1jaGFwdGVyMzctZnJvbnQ%3D%7C%7C%7C0%7Cfalse%7Cprelim&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section1907&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section1907&num=0&edition=prelim https://www.acquisition.gov/far/12.505#FAR_12_505

(c) Offerors may obtain from the Contracting Officer a list of foreign articles that the Contracting Officer will treat as domestic for this contract.

(d) The Contractor shall deliver only domestic end products except to the extent that it specified delivery of foreign end products in the provision of the solicitation entitled "Buy American Certificate."

(End of clause)

52.226-8: Encouraging Contractor Policies to Ban Text Messaging While Driving.

52.232-33: Payment by Electronic Funds Transfer (Standard via SAM).

52.232-40: Providing Accelerated Payments to Small Business Subcontractors.

52.233-3: Protest After Award.

52.233-4: Applicable Law for Breach of Contract Claim.

52.247-34, F.O.B. Destination (Jan 1991). delivery shall be FOB destination to UNICOR locations listed above.

52.252-2, Clauses Incorporated By Reference (Feb 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

___________www.acquisition.gov__________________

52.252-6, Authorized Deviation in Clauses (NOV 2020). (a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Local Level Economic Price Adjustment clause (48 CFR Chapter 16) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation. (END OF CLAUSE)

DOJ-01 Whistleblower Information Distribution (OCT 2021)

Within 30 days of contract award, the contractor and its subcontractors must distribute the “Whistleblower Information for Employees of DOJ Contractors, Subcontractors, Grantees, or Sub-Grantees or Personal Services Contractors” (“Whistleblower Information”) document to their employees performing work in support of the products and services delivered under this contract (https://oig.justice.gov/sites/default/files/2020-04/NDAA-brochure.pdf). By agreeing to the terms and conditions of this contract, the prime contractor acknowledges receipt of this requirement, in accordance with 41 U.S.C. § 4712 and FAR 3.906 & 52.203-17, and commits to distribution. Within 45 days of award, the contractor must provide confirmation to the contracting officer verifying that it has distributed the whistleblower information as required.

(End of Clause)

2852.233-70 PROTESTS FILED DIRECTLY WITH THE DEPARTMENT OF JUSTICE

(JAN 1998)

(a) The following definitions apply in this provision:

(1) "Agency Protest Official" means the official, other than the contracting officer, designated to review and decide procurement protests filed with a contracting activity of the Department of Justice.

(2) "Deciding Official" means the person chosen by the protestor to decide the agency protest; it may be either the Contracting Officer or the Agency Protest Official.

(3) "Interested Party" means an actual or prospective offeror whose direct economic interest would be affected by the award of a contract or by the failure to award a contract.

(b) A protest filed directly with the Department of Justice must:

(1) Indicate that it is a protest to the agency.

(2) Be filed with the Contracting Officer.

(3) State whether the protestor chooses to have the Contracting Officer or the Agency Protest Official decide the protest. If the protestor is silent on this matter, the Contracting Officer will decide the protest.

(4) Indicate whether the protestor prefers to make an oral or written presentation of arguments in support of the protest to the deciding official.

(5) Include the information required by FAR 33.103(d)(2):

(i) Name, address, facsimile number and telephone number of the protestor.

(ii) Solicitation or contract number.

(iii) Detailed statement of the legal and factual grounds for the protest, to include a description of resulting prejudice to the protestor.

(iv) Copies of relevant documents.

(v) Request for a ruling by the agency.

(vi) Statement as to the form of relief requested.

(vii) All information establishing that the protestor is an interested party for the purpose of filing a protest.

(viii) All information establishing the timeliness of the protest.

(c) An interested party filing a protest with the Department of Justice has the choice of requesting either that the Contracting Officer or the Agency Protest Official decide the protest.

(d) The decision by the Agency Protest Official is an alternative to a decision by the Contracting Officer. The Agency Protest Official will not consider appeals from the Contracting Officer's decision on an agency protest.

(e) The deciding official must conduct a scheduling conference with the protestor within five (5) days after the protest is filed. The scheduling conference will establish deadlines for oral or written arguments in support of the agency protest and for agency officials to present information in response to the protest issues. The deciding official may hear oral arguments in support of the agency protest at the same time as the scheduling conference, depending on availability of the necessary parties.

(f) Oral conferences may take place either by telephone or in person. Other parties may attend at the discretion of the deciding official.

(g) The protestor has only one opportunity to support or explain the substance of its protest. Department of Justice procedures do not provide for any discovery. The deciding official may request additional information from either the agency or the protestor. The deciding official will resolve the protest through informal presentations or meetings to the maximum extent practicable.

(h) An interested party may represent itself or be represented by legal counsel. The Department of Justice will not reimburse the protester for any legal fees related to the agency protest.

(i) The Department of Justice will stay award or suspend contract performance in accordance with FAR 33.103(f). The stay or suspension, unless over-ridden, remains in effect until the protest is decided, dismissed, or withdrawn.

(j) The deciding official will make a best effort to issue a decision on the protest within twenty (20) days after the filing date. The decision may be oral or written.

(k) The Department of Justice may dismiss or stay proceeding on an agency protest if a protest on the same or similar basis is filed with a protest forum outside the Department of Justice.]

PART III: PROVISIONS

52.203-18: Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation.

52.204-7: System for Award Management (Required for registration) (Nov 2024)

52.212-1: Instructions to Offerors—Commercial Products and Commercial Services (Sept 2023)

Instructions to Offerors—Commercial Products and Commercial Services (Sep 2023)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code(s) and small business size standard(s) for this acquisition appear elsewhere in the solicitation. However, the small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition—

(1)Is set aside for small business and has a value above the simplified acquisition threshold;

(2)Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(3)Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show—

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

https://www.gsa.gov/forms-library/solicitationcontractorder-commercial-items

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at Federal Acquisition Regulation (FAR) 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender’s request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with FAR subpart 4.10), or alternative commercial products or commercial services for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers.

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2) (i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, https://www.acquisition.gov/far/part-52#FAR_52_212_3 https://www.acquisition.gov/far/part-52#FAR_52_212_3 https://www.gsa.gov/forms-library/solicitationcontractorder-commercial-items https://www.acquisition.gov/far/part-4#FAR_Subpart_4_10 the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror’s initial offer should contain the offeror’s best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation.

(1) (i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101–29, and copies of Federal specifications, standards, and product descriptions can be downloaded from the ASSIST website at https://assist.dla.mil.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained from the address in paragraph (i)(1)(i) of this provision.

(2) Most unclassified Defense specifications and standards may be downloaded from the ASSIST website at https://assist.dla.mil.

(3) Defense documents not available from the ASSIST website may be requested from the Defense Standardization Program Office by—

(i) Using the ASSIST feedback module ( https://assist.dla.mil/feedback); or

(ii) Contacting the Defense Standardization Program Office by telephone at 571–767–6688 or email at assisthelp@dla.mil.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier.(Applies to all offers that exceed the micro-purchase threshold, and offers at or below the micro-purchase threshold if the solicitation requires the Contractor to be registered in the System for Award Management (SAM).)

The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see FAR subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity https://assist.dla.mil/ https://assist.dla.mil/ https://assist.dla.mil/feedback mailto:assisthelp@dla.mil https://www.acquisition.gov/far/part-32#FAR_Subpart_32_11 http://www.sam.gov/ identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) [Reserved]

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency’s evaluation of the significant weak or deficient factors in the debriefed offeror’s offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial products, the make and model of the product to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

52.212-2: Evaluation—Commercial Products and Commercial Services (Nov 2021)

(a) The government will award a contract resulting from this solicitation to the responsible Offeror whose Offer conforming to the solicitation will be most advantageous to the government, price and other factors considered. The following factors shall be used to evaluate offers:

Price, technical capabilities, warranty and delivery time.

(b) Options. The government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The government may determine that an offer is unacceptable if the option prices are significantly unbalanced.

Evaluation of options shall not obligate the government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful Offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified http://www.sam.gov/ expiration time, the government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(END OF PROVISION)

52.222-18: Certification Regarding Knowledge of Child Labor for Listed End Products

Certification Regarding Knowledge of Child Labor for Listed End Products (Feb 2021)

(a) Definition.

Forced or indentured child labor means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

(b) Listed end products. The following end product(s) being acquired under this solicitation is (are) included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, identified by their country of origin. There is a reasonable basis to believe that listed end products from the listed countries of origin may have been mined, produced, or manufactured by forced or indentured child labor.

Listed End Product Listed Countr

(c) Certification. The Government will not make award to an offeror unless the offeror, by checking the appropriate block, certifies to either paragraph (c)(1) or paragraph (c)(2) of this provision.

(1) □ The offeror will not supply any end product listed in paragraph (b) of this provision that was mined, produced, or manufactured in a corresponding country as listed for that end product.

(2) □ The offeror may supply an end product listed in paragraph (b) of this provision that was mined, produced, or manufactured in the corresponding country as listed for…