SUBCONTRACTOR_DATA_FORM.pdf

This is a Subcontractor Data Form issued by Dorchester County in South Carolina for use with solicitations requiring identification of subcontractors on proposed projects. Respondents must complete the form in its entirety and submit it with their original proposal response, listing all subcontractors that will be utilized on the project. The form requires documentation of each subcontractor's business name, address, phone number, and principal contact name, along with a brief description of the goods or services each subcontractor will provide. Respondents must indicate whether any licenses or certifications required by South Carolina law apply to each listed subcontractor or its employees. The form explicitly states that substitutions or alternative formats are not acceptable, and failure to complete and submit the form with the original solicitation response may result in rejection of the proposal.

The form serves as a standardized compliance document for the Job Order Contracting (JOC) Services for Sitework Trade Projects solicitation and requires complete transparency regarding all subcontractors involved in project delivery. Additional copies of the form may be attached if more subcontractors require documentation beyond the space provided on a single form. This requirement ensures that Dorchester County maintains a comprehensive record of all entities involved in contract performance and can verify that subcontractors meet applicable South Carolina regulatory requirements prior to award.