SPECS_W9128F21R0006.pdf

REQUEST FOR PROPOSAL

(FOR CONSTRUCTION CONTRACT)

SOLICITATION NO. W9128F-21-R-0006

REPAIR MASS PARKING APRON

SECTION IV, QJVF 1007861

MINOT AFB, NORTH DAKOTA

DECEMBER 2020

PREPARED BY:

U.S. Army Corps of Engineers, Omaha District

This page was intentionally left blank for duplex printing.

00 01 10 - 1 PROJECT TABLE OF CONTENTS

SPECIFICATIONS FOR CONSTRUCTION

REPAIR MASS PARKING APRON – SECTION IV

PN 1007861, FY21

MINOT AFB, NORTH DAKOTA

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 10 PROJECT TABLE OF CONTENTS

00 10 00-SF1442 SOLICITATION/CONTRACT FORM (SF 1442)

00 10 00CLIN CONTRACT LINE ITEM PRICING SCHEDULE

00 21 00 INSTRUCTIONS TO OFFERORS (RFP)

00 21 00AT MAP TO BASE GOLF COURSE

00 22 00 PROPOSAL INSTRUCTIONS, SUBMISSION REQUIREMENTS AND

EVALUATION

00 45 00 REPRESENTATIONS AND CERTIFICATIONS

00 72 01 GENERAL CONDITIONS (CONTRACT CLAUSES – RFP)

00 73 00 SPECIAL CONTRACT REQUIREMENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

AF FORM 103 BASE CIVIL ENGINEER WORK CLEARANCE REQUEST

PROJSIGN PROJECT SIGN DETAILS

ND20200037 GENERAL WAGE DECISION – HIGHWAY

01 30 00.24AT CONNECTION CHARGE AGREEMENT

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

REGISTER SUBMITTAL REGISTER

E4025 ENGINEERING FORM 4025 TRANSMITTAL FORM

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 35 29.13 HEALTH, SAFETY, AND EMERGENCY RESPONSE PROCEDURES FOR

CONTAMINATED SITES

01 41 26.06 24 (NORTH DAKOTA) NPDES PERMIT REQUIREMENTS FOR STORM WATER

DISCHARGES FROM CONSTRUCTION SITES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.00 10AT SAMPLE DAILY QUALITY CONTROL REPORT

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 62 35 RECYCLED / RECOVERED MATERIALS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 36.00 24 WARRANTY OF CONSTRUCTION

01 78 39.00 24 AS-BUILT DRAWINGS

01 78 39.00 24AT MODIFICATIONS AND TITLE BLOCK EXAMPLES

00 01 10 - 2 PROJECT TABLE OF CONTENTS

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 61 13 HANDLING OF CONTAMINATED MATERIAL

02 61 13AT1 MINOT AFB ANALYTICAL REPORT DATED 6 APR 2018

02 61 13AT2 SOIL BORING LOCATIONS

02 61 13AT3 PERFORMANCE STATEMENT OF WORK, POL CONTAMINATION

INVESTIGATION/REMOVAL

DIVISION 03 - CONCRETE

03 30 04 CONCRETE FOR MINOR STRUCTURES

DIVISION 26 - ELECTRICAL

26 42 19.00 20 CATHODIC PROTECTION BY IMPRESSED CURRENT

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 16.17 COLD MILLING OF BITUMINOUS PAVEMENTS

32 01 19.61 SEALING OF JOINTS IN RIGID PAVEMENTS

32 11 20 SUBBASE COURSE

32 11 23 AGGREGATE BASE COURSE

32 12 13 BITUMINOUS TACK AND PRIME COATS

32 12 15.13 ASPHALT PAVING FOR AIRFIELDS

32 13 14.13 CONCRETE PAVEMENT FOR AIRFIELDS AND OTHER HEAVY DUTY

PAVEMENTS

32 13 73.19 COMPRESSION CONCRETE PAVING JOINT SEALANT

32 17 23 PAVEMENT MARKINGS

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 46 16 SUBDRAINAGE SYSTEM

DIVISION 34 - TRANSPORTATION

34 73 16 AIRFIELD GROUNDING

-- End of Project Table of Contents --

00 10 00 - 1

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W9128F21R0006

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

9 DEC 2020

PAGES OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

6. PROJECT NO.

7. ISSUED BY CODE CT 8. ADDRESS OFFER TO

Rocky Mountain Area Office Attn: CONTRACTING DIVISION (CENWO-CT-M) 5475 Tech Center Drive, Suite 205 Colorado Springs, CO 80919

See Block 7

9. FOR INFORMATION

CALL:

A. NAME

Booker L. Jordan, Jr.

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS) Use Email: Booker.L.Jordan@usace.army.mil

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

The offeror hereby agrees to do all work described in the documents entitled:

REPAIR MASS PARKING APRON – SECTION IV

QJVF 1007861

MINOT AFB, NORTH DAKOTA

RETURN WITH OFFER: INFORMATION REQUIRED BY SECTION 00 10 00 (SF1442), SECTIONS 00 22 00 AND 00 45 00.

REFER TO BLOCK 13A FOR THE NUMBER OF COPIES TO BE SUBMITTED WITH THE ORIGINAL OFFER.

THIS SOLICITATION IS UNRESTRICTED AND IS OPEN TO BOTH LARGE AND SMALL BUSINESS PARTICIPITATION

11. The Contractor shall begin performance within 10 calendar days and complete it within ** calendar days after receiving award, notice to proceed. This performance period is mandatory, negotiable. (** See Section 00 73 00____________)

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 0 copies to perform the work required are due at the place specified in Item 8 by 1400 (hour) local time 11 JAN 2021. If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than ___60_____ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442(REV. 4-85)

Prescribed by GSA FAR(48 CFR) 53.236-1(d)

00 10 00 - 2

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

DUNS Number:

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within 60 calendar days after the date offers are due.

AMOUNTS

SEE ATTACHED CLIN PRICING SCHEDULE

Contractor’s Fax No. CAGE CODE Contractor’s E-Mail address

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

U.S. Army Engineer District, Omaha 1616 Capitol Ave.

Omaha, Nebraska 68102-4901

USAED Omaha c/o USACE Finance Center 5722 Integrity Drive Millington, TN 38054-5005

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (contractor is required to sign this document and return _______ copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award,

(b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation, is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. UNITED STATES OF AMERICA

BY

31C. AWARD DATE

STANDARD FORM 1442 BACK (REV. 4-85)

CLIN SCHEDULE 00 10 00 - 3 W9128F-21-R-0006

CONTRACT LINE ITEM PRICING SCHEDULE

ITEM

NO.

DESCRIPTION QTY UNIT UNIT

PRICE

AMOUNT

BASIC ITEMS

All work complete for construction of Repair Mass Parking Apron – Section IV, PN QJVF1007861, FY21, Minot AFB, North Dakota, excluding all CLIN’s listed separately below.

1 Job XXX $ ________________________

All work complete for the Concrete Pavement in accordance with the drawings and Section 32 13 14.13 CONCRETE

PAVEMENT FOR AIRFIELDS AND

OTHER HEAVY DUTY PAVEMENTS.

1 Job XXX $ ________________________

All work complete for the Hot-Mix Asphalt in accordance with the drawings and Section

32 12 15.13 HOT-MIX ASPHALT

AIRFIELD PAVING.

1 Job XXX $ ________________________

TOTAL AMOUNT BASIC ITEMS $_________________________

OPTION ITEMS

[Option]

Additional cost of all work complete for airfield pavement marking using Type III retroreflective beads in accordance with the drawings and Section 32 17 23 PAVEMENT MARKINGS in lieu of Type I retroreflective beads.

1 Job XXX $ ________________________

[Option]

Contaminated Soil Disposal – Includes all work to dispose of fuel contaminated soil found to be above North Dakota action levels requiring offsite disposal during construction and any offsite clean soil to replace contaminated soil volume.

8,000 Cubic Yards

Per Cubic

Yard

[Option]

Contaminated Groundwater – Includes all work to containerize, and properly dispose of contaminated petroleum-contaminated groundwater and provide notification to regulatory agencies for petroleum contaminated groundwater that cannot be discharged to the sewer.

500 Gallons

Per Gallon

[Option]

Access delays during concrete production placement. Estimated quantities are 25 hours. See Note 5 below.

1 Job XXX $ ________________________

[Option]

Access delays other than during concrete production placement. Estimated quantities are 75 hours. See Note 5 below.

1 Job XXX $ ________________________

TOTAL AMOUNT (ALL BASIC PLUS OPTION ITEMS)

CLIN SCHEDULE 00 10 00 - 4 W9128F-21-R-0006

NOTES:

1. See SECTION 00 21 00, INSTRUCTIONS TO OFFERORS (RFP) for evaluation of options. The Government reserves the right to exercise Option 0004 within 60 calendar days after issuance of Notice to Proceed, Options 0005 & 0006 anytime during required excavations for the contract, and remaining Options any time during construction.

2. Prices must be entered for all items of the schedule. Total amounts submitted without prices being entered on individual items will be rejected. In case of variation between the lump-sum prices and the total amount, the lump-sum prices will be considered the price submitted. In case of variation between the unit prices and the extensions, the unit prices will be considered the price submitted.

3. A modification to a proposal which provides for a single adjustment to the total amount submitted, should state the application of the adjustment to each respective lump-sum price and unit price affected.

4. Quantities for unit priced items are estimated only and the respective unit price will prevail in the event of an overrun or under-run subject to General Conditions (Contract Clauses) clause “Variation in Estimated Quantities”

5. Access Delays. Access Delays under Items 0007 and 0008 - Measure and pay for each half hour that the entire workforce is delayed, or prevented from accessing the project site. The Contractor’s superintendent shall notify the Contracting Officer’s on-site representative within twenty-four hours (24) of any delay restricting access to the jobsite. This item will be paid based on a half-hour of work basis. All partial half hours for a notified delay will be rounded up to the next half-hour increment. These access delays apply to Items 0001, 0002, 0003, 0005, and 0006.

Repair Mass Parking Apron - Section 4, QJVF 100119, Minot AFB, ND MIB8

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 21 00

INSTRUCTIONS TO OFFERORS (RFP)

07/20

PART 1 GENERAL

1.1 (FAR 52.204-7) SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

1.2 (FAR 52.204-16) COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING

(AUG 2020)

1.3 (FAR 52.204-22) ALTERNATIVE LINE ITEM PROPOSAL (JAN 2017)

1.4 (FAR 52.211-2) AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA

ITEM DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND

STANDARDIZATION INFORMATION SYSTEM (ASSIST) (APR 2014)

1.5 (FAR 52.215-1) INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION

(JAN 2017)

1.6 (FAR 52.216-1) TYPE OF CONTRACT (APR 1984)

1.7 (FAR 52.217-5) EVALUATION OF OPTIONS (JUL 1990)

1.8 FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS-SECONDARY SITE

OF THE WORK (MAY 2014)

1.9 *FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

1.10 (FAR 52.232-18) AVAILABILITY OF FUNDS (APR 1984)

1.11 (FAR 52.233-2) SERVICE OF PROTEST (SEPT 2006)

1.12 (FAR 52.236-27) SITE VISIT (CONSTRUCTION) (FEB 1995)- ALTERNATE I

(FEB 1995).

1.13 (FAR 52.252-1) SOLICITATION PROVISIONS INCORPORATED BY

REFERENCE (FEB 1998)

1.14 (DFARS 252.204-7008) COMPLIANCE WITH SAFEGUARDING COVERED

DEFENSE INFORMATION CONTROLS (OCT 2016)

1.15 (DFARS 252.215-7008) ONLY ONE OFFER (JUN 2019)

1.16 (DFARS 252.215-7010) REQUIREMENTS FOR CERTIFIED COST OR PRICING

DATA AND DATA OTHER THAN CERTIFIED COST OR PRICING DATA—BASIC (JUN

2019)

1.17 SOLICITATION RESTRICTIONS

1.17.1 GENERAL CONTRACTOR

1.17.2 ESTIMATED CONSTRUCTION COST

1.17.3 SUBMISSION, MODIFICATION, REVISION, AND WITHDRAWAL OF

PROPOSALS

1.17.4 SUBMISSION DEADLINE

1.17.5 CAD AND ELECTRONIC DESIGN FILES (PROVIDED)

1.18 COPIES OF SOLICITATION DOCUMENT AND AMENDMENTS

1.19 OFFEROR'S QUESTIONS AND COMMENTS

1.19.1 BIDDER INQUIRY

1.19.2 PLAN HOLDER'S LIST

1.20 GENERAL DESCRIPTION OF WORK

1.21 PROPOSAL SUBMISSION REQUIREMENTS, EVALUATION AND CONTRACT AWARD

1.22 SOURCE SELECTION BOARD (SSB)

1.23 FEDERAL, STATE AND LOCAL TAXES

1.24 TAXES - NORTH DAKOTA

1.24.1 USE TAX

DOCUMENT 00 21 00 Page 1

1.25 SUBCONTRACTING PLAN/SUBCONTRACTING GOALS REGARDING THE

UTILIZATION OF SMALL BUSINESS CONCERNS

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section Table of Contents --

DOCUMENT 00 21 00 Page 2

SECTION 00 21 00

INSTRUCTIONS TO OFFERORS (RFP)

07/20

PART 1 GENERAL

1.1 (FAR 52.204-7) SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

(a) Definitions. As used in this provision-

“Electronic Funds Transfer (EFT) indicator” means a fourcharacter suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

"Registered in the System for Award Management (SAM)" means that-

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14) into SAM;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record "Active".

“Unique entity identifier” means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b)(1) An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “Unique Entity Identifier” followed by the unique entity identifier that identifies the Offeror’s name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in SAM.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of

DOCUMENT 00 21 00 Page 3 the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company Physical Street Address, City, State, and Zip Code.

(4) Company Mailing Address, City, State and Zip Code (if separate from physical).

(5) Company Telephone Number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company Headquarters name and address (reporting relationship within your entity).

(d) Processing time should be taken into consideration when registering. Offerors who are not registered in SAM should consider applying for registration immediately upon receipt of this solicitation.

See https://www.sam.gov for information on registration.

(End of provision)

1.2 (FAR 52.204-16) COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (AUG

2020)

(a) Definition. As used in this provision –

“Commercial and Government Entity (CAGE) code” means –

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic

Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its proposal. The CAGE code must be for that name and location address. Insert the word “CAGE” before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via–

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

DOCUMENT 00 21 00 Page 4

(2) The DLA Contractor and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an Offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity’s country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity’s country is not a member of NATO or a sponsored nation.

Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE code is required for the immediate owner and/or the highest-level owner by Federal Acquisition Regulation (FAR) 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE code from that entity to supply the CAGE code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(g) If the solicitation includes FAR clause 52.204-2, Security Requirements, a subcontractor requiring access to classified information under a contract shall be identified with a CAGE code on the DD Form 254.

The Contractor shall require a subcontractor requiring access to classified information to provide its CAGE code with its name and location address or otherwise include it prominently in the proposal. Each location of subcontractor performance listed on the DD Form 254 is required to reflect a corresponding unique CAGE code for each listed location unless the work is being performed at a Government facility, in which case the agency location code shall be used. The CAGE code must be for that name and location address. Insert the word “CAGE” before the number. The CAGE code is required prior to award.

(End of provision)

1.3 (FAR 52.204-22) ALTERNATIVE LINE ITEM PROPOSAL (JAN 2017)

(a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror’s practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments. Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract is economically and administratively advantageous to the Government and the Offeror.

(b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation.

However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be

DOCUMENT 00 21 00 Page 5 nonresponsive or unacceptable.

(End of provision)

1.4 (FAR 52.211-2) AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA

ITEM DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND STANDARDIZATION

INFORMATION SYSTEM (ASSIST) (APR 2014)

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (https://assist.dla.mil/online/start/);

(2) Quick Search (http://quicksearch.dla.mil/);

(3) ASSISTdocs.com (http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by-

(1) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.

(End of provision)

1.5 (FAR 52.215-1) INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN

2017)

(a) Definitions. As used in this provision- "Discussions" are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal.

"In writing," "writing," or "written" means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

"Proposal modification" is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

"Proposal revision" is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

"Time," if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show-

(i) The solicitation number;

DOCUMENT 00 21 00 Page 6

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation.

If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the

DOCUMENT 00 21 00 Page 7 provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award.

Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall-

(1) Mark the title page with the following legend:

This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed-in whole or in part-for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of-or in connection with-the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend:

Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award. (1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government's interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit

DOCUMENT 00 21 00 Page 8 the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government's best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

1.6 (FAR 52.216-1) TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed price contract resulting from this solicitation.

(End of provision)

1.7 (FAR 52.217-5) EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

DOCUMENT 00 21 00 Page 9

1.8 FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS-SECONDARY SITE OF

THE WORK (MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

1.9 *FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "designated country construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials Under Trade Agreements" (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a

DOCUMENT 00 21 00 Page 10 separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

1.10 (FAR 52.232-18) AVAILABILITY OF FUNDS (APR 1984)

Funds are not presently available for this contract. The Government's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made.

No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

1.11 (FAR 52.233-2) SERVICE OF PROTEST (SEPT 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from District Counsel, 1616 Capitol Avenue, Omaha, Nebraska 68102-4901.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

1.12 (FAR 52.236-27) SITE VISIT (CONSTRUCTION) (FEB 1995)- ALTERNATE I

(FEB 1995).

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation.

Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for--

17 DEC 2020 at 1000 (10:00 a.m. Mountain).

(c) Participants will meet at the clubhouse parking lot of the:

Roughrider Golf Course 220 Golf Drive Minot AFB, ND 58705

DOCUMENT 00 21 00 Page 11

Please Note: The Roughrider Golf Course is not actually on the Base proper. The course is just north of the Minot AFB MINOT GATE and south of the Minot AFB MAGIC CITY GATE on the west side of HIGHWAY 83. See attached "Map to Base Golf Course."

**Pre-registration is required, provide the following information seven calendar days prior to the site visit date for each site visit attendee to the site visit point of contact (POC) listed below:

-Names of persons attending -Name of company -Date of birth -Driver's license number and state

-SOCIAL SECURITY NUMBER.

Site Visit POC:

Madeleine Cowell 701-727-6127 Madeleine.H.Cowell@usace.army.mil

There will be NO PHOTOGRAPHY allowed on base. If an attendee would like photos taken, they shall inform the designated government personnel.

Photos will be taken by that designated personnel and made available to attendees within one week.

Visitors will be required to wear face masks and will be split into appropriately-sized groups to tour the site.

(End of Provision)

1.13 (FAR 52.252-1) SOLICITATION PROVISIONS INCORPORATED BY REFERENCE

(FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://acquisition.gov/comp/far/index.html http://www.acq.osd.mil/dpap/ (End of provision)

1.14 (DFARS 252.204-7008) COMPLIANCE WITH SAFEGUARDING COVERED DEFENSE

INFORMATION CONTROLS (OCT 2016)

(a) Definitions. As used in this provision—

“Controlled technical information,” “covered contractor information system,” covered defense information, cyber incident, information system, and technical information are defined in clause 252.204-7012, Safeguarding Covered Defense Information and Cyber Incident Reporting.

DOCUMENT 00 21 00 Page 12

(b) The security requirements required by contract clause 252.204-7012 shall be implemented for all covered defense information on all covered contractor information systems that support the performance of this contract.

(c) For covered contractor information systems that are not part of an information technology service or system operated on behalf of the Government (see 252.204-7012(b)(2))—

(1) By submission of this offer, the Offeror represents that it will implement the security requirements specified by National Institute of Standards and Technology (NIST) Special Publication (SP) 800-171, “Protecting Controlled Unclassified Information in Nonfederal Information Systems and Organizations” (see http://dx.doi.org/10.6028/NIST.SP.800-171) that are in effect at the time the solicitation is issued or as authorized by the contracting officer, not later than December 31, 2017.

(2)(i) If the Offeror proposes to vary from any of the security requirements specified by NIST SP 800-171 that are in effect at the time the solicitation is issued or as authorized by the Contracting Officer, the Offeror shall submit to the Contracting Officer, for consideration by the DoD Chief Information Officer (CIO), a written explanation of—

(A) Why a particular security requirement is not applicable; or

(B) How an alternative but equally effective, security measure is used to compensate for the inability to satisfy a particular requirement and achieve equivalent protection.

(ii) An authorized representative of the DoD CIO will adjudicate offeror requests to vary from NIST SP 800-171 requirements in writing prior to contract award. Any accepted variance from NIST SP 800-171 shall be incorporated into the resulting contract.

(End of provision)

1.15 (DFARS 252.215-7008) ONLY ONE OFFER (JUN 2019)

(a) Cost or pricing data requirements. After initial submission of offers, if the Contracting Officer notifies the Offeror that only one offer was received, the Offeror agrees to-

(1) Submit any additional cost or pricing data that is required in order to determine whether the price is fair and reasonable or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 2306a and FAR 15.403-3); and

(2) Except as provided in paragraph (b) of this provision, if the acquisition exceeds the certified cost or pricing data threshold and an exception to the requirement for certified cost or pricing data at FAR 15.403-1(b)(2) through (5) does not apply, certify all cost or pricing data in accordance with paragraph (c) of DFARS provision 252.215-7010, Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data, of this solicitation.

(b) Canadian Commercial Corporation. If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required.

DOCUMENT 00 21 00 Page 13

If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with DFARS 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.S. Contracting Officer that the proposed price is fair and reasonable [U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(c) Subcontracts. Unless the Offeror is the Canadian Commercial Corporation, the Offeror shall insert the substance of this provision, including this paragraph (c), in all subcontracts exceeding the simplified acquisition threshold defined in FAR part 2.

(End of provision)

1.16 (DFARS 252.215-7010) REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA

AND DATA OTHER THAN CERTIFIED COST OR PRICING DATA—BASIC (JUN 2019)

(a) Definitions. As used in this provision—

“Market prices” means current prices that are established in the course of ordinary trade between buyers and sellers free to bargain and that can be substantiated through competition or from sources independent of the offerors.

“Non-Government sales” means sales of the supplies or services to non-Governmental entities for purposes other than governmental purposes.

“Relevant sales data” means information provided by an offeror on sales of the same or similar items that can be used to establish price reasonableness taking into consideration the age, volume, and nature of the transactions (including any related discounts, refunds, rebates, offsets, or other adjustments).

“Sufficient non-Government sales” means relevant sales data that reflects market pricing and contains enough information to make adjustments covered by FAR 15.404-1(b)(2)(ii)(B).

“Uncertified cost data” means the subset of “data other than certified cost or pricing data” (see FAR 2.101) that relates to cost.

(b) Exceptions from certified cost or pricing data.

(1) In lieu of submitting certified cost or pricing data, DOCUMENT 00 21 00 Page 14 the Offeror may submit a written request for exception by submitting the information described in paragraphs (b)(1)(i) and (ii) of this provision.

The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted and whether the price is fair and reasonable.

(i) Exception for prices set by law or regulation - Identification of the law or…