Attachment_F_Offeror_Submission_Package_COG_3.pdf

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

OFFEROR SUBMISSION PACKAGE

SOLICITATION: SPE600-17-R-0210

PURCHASE PROGRAM: COG 3

THE ENCLOSED SOLICITATION COVERS THE PERIOD:

ORDERING PERIOD

01 AUGUST 2017 THROUGH 31 JULY 2022

DELIVERY PERIOD

01 AUGUST 2017 THROUGH 31 AUGUST 2022

TO BE TIMELY, OFFERS MUST BE RECEIVED AT THE DLA ENERGY CENTER BY:

01 MAY 2017, 2:00 P.M. Eastern Standard Time (EST)

OFFERS MUST BE ACCOMPANIED BY SPECIFICATION SHEETS FOR THE

TYPES OF FUEL OFFERED OR WILL NOT BE CONSIDERED FOR EVALUATION.

All documents to be completed and returned are contained in this Offer Submission Package:

X Standard Form 1449, Solicitation/Contract/Order for Commercial Items

The SF 1449 must be signed by an Officer of the Company

NOTE: Clause K33 only authorizes other designated employees to prepare offers and conduct negotiations with the Contracting Officer or his designated Government representative in lieu of an Officer of the Company.

X All applicable fill-in clauses. Please type in all prices.

1. Please be sure to proofread all offers for accuracy and legibility prior to submission. Initial all changes and sign and date the Standard Form 1449. ALL PAGES MUST SHOW SOLICITATION NUMBER AND OFFEROR’S COMPANY NAME.

ALL PAGES MUST BE RETURNED.

2. Facsimile proposals may be submitted in accordance with Clause 52.215-5, FACSIMILE OFFERS. The DLA Energy facsimile number is (703) 767-8506.

3. By submission of this package, you are stating that all terms and conditions of the entire solicitation are accepted and apply to your offer unless clearly stated herein and in a formal letter accompanying this OSP on company letterhead with a full explanation of ALL exceptions be taken and what is proposed instead. The Offeror should be prepared to provide a cost savings summary to the Government for review based on any exceptions submitted.

COMPANY NAME:___________________________________

SPE600-17-R-0210

Table of Contents

SECTION F ----------------------------------------------------------------------------------------------2

F-0005 F3 TRANSPORT TRUCK AND/OR TRUCK AND TRAILER FREE TIME AND DETENTION RATES

(PC&S) (DLA ENERGY AUG 2005) ----------------------------------------------------------------------------- 2

F-0006 F3.03 NOTIFICATION OF CHANGE IN TRANSPORTATION COMPANY (PC&S) (DLA ENERGY APR 2005) ---------------------------------------------------------------------------------------------------------------------- 2

F-0008 F16 BARGE UNLOADING CONDITIONS (DLA ENERGY JAN 2012) ------------------------------------------- 2

SECTION G ----------------------------------------------------------------------------------------------4

G-0002 G9.06 ADDRESS TO WHICH REMITTANCE SHOULD BE MAILED (DLA ENERGY JAN 2017) ------- 4

G-0003 G9.07 ELECTRONIC TRANSFER OF FUNDS PAYMENTS - CORPORATE TRADE EXCHANGE (DLA ENERGY JUL 2007) -------------------------------------------------------------------------------------------------- 5

SECTION K ----------------------------------------------------------------------------------------------7

FAR 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS -- COMMERCIAL ITEMS (JAN

2017) ---------------------------------------------------------------------------------------------------------------------- 7

FAR 52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015) ----------------------- 23

FAR 52.209-6 PROTECTING THE GOVERNMENTS INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT. ------------ 25

FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013) -------------------------- 26

K-0001 K1.01-7 OFFEROR REPRESENTATIONS AND CERTIFICATIONS – COMMERCIAL ITEMS

(CONT’D) (DLA ENERGY FEB 2009) -------------------------------------------------------------------------- 26

K-0004 K33.01 AUTHORIZED NEGOTIATORS (DESC APR 2007) -------------------------------------------------------- 27

K-0005 K45.01 FACSIMILE OR ELECTRONIC INVOICING (DLA ENERGY JAN 2012) ---------------------------- 27

SECTION L -------------------------------------------------------------------------------------------- 28

FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (PC&S) (TAILORED) (DLA

ENERGY) (Jan 2017) ------------------------------------------------------------------------------------------------ 28

DLAD 52.233-9001 DISPUTES - AGREEMENT TO USE ALTERNATIVE DISPUTE RESOLUTION (DEC 2016)

L-0002 L2.07 EVIDENCE OF RESPONSIBILITY (DLA ENERGY JAN 1998) ------------------------------------------- 31

L-0006 L117 NOTIFICATION OF TRANSPORTATION COMPANY TO BE UTILIZED IN THE DELIVERY OF PRODUCT (PC&S) (DLA ENERGY JAN 2012) ---------------------------------------------------------------- 32

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE 17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NO.

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

RFQ IFB RFP

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

29. AWARD OF CONTRACT: REF.

DATED . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 3/2005)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITON IS

UNRESTRICTED OR

NAICS:

SIZE STANDARD:

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

OFFER

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

SET ASIDE:

% FOR:

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS

EMERGING SMALL

BUSINESS

8(A)

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

FPR1816

Highlight

FPR1816

Highlight

FPR1816

Highlight

FPR1816

Highlight

FPR1816

Highlight

FPR1816

Highlight

OSP-2

SECTION F

F-0005 F3 TRANSPORT TRUCK AND/OR TRUCK AND TRAILER FREE TIME AND DETENTION RATES (PC&S) (DLA

ENERGY AUG 2005)

(a) Upon arrival of Contractor's transport truck or truck and trailer, the receiving activity shall promptly designate the tanks into which the load is to be discharged. Free time will commence when the discharge hose is connected to the receiving line at the delivery point and will end when discharge is completed. The Contractor shall be paid for detention beyond free time for delays caused by the Government. A minimum of one hour free time is required.

(1) Free time for unloading a transport truck or truck and trailer (includes one hour minimum plus any additional time): _______________________________________________.

(2) Rate for detention beyond free time:

The above will not be considered in the evaluation of offers for award except that a free time of less than one hour may render an offer unacceptable. Notwithstanding the above, the Government is entitled to at least as much free time as is allowed by the common carrier or that the Contractor normally allows its regular commercial customers, whichever is greater.

Free time only applies to single-drop deliveries (it is not applicable to multiple-drop tank truck/truck and trailer deliveries or any tank wagon deliveries).

(b) Notwithstanding the above, the Government will not pay more in detention rates than the actual rate charged by the common carrier or the rate the Contractor normally charges its regular commercial customers, whichever is lower. Detention costs will be the sole responsibility of the activity incurring them and are only allowable on single drop deliveries (they are not allowable on multiple drop tank truck/truck and trailer deliveries or any tank wagon deliveries. Invoices for detention costs will be submitted by the Contractor directly to the activity receiving the product. These provisions are applicable to DLA-owned/capitalized as well as non-DLA-owned/noncapitalized products.

(c) UNLESS THE OFFEROR OTHERWISE INDICATES IN PARAGRAPHS (a)(1) AND (a)(2) ABOVE, FREE TIME

WILL BE CONSIDERED UNLIMITED AND DETENTION COSTS WILL NOT BE CHARGEABLE.

F-0006 F3.03 NOTIFICATION OF CHANGE IN TRANSPORTATION COMPANY (PC&S) (DLA ENERGY APR 2005)

(a) In the performance of this contract, the Contractor agrees not to utilize transportation companies that have been debarred or suspended, are ineligible for receipt of contracts with Government agencies, are in receipt of a notice of proposed debarment or ineligibility from any Government agency, or are otherwise ineligible under Federal programs. Substitution of a new transportation company is subject to review by the Contracting Officer for use under this contract.

(b) If the Contractor changes transporters after award, the Contractor shall provide the Contracting Officer with the following information on alternative or new transportation company(ies) being utilized in the transportation of supplies under this contract.

Name, Address, and Phone Number State(s) in which transporter of Transportation Company is authorized to operate

F-0008 F16 BARGE UNLOADING CONDITIONS (DLA ENERGY JAN 2012)

(a) On items calling for delivery f.o.b. destination by means of barge--

(1) The supplies ordered hereunder shall be delivered, all transportation charges paid, to the destination specified in the Schedule. Unless otherwise specified in the Schedule, orders placed under items of the Schedule calling for delivery f.o.b. destination by means of barge will be furnished the Contractor at least 24 hours, plus the normal barge running time from point of loading to the destination, in advance of the date on which delivery is to be made, which date is hereinafter referred to in this contract provision as the "scheduled delivery date." Each order will specify the quantity to be delivered and the scheduled delivery date. The scheduled delivery date may be changed by the Contractor at any time if the Ordering Officer approves.

(2) Within 3 hours after receipt of notice by the receiving activity from the Master or Mate of a tug or of a self-propelled barge of readiness to unload, the Government will provide, free of cost, a reachable safe berth for the tug and tow or self-propelled barge to be afloat at all times at the unloading port: PROVIDED, however, that if the receiving activity does not receive notice of a barge's readiness to unload within 24 hours before or after noon of the latest approved scheduled delivery date, the Government will be allowed 12 hours after receipt of notice within which to provide a berth.

OSP-3

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

(3) Unless otherwise provided in the Schedule, the Government shall be allowed and will complete unloading within laytime determined as follows: 1 hour for each 2,000 barrels of supplies to be unloaded, plus 1 1/2 hours; PROVIDED, however, that if the condition or facilities of the barge to be unloaded do not permit unloading within the number of hours so determined, such allowed laytime shall be increased by a number of hours sufficient to permit the unloading of the barge;

PROVIDED, further, that when the barge is delayed in reaching its berth within 3 hours or 12 hours, as the case may be, from the time notice of readiness to unload is given, and the delay is caused by the fault of the barge, such allowed laytime shall be increased by the duration of such delay; and PROVIDED, further, that if regulations of the owner or operator of the barge or Port Authorities prohibit unloading at any time, time so lost shall be added to the amount of such allowed laytime. Laytime shall commence either--

(i) At the expiration of the notice period prescribed by (2) above (the 3 hours' or the 12 hours' notice, as the case may be), berth or no berth; or

(ii) Immediately upon the barge's arrival in berth (i.e., all fast), with or without notice of readiness, whichever first occurs. Laytime shall continue 24 hours a day, 7 days a week, without interruption from its commencement, until unloading of the barge is completed and the hoses have been disconnected.

(4) For all hours of laytime that elapse in excess of the allowed laytime for unloading provided for by paragraph

(3) above, or as otherwise provided for in the Schedule, demurrage will be paid by the Government at the demurrage rate in the charter for the barge unloading, except (i) that such rate shall be reduced by 1/2 if demurrage is incurred due to causes beyond the control and without the fault and negligence of the Government; and (ii) that the demurrage payable by the Government shall in no event exceed the actual demurrage expense incurred by the Contractor under the charter. For purposes of computing demurrage payable by the Government, if the laytime allowed in the charter is a combined total for both loading and discharging, 1/2 thereof shall be allocated to the unloading operation, except when less than a full cargo is unloaded, where such allocation shall be determined on a pro-rata basis.

(5) In the event of breakdown of Contractor's equipment, which will prohibit unloading for at least two hours, the Contractor will be required to remove the equipment from the Government-provided berth, unless permission is granted by the Government to allow the equipment to remain on berth. When the Government grants permission for the Contractor equipment to remain on berth, the Contractor will be responsible to reimburse the Government for any cost incurred by the Government for furnishing personnel to remain with the barge during repair; PROVIDED further, that if the Contractor removes the equipment from the Government provided berth, notice of readiness to unload will be again required as provided in (2) above.

(6) For all deliveries, hoses for unloading a barge will be furnished, connected, and disconnected by the Government.

(7) Title to the supplies delivered, and risk of loss thereof, shall pass from the Contractor to the Government when the supplies pass the permanent hose connections of the barge unloading the supplies.

(8) The term barge, as used herein, shall include lake tankers.

(b) BARGE FREE TIME AND DEMURRAGE CHARGES FOR DOMESTIC POSTS, CAMPS, AND STATIONS

CONTRACTS.

(1) Unless the offeror indicates otherwise, free time will be unlimited. Free time allowed and demurrage rates will not be considered in evaluation of offers for award.

DEMURRAGE BEYOND FREE TIME

ITEM FREE TIME ALLOWED BARGE TUG OTHER

(2) Notwithstanding the above, the Government will not pay more than the actual rate charged by the barge carrier or the rate the Contractor normally charges its regular commercial customers, whichever is lower. Free time is in addition to all hours of laytime that elapse in excess of the allowed laytime for unloading as provided in this contract provision.

OSP-4

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

SECTION G

G-0002 G9.06 ADDRESS TO WHICH REMITTANCE SHOULD BE MAILED (DLA ENERGY JAN 2017)

Remittances shall be mailed only at the Government’s option or where an exception to payment by Electronic Funds Transfer (EFT) applies. (See the PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT or the PAYMENT BY ELECTRONIC FUNDS TRANSFER - OTHER THAN SYSTEM FOR AWARD MANAGEMENT clause.)

Offeror shall indicate below the complete mailing address (including the nine-digit zip code) to which remittances should be mailed if such address is other than that shown in Block 15a (Standard Form (SF) 33) for noncommercial items or Block 17a (SF 1449) for commercial items. In addition, if offeror did not incorporate its nine-digit zip code in the address shown in Block 15a of the SF 33 or in Block 17a of the SF 1449, the offeror shall enter it below:

(a) Payee Name (Contractor): | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

(b) Check Remittance Address:

(DO NOT EXCEED 30 CHARACTERS PER LINE)

(c) Narrative Information (special instructions).

(DO NOT EXCEED 153 CHARACTERS)

THIS CLAUSE APPLIES ONLY TO DLA ENERGY-FUNDED ITEMS FOR DOMESTIC AND FOREIGN SUPPLIERS

WHO CHOOSE TO BE PAID BY THE CORPORATE TRADE EXCHANGE WHEN THE RECEIVING BANK IS

LOCATED IN THE UNITED STATES .

OSP-5

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

G-0003 G9.07 ELECTRONIC TRANSFER OF FUNDS PAYMENTS - CORPORATE TRADE EXCHANGE (DLA ENERGY

JUL 2007)

(a) The Contractor shall supply the following information to the Contracting Officer no later than 5 days after contract award and before submission of the first request for payment. The bank designated as the receiving bank must be located in the United States and must be capable of receiving Automated Clearing House (ACH) transactions.

NAME OF RECEIVING BANK: | | | | | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 29 CHARACTERS)

CITY AND STATE OF RECEIVING BANK: | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 20 CHARACTERS)

AMERICAN BANKERS ASSOCIATION NINE DIGIT IDENTIFIER OF RECEIVING BANK: | | | | | | | | | |

ACCOUNT TYPE CODE: (Contractor to designate one)

[ ] CHECKING TYPE 22

[ ] SAVINGS TYPE 32

RECIPIENT'S ACCOUNT NUMBER ENCLOSED IN PARENTHESES: | | | | | | | | | | | | | | | |

(DO NOT EXCEED 15 CHARACTERS)

RECIPIENT'S NAME: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

STREET ADDRESS: | | | | | | | | | | | | | | | | | | | | | | | | | |

CITY AND STATE: | | | | | | | | | | | | | | | | | | | | | | | | | |

NOTE: Additional information may be entered in EITHER paragraph (b) OR paragraph (c) below. Total space available for information entered in (b) OR (c) is 153 characters.

(b) SPECIAL INSTRUCTIONS/OTHER IDENTIFYING DATA:

OR

OSP-6

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

(c) THIRD PARTY INFORMATION: Where payment is to be forwarded from the receiving bank to another financial institution for deposit into Contractor's account, the following information must be supplied by the Contractor: Second Bank Name, City/State and/or Country, Account Number, and Account Name.

(d) CONTRACTOR'S DESIGNATED OFFICIAL SUBMITTING ELECTRONIC FUNDS TRANSFER

INFORMATION.

NAME: | | | | | | | | | | | | | | | | | | | | | | | | | |

TITLE: | | | | | | | | | | | | | | | | | | | | | | | | | |

TELEPHONE NUMBER: | | | | | | | | | | | | | | | | | | | | | | | | | |

SIGNATURE: ______________________________________________________________________

(e) Any change by the Contractor in designation of the bank account to receive electronic transfer of funds in accordance with this clause must be received by the Contracting Officer no later than 30 days prior to the date the change is to become effective.

(f) The electronic transfer of funds does not constitute an assignment of such funds in any form or fashion.

(g) In the event corporate trade exchange (CTX) payments cannot be processed, the Government retains the option to make payments under this contract by check.

(h) NOTICE TO FOREIGN SUPPLIERS.

(1) Payment may be made through the Federal Reserve Wire Transfer system. The bank designated as the receiving bank must be located in the United States and must be capable of receiving ACH transactions. The appropriate American Bankers Association nine-digit identifier must be supplied in order for payments to be processed through CTX.

(2) If your account is with a foreign bank that has an account with a bank located within the United States, the U.S.

bank may be designated as the receiving bank. The recipient's name and account number shall identify the foreign bank, and transfer instructions to supplier's account must be specified in (b) OR (c) above.

(3) The Third Party information supplied in (c) above will be located in the first RMT segment of the CTX payment information sent to the receiving bank.

(i) Notwithstanding any other provision of the contract, the requirements of this clause shall control.

OSP-7

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

SECTION K

FAR 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS -- COMMERCIAL ITEMS (JAN 2017)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’ “. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(vi) The Family and Medical Leave Act; and

(vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(4) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

OSP-8

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(5) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(6) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C.

395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

OSP-9

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

OSP-10

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C.

101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

OSP-11

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ____________. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas.

Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [_] is, [_] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [_] is, [_] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:

_________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

OSP-12

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

(i) It [_] is, [_] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: _____________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [_] is, [_] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [_] is, [_] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Representations required to implement provisions of Executive Order 11246 --

(1) Previous contracts and compliance. The offeror represents that --

(i) It [_] has, [_] has not, participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and

(ii) It [_] has, [_] has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that --

(i) It [_] has developed and has on file, [_] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or

(ii) It [_] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American – Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic

OSP-13

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

LINE ITEM NO.

COUNTRY OF ORIGIN

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)

(1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American- -Free Trade Agreements--Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) or this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

OSP-14

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian End Products:

Line Item No.:

[List as necessary]

(3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act'':

Canadian or Israeli End Products:

Line Item No.:

Country of Origin:

(4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

OSP-15

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this…