Solicitation_W912WJ20Q0104.pdf

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912WJ20Q0104 20-Aug-2020 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

SEE SCHEDULE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ] FOB

DESTINATION

[ ] OTHER X

(See Schedule)

08-Sep-2020(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

AMANDA N LANE

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912WJ20Q0104

Section B - Supplies or Services and Prices

INSTRUCTIONS TO OFFERORS

*SITE VISITS ARE HIGHLY RECOMMENDED PRIOR TO PROVIDING A QUOTE. SEE CLAUSE 52.236-27

FOR ADDITIONAL INFORMATION.

*PLEASE DIRECT QUESTIONS TO AMANDA LANE AT (978) 318-8814 or

AMANDA.N.LANE@USACE.ARMY.MIL. ANY INFORMATION RECEIVED AT THE SITE VISIT WHICH

CONFLICTS WITH THIS SOLICITAION SHOULD BE BROUGHT TO THE ATTENTION OF AMANDA

LANE. THE SOLICITATION AND RESULTING CONTRACT SHALL BE THE GOVERNING DOCUMENT

IN ALL CASES.

** QUOTES CAN BE E-MAILED TO AMANDA LANE AT AMANDA.N.LANE@USACE.ARMY.MIL.

NOTE 1: In accordance with FAR Part 28.101-1(c), the Contractor will NOT be required to provide a Bid Guarantee.

NOTE 2: In accordance with FAR Part 28.102-1(b), the Contractor will be required to provide the following payment protections for all construction contracts greater than $150,000.00.

(i) Payment Bond or

(ii) Irrevocable Letter of Credit and

(iii) Performance Bond

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

A Performance Bond shall be required if the total price of the quote is greater than $150,000.00. The penal amount of the Performance Bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall also be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 3: In accordance with FAR Part 28.102-1(c), the Contractor will be required to provide one of the following payment protections for all construction contracts greater than $35,000.00 but not greater than $150,000.00.

(i) Payment bond or

(ii) Irrevocable letter of credit

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 4:

QUOTATION INSTRUCTIONS:

1. If subcontractor will be used for this work, please provide company name:

2. In accordance with FAR Part 52.204-7(b)(1) Contractors must be registered in the System for Award Management (SAM) database (www.SAM.gov) to submit an offer. (Formerly the Central Contractor Registration

(CCR) database and the On-Line Representations and Certifications (ORCA).) Any reference to CCR or ORCA in any clause or provision is referring to the www.sam.gov website. Please note that Google and Google Chrome are not supported browsers for SAM registration. Mozilla FireFox, Safari, and Internet Explorer are supported browsers.

NOTE: SAM.gov registration takes approximately 3 weeks (DUNS registration 1-2 business days; CAGE code validation up to 10 business days; IRS validation and overall submission 7-10 business days). It is the contractor’s responsibility to track SAM.gov registration and follow-up with required tasks.

In addition, if you are registering a new entity in SAM.gov, you must provide an original, signed notarized letter stating that you are the authorized Entity Administrator. The Entity Administrator must establish a LOGIN.GOV account using the e-mail address that will be associated with the SAM registration. See https://www.gsa.gov/about-us/organization/federal-acquisition-service/office-of-systems-management/integrated-award-environment-iae/sam-update for additional information.

3. Provide business DUNS number: _______________________________ (phone 800-333-0505 for DUNS).

4. Provide business CAGE code: __________________________________

5. Tax Identification Number: ___________________________________

6. Contractors shall provide completed FAR clause 52.204-8 (Annual Representations and Certifications) found in Section K of this solicitation with their quote, if the Contractors have not completed their annual representations and certifications electronically via the SAM website at www.sam.gov. (See Paragraph 2 above).

7. Contractors are not required to submit an Accident Prevention Plan (APP) with their quote. The successful offeror will be required to submit this document at the direction of the Technical Point of Contact. The APP must be accepted by the Government Designated Authority prior to the commencement of work.

POTENTIAL OFFERORS ARE NOTIFIED THAT THE BASIS ON WHICH AWARD WILL BE MADE IS

PRICE ALONE.

ALL RESPONSIBLE SOURCES MAY SUBMIT A RESPONSE WHICH, IF TIMELY RECEIVED, MUST BE

CONSIDERED BY THE AGENCY.

INVOICES SHALL BE SENT TO TECHNICAL POINT OF CONTACT.

BID SCHEDULE

BIDDING SCHEDULE

Refer to Section 2.2 MEASUREMENT / PAYMENT.

Item Estimated Unit Estimated

No. Description Quantity Unit Price Amount

Base Bid Items

0001 Concrete Repairs (3”) 2210 SF $ $

0002 Concrete Repairs (3”-5”)

600 SF $ $

0003 Hazard Markers 1 LS Job $

0004 Granite Curb Installation 94 LF $ $

TOTAL ESTIMATED AMOUNT $

Note 1: "SF" = Square Foot, "LF" = Linear Foot, “LS” = Lump Sum

Note 2: Quoters must quote all items. The work will be awarded as a whole to one quoter. Quotes will be evaluated and the low quoter determined by the Total Estimated Amount for Line Items 0001 through 0004.

Note 3: All work shall be completed within the time period specified in SPECIAL CONTRACT

REQUIREMENTS, COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK (APR 1984)

FAR 52.211-10.

Note 4: In the event there is a difference between a unit price and the extended total, the unit price will be held to be the intended quote. If the quoter shows only the total price but fails to enter a unit price, the total divided by the estimated quantity will be held to be the intended unit price.

Section C - Descriptions and Specifications

STATEMENT OF WORK

SEE SPECIFICATIONS AND DRAWINGS INCLUDED AS SEPARATE FILES.

Section E - Inspection and Acceptance

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

Section H - Special Contract Requirements

SECURITY REQUIREMENTS

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the Contracting Officer Representative (COR) NLT 5 calendar days after the completion of the training.

WAGE DETERMINATION

"General Decision Number: MA20200002 08/07/2020

Superseded General Decision Number: MA20190002

State: Massachusetts

Construction Types: Heavy (Heavy and Dredging)

HEAVY CONSTRUCTION PROJECTS; AND

MARINE CONSTRUCTION PROJECTS

County: Worcester County in Massachusetts.

HEAVY CONSTRUCTION PROJECTS; AND MARINE CONSTRUCTION PROJECTS

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.80 for calendar year 2020 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.80 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2020. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the

Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/03/2020 1 02/14/2020 2 02/21/2020 3 03/13/2020 4 08/07/2020

ASBE0006-005 09/01/2019

Rates Fringes

Insulator/asbestos worker Includes the application of all insulating materials, protective coverings, coating, and finishes to all types of mechanical systems..........$ 43.60 29.90

BOIL0029-001 01/01/2017

Rates Fringes

BOILERMAKER......................$ 42.42 24.92

* BRMA0001-002 02/01/2020

SPRINGFIELD/PITTSFIELD CHAPTER WORCESTER (Warren County)

Rates Fringes

Bricklayer, Cement Mason, Plasterer & Stonemason...........$ 42.81 32.59

* BRMA0001-014 02/01/2020

WORCESTER CHAPTER

WORCESTER (Auburn Barre, Blackstone, Berlin, Bolton, Boylston, the Brookfields, Charlton, Clinton, Douglas, Dudley, Grafton, Hardwick, Holden, Leicester, Mendon, Millbury, Milville, New

Braintree, Northboro, Northbridge, Oakham, Oxford, Paxton, Rutland, Shrewbury, Southbridge, Spencer, Sturbridge, Sutton, Upton, Uxbridge, Webster, Westboro, West Boylston, Worcester)

Rates Fringes

Bricklayer, Cement Mason, Plasterer & Stonemason...........$ 52.26 34.26

* BRMA0001-015 02/01/2020

LOWELL CHAPTER

WORCESTER (Hopedale, Milford, Southboro)

Rates Fringes

Bricklayer, Cement Mason, Plasterer & Stonemason...........$ 52.26 34.26

* BRMA0001-023 02/01/2020

LOWELL CHAPTER

WORCESTER (Ashburhanm, Athol, Fitchburg, Gardner, Harvard, Hubbardston, Lancaster, Leominster, Lunenburg, Petersham, Phillipston, Princeton, Royalston, Sterling, Templeton, Westminster, Winchendon)

Bricklayer, Cement Mason, Plasterer & Stonemason...........$ 52.26 34.26

* BRMA0003-001 02/01/2020

Rates Fringes

Marble & Tile Finisher...........$ 41.49 32.82 Marble, Tile & Terrazzo Workers..........................$ 53.34 34.80

TERRAZZO FINISHER................$ 54.42 34.98

CARP0056-004 08/01/2018

DIVER TENDER.....................$ 46.07 32.25

DIVER............................$ 64.50 32.25

CARP0056-008 08/01/2018

Rates Fringes

PILEDRIVERMAN....................$ 46.07 32.25

CARP0108-001 09/04/2017

WORCESTER (Gilbertville, Hardwick, Warren, West Brookfield)

Rates Fringes

Carpenter/Lather.................$ 35.56 23.76

CARP0336-002 09/01/2019

WORCESTER (Except Gilbertville, Harwick, Warren, West Brookfield)

Carpenter/Lather.................$ 41.90 29.00

CARP1121-004 01/06/2020

Rates Fringes

MILLWRIGHT.......................$ 36.71 31.15

ELEC0096-002 07/01/2019

WORCESTER (Warren)

Rates Fringes

ELECTRICIAN......................$ 44.07 11%+22.53

ELEC0104-001 09/03/2017

Line Construction:

Cableman....................$ 38.45 18.42+A Equipment Operator..........$ 38.45 22.50+A Groundman...................$ 24.88 10.24+A Lineman.....................$ 45.23 25.71+A

A. PAID HOLIDAYS: New Year's Day; Memorial Day;

Independence Day; Labor Day; Thanksgiving Day; Christmas Day and Columbus Day, provided the employee has been employed 5 working days prior to any one of the listed holidays.

ELEV0041-002 01/01/2020

Rates Fringes

ELEVATOR MECHANIC................$ 54.85 34.765+a+b

FOOTNOTE:

a.Vacation: 6%/under 5 years based on regular hourly rate for all hours worked. 8%/over 5 years based on regular hourly rate for all hours worked.

b. PAID HOLIDAYS: New Year's Day; Memorial Day; Independence Day; Labor Day; Veterans' Day; Thanksgiving Day; the Friday after Thanksgiving Day; and Christmas Day.

* ENGI0004-003 06/01/2020

WORCESTER (Except Athol, Barre, Brookfield, East Brookfield, Hardwick, New Braintree, North Brookfield, Oakham, Petersham, Phillipston, Royalston, Strutbridge, Templeton, Warren, West Brookfield, Winchendon)

Power equipment operators:

BUILDING, HEAVY & MARINE

GROUP 1....................$ 48.73 29.25

Group 1....................$ 49.33 29.75

GROUP 2....................$ 48.23 29.25

Group 2....................$ 48.81 29.75

GROUP 3....................$ 32.47 29.25

Group 3....................$ 32.72 29.75

GROUP 4....................$ 39.89 29.25

Group 4....................$ 40.30 29.75

GROUP 5....................$ 23.08 29.25

Group 5....................$ 23.13 29.75

GROUP 6....................$ 27.64 29.25

Group 6....................$ 27.79 29.75

FOOTNOTE FOR POWER EQUIPMENT OPERATORS:

A. PAID HOLIDAYS: New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Patriot's Day, Columbus Day, Veteran's Day, Thanksgiving Day, Christmas Day

HOURLY PREMIUM FOR BOOM LENGTHS (Including Jib):

Over 150 ft. +2.18 Over 185 ft. +3.84 Over 210 ft. +5.39 Over 250 ft. +8.16 Over 295 ft. +11.29 Over 350 ft. +13.14

POWER EQUIPMENT OPERATORS CLASSIFICATIONS BUILDING AND HEAVY

CONSTRUCTION

GROUP 1: Power shovel; crane; truck crane; derrick; pile driver; trenching machine; mechanical hoist pavement breaker; cement concrete paver; dragline; hoisting engine;

three drum machine; pumpcrete machine; loaders; shovel dozer; front end loader; mucking machine; shaft hoist;

steam engine; backhoe; gradall; cable way; fork lift;

cherry picker; boring machine; rotary drill; post hole hammer; port hole digger; asphalt plant on job site;

concrete batching and/or mixing plant on job site; crusher plant on job site; paving concrete mixer; timber jack GROUP 2: Sonic or vibratory hammer; grader; scraper; tandem scraper; bulldozer; tractor; mechanic - maintenance; York rake; mulching machine; paving screed machine;stationary steam boiler; paving concrete finishing machine; grout pump; portable steam boiler; portable steam generator;

roller; spreader; asphalt paver; locomotives or machines used in place thereof; tamper (self propelled or tractor-draw); cal tracks; ballast regulator;rail anchor machine; switch tamper; tire truck GROUP 3: Pumps (1-3 grouped); compressor; welding machines (1-3 grouped); generator; sighting plant; heaters (power driven, 1- 5); syphon-pulsometer; concrete mixer; valves controlling permanent plant air steam, conveyor, wellpoint system (operating) GROUP 4: Assitant engineer (fireman) GROUP 5: Oiler (other than truck cranes and gradalls) GROUP 6: Oiler (on truck cranes and gradalls)

POWER EQUIPMENT OPERATORS CLASSIFICATIONS MARINE CONSTRUCTION

GROUP 1: Shovel; crane; truck crane; cherry picker; derrick;

pile driver; two or more drum machines; lighters; derrick boats; trenching machines; mechanic hoist pavement breakers; cement concrete pavers; draglines; hoisting engines; pumpcrete machines; elevating graders; shovel dozer; front end loader; backhoe; gradall; cable ways;

boring machine; rotary drill; post hole hammer; post hole digger; fork lift; timber jack; asphalt plant (on site);

concrete batching and/or mixing plant (on site); crusher plant (on site); paving concrete mixer GROUP 2: Portable steam boiler; portable steam generator;

sonic or vibratory hammer; grader; scraper; tandem scraper;

concrete pump; bulldozer; tractor; York rake; mulching machine; roller; spreader; tamper (self-propelled or tractor-drawn); asphalt paver; concrete mixer with side loader; mechanic - maintenance; cal tracks; ballast regulator; switch tamper; rail anchor machine; tire truck GROUP 3: Pumps (1-3 grouped); comressor; welding machines (1-3 grouped); generator; lighting plant; heaters (power driven 1-5); syphon-pulsometer; concrete mixer; valves controlling permanent plant air or steam; conveyor; well point systems; auger (powered by independent engines and attached to pile drivers); hydraulic saws GROUP 4: Fireman GROUP 5: Assistant engineer (other than truck crane and gradall) GROUP 6: Assistant engineer (on truck crane and gradall)

ENGI0098-005 12/01/2016

Rates Fringes

Power equipment operators:

Group 1....................$ 33.68 23.96+A Group 2....................$ 33.37 23.96+A Group 3....................$ 33.15 23.96+A Group 4....................$ 32.54 23.96+A Group 5....................$ 29.92 23.96+A Group 6....................$ 28.80 23.96+A

Group 7....................$ 26.86 23.96+A Group 8....................$ 305.95 23.96+A Group 9....................$ 230.69 23.96+A Group 10....................$ 35.17 23.96+A Group 11....................$ 38.18 23.96+A Group 12....................$ 39.68 23.96+A Group 13....................$ 40.68 23.96+A Group 14....................$ 41.68 23.96+A Group 15....................$ 43.18 23.96+A

HAZARDOUS WASTE PREMIUM $2.00

FOOTNOTE FOR POWER EQUIPMENT OPERATORS:

Group 8 and Group 9 are per day wages.

A. Paid Holidays: New year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day and Christmas Day

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

Group 1: Shovels; crawlers and truck cranes including all tower; self-propelled hydraulic cranes 10 tons and over;

draglines; clam shells; cableways; shaft hoists; mucking machines derricks; backhoes; bulldozers; gradalls;

elevating graders; pile drivers; concrete pavers; trenching machines; front end loaders- 5 1/2 cu yds and over; dual drum paver; automatic grader-excavator(C.M.I. or equal);

scrapers towing pan or wagon; tandem dozers or push cats(2 units in tandem); shotcrete machine; tunnel boring machine;

combination backhoe/loader 3/4 cu yd hoe or over; jet engine dryer; tree shredder; post hole digger; post hole hammer; post extractor; truck mounted concrete pump with boom; roto-mill; Grader; Horizontal Drilling Machine; John Henry Rock Drill and similar equipment.

Group 2: Rotary drill with mounted compressor; compressor house (3 to 6 compressors); rock and earth boring machines (excluding McCarthy and similar drills); front end loaders 4 cu yds to 5 1/2 cu yds); forklifts-7 ft lift and over 3 ton capacity; scraper 21 yds and over (struck load); sonic hammer console; reclaimers road planer/milling machine; cal tracks; ballast regulators; rail anchor machines; switch tampers, asphalt pavers; mechanic; welder and transfer machine.

Group 3: Combination backhoe/loader up to 3/4 cu yd;

scrapers up to 21 cu yd (struck load, self propelled or tractor drawn); tireman; front end loaders up to 4 yds;

well drillers; engineer or fireman on high pressure boiler;

self-loading batch plant; well point operators electric pumps used in well point system; pumps, 16 inches and over (total discharge); compressor, one or two 900 cu ft and over; powered grease truck; tunnel locomotives and dingys;

grout pumps; hydraulic jacks; boom truck; hydraulic cranes-up to 10 ton.

Group 4: Asphalt rollers; self-powered rollers and compactors; tractor without blade drawing sheepsfoot roller; rubber tire roller; vibratory roller or other type of compactors including machines for pulverizing and aerating soil; york rake.

Group 5: Hoists; conveyors; power pavement breakers;

self-powered concrete pavement finishing machines; two bag mixers with skip; McCarthy and similar drills; batch plants (not self loading); bulk cement plants; self-propelled material spreaders; three or more 10 KW light plants; 30 KW or more generators; power broom.

Group 6: Compressor (one or two) 315 cu ft to 900 cu ft;

pumps 4 inches to 16 inches (total discharge).

Group 7: Compressors up to 315 cu ft; small mixers with skip; pumps up to 4 inches; power heaters; oiler; A-frame trucks; forklifts-up to 7 ft. lift and up to 3 ton capacity; hydro broom; stud welder.

Group 8: Truck crane crews Group 9: Oiler Group 10: Master Mechanic Group 11: Boom lengths over 150 feet including jib Group 12: Boom lengths over 200 feet including jib Group 13: Boom lengths over 250 feet including jib Group 14: Boom lengths over 300 feet including jib Group 15: Boom lengths over 350 feet including jib

* IRON0007-012 09/16/2019

Rates Fringes

IRONWORKER.......................$ 47.09 32.81

LABO0022-001 06/01/2018

Rates Fringes

Laborers: (HEAVY CONSTRUCTION)

GROUP 1.....................$ 33.25 22.92

GROUP 2.....................$ 33.50 22.92

GROUP 3.....................$ 34.00 22.92

GROUP 4.....................$ 34.25 22.92

GROUP 5.....................$ 21.50 22.92

GROUP 6.....................$ 34.25 22.92

LABORERS CLASSIFICATIONS

GROUP 1: Laborers; carpenter tenders; cement finisher tenders, plasterer tenders

GROUP 2: Asphalt raker; fence and guard rail erector; laser beam operator; mason tender; pipelayer; pneumatic drill operator; pneumatic tool operator; wagon drill operator, jack hammer operator, pavement breaker, carbide core drilling machine, chain saw operator, barco type jumping tampers, concrete pump, motorized mortar mixer, ride-on-motorized buggy

GROUP 3: Air track operator; block paver; rammer; curb setter, hydraulic and similar self powered drills

GROUP 4: Blaster; powderman

GROUP 5: Flagger

GROUP 6: Asbestos Abatement; Toxic and Hazardous Waste Laborers

LABO0022-013 06/01/2018

Rates Fringes

Laborers:

(FREE AIR OPERATION):

SHIELD DRIVEN AND LINER

PLATE IN FREE AIR)

GROUP 1....................$ 39.40 21.80+a GROUP 2....................$ 39.40 21.80+a

(OPEN AIR CASSONS,

UNDERPINNING AND TEST

BORING INDUSTRIES):

TEST BORING & WELL DRILLING

Driller....................$ 39.35 24.30+A Laborer....................$ 37.95 24.30+A

(OPEN AIR CASSONS,

UNDERPINNING AND TEST

BORING INDUSTRIES):

OPEN AIR CASSON,

UNDERPINNING WORK & BORING

CREW

Bottom man.................$ 39.10 24.30+A Laborers; Top man..........$ 37.95 24.30+A

(TUNNELS, CAISSON &

CYLINDER WORK IN

COMPRESSED AIR)

GROUP 1....................$ 39.75 24.70+a GROUP 2....................$ 42.30 24.70+a GROUP 3....................$ 42.30 24.70+a GROUP 4....................$ 42.30 24.70+a GROUP 5....................$ 42.30 24.70+a GROUP 6....................$ 44.30 24.70+a

CLEANING CONCRETE AND

CAULKING TUNNEL (Both New & Existing) GROUP 1....................$ 39.40 21.80+a GROUP 2....................$ 39.40 21.80+a

ROCK SHAFT, CONCRETE

LINING OF SAME AND TUNNEL

IN FREE AIR

GROUP 1....................$ 36.85 21.80+a GROUP 2....................$ 39.40 21.80+a GROUP 3....................$ 39.40 21.80+a GROUP 4....................$ 39.40 21.80+a GROUP 5....................$ 41.40 21.80+a

LABORERS CLASSIFICATIONS for TUNNELS, CAISSON & CYLINDER WORK

IN COMPRESSED AIR

GROUP 1: Powder watchman; Top man on iron bolt; change house attendant

GROUP 2: Brakeman; trackman; groutman; tunnel laborer;

outside lock tender; lock tender; guage tender

GROUP 3: Motorman, miner

GROUP 4: Blaster

GROUP 5: Mucking machine operator

GROUP 6: Hazardous Waste work within the ""HOT"" zone. (A premium of two dollars $2.00 per hour over the basic wage rate.

LABORERS CLASSIFICATIONS for (FREE AIR OPERATION): SHIELD

DRIVEN AND LINER PLATE IN FREE AIR

GROUP 1: Miner; miner welder; conveyor operator; motorman;

mucking machine operator; nozzle man; grout man-; pumps, shaft and tunnel steel and rodman; shield and erector arm operators, mole nipper, outside motorman, burner, TBM operator, safety miner; laborer topside; heading motormen;

erecting operators; top signal men

GROUP 2: Brakeman; trackman

LABORERS CLASSIFICATIONS FOR CLEANING CONCRETE AND CAULKING

TUNNEL (Both New & Existing)

GROUP 1: Concrete workers; strippers and form movers (wood & steel), cement finisher

GROUP 2: Form erector (wood & steel and all accessories)

LABORERS CLASSIFICATIONS for ROCK SHAFT, CONCRETE LINING OF

SAME AND TUNNE IN FREE AIR

GROUP 1: Change house attendants

GROUP 2: Laborers, topside, bottom men (when heading is 50

ft. from shaft) and all other laborers

GROUP 3: Brakeman; trackman; tunnel laborers; shaft laborers

GROUP 4: Miner; cage tender; bellman

GROUP 5: Hazardous Waste work within the ""HOT"" zone. (A premium of two dollars $2.00 per hour over the basic wage rate)

FOOTNOTE FOR LABORERS:

A. PAID HOLIDAYS: New Year's Day, Washington's Birthday, Patriot's Day, Memorial Day, Independence Day, Labor Day, Columbus Day, Veteran's Day, Thanksgiving Day, and Christmas Day

LABO1421-003 06/01/2018

Rates Fringes

Laborers:

Group 1.....................$ 38.15 24.10 Group 2.....................$ 38.90 24.10 Group 3.....................$ 39.15 24.10 Group 4.....................$ 34.15 24.10 Group 5.....................$ 37.25 24.10 Group 6.....................$ 38.15 24.10

Group 1: Adzeman, Wrecking Laborer.

Group 2: Burners, Jackhammers.

Group 3: Small Backhoes, Loaders on tracks, Bobcat Type Loaders, Hydraulic ""Brock"" Type Hammer Operators, Concrete Cutting Saws.

Group 4: Yardman (Salvage Yard Only).

Group 5: Yardman, Burners, Sawyers.

Group 6: Asbestos, Lead Paint, Toxic and Hazardous Waste.

PAIN0035-006 07/01/2019

Rates Fringes

PAINTER

NEW CONSTRUCTION:

Bridge.....................$ 50.66 30.90 Brush, Taper...............$ 39.86 30.25 Spray, Sandblast...........$ 41.26 30.25

REPAINT

Bridge.....................$ 50.66 30.90

Brush, Taper...............$ 37.92 30.25 Spray, Sandblast...........$ 39.32 30.25

PAIN0035-021 01/01/2019

Rates Fringes

GLAZIER..........................$ 39.86 30.25

* PLUM0004-002 03/01/2020

WORCESTER (Except Hopedale and Southboro)

Rates Fringes

Plumbers and Pipefitters.........$ 46.16 26.61

PLUM0012-002 03/01/2019

WORCESTER (Hopedale and Southboro)

Rates Fringes

PLUMBER..........................$ 56.69 29.93

* ROOF0033-001 03/01/2020

Rates Fringes

Roofers:

All Tear-off and/or removal of any types of roofing and all spudding, sweeping, vacuuming and/or cleanup of any and all areas of any type where a roof is to be relaid........$ 45.67 28.25

* SFMA0669-002 04/01/2020

Rates Fringes

SPRINKLER FITTER.................$ 41.61 36.86

* SHEE0017-004 02/01/2020

WORCESTER (Harvard, Lancaster)

Sheet metal worker...............$ 49.36 44.03

* SHEE0063-002 01/01/2020

WORCESTER (Except Harvard & Lancaster)

Rates Fringes

Sheet metal worker...............$ 35.49 31.04

TEAM0379-003 06/01/2019

Rates Fringes

Truck drivers:

Group 1.....................$ 34.08 25.1125+A+B Group 2.....................$ 34.25 25.1125+A+B Group 3.....................$ 34.32 25.1125+A+B Group 4.....................$ 34.44 25.1125+A+B Group 5.....................$ 34.54 25.1125+A+B Group 6.....................$ 34.83 25.1125+A+B Group 7.....................$ 35.12 25.1125+A+B

TRUCK DRIVERS CLASSIFICATIONS

Group 1: Station wagons; panel trucks; and pickup trucks

Group 2: Two axle equipment; & forklift operator

Group 3: Three axle equipment and tireman

Group 4: Four and Five Axle equipment

Group 5: Specialized earth moving equipment under 35 tons other than conventional type trucks; low bed; vachual;

mechanics, paving restoration equipment

Group 6: Specialized earth moving equipment over 35 tons

Group 7: Trailers for earth moving equipment (double hookup)

POWER TRUCKS $.25 DIFFERENTIAL BY AXLE TUNNEL WORK

(UNDERGROUND ONLY) $.40 DIFFERENTIAN BY AXLE HAZARDOUS

MATERIALS (In Hot Zone Only) $2.00 premium

FOOTNOTES: A. PAID HOLIDAYS: New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Patriot's Day, Columbus Day, Veteran's Day, Thanksgiving Day, & Christmas Day

B. PAID VACATION: Employees with 4 months to 1 year of service receive 1/2 day's pay per month; 1 week vacation for 1 - 5 years of service; 2 weeks vacation for 5 - 10 years of service; and 3 weeks vacation for more than 10 years of service

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION"

52.236-4002

52.236-4002 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE entitled “DEFAULT (FIXED

PRICE CONSTRUCTION).” In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS BASED ON 5

DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(4) (2) (2) (0) (0) (0) (0) (0) (0) (0) (2) (4)

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day.

The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delaydays exceeds the number of days anticipated in paragraph b, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled “DEFAULT (FIXED PRICE CONSTRUCTION).”

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-18 Variation in Estimated Quantity APR 1984 52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION

2020-O0008).

MAR 2020

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets AUG 2018 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-16 Quantity Surveys APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within Fifteen (15) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 1 May 2021. Construction activities including closure of the bridge shall commence no earlier than 1 March 2021. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,369.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (AUG 2019).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Jan 2020) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (JAN 2019) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract…