Solicitation - FA500022R0038.pdf

PDF 286 KB Posted Sep 8, 2022

Attached to: Repair Concrete Laundry Facility B726 Federal contract opportunity
Solicitation number: FA500022R0038
Issued by: Department of the Air Force Pacific Air Forces

View the file

Other files for this federal contract opportunity

Other files attached to Repair Concrete Laundry Facility B726, newest first.
File	Type	Posted
HJZH 22-1029 Specs.pdf	PDF	Sep 8, 2022
HJZH 22-1029 SOW.pdf	PDF	Sep 8, 2022
Davis-Bacon Act WD AK20220001.pdf	PDF	Sep 8, 2022
HJZH 22-1029 DRAWINGS.pdf	PDF	Sep 8, 2022

On GovTribe

Work with this file on GovTribe

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

Created On: 07 Sep 2022, 01:43 PM Alaska Standard Time

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

Section A - Solicitation/Contract Form

REPAIR CONCRETE LAUNDRY FAC B726 - Project# HJZH 22-1029

Purchase Requisition Number: F1W3EA2165AW02 Date: 06 Sep 2022 Proposal Identifier: FA500022R0038 Date: 07 Sep 2022

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Qty Unit Unit Price

Amount

This project will repair/replace concrete pads and provide new landings and steps at egresses for building 726. Work includes saw-cutting/removing asphalt and concrete, excavation under new concrete, D-1 placement, placing new reinforced concrete, installing handrails, installing new steel steps/landings, and some concrete repair.

All work to be completed as stated in the Statement of Work.

Dun and Bradstreet Standard Product and Service Code: Z2JZ Product Service Code: Z2JZ Pricing Arrangement: Firm Fixed Price

1 Project

Section C - Description/Specifications/Statement of Work

Requirements This project will repair/replace concrete pads and provide new landings and steps at egresses for building 726. Work includes saw-cutting/removing asphalt and concrete, excavation under new concrete, D-1 placement, placing new reinforced concrete, installing handrails, installing new steel steps/landings, and some concrete repair. Review the statement of work (SOW) for full scope of work.

DFARS Clauses Incorporated by Full Text

252.222-7000 Restrictions on Employment of Personnel Mar 2000

As prescribed in 222.7004, use the following clause:

RESTRICTIONS ON EMPLOYMENT OF PERSONNEL (MAR 2000)

(a) The Contractor shall employ, for the purpose of performing that portion of the contract work in , individuals who are residents Alaska thereof and who, in the case of any craft or trade, possess or would be able to acquire promptly the necessary skills to perform the contract.

(b) The Contractor shall insert the substance of this clause, including this paragraph (b), in each subcontract awarded under this contract.

(End of clause)

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. Aug 1996

Section F - Deliveries or Performance

Overall Contract Delivery Period

From date of lead time event to beginning of performance 10 Calendar Days Date of Notice to Proceed Receipt

From date of lead time event to completion of performance 180 Calendar Days Date of Notice to Proceed Receipt

Line Item Delivery Schedule QTY Address and POC

Delivery Schedule From date of lead time event to completion of performance 180 Calendar Days Date of Notice to Proceed Receipt

1 Project Ship To DoDAAC: F1W3EA CountryCode: USA

673D CES CEP/CER/CEA

AF BPN NO MILSBILLS PROCESSES

6326 ARCTIC WARRIOR

JBER, AK 99506-3221

UNITED STATES

Jacob Minturn Email: jacob.minturn@us.af.mil Telephone: 907-384-3027

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.236-7000 Modification Proposals--Price Breakdown. Dec 1991

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. Dec 2018

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports WAWF payment instructions.

in WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

N/A

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

Construction Invoice

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in Document routing.

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F87700

Issue By DoDAAC FA5000

Admin DoDAAC FA5000

Inspect By DoDAAC F1W3EA

Ship To Code F1W3EA

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) F1W3EA

Service Acceptor (DoDAAC) F1W3EA

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

jazmine.mcwilliams@us.af.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

Section H - Special Contract Requirements

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.219-6 Notice of Total Small Business Set-Aside. Nov 2020 52.219-13 Notice of Set-Aside of Orders. Mar 2020 52.222-6 Construction Wage Rate Requirements. Aug 2018 52.222-7 Withholding of Funds. May 2014 52.222-8 Payrolls and Basic Records. Jul 2021 52.222-9 Apprentices and Trainees. Jul 2005 52.222-10 Compliance with Copeland Act Requirements. Feb 1988 52.222-11 Subcontracts (Labor Standards). May 2014 52.222-12 Contract Termination-Debarment. May 2014 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. May 2014 52.222-14 Disputes Concerning Labor Standards. Feb 1988 52.222-15 Certification of Eligibility. May 2014 52.222-62 Paid Sick Leave Under Executive Order 13706. Jan 2022 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. Jun 2020 52.223-21 Foams. Jun 2016 52.233-3 Protest after Award. Aug 1996 52.236-5 Material and Workmanship. Apr 1984 52.236-7 Permits and Responsibilities. Nov 1991 52.242-14 Suspension of Work. Apr 1984 52.243-5 Changes and Changed Conditions. Apr 1984 52.249-4 Termination for Convenience of the Government (Services) (Short Form). Apr 1984

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Sep 2013 252.204-7003 Control of Government Personnel Work Product. Apr 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. Dec 2019 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. May 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2021

252.223-7008 Prohibition of Hexavalent Chromium. Jun 2013 252.225-7048 Export-Controlled Items. Jun 2013 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. May 2022 252.232-7010 Levies on Contract Payments. Dec 2006 252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. Jun 2013 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.244-7000 Subcontracts for Commercial Items. Jan 2021

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. Dec 1989

As prescribed in , insert the following clause:4.103

APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of [identify title of designated agency official here] and shall not be binding until Contracting Officer so approved.

(End of clause)

52.211-10 Commencement, Prosecution, and Completion of Work. Apr 1984

As prescribed in , insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The 11.404(b) clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the ____ date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than .____

* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 Liquidated Damages-Construction. Sep 2000

As prescribed in , insert the following clause in solicitations and contracts:11.503(b)

LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the (a) Government in the amount of $692.84 for the first and last day of inexcusable delay and $450.71 for each additional day of inexcusable delay [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. (b) These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.213-4 Terms and Conditions-Simplified Acquisitions (Other Than Commercial Products and Commercial Services).

Jan 2022

As prescribed in , insert the following clause:13.302-5(d)

TERMS AND CONDITIONS-SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES) (JAN 2022)

The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:(a)

The clauses listed below implement provisions of law or Executive order:(1)

52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (section 743 of Division (i) (JAN 2017) E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other (ii) Covered Entities (Section 1634 of Pub. L. 115-91).(NOV 2021)

52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (iii) (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

52.222-3, Convict Labor (E.O.11755).(iv) (JUN 2003)

52.222-21, Prohibition of Segregated Facilities .(v) (APR 2015)

52.222-26, Equal Opportunity ( 2016) (E.O.11246).(vi) Sept

52.225-13, Restrictions on Certain Foreign Purchases ( ) (E.O.s, proclamations, and statutes administered by the Office of (vii) FEB 2021 Foreign Assets Control of the Department of the Treasury).

52.233-3, Protest After Award (31 U.S.C.3553).(viii) (AUG 1996)

52.233-4, Applicable Law for Breach of Contract Claim (Pub.L.108-77, 108-78 (19 U.S.C. 3805 note)).(ix) (OCT 2004)

Listed below are additional clauses that apply:(2)

52.232-1, Payments .(i) (APR 1984)

52.232-8, Discounts for Prompt Payment .(ii) (FEB 2002)

52.232-11, Extras .(iii) (APR 1984)

52.232-25, Prompt Payment (iv) (JAN 2017).

52.232-39, Unenforceability of Unauthorized Obligations .(v) (JUN 2013)

52.232-40, Providing Accelerated Payments to Small Business Subcontractors (vi) (NOV 2021).

52.233-1, Disputes .(vii) (MAY 2014)

(viii) 52.244-6, Subcontracts for Commercial Products and Commercial Services .(JAN 2022)

52.253-1, Computer Generated Forms .(ix) (JAN 1991)

The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:(b)

The clauses listed below implement provisions of law or Executive order:(1)

52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Pub. L. 109-282) (31 U.S.C. 6101 (i) (JUN 2020) note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

52.222-19, Child Labor-Cooperation with Authorities and Remedies (E.O. 13126) (Applies to contracts for supplies (ii) (JAN 2022) exceeding the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract).

52.222-20, Contracts for Materials, Supplies, Articles, and Equipment., Contracts for Materials, Supplies, Articles, and Equipment (iii) (41 U.S.C.chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in (JUN 2020) the United States, Puerto Rico, or the U.S. Virgin Islands).

52.222-35, Equal Opportunity for Veterans (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold (iv) (JUN 2020) specified in FAR 22.1303(a) on the date of award of this contract).

52.222-36, Equal Employment for Workers with Disabilities (29 U.S.C. 793) (Applies to contracts over the threshold (v) (JUN 2020) specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

52.222-37, Employment Reports on Veterans (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold (vi) (JUN 2020) specified in FAR 22.1303(a) on the date of award of this contract).

52.222-41, Service Contract Labor Standards (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are (vii) (AUG 2018) subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii) 52.222-50, Combating Trafficking in Persons (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations (A) (NOV 2021) and contracts).

Alternate I (Applies if the Contracting Officer has filled in the following information with regard to applicable (B) (MAR 2015) directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Applies when 52.222-6 or 52.222-(JAN 2022) 41 are in the contract and performance in whole or in part is in the United States (the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the

))).Outer Continental Shelf Lands Act (43 U.S.C. 1331, et seq.

52.222-62, Paid Sick Leave Under Executive Order 13706 (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the (x) (JAN 2022) contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

52.223-5, Pollution Prevention and Right-to-Know Information (E.O. 13423) (Applies to services performed on (xi) (MAY 2011) Federal facilities).

52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (E.O. 13693)(applies (xii) (JUN 2016) to contracts for products as prescribed at FAR 23.804(a)(1)).

52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (E.O. 13693) (xiii) (JUN 2016) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

52.223-15, Energy Efficiency in Energy-Consuming Products (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, (xiv) (MAY 2020) applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program (FEMP)) will be-

Delivered;(A)

Acquired by the Contractor for use in performing services at a Federally-controlled facility;(B)

Furnished by the Contractor for use by the Government; or(C)

Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).(D)

52.223-20, Aerosols (E.O. 13693) (Applies to contracts for products that may contain high global warming potential (xv) (JUN 2016) hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

52.223-21, Foams (E.O. 13693) (Applies to contracts for products that may contain high global warming potential (xvi) (JUN 2016) hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

52.225-1, Buy American-Supplies (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for (xvii) (NOV 2021) services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract, and the acquisition-

Is set aside for small business concerns; or(A)

Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).(B)

52.226-6, Promoting Excess Food Donation to Nonprofit Organizations., Promoting Excess Food Donation to Nonprofit (xviii) Organizations (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this (JUN 2020) contract, that provide for the provision, the service, or the sale of food in the United States).

52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Applies when the payment will be (xix) (OCT 2013) made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information).

52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Applies when the (xx) (JUL 2013) payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information).

52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (46 U.S.C. 55305)(Applies to supplies (xxi) (NOV 2021) transported by ocean vessels (except for the types of subcontracts listed at 47.504(d)).

Listed below are additional clauses that may apply:(2)

52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Applies to contracts when the contractor or (i) (NOV 2021) a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.)

52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for (ii) Debarment (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).(NOV 2021)

52.211-17, Delivery of Excess Quantities ( 1989) (Applies to fixed-price supplies).(iii) Sept

52.247-29, F.o.b. Origin (Applies to supplies if delivery is f.o.b. origin).(iv) (FEB 2006)

52.247-34, F.o.b. Destination (Applies to supplies if delivery is f.o.b. destination).(v) (NOV 1991)

. This contract incorporates one or more clauses by reference, with the same (c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998) force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

[Insert one or more Internet addresses]____

. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The (d) Inspection/Acceptance Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights-

Within a reasonable period of time after the defect was discovered or should have been discovered; and(1)

Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.(2)

. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable (e) Excusable delays control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

. The Government reserves the right to terminate this contract, or any part hereof, for its sole (f) Termination for the Government's convenience convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the (g) Termination for cause Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular (h) Warranty purpose described in this contract.

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. Sep 2021

As prescribed in , insert the following clause:19.309(c)(1)

POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (SEP 2021)

. As used in this clause-(a) Definitions means a contract of more than five years in duration, including options. However, the term does not include contracts that Long-term contract exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

-Small business concern

Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is (1) bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the (2) Affiliates others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the (b) Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the (1) novation agreement was executed prior to inclusion of this clause in the contract.

Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to (2) include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

For long-term contracts-(3)

Within 60 to 120 days prior to the end of the fifth year of the contract; and(i)

Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.(ii)

If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the (c) Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that (d) corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a (e) contract other than a construction or service contract, is 500 employees if the acquisition-

Was set aside for small business and has a value above the simplified acquisition threshold;(1)

Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; (2) or

Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business (3) set-aside or sole-source award regardless of dollar value.

Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this (f) clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not (g) required to, take the actions required by paragraphs (f) or (h) of this clause.

If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code (h) applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it is, is not a small business concern under NAICS Code assigned to contract number .(1) ____ ____

[ .] The Contractor (2) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause represents that it is, is not, a small disadvantaged business concern as defined in .13 CFR 124.1002

[ ] The Contractor (3) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that it is, is not a women-owned small business concern.

Women-owned small business (WOSB) concern eligible under the WOSB Program. [(4) Complete only if the Contractor represented itself ] The Contractor represents that-as a women-owned small business concern in paragraph (h)(3) of this clause.

It is, is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB (i) Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

It is, is not a joint venture that complies with the requirements of , and the representation in paragraph (h)(4)(ii) 13 CFR part 127

(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [ The Contractor shall ____ enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:. ] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

Economically disadvantaged women-owned small business (EDWOSB) concern.[(5) Complete only if the Contractor represented itself as a ] The Contractor represents that-women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause.

It is, is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB (i) Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

It is, is not a joint venture that complies with the requirements of , and the representation in paragraph (h)(5)(ii) 13 CFR part 127

(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [ The Contractor shall enter the name or names of the ____ EDWOSB concern and other small businesses that are participating in the joint venture: . ] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

[ ] The Contractor (6) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that it is, is not a veteran-owned small business concern.

[ ] The (7) Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.

Contractor represents that it is, is not a service-disabled veteran-owned small business concern.

[ ] The Contractor (8) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that-

It is, is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone (i) Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in (ii) paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The ____ Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[ ] Contractor to sign and date and insert authorized signer's name and title.

(End of clause)

52.219-28 Alternate I Post-Award Small Business Program Rerepresentation. (Alternate I) Sep 2021