Sol_140P6225B0003.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION CALL

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0044009029

NPS, MWR - Missouri MABO

DOI, NPS, MWR - Missouri MABO

601 Riverfront Drive Omaha NE 68102

PMM

mwromabobids@nps.gov

Matthew Frank 5017629927 x

08/01/2025

140P6225B0003

INVITATION FOR BID

REQUEST FOR PROPOSAL

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Lincoln Boyhood National Monument (LIBO) - Septic System Replacement

This solicitation is a Sealed Bid. This is an electronic Invitation for Bid (IFB) for construction work at Lincoln Home National Monument, Indiana. The resulting contract will be firm-fixed price. The complete specifications, provisions, and clauses are available at http://www.sam.gov. If there is a conflict between the contract and the specification, the contract will rule over the specifications.

The project includes removal and replacement of the sanitary sewer system at the

Gale House within Lincoln Boyhood National Memorial. This will include removing the existing septic tank & gravity sewer, abandoning the existing drain field by capping observation ports and plugging the sewer lines, installation of a new septic tank, gravity sewer service lines, new dual pump sewage lift station and valve vault with automatic controls/flow measurement and new force main connecting to the existing gravity sewer at Lincoln Boyhood National Memorial.

Bid Opening Information: The sealed bid opening process will be conducted virtually.

There will be no in person bid opening available. Refer to the virtual bid opening

Continued ...

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 185 calendar days and complete it within ________________ ________________ calendar days after receiving

52.211-10

09/02/2025

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 12/2022)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

NPS, MWR - Missouri MABO DOI, NPS, MWR - Missouri MABO

601 Riverfront Drive Omaha NE 68102

PMM

Bridget Parizek

28. NEGOTIATED AGREEMENT 29. AWARD

and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations,certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

10 U.S.C. 3204(a) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 12/2022) BACK

Continued...

and return

(Contractor is not required to sign this document.) Your offer on this

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 51

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140P6225B0003 information below for call-in information.

Bid Opening Time/Date: 3 September 2025, 13:00 PM

CDT

Meeting Id: 264 829 906 624 2

Passcode: Gr7V6kA6

See page six for more information

Project Location: Lincoln Boyhood National

Monument in Lincoln City, IN

PROJECT MAGNITUDE: Between $250,000 and $500,000

Bonds: Required as stated in Block 12. A bid guarantee is required 20% but not to exceed $3M.

Bid bond is required to be submitted on a

Standard Form 24. A copy of the bid guarantee shall be emailed with your bid package.

Performance and Payment bonds/protection in the amount of 100% of the final contract award amount.

NAICS: The associated NAICS code is 238910, Septic System Contractors, with a small business size standard of $19m.

Notice of Set-Aside: 100% set-aside for Total

Small Businesses

Period of performance: 185 calendar days from the

Notice to Proceed.

Site Visit: A site visit is highly encouraged.

Please see 52.236-27 for specific guidance.

Wage Rates: Wage Rate requirements are incorporated into the terms and conditions as an attachment.

System for Award Management (SAM): The successful offeror must be registered in SAM.gov and have current online Representations and

Certifications. Please access http://www.sam.gov to update your records prior to submitting final offer. To be considered for award your company

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 51

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140P6225B0003 must obtain a Unique Entity Identifier (UEI).

Your company needs to be registered in the System for Award Management (SAM) and be considered a small business for the size standard associated with the NAICS code state above/utilized throughout this solicitation - this registration needs to be in an 'active' status in SAM.gov at the time of IFB submission close date - as well as, at the time of award and throughout the entire award/contract performance.

Method and Instructions for Submitting Offer:

Refer to Section B, Bid Schedule, and Section L, Instructions, Conditions, and Notices to Offerors or Respondents. Complete bid package shall be emailed directly to mwromabobids@nps.gov.

THE TIMING OF BID SUBMISSION DOES NOT HAVE ANY

EFFECT ON THE GOVERNMENT'S DETERMINATION; ALL

BIDS RECEIVED BY THE DUE DATE ARE CONSIDERED

RECEIVED. THERE IS NO BENEFIT IN LAST MINUTE

SUBMISSION.

Questions: All questions shall be submitted in writing to matthew_frank@nps.gov. All questions must be submitted in writing no later than 5 days following the scheduled site visit.

Delivery: 02/13/2026

Delivery Location Code: 0011283148

NPS, MWR, Admin, Lincoln Boyhood NM

2916 E South Street

P.O. Box 1816

Lincoln City IN 47552-1816 US

FOB: Destination

00010 Reconstruct failing sewer

Product/Service Code: Z2ND

Product/Service Description: REPAIR OR ALTERATION

OF SEWAGE AND WASTE FACILITIES

Period of Performance: 02/13/2025 to 02/13/2026

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 5 of 51

TABLE OF CONTENT

Part I – The Schedule SECTION A – Solicitation/Contract Form Special Notice for Bidders SECTION B – Bid Schedule SECTION C – Specifications/Drawings SECTION D - Packaging and Marking SECTION E - Inspection and Acceptance SECTION G - Contract Administration Data SECTION H - Special Contract Requirements Part II – Contract Clauses SECTION I - Contract Clauses

CLAUSES INCORPORATED BY FULL TEXT

Part III – List of Documents, Exhibits, and Other Attachments SECTION J – List of Attachments Part IV – Representations and Instructions SECTION K - Representations, Certifications, and Other Statements of Offerors

PROVISIONS INCORPORATED BY FULL TEXT

(End of provision) SECTION L - Instructions, Conditions, and Notices to Offerors

INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS OR RESPONDENTS

SECTION M - EVALUATION FACTORS FOR AWARD

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 6 of 51

Part I – The Schedule

SECTION A – Solicitation/Contract Form

Invitation for Bids (IFB) are issued on a Standard Form (SF) 1442, Solicitation, Offer, and Award document.

Reference DIAR 1436.270-1 Uniform contract format.

Special Notice for Bidders

Signing of the bid shall be deemed to be a representation by the bidder that:

1.) Bidder is a construction contractor who owns, operates, or maintains a place of business, regularly engaged in the work described herein; or

2.) If newly entering into a construction activity, bidder has made all necessary arrangements for personnel, construction equipment, and required licenses to perform construction work as specified;

and

3.) Upon request, prior to award, bidder will promptly furnish to the Government a statement of facts in detail as to bidder’s previous experience (including recent and current contracts), organization (including company officers), technical qualifications, financial resources and facilities available to perform the contemplated work.

4.) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code for this acquisition is 238910 with a size standard of $19.0 Million. To be considered for award your company must obtain a Unique Entity Identifier (UEI). Your company needs to be registered in the System for Award Management (SAM) and be considered a small business for the size standard associated with the NAICS code stated above/utilized throughout this solicitation - this registration needs to be in an “active” status in SAM.gov at the time of RFQ/RFP/IFB submission close date - as well as, at the time of award and throughout the entire award/contract performance.

5.) Bidder agrees to the requirements contained in FAR 52.219-14, Limitations on Subcontracting

The bid opening will be held virtually. Bids are to be emailed and delivery confirmed on or before the date and time of the virtual bid opening. Bids are required to be submitted electronically following instructions contained in this solicitation.

CALL-IN INFORMATION: Bid Openings will be performed via meeting ID/conference call.

Interested parties may attend the bid openings by using the call-in information below:

Bid Opening Date/Time: 13:00 CDT 2 September 2025

Microsoft Teams Need help?

Join the meeting now Meeting ID: 264 829 906 624 2 Passcode: Gr7V6kA6

SECTION B – Bid Schedule

Preparation of Bids: The Government will not be responsible for any costs incurred by offeror in the research, preparation, or submission of its bid.

Bid pricing shall be provided in accordance with Section L and is incorporated herein.

https://www.acquisition.gov/diar/part-1436-construction-and-architect-engineer-contracts#Section_1436_270_1_T48_5075734113 https://aka.ms/JoinTeamsMeeting?omkt=en-US https://teams.microsoft.com/l/meetup-join/19%3ameeting_YjE4ZTA5MDItMmI1Yy00ZmUyLWEzM2EtNTU4ODQ2NDRjYmFi%40thread.v2/0?context=%7b%22Tid%22%3a%220693b5ba-4b18-4d7b-9341-f32f400a5494%22%2c%22Oid%22%3a%227e229917-c898-4967-94c4-69a1e73fab10%22%7d

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 7 of 51

SECTION C – Specifications/Drawings

Project work consists of: The project includes removal and replacement of the sanitary sewer system at the Gale House within Lincoln Boyhood National Memorial. This will include removing the existing septic tank & gravity sewer, abandoning the existing drain field by capping observation ports and plugging the sewer lines, installation of a new septic tank, gravity sewer service lines, new dual pump sewage lift station and valve vault with automatic controls/flow measurement and new force main connecting to the existing gravity sewer at Lincoln Boyhood National Memorial.

1. Demolition of the existing sewer system at Gale House including abandoning the existing drain field.

2. New dual pump lift station to include submersible pumps, stainless steel guiderails, stainless steel hangers, chains, floats, automatic controls, flow measurement, power surge protection and motor saver protection.

3. New wet well sized for the existing and future needs. The wet well cover shall be easy to lift, be lockable and have fall safety grates incorporated within the cover.

4. New valve vault to include check valves, gate valves and cleanout Ferrell for future pigging of the force main.

The valve vault shall also provide for accurate flow measurement of the sewage pumped into the sewage system.

5. New septic tank ahead of the lift station.

6. Boring a new force main extending from the new lift station valve vault to the existing sewer system within the park.

Additional requirements information is provided in the solicitation, specifications, supporting documents and other pertinent attachments.

“Specifications and other supporting documents are attached and incorporated herein. Refer to SECTION J.”

SECTION D - Packaging and Marking

No clauses included

SECTION E - Inspection and Acceptance

52.246-12 -- Inspection of Construction. Inspection of Construction (Aug 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not --

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 8 of 51

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph

(i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may --

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of Clause)

SECTION F - Deliveries or Performance

Work shall be completed by skilled personnel per industry standards and manufacturer specifications.

52.211-10 -- Commencement, Prosecution, and Completion or Work (Apr 1984)

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 9 of 51

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 185 calendar days after receipt of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of Clause)

52.236-15 Schedules for Construction Contracts (Apr 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

(End of clause)

52.242-14 -- Suspension of Work (Apr 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 10 of 51

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

SECTION G - Contract Administration Data

(a) Contact Information:

The Contracting Specialist administrating the Contract:

Matt Frank Contract Specialist National Park Service

(501) 762-9927 Matthew_Frank@nps.gov

Contracting Officer administrating the Contract:

Bridget Parizek Contract Specialist National Park Service (402)800-7927 bridget_parizek@nps.gov

(b) The Contracting Officer (CO) is the only person authorized to approve changes or modify any of the requirements under this contract and notwithstanding any provisions contained elsewhere in this contract, the said authority remains solely with the CO. In the event the contractor effects any such change at the direction of any person other than the CO, the change will be considered made without authority and no adjustment will be made in the contract price to cover increase in costs incurred as a result thereof.

(c) Contractual problems, of any nature, which might occur during the life of the contract, must be handled in conformance with very specific public laws and regulations (e.g., Federal Acquisition Regulation), and must be referred to the CO for resolution. Only the CO is authorized to formally resolve such problems. Therefore, the contractor is hereby directed to bring all such contractual problems to the immediate attention of the CO.

(d) Any request for contract changes/modifications shall be submitted to the CO.

(e) The contractor and the Government may agree to perform a no-cost field change. Field changes are made when the change appears to be mutually beneficial to all parties and would not require changing the negotiated line items.

All field changes must be approved by the CO prior to execution.

(f) All correspondence concerning this contract, such as requests for information (RFI), explanation of terms, and contract interpretation, shall be submitted to the CO.

FINAL PAYMENT

Final payment will be made only after receipt of all payrolls to include subcontractors, SF 1413 Statement of Acknowledgement for each subcontractor, project schedule, updated progress reports, material submittals, test reports, as-built drawings, warranty of construction, release of claims and any other documents requested by the

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 11 of 51 contracting office as applicable. Contractor must provide a signed copy of the 'Release of Claims' to the Contract Administrator upon submittal of final invoice.

AVAILABILITY OF UTILITIES SERVICES

Notwithstanding the provisions of contract clause FAR 52.236-14, Availability and Use of Utility Services, all reasonable required amounts of water, gas, electricity, etc., essential to contract performance shall be made available, at no cost to the contractor, from existing systems, outlets, and supplies. All temporary connections, outlets, and distribution lines as may be required will be installed by the contractor at the contractor's own expense.

UTILITIES CONSERVATION

The contractor will be required to participate in government energy conservation programs. For the purpose of this contract, utilities such as water, electricity, etc., will be furnished by the government at no cost to the contractor.

OCCUPATIONAL SAFETY AND HEALTH ACT (OSHA) INSPECTIONS

The contractor shall be subject to inspections under the OCCUPATIONAL SAFETY AND HEALTH ACT (OSHA) program by inspectors of the Department of Labor.

INTERIM AND FINAL INSPECTIONS

1. Prior to covering, enclosing, or hiding any of type work, the Contractor must contact the Government representative to perform an interim inspection. Failure to contact the Government representative perform an interim inspection prior to concealment may result in the Contractor being required to uncover performed work sufficiently to allow for proper inspection.

2. When ready for final inspection, the Contractor shall notify the CO and COR, requesting a final inspection in writing to the CO. The final inspection shall normally be requested a minimum of three (3) calendar days before the desired date or as otherwise negotiated with the Contracting Officer.

3. The final inspection will be onsite with the Contractor, the Contracting Officer’s Representative, and Contract Specialist/Contracting Officer (when possible).

1452.201-70 Authorities and Delegations (Sep 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

The COR for this contract will be:

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 12 of 51

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR’s appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor’s risk.

(End of Local Clause)

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (Feb 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Copy of vendor invoice document in PDF format, completed on the pay application document provided by contracting, which shows pricing breakdown for all line items. Once all signatures (Contractor’s / COR / CO) and approvals are completed on the pay application, the vendor can then upload this document into IPP as their invoice attachment.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date.

Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email IPPCustomerSupport@fiscal.treasury.gov or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

Construction Contract Administration https://www.ipp.gov/ mailto:IPPCustomerSupport@fiscal.treasury.gov

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 13 of 51

Federal Acquisition Regulation (FAR) 36.211(b) requires agencies provide description of policies and procedures that apply to definitization of equitable adjustments for change orders under construction contracts and data on the time required to definitize equitable adjustments for change orders under construction contracts. This information can be found at: https://www.doi.gov/pam/acquisition/policy/constructioncontract.

COMPLIANCE WITH RECENT EXECUTIVE ORDERS 14148/14208

System updates may lag policy updates. The System for Award Management (SAM) may continue to require entities to complete representations based on provisions that are not included in agency solicitations, including 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals—Representation, and paragraph

(t) of 52.212-3, Offeror Representations and Certifications—Commercial Products and Commercial Services.

Agencies will not consider or use these representations. Entities are not required to, nor are they able to, update their entity registration to remove these representations in SAM.

SECTION H - Special Contract Requirements

No clauses included

Part II – Contract Clauses

SECTION I - Contract Clauses

52.252-2 – Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov

52.202-1 Definitions (Jun 2020) 52.203-3 Gratuities (Apr 1984) 52.203-5 Covenant Against Contingent Fees (May 2014) 52.203-6 Restrictions on Subcontractor Sales to the Government (Jun 2020) 52.203-7 Anti-Kickback Procedures (Jun 2020) 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (May 2014) 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (May 2014) 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (Jun 2020) 52.203-17 Contractor Employee Whistleblower Rights (Nov 2023) 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) 52.204-13 System for Award Management Maintenance (Oct 2018) 52.204-14 Service Contract Reporting Requirements (Oct 2016) 52.204-18 Commercial and Government Entity Code Maintenance (Aug 2020) 52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014) 52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021) https://www.doi.gov/pam/acquisition/policy/constructioncontract http://www.acquisition.gov/

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 14 of 51

52.204-27 Prohibition on a ByteDance Covered Application (Jun 2023) 52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded (Jan 2025) 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) 52.214-26 Audit and Records – Sealed Bidding (Jun 2020) Alternate I (Mar 2009) 52.214-29 Order of Precedence – Sealed Bidding (Jan 1986) 52.219-6 Notice of Total Small Business Set-Aside (Nov 2020) 52.219-8 Utilization of Small Business Concerns (Jan 2025) 52.222-1 Notice to the Government of Labor Disputes (Feb 1997) 52.222-3 Convict Labor (June 2003) 52.222-4 Contract Work Hours and Safety Standards- Overtime Compensation (Mar 2018) 52.222-6 Construction Wage Rate Requirements (Aug 2018) 52.222-7 Withholding of Funds (May 2014) 52.222-8 Payrolls and Basic Records (Jul 2021) 52.222-9 Apprentices and Trainees (Jul 2005) 52.222-10 Compliance with Copeland Act Requirements (Feb 1988) 52.222-11 Subcontracts (Labor Standards) (May 2014) 52.222-12 Contract Termination-Debarment (May 2014) 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014) 52.222-14 Disputes Concerning Labor Standards (Feb 1988) 52.222-15 Certification of Eligibility (May 2014) 52.222-21 Prohibition of Segregated Facilities (Apr 2015) 52.222-26 Equal Opportunity (Sep 2016) 52.222-27 Affirmative Action Compliance Requirements for Construction (Apr 2015) 52.222-35 Equal Opportunity for Veterans (Jun 2020) 52.222-36 Equal Opportunity for Workers With Disabilities (Jun 2020) 52.222-37 Employment Reports on Veterans (Jun 2020) 52.222-40 Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) 52.222-50 Combating Trafficking in Persons (Nov 2021) 52.222-54 Employee Eligibility Verification (Jan 2025) 52.222-55 Minimum Wages Under Executive Order 13658 (Jan 2022) 52.222-62 Paid Sick Leave Under Executive Order 13706 (Jan 2022) 52.223-3 Hazardous Material Identification and Material Safety Data (Feb 2021) 52.223-5 Pollution Prevention and Right-to-Know Information (May 2024) 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) 52.225-13 Restriction on Certain Foreign Purchases (Feb 2021) 52.226-7 Drug-Free Workplace (May 2024) 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) 52.227-1 Authorization and Consent (Jun 2020) 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (Jun 2020) 52.227-4 Patent Indemnity- Construction Contracts (Dec 2007) 52.228-1 Bid Guarantee (Sep 1996) 52.228-2 Additional Bond Security (Oct 1997) 52.228-5 Insurance- Work on a Government Installation (Jan 1997) 52.228-12 Prospective Subcontractor Request for Bonds (May 2014) 52.228-15 Performance and Payment Bonds- Construction (Jun 2020) (DEVIATION May 2023) 52.229-3 Federal, State, and Local Taxes (Feb 2013) 52.229-4 Federal, State, and Local Taxes (State and Local Adjustments)(Feb 2013) 52.229-11 Tax on Certain Foreign Procurements – Notice and Representation (Jun 2020) 52.229-12 Tax on Certain Foreign Procurements (Feb 2021) 52.232-5 Payments under Fixed-Price Construction Contracts (May 2014) 52.232-17 Interest (May 2014) 52.232-23 Assignment of Claims (May 2014) 52.232-27 Prompt Payment for Construction Contracts (Jan 2017) 52.232-33 Payment by Electronic Funds Transfer - System for Award Management (Oct 2018) 52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) 52.233-1 Disputes (May 2014)

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 15 of 51

52.233-3 Protest after Award (Aug 1996) 52.233-4 Applicable Law for Breach Of Contract Claim (Oct 2004) 52.236-2 Differing Site Conditions (Apr 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (Apr 1984) 52.236-5 Material and Workmanship (Apr 1984) 52.236-6 Superintendence by the Contractor (Apr 1984) 52.236-7 Permits and Responsibilities (Nov 1991) 52.236-8 Other Contracts (Apr 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (Apr 1984) 52.236-10 Operations and Storage Areas (Apr 1984) 52.236-11 Use and Possession Prior to Completion (Apr 1984) 52.236-12 Cleaning Up (Apr 1984) 52.236-13 Accident Prevention (Nov 1991) 52.236-14 Availability and Use of Utility Services (Apr 1984) 52.236-16 Quantity Surveys (Apr 1984) 52.236-17 Layout of Work (Apr 1984) 52.236-21 Specifications and Drawings for Construction (Feb 1997) 52.236-26 Preconstruction Conference (Feb 1995) 52.240-1 Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act- Covered Foreign Entities (Nov 2024) 52.242-13 Bankruptcy (July 1995) 52.243-4 Changes (Jun 2007) 52.244-5 Competition in Subcontracting (Dec 1996) 52.244-6 Subcontracts for Commercial Products and Commercial Services (Jan 2025) 52.246-21 Warranty of Construction (Mar 1994) 52.248-3 Value Engineering-Construction (Oct 2020) 52.249-2 Termination for Convenience of the Government (Fixed-Price) (Apr 2012) - (ALT I) (Sept 1996) 52.249-10 Default (Fixed-Price Construction) (Apr 1984) 52.253-1 Computer Generated Forms (Jan 1991)

CLAUSES INCORPORATED BY FULL TEXT

1452.203-70 -- Restrictions on Endorsements (Jul 1996)

Restriction on Endorsements—Department of the Interior

The Contractor shall not refer to contracts awarded by the Department of the Interior in commercial advertising, as defined in FAR 31.205–1, in a manner which states or implies that the product or service provided is approved or endorsed by the Government, or is considered by the Government to be superior to other products or services. This restriction is intended to avoid the appearance of preference by the Government toward any product or service. The Contractor may request the Contracting Officer to make a determination as to the propriety of promotional material.

(End of clause)

1452.204-70 -- Release of Claims (Jul 1996)

Release of Claims—Department of the Interior

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 16 of 51

(End of clause)

1452.228-70 -- Liability Insurance—Department of the Interior (Jul 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$200,000.00 each person

$500,000.00 each occurrence

$500,000.00 property damage

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

(End of clause)

52.204-21 – Basic Safeguarding of Covered Contractor Information Systems (Nov 2021)

(a) Definitions. As used in this clause— Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 17 of 51

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial products or commercial services, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.204-28 Federal Acquisition Supply Chain Security Act Orders – Federal Supply Schedules, Government Acquisition Contracts, and Multi-Agency Contracts (Dec 2023)

(a) Definitions. As used in this clause—

Covered article as defined in 41 U.S.C. 4713(k), means—

(1) Information technology, as defined in 40 U.S.C. 11101, including cloud computing services of all types;

(2) Telecommunications equipment or telecommunications service, as those terms are defined in section 3 of the Communications Act of 1934 ( 47 U.S.C. 153);

(3) The processing of information on a Federal or non-Federal information system, subject to the requirements of the Controlled Unclassified Information program (see 32 CFR part 2002); or

(4) Hardware, systems, devices, software, or services that include embedded or incidental information technology.

140P6225B0003 LIBO – Gale House Septic and Sewer System Replacement Page 18 of 51

FASCSA order, means any of the following orders issued under the Federal Acquisition Supply Chain Security Act (FASCSA) requiring the removal of covered articles from executive agency information systems or the exclusion of one or more named sources or named covered articles from executive agency procurement actions, as described in 41 CFR 201–1.303(d)…