Sol_140L3121Q0004.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040522439

BLM CENTRAL MT DISTRICT OFC(MTL000)

920 NE MAIN STREET

LEWISTOWN MT 59457

LML

Gina Merwin (406) 538-1911

102/26/2021

140L3121Q0004

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

*** Request for Quote *** Little Rockies Fire Station (LRFS) Building Residing ***

See 140L3121Q0004 as posted to https://beta.sam.gov/

NAICS is 238170 Siding Contractor with a ceiling of $16.5 to qualify as a Small

Business.

The BLM intends to award a contract to furnish labor, equipment, supplies and materials to remove and dispose of existing vinyl siding from three (3) buildings, repair and damaged insulation, replace any compromised substrate, install new steel siding, aluminum soffits, steel fascia, and seamless metallic gutters where shown on the plans and specification.

The full Request for Quote is available on https://beta.sam.gov/. No hard copies of the solicitation will be issued.

A site tour will be Wednesday, March 10, 2021 10:00 a.m. Interested quoters are to meet at the BLM, LRFS located at 7265 Bear Gulch Road, Zortman MT 59546.

Period of Performance is 05/03/2021 to 09/01/2021. Contractor will have 45 days to

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

0 45 calendar days and complete it within ________________ ________________ calendar days after receiving

04/15/2021

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

BLM CENTRAL MT DISTRICT OFC(MTl000)

920 NE MAIN STREET

LEWISTOWN MT 59457

LML

Gina Merwin

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 31

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140L3121Q0004 complete the work once the work begins, or no later than 09/01/2021.

Per 36.204 Disclosure of Construction Project

Magnitude: Estimate is less than $100,000. 100% payment protection is required for construction contracts awarded over $35,000 (required within

10 days of award). Performance bond not required.

All questions are to be emailed to gmerwin@blm.gov and must be received 5 business days prior to the close date to receive a response. You will be asked to email any questions received by phone.

This is a Small Business Set-aside. Offers will be accepted from all responsive and responsible small business concerns.

An active registration in System for Award

Management (SAM) (www.sam.gov) is required by the solicitation close date. Registration in SAM is free. For FREE assistance in registering, please contact the Montana Procurement Technical

Assistance Center (PTAC) nearest you. Please go to www.montanaptac.org.

Period of Performance: 05/03/2021 to 09/01/2021

00010 RE-SIDING UNITS A, B, & C

Product/Service Code: Z1FZ

Product/Service Description: MAINTENANCE OF OTHER

RESIDENTIAL BUILDINGS

A complete quote package is to include:

___Signed SF-1442 (Please complete blocks 14-16.

No signature required on this form)

___Quote Schedule (attached)

___Experience and Past Performance Questionnaire

(attached)

___Subcontractor Form (attached)

___Section K: Representations, Certifications, and Other Statements of Bidders (signature page(s) only)

___FAR 52.204-24 (attached)

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 31

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140L3121Q0004

___FAR 52-204-26 (attached)

___Work Plan: See Section M

___Acknowledgement of all amendments associated with this solicitation

To submit your quote package, either by:

--- FAX: 406.538.1994

--- EMAIL: gmerwin@blm.gov

--- MAIL: BLM Central Montana DO, ATTN G. Merwin, 920 NE Main, Lewistown MT 59457

With each option, a follow up call to

406.538.1911 to confirm receipt of quote is highly recommended. The Contracting Officer will not be accountable for missing information.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Construction Projects (Feb 2021)

Contents

SECTION B: Supplies or Services / Prices SECTION C: Description/Specifications SECTION E: Inspection and Acceptance SECTION F: Deliveries or Performance SECTION G: Contract Administration Data SECTION H: Special Contract Requirements SECTION I: Contract Clauses SECTION J: List of Documents, Exhibits and Other Attachments SECTION K: Representations, Certifications, and Other Statements of Bidders SECTION L: Instructions, Conditions, and Notices to Bidders SECTION M: Evaluation Factors for Award

SEE SECTION “L” FOR

QUOTE SUBMISSION REQUIREMENTS

AND

SITE TOUR INFORMATION

All contractors must have an active registration in System for Award Management (www.sam.gov) prior to the solicitation close date and throughout the life of this contract.

Registration in SAM is FREE. For FREE registration assistance please contact a Montana Procurement Technical Assistance Center. To find one near you, go to www.montanaptac.org.

This contract incorporates clauses and provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, full text may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/vffara.htm https://www.acquisition.gov/browse/index/far (official version) http://www.sam.gov/ http://farsite.hill.af.mil/vffara.htm

SECTION B: Supplies or Services / Prices

The Quote Schedule is attached as an external document.

See Section J for a list of all attachments

SECTION C: Description/Specifications

The Specifications, Maps and Drawings are attached as external attachments.

See Section J for a list of all attachments

SECTION E: Inspection and Acceptance

52.246-12 Inspection of Construction (Aug 1996) 52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements (Aug 1996)

Inspection

(a) Work will be subject to periodic inspections by the Government to assure satisfactory progress, to determine quantities or work performed for progress payment purposes, to be certain that work is being performed in accordance with contract specifications, and to determine if work corrections are necessary.

(b) Inspection in the form of a review of all required reports will be performed by the Contracting Officer’s Representative (COR). Accordingly, all reports, data, and documentation required by the contact will be submitted to the COR who will recommend approval/disapproval for acceptance purposes to the Contracting Officer.

(c) The Contractor shall notify the COR or the Project Inspector (PI) at least 3 days before the scheduled completion date, so the Government can schedule final inspection. The Contractor will not be granted a time extension to perform a work correction required as a result of a periodic or final inspection if such correction is necessary because of improper work by the Contractor. The Contractor or his authorized representative must be at the worksite at time of final inspection.

Acceptance Final inspection and acceptance of all items/services to be delivered under this contract shall be the responsibility of the Contracting Officer. Quality of work is subject to verification by the COR, the final payment to be withheld pending completion of any necessary rework by the Contractor.

SECTION F: Deliveries or Performance

52.242-14 Suspension of Work (Apr 1984) 52.246-21 Warranty of Construction (Mar 1994)

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work according to Block 11 of the SF 1442, (b) prosecute the work diligently, and (c) complete the entire work ready for use no later than set delivery date. The time stated for completion shall include final cleanup of the premises.

52.211-18 Variation in Estimated Quantity. (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

(End of clause)

Charges for Actual Damages – Delayed Performance Should the Contractor fail to complete the work within the performance time allowed or any extension thereof, and his right to proceed is not terminated, he shall, in the absence of a liquidated damages provision, be charged actual damages suffered by the Government which can be directly attributable to the Contractor’s delayed performance.

Such damages shall include, but not necessarily be limited to, the Project Inspector’s hourly salary, per-diem, travel or other expenses as well as losses of Government- Furnished property which can be accurately determined.

SECTION G: Contract Administration Data

1452.201-70 Authorities and Delegations (Sep 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

DOI Electronic Invoicing and Payment Requirements – Invoice Processing Platform (IPP)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in FAR 32.905(b), "Payment documentation and process" and the applicable Prompt Payment clause included in this contract. The IPP website address is: https://www.ipp.gov.

Under this contract, a proper invoice is required to be submitted as an attachment to the IPP invoice. To prevent delays and other complications, deliverables are to be received and accepted prior to invoicing. Email a detailed invoice to gmerwin@blm.gov for approval prior to invoicing via IPP.

A proper invoice must include the following items (except for interim payments on cost reimbursement contracts for services):

(i) Name and address of the contractor.

(ii) Invoice date and invoice number. (Contractors should date invoices as close as possible to the date of mailing or transmission.)

(iii) Contract number or other authorization for supplies delivered or services https://www.ipp.gov/ mailto:gmerwin@blm.gov performed (including order number and line item number).

(iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed.

(v) Shipping and payment terms (e.g., shipment number and date of shipment, discount for prompt payment terms). Bill of lading number and weight of shipment will be shown for shipments on Government bills of lading.

(vi) Name and address of contractor official to whom payment is to be sent (must be the same as that in the contract or in a proper notice of assignment).

(vii) Name (where practicable), title, phone number, and mailing address of person to notify in the event of a defective invoice.

(x) Any other information or documentation required by the contract (e.g., evidence of shipment).

Per 52.222-8, payrolls are to be submitted weekly. In addition, a Subcontractor Substantiation Form (if applicable) may be required prior to invoicing. Once these and the amount requested have been approved for the proposed invoicing period, the following documents are required to be submitted as an attachment to the IPP payment request:

An itemized invoice A “Certification of Progress Payments under Fixed-Price Construction Contracts” is to be provided with each progress payment per 52.232-5, A DI-137 “Release of Claims” is to be provided with the final payment IF required by the Contracting Officer (optional under SAT) per 1452.204-70 (CO will make that determination)

Please Note: Deliverables (payrolls, work completed, etc.) are to be reviewed and accepted by the CO/COR prior to invoicing. Invoices submitted without CO/COR approval may be rejected.

The Contractor must use the IPP website to enroll, access and use IPP for submitting requests for payment. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

1452.204-70 Release of Claims—Department of the Interior (JUL 1996)

After completion of work and prior to final payment, upon request, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI-137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release. (End of clause)

SECTION H: Special Contract Requirements

Work Hours Work hours under this contract shall be limited to the time between one-half- hour before sunrise to one-half hour after sunset each day. No work will be done on Saturday, Sunday, or legal National Holidays unless authorized by the COR.

Fire Danger Season

If the COR allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

Drawings

(a) Typical Drawings. Any drawing titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as “REDUCED SIZE DRAWINGS” appearing in the solicitation are photographically reduced to size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full size drawings may contact the Contracting Officer identified in the solicitation.

Preservation of Historical and Archaeological Data

(a) Public Law 93-291, May 24, 1974, provides for the preservation of scientific, prehistorical, and archeological data (including relics and specimens) which might otherwise be lost due to alteration of the terrain as a result of any Federal construction project.

(b) The Contractor agrees that should he or any of his employees in the performance of this contract discover evidence of possible scientific, prehistorical, or archeological data he will notify the Contracting Officer immediately in writing giving the location and nature of the findings.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the applicable clauses in the Contract Clauses Section of this contract.

(d) The Contractor agrees to insert this paragraph in all subcontracts which involve the performance of work on the terrain of the site.

Notice to Proceed – Removed. Period of Performance identified in solicitation/contract.

SECTION I: Contract Clauses

52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/browse/index/far

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) 52.204-13 System for Award Management Maintenance (Oct 2018) 52.204-18 Commercial and Government Entity Code Maintenance (Aug 2020) 52.209-6 Protecting the Governments Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Jun 2020) 52.213-4 Terms & Conditions -- Simplified Acquisitions (Other Than Commercial Items) (Feb 2021) 52.219-6 Notice of Total Small Business Set-Aside (Nov 2020) 52.219-14 Limitations on Subcontracting (Mar 2020) 52.219-28 Post Award Small Business Program Representation (Nov 2020)

52.222-6 Compliance w/Construction Wage Rate Requirements & Related Regulations (Aug 2018) 52.222-7 Withholding of Funds (May 2014) 52.222-8 Payroll and Basic Records (Aug 2018) 52.222-9 Apprentices and Trainees (Jul 2005) 52.222-10 Compliance with Copeland Act Requirements (Feb 1988)

52.222-11 Subcontracts (Labor Standards) (May 2014) 52.222-12 Contract Termination - Debarment (May 2014) 52.222-13 Compliance w/Construction Wage Rate Requirements and Related Regulations (May 2014) 52.222-14 Disputes Concerning Labor Standards (Feb 1988) 52.222-15 Certification of Eligibility (May 2014) 52.222-27 Affirmative Action Compliance Requirements for Construction (Apr 2015) 52.222-50 Combating Trafficking in Persons (Oct 2020)

52.223-6 Drug-Free Workplace (May 2001) 52.223-18 Encouraging Contractor Policies to Ban Text Messaging (Jun 2020) 52.232-5 Payments under Fixed-Price Construction Contracts (May 2014) 52.232-16 Progress Payments (Jun 2020) 52.232-18 Availability of Funds (Apr 1984) 52.232-27 Prompt Payment for Construction Contracts (Jan 2017) 52.232-33 Payment by electronic funds Transfer – System for Awards Management (Oct 2018) 52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (Dec 2013) 52.233-4 Applicable Law for Breach of Contract Claim (Oct 2004)

52.236-2 Differing Site Conditions (Apr 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (Apr 1984) 52.236-5 Material and Workmanship (Apr 1984) 52.236-6 Superintendence by the Contractor (Apr 1984) 52.236-7 Permits and Responsibilities. (Nov 1991) 52.236-8 Other Contracts. (Apr 1984) 52.236-9 Protection of Existing Vegetation, Structures, etc. (Apr 1984)

52.236-10 Operations and Storage Areas (Apr 1984) 52.236-11 Use and Possession Prior to Completion (Apr 1984) 52.236-12 Cleaning Up (Apr 1984) 52.236-13 Accident Prevention (Nov 1991) 52.236-17 Layout of Work (Apr 1984) 52.236-21 Specs and Drawings for Construction (Feb 1997)

52.243-5 Changes and Changed Conditions (Apr 1984) 52.245-1 Government Property (Jan 2017) 52.245-9 Use and Charges (Apr 2012) 52.247-12 Supervision, Labor, or Materials (Apr 1984) 52.247-21 Contractor Liability for Personal Injury and/or Property Damage (Apr 1984) 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form) (Apr 1984)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Aug 2020)

(a) Definitions. As used in this clause— Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People’s Republic of China.

Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or https://acquisition.gov/far/part-4#FAR_4_2104 https://acquisition.gov/far/part-4#FAR_4_2104 otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification:

the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

(End of clause)

52.225-9 Buy American—Construction Materials (May 2021) As prescribed in 25.1102(a), insert the following clause:

BUY AMERICAN—CONSTRUCTION MATERIALS (FEB 2021)

(a) Definitions. As used in this clause— Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial item (as defined in paragraph (1) of the definition at

Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace;

and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, https://dibnet.dod.mil/ https://dibnet.dod.mil/ https://acquisition.gov/far/current/html/Subpart%2025_11.html#wp1078063 https://www.acquisition.gov/far/2.101#FAR_2_101 materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the

United States; or

(ii) A construction material manufactured in the United States, if–

(A) The cost of its components mined, produced, or manufactured in the

United States exceeds 55 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C.chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: N/A

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/12.505#FAR_12_505

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

FOREIGN AND DOMESTIC CONSTRUCTION MATERIALS PRICE COMPARISON

Construction Material Description Unit of Measure Quantity Price (Dollars)*

Item 1:

Foreign construction material _______ _______ _______ Domestic construction material _______ _______ _______ Item 2: _______ _______ _______ Foreign construction material _______ _______ _______ Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

52.228-13 Alternative Payment Protections (Jul 2000)

(a) The Contractor shall submit one of the following payment protections (if award is over $35,000):

1. Irrevocable Letter of Credit

2. Certificate of Deposit

3. Payment Bond

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within the timeframe stated in the Notice of Intent to Award.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement. (End of clause)

52.228-14 Irrevocable Letter of Credit (Nov 2014)

(a) “Irrevocable letter of credit” (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit.

(b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used.

(c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and—

(1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period;

(2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be:

(i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of—

(A) One year following the expected date of final payment;

(B) For performance bonds only, until completion of any warranty period; or

(C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment.

(ii) For contracts not subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of—

(A) 90 days following final payment; or

(B) For performance bonds only, until completion of any warranty period.

(d)(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC.

http://uscode.house.gov/ http://uscode.house.gov/

(2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year.

(3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC.

(4) The current rating for a financial institution is available through any of the following rating services registered with the U.S. Securities and Exchange Commission (SEC) as a Nationally Recognized Statistical Rating Organization (NRSRO). NRSRO’s can be located at the website http://www.sec.gov/answers/nrsro.htm maintained by the SEC.

(e) The following format shall be used by the issuing financial institution to create an ILC:

[Issuing Financial Institution’s Letterhead or Name and Address] Issue Date __________ Irrevocable Letter of Credit No.

Account party’s name Account party’s address For Solicitation No. _________________ (for reference only) To: [U.S. Government agency] [U.S. Government agency’s address]

1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United…