Sol_1305M225Q0191.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3.AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 29. AWARD OF CONTRACT: REFERENCE

. YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4.

FAR 52.212-3 AND 52.212-5 ARE ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED.

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

DATED.

OFFER

ADDENDA

ADDENDA

1305M225Q0191

See Schedule See Schedule

EAD-SAP

FED BLDG 200 GRANBY ST SUITE 815

NORFOLK VA 23510

08/08/2025 1100 ED

141014-25-0091

CHELSEA VERA

757-828-6329

DAWN DABNEY

713930

$11

07/23/2025

ND601312

ADMINISTERED BY:

FED BLDG 200 GRANBY ST SUITE 815

NORFOLK VA 23510 USA

DELIVER TO:

GRAY'S REEF NAT'L MARINE SANCT

Continued...

STOCK RECORD (S/R)

STANDARD FORM 1449 (REV. 11/2021) BACK

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE RECEIVED (MM/DD/YYYY) 42d. TOTAL CONTAINERS

40. PAID BY

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32g. EMAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

PARTIAL FINAL

37. CHECK NUMBER

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER

36. PAYMENT

COMPLETE PARTIAL FINAL

ACCEPTED,

10 OCEAN SCIENCE CIRCLE

/N/ORM6X13

SAVANNAH GA 31411 USA

Period of Performance: 09/16/2025 to

09/15/2026

BASE YEAR

0001 Dockage services for R/V Gannet at Gray's Reef

National Marine Sanctuary

Delivery: 09/16/2025

OPTION YEAR 1

0002 Dockage Services for R/V Gannet and R/V Sam

Gray at GRNMS

(Option Line Item)

Delivery: 09/16/2026

Period of Performance: 09/16/2026 to

09/15/2027

OPTION YEAR 2

0003 Dockage Services for R/V Gannet and R/V Sam

Gray at GRNMS

Continued...

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

1305M225Q0191

(Option Line Item)

Delivery: 09/16/2027

Period of Performance: 09/16/2027 to

09/15/2028

SCA Wage Determination 2015-4491 is incorporated and attached.

1305M225Q0191 BASE

Section II - Supplies or Services and Price/Costs Section IX - Contract Clauses Section X - List of Attachments

Section II - Supplies or Services and Price/Costs

CLIN List

Item Number Description Quantity Unit Unit Price Amount

BASE YEAR

Dockage services for R/V Gannet at Gray's Reef National Marine Sanctuary Award Type: Firm-fixed-price Requisition No: 141014-25-0091

OPTION YEAR 1

Dockage Services for R/V Gannet and R/V Sam Gray at GRNMS Award Type: Firm-fixed-price

(Option Line Item)

Requisition No: 141014-25-0091 Period of Performance: 09/16/2026 to 09/15/2027

OPTION YEAR 2

Dockage Services for R/V Gannet and R/V Sam Gray at GRNMS Award Type: Firm-fixed-price

(Option Line Item)

Requisition No: 141014-25-0091 Period of Performance: 09/16/2027 to 09/15/2028

Section IX - Contract Clauses

Clauses Incorporated by Reference Clause Number Clause Title

52.204-7 System for Award Management. (NOV 2024)

52.204-13 System for Award Management Maintenance. (OCT 2018)

52.204-16 Commercial and Government Entity Code Reporting.

(AUG 2020)

52.204-17 Ownership or Control of Offeror. (AUG 2020)

52.204-18 Commercial and Government Entity Code Maintenance.

(AUG 2020)

52.204-20 Predecessor of Offeror. (AUG 2020)

52.209-2 Prohibition on Contracting With Inverted Domestic Corporations-Representation. (NOV 2015)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (FEB 2016)

52.212-4 Contract Terms and Conditions - Commercial Products and Commercial Services. (NOV 2023)

1352.201-70 Contracting Officer's Authority. (MAR 2010) 1352.209-73 Compliance with the laws. (APR 2010) 1352.209-74 Organizational conflict of interest. (APR 2010)

Standard Language UTILIZATION OF FEDCONNECT FOR CONTRACT ADMINISTRATION

The Department of Commerce will utilize the FedConnect® web portal in administering this award. The contractor must be registered in FedConnect® and have access to the FedConnect® website located at https://www.fedconnect.net/Fedconnect/. For assistance in registering or for other FedConnect® questions please call the FedConnect® Help Desk at (800) 899-6665 or email at support@fedconnect.net. There is no charge for registration in or use of FedConnect®.

FAR 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Products and Commercial Services.

The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to-

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to-

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that-

(1) It [ ] will, [ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that-

It [ ] does, [ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment-

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services-

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment-

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services-

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

FAR 52.204-29 Federal Acquisition Supply Chain Security Act Orders-Representation and Disclosures.

(DEC 2023)

(a) Definitions. As used in this provision, Covered article, FASCSA order, Intelligence community, National security system, Reasonable inquiry, Sensitive compartmented information, Sensitive compartmented information system, and Source have the meaning provided in the clause 52.204-30, Federal Acquisition Supply Chain Security Act Orders-Prohibition.

(b) Prohibition. Contractors are prohibited from providing or using as part of the performance of the contract any covered article, or any products or services produced or provided by a source, if the prohibition is set out in an applicable Federal Acquisition Supply Chain Security Act (FASCSA) order, as described in paragraph (b)(1) of FAR 52.204-30, Federal Acquisition Supply Chain Security Act Orders-Prohibition.

(c) Procedures. (1) The Offeror shall search for the phrase "FASCSA order" in the System for Award Management (SAM)(https://www.sam.gov) for any covered article, or any products or services produced or provided by a source, if there is an applicable FASCSA order described in paragraph (b)(1) of FAR 52.204-30, Federal Acquisition Supply Chain Security Act Orders- Prohibition.

(2) The Offeror shall review the solicitation for any FASCSA orders that are not in SAM, but are effective and do apply to the solicitation and resultant contract (see FAR 4.2303(c)(2)).

(3) FASCSA orders issued after the date of solicitation do not apply unless added by an amendment to the solicitation.

(d) Representation. By submission of this offer, the offeror represents that it has conducted a reasonable inquiry, and that the offeror does not propose to provide or use in response to this solicitation any covered article, or any products or services produced or provided by a source, if the covered article or the source is prohibited by an applicable FASCSA order in effect on the date the solicitation was issued, except as waived by the solicitation, or as disclosed in paragraph (e).

(e) Disclosures. The purpose for this disclosure is so the Government may decide whether to issue a waiver. For any covered article, or any products or services produced or provided by a source, if the covered article or the source is subject to an applicable FASCSA order, and the Offeror is unable to represent compliance, then the Offeror shall provide the following information as part of the offer:

(1) Name of the product or service provided to the Government;

(2) Name of the covered article or source subject to a FASCSA order;

(3) If applicable, name of the vendor, including the Commercial and Government Entity code and unique entity identifier (if known), that supplied the covered article or the product or service to the Offeror;

(4) Brand;

(5) Model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

(6) Item description;

(7) Reason why the applicable covered article or the product or service is being provided or used;

(f) Executive agency review of disclosures. The contracting officer will review disclosures provided in paragraph (e) to determine if any waiver may be sought. A contracting officer may choose not to pursue a waiver for covered articles or sources otherwise subject to a FASCSA order and may instead make an award to an offeror that does not require a waiver.

(End of provision)

FAR 52.212-1 Instructions to Offerors - Commercial Products and Commercial Services. (SEP 2023)

(a) North American Industry Classification System (NAICS) code and small business size standard.

The NAICS code(s) and small business size standard(s) for this acquisition appear elsewhere in the solicitation. However, the small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Is set aside for small business and has a value above the simplified acquisition threshold;

(2) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(3) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show-

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at Federal Acquisition Regulation (FAR) 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with FAR subpart 4.10), or alternative commercial products or commercial services for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers. (1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of Federal specifications, standards, and product descriptions can be downloaded from the ASSIST website at https://assist.dla.mil.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained from the address in paragraph (i)(1)(i) of this provision.

(2) Most unclassified Defense specifications and standards may be downloaded from the ASSIST website at https://assist.dla.mil.

(3) Defense documents not available from the ASSIST website may be requested from the Defense Standardization Program Office by-

(i) Using the ASSIST feedback module (https://assist.dla.mil/feedback); or

(ii) Contacting the Defense Standardization Program Office by telephone at 571- 767-6688 or email at assisthelp@dla.mil.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers that exceed the micro-purchase threshold, and offers at or below the micro-purchase threshold if the solicitation requires the Contractor to be registered in the System for Award Management (SAM).) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable.

The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see FAR subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) [Reserved]

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial products, the make and model of the product to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

FAR 52.217-5 Evaluation of Options. (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

FAR 52.217-8 Option To Extend Services. (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within one (1) day.

(End of clause)

FAR 52.217-9 Option To Extend the Term of the Contract. (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within one (1) day; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least one (1) days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed Three (3) years and six (6) months..

(End of clause)

FAR 52.252-1 Solicitation Provisions Incorporated by Reference. (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): www.acquisition.gov

(End of provision)

FAR 52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov

(End of clause)

FAR 52.252-5 Authorized Deviations in Provisions. (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR chapter 1) provision with an authorized deviation is indicated by the addition of (DEVIATION) after the date of the provision.

(b) The use in this solicitation of any Commerce Acquisition Regulation (48 CFR chapter 1352) provision with an authorized deviation is indicated by the addition of (DEVIATION) after the name of the regulation.

(End of provision)

FAR 52.252-6 Authorized Deviations in Clauses. (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter

1) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the date of the clause.

(b) The use in this solicitation or contract of any Commerce Acquisition Regulation (48 CFR 1352) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the name of the regulation.

(End of clause)

CAR 1352.213-70 Evaluation utilizing simplified acquisition procedures. (APR 2010)

The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation is the Lowest Price Technically Acceptable Offer (LPTA). Technically acceptable is defined as the offeror’s ability to meet all the requirements/salient characteristics identified in the Statement of Work/Specification and the offeror’s demonstrated ability to perform the contract successfully through Past Performance. Only the lowest priced offer will be evaluated for technical acceptability. If the lowest priced offer is found not to be technically acceptable, then the next lowest priced offer will be evaluated. This process will continue until a technically acceptable offer is identified; not all offers will be evaluated. The following factors shall be used to evaluate offers: (1) Technical, (2) Past Performance, and (3) Price:

(1) Technical (Pass/Fail) The government will evaluate the offeror’s ability and method/approach to providing all the requirements in the Statement of Work as identified in their technical section/proposal. Technical will be rated as to the extent the offeror can clearly and fully demonstrate that it has a thorough understanding of the requirements and can successfully provide the requirements. Offerors that cannot specifically address their ability and method/approach to providing all the requirements in the Statement of Work or that do not submit a Technical Section with their offer may be rejected without further consideration.

(2) Past Performance (Pass/Fail) The Government will evaluate an offeror’s past performance to determine the degree to which current and previous contract efforts indicate the probability of the offeror successfully accomplishing/performing the requirements of the Statement of Work. The currency and relevancy of the information, source of the information, context of the data, and general trends in contractor’s performance will be considered.

Past performance information received from the offeror shall be within the past 3 years or ongoing and be relevant to this requirement (i.e. the same or similar requirements.) Only relevant past performance will be evaluated.

(3) Price (Only the lowest priced technically acceptable offer will be evaluated on Price) The Government will evaluate price for reasonableness and award a contract to the offeror with the lowest priced technically acceptable offer. Offerors are required to provide a unit price for all items. A zero dollar figure ($0.00) unit price means the Offeror will provide the service or supply at no charge to the Government. Unit price left blank or annotated with something other than a dollar figure will be considered unacceptable and the Government has discretion whether to reject the offer without any further consideration.

(End of clause)

CAR 1352.215-72 Inquiries. (APR 2010)

Offerors must submit all questions concerning this solicitation in writing to chelsea.vera@noaa.gov.

Questions should be received no later than 7 calendar days after the issuance date of this solicitation.

Any responses to questions will be made in writing, without identification of the questioner, and will be included in an amendment to the solicitation. Even if provided in other form, only the question responses included in the amendment to the solicitation will govern performance of the contract.

(End of clause)

CAR 1352.233-70 Agency protests. (APR 2010)

(a) An agency protest may be filed with either: (1) The contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 FR 16,651 (April 6, 1999).

(b) Agency protests filed with the Contracting Officer shall be sent to the following address:

ATTN: Dawn Dabney, Contracting Officer Dawn.Dabney@noaa.gov

(c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: Eastern Acquisition Division ATTN: Dawn Dabney, NOAA Simplified Acquisition Branch Chief Dawn.Dabney@noaa.gov

(d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority.

(e) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)

CAR 1352.233-71 GAO and Court of Federal Claims protests. (APR 2010)

(a) A protest may be filed with either the Government Accountability Office (GAO) or the Court of Federal Claims unless an agency protest has been filed.

(b) A complete copy of all GAO or Court of Federal Claims protests, including all attachments, shall be served upon (i) the Contracting Officer, and (ii) the Contract Law Division of the Office of the General Counsel, within one day of filing a protest with either GAO or the Court of Federal Claims.

(c) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)

CAR 1352.246-70 Place of acceptance. (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be:

GRAY'S REEF NAT'L MARINE SANCTUARY

10 OCEAN SCIENCE CIRCLE

/N/ORM6X13

SAVANNAH GA 31411

(End of clause)

CAR 1352.270-70 Period of performance. (APR 2010)

(a) The base period of performance of this contract is from 9/16/2025 through 9/15/2026. If an option is exercised, the period of performance shall be extended through the end of that option period.

(b) The option periods that may be exercised are as follows:

OPTOIN YEAR ONE: 9/16/2026 - 9/15/2027

OPTION YEAR TWO: 9/16/2027 - 9/15/2028

(c) The notice requirements for unilateral exercise of option periods are set out in FAR 52.217-9.

(End of clause)

CAR 1352.271-75 Delivery and shifting of the vessel. (APR 2010)

(a) The Government shall deliver the vessel to the contractor, at the location specified in the contract.

(b) Whether the specified location of performance is the contractor's own facility or any other authorized facility, it shall be understood to mean the fairway of the facility. The contractor shall provide necessary tugs and pilot services to move the vessel from the fairway to the pier or dock, and, upon completion of all work, from the pier or dock to the fairway of the facility.

(c) While the vessel is in the possession of the contractor, any necessary movement of the vessel incidental to the work specified in the contract shall be furnished by the contractor without additional charge to the Government.

(End of clause)

CAR 1352.271-76 Performance. (APR 2010)

(a) The contractor shall not commence work until a notice to proceed has been issued by the Contracting Officer.

(b) The Government shall deliver the vessel described in the contract at such time and location as may be specified in the contract. Upon completion of the work, the Government shall accept delivery of the vessel at such time and location as may be specified in the contract.

(c) Without additional charge to the Government, and without specific requirement in the contract, the contractor shall:

(1) Make available, at the facility, to personnel of the vessel while in drydock or on a marine railway, sanitary facilities adequate for the number of personnel using them and acceptable to the Contracting Officer;

(2) Supply and maintain, in such condition as the Contracting Officer may reasonably require, suitable brows and gangways from the pier, drydock or marine railway to the vessel;

(3) Perform, or pay the cost of, any repair, reconditioning or replacement made necessary as the result of the use by the contractor of any of the vessel's machinery, equipment or fittings, including, but not limited to, winches, pumps, riggings, or pipe lines; and

(4) Furnish suitable offices, office equipment and telephones at or near the site of the work as the Contracting Officer reasonably requires for personnel designated by the Government.

(d) Except as otherwise provided in the contract, the contractor shall furnish all necessary material, labor, supervision, services, equipment, tools, supplies, power, accessories, facilities, and other things and services necessary for accomplishing the work.

(e) The contractor shall conduct dock and sea trials of the vessel as required by the contract.

Unless otherwise expressly provided in the contract, during the conduct of these trials the vessel shall be under the control of the vessel's commander and crew with representatives of the contractor and the Government on board to determine whether the work provided by the contractor has been satisfactorily performed. Dock and sea trials not specified which the contractor requires for its own benefit shall not be undertaken by the contractor without prior notice to and approval of the Contracting Officer; any such dock or sea trial shall be conducted at the risk and expense of the contractor. The contractor shall provide and install all fittings and appliances which may be necessary for the dock and sea trials to enable the representatives of the Government to determine whether the requirements of the contract plans and specifications have been met. The contractor shall also be responsible for the care, installation and removal of any instruments and apparatus furnished by the Government for such trials.

(End of clause)

CAR 1352.271-77 Delays. (APR 2010)

When, during the performance of this contract, the contractor is required to delay the work on a vessel temporarily, due to orders or actions of the Government respecting stoppage of work to permit shifting the vessel, stoppage of hot work to permit bunkering, fueling, embarking or debarking of passengers or loading or discharging of cargo, and the contractor is not given sufficient advance notice or is otherwise unable to avoid incurring additional costs on account thereof, an equitable adjustment may be made in the contract. Any such request for equitable adjustment shall be asserted in writing as soon as practicable after the delay or disruption, but not later than the day of final payment under the contract.

(End of clause)

CAR 1352.271-78 Minimization of delay due to Government furnished property. (APR 2010)

(a) In order to assure timely performance under this contract, it is imperative that delay in the contract's performance period resulting from late, damaged, or unsuitable Government furnished property be held to an absolute minimum. In order to achieve minimization of delay, it is agreed that:

(1) Subject to adjustment as provided in paragraph (b) of this clause, the Government shall deliver each item of Government furnished property to the contractor on or before the date specified in the contract or, if later, in sufficient time for the contractor to meet the contract performance period.

(2) The Government may forego furnishing any item of Government property to the contractor. In that event, the contractor shall prepare the vessel in terms of piping, wiring, structure, foundation, ventilation, and any other pre-installation requirements of the item, so that the work on the vessel may continue without delay and disruption resulting from the absence of the item. If the Government does not furnish an item designated as Government furnished property, the contract price may be adjusted accordingly.

(b) The delivery or performance dates for the supplies or services to be furnished by the contractor under this contract are based upon the expectation that Government furnished property suitable for use (except for such property furnished "as is") will be delivered to the contractor at the time stated in the specification or, if not so stated, in sufficient time to enable the contractor to meet such delivery or performance dates. If the Government furnished property is not furnished in the time stated in the contract, or, if a date is not specified, and the late delivery does not give the contractor sufficient time to enable the contractor to meet required contract delivery or performance dates, the contractor shall notify the Government in writing of the late delivery. Notification shall include cost and schedule impacts, including delays and disruptions to schedules. This notification shall be submitted as soon as practical or known.

(c) The provisions in subsection (b) of this clause and in FAR 52.245-1, if applicable, provide the exclusive remedies to the contractor resulting from delay in delivery of Government furnished property or delivery of such property in a condition not suitable for its intended use.

(End of clause)

CAR 1352.271-79 Liability and insurance. (APR 2010)

(a) The contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property, in and about the work, and to the vessel or part thereof upon which work is done.

(b) The contractor shall be responsible for and make good at its own cost and expense any and all loss of or damage of whatsoever nature to the vessel (or part thereof), its equipment, movable stores and cargo, and Government-owned material and equipment for the repair, completion, alteration of or addition to the vessel in the possession of the contractor, whether at the plant or elsewhere, arising or growing out of the performance of the work, except where the contractor can affirmatively show that such loss or damage was due to causes beyond the contractor's control, was proximately caused by the fault or negligence of agents or employees of the Government, or which loss or damage the contractor by exercise of reasonable care was unable to prevent. However, the contractor shall not be responsible for any such loss or damage discovered after redelivery of the vessel unless the loss or damage is discovered within 90 days after redelivery of the vessel and loss or damage is affirmatively shown to be the result of the fault or negligence of the contractor. To induce the contractor to perform the work for the compensation provided, it is specifically agreed that the contractor's aggregate liability on account of loss of or damage to the vessel (or part thereof), its equipment, movable stores and cargo and Government-owned materials and equipment, shall in no event exceed the sum of $1,000,000.00. As to the contractor, the Government assumes the risk of loss or damage to the Government-owned vessel (or part thereof), its equipment, movable stores and cargo and said Government-owned materials and equipment in excess of $1,000,000.00. This assumption of risk includes but is not limited to loss or damage from negligence of whatsoever degree of the contractor's servants, employees, agents or subcontractors, but specifically excludes loss or damage from willful misconduct or lack of good faith on the part of contractor's personnel, who have supervision or direction of all or substantially all of the contractor's business, or all or substantially all of the contractor's operation at any one plant. However, as to such risk assumed and borne by the Government, the Government shall be subrogated to any claim, demand or cause of action against third persons which exists in favor of the contractor, and the contractor shall, if required, execute a formal assignment or transfer of claims, demands or causes of action. Nothing contained in this paragraph shall create or give rise to any right, privilege or power in any person except the contractor, nor shall any person (except the contractor) be or become entitled thereby to proceed directly against the Government, or join the Government as a co-defendant in any action against the contractor brought to determine the contractor's liability, or for any other purpose.

(c) The contractor indemnifies and holds harmless the Government, its agencies and instrumentalities, and the vessel against all suits, actions, claims, costs or demands (including without limitation, suits, actions, claims, costs or demands resulting from death, personal injury and property damage) to which the Government, its agencies and instrumentalities, or the vessel may be subject or put by reason of damage or injury (including death) to the property or person of anyone other than the Government, its agencies, instrumentalities and personnel, or the vessel, arising or resulting in whole or in part from the fault, negligence, wrongful act or wrongful omission of the contractor, or any…