RFQ_VFD_Trouble_shooting_FEDBIZ.pdf

TABLE OF CONTENTS

Section 1 - The Schedule

SF 1449 cover sheet

Continuation To SF-1449, RFQ Number SFJ60016Q0005, Prices, Block 23

Continuation To SF-1449, RFQ Number SFJ60016Q0005, Schedule Of Supplies/Services, Block 20

Description/Specifications/Work Statement

Attachment 1 – List of Equipment to be Inspected and Tested (Including Pictures)

Section 2 - Contract Clauses

Contract Clauses

Addendum to Contract Clauses - FAR and DOSAR Clauses not Prescribed in Part 12

Section 3 - Solicitation Provisions

Solicitation Provisions

Addendum to Solicitation Provisions - FAR and DOSAR Provisions not Prescribed in Part 12

Section 4 - Evaluation Factors

Evaluation Factors

Addendum to Evaluation Factors - FAR and DOSAR Provisions not Prescribed in Part 12

Section 5 - Representations and Certifications

Offeror Representations and Certifications

Addendum to Offeror Representations and Certifications - FAR and DOSAR Provisions not

Prescribed in Part 12

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER

2. CONTRACT NO.

3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER

5. SOLICITATION

NUMBER

SFJ60016Q0005

6. SOLICITATION ISSUE

DATE

July 15th 2016

(local time) 7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

Stephen White

b. TELEPHONE

NUMBER(No collect calls)

679 331-4466

8. OFFER DUE DATE/

LOCAL TIME

August 16th at 12 NOON

9. ISSUED BY

CODE

10. THIS

ACQUISITION IS

UNRESTRICTED

OR

SET ASIDE:____ %

FOR:

US EMBASSY SUVA

158 PRINCES ROAD

SUVA, FIJI

SMALL BUSINESS WOMEN-OWNED SMALL BUSINESS

HUBZONE

SMALL

BUSINESS

(WOSB) ELLIGIBLE UNDER THE WOMEN-

OWNED

SMALL BUSINESS PROGRAM NAICS: SERVICE-

DISABLED

VETERAN-

OWNED

SMALL

BUSINESS

EDWOSB

8 (A) SIZE STANDARD:

11. DELIVERY FOR FOB

DESTINAION UNLESS

BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS 13a. THIS CONTRACT IS

A

RATED ORDER

UNDER

DPAS (15 CFR 700)

13b. RATING

14. METHOD OF SOLICITATION

RFQ IFB RFP

15. DELIVER TO:

US EMBASSY SUVA

CODE 16. ADMINISTERED BY

CODE

158 PRINCES ROAD

SUVA, FIJI

17a. CONTRACTOR/

OFFERER

TELEPHONE NO.

CODE FACILITY

CODE

18a. PAYMENT WILL BE MADE BY

US EMBASSY SUVA

FMO

158 PRINCES ROAD

SUVA

CODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

SUCH ADDRESS IN OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED SEE ADDENDUM

19.

ITEM

NO

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

See section 1 attached

Perform power quality analysis and electrical troubleshooting.

Please see attached

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (For Govt.

Use Only)

27a.SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5

ARE ATTACHED. ADDENDA

ARE ARE NOT

ATTACHED

27b.CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS

ATTACHED. ADDENDA

ARE ARE NOT

ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND

RETURN ____ COPIES TO ISSUING OFFICE. CONTRACTOR AGREES

TO FURNISH AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE

IDENTIFIED ABOVE AND ON ANY ADDITIONAL SHEETS SUBJECT

TO THE TERMS AND CONDITIONS SPECIFIED HEREIN.

29. AWARD OF CONTRACT: REF. _________________ OFFER

DATED ____________. YOUR OFFER ON SOLICITATION (BLOCK

5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING

OFFICER)

30b. NAME AND TITLE OF SIGNER (Type or print)

30c. DATE SIGNED

31b. NAME OF CONTRACTING OFFICER

Stephen White

31c. DATE SIGNED

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ____________________________

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

36. PAYMENT 37. CHECK NUMBER

PARTIAL FINAL

COMPLETE PARTIAL

FINAL

38. S/R ACCOUNT NO.

39. S/R VOUCHER NO. 40. PAID BY

41.a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT 42a. RECEIVED BY (PRINT)

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41C. DATE

42b. RECEIVED AT (Location)

42c. DATE REC’D (YY/MM/DD) 42d. TOTAL CONTAINERS

SECTION 1 - THE SCHEDULE

CONTINUATION TO SF-1449

RFQ NUMBER SFJ60016Q0005

PRICES, BLOCK 23

1.0 DESCRIPTION

The Contractor shall provide the American Embassy in Suva, Fiji with power quality analysis and electrical troubleshooting to identify the cause of an intermittent failure of installed Variable Frequency Drives (VFD) located at the American Embassy in Suva, Fiji. This is a one-time service visit. All power transfers and system outages work must occur during non-Embassy working hours. Bidders are asked to schedule their system testing to occur within one-weekend, beginning after 3 PM on a Friday, with completion no later than 8 PM on Sunday. The price listed below shall include all labor, materials, insurance (see FAR 52.228-4 and 52.228-5), overhead, profit, and transportation necessary perform these preventive maintenance services to the Embassy.

2.0 PRICING

2.1 VALUE ADDED TAX

VALUE ADDED TAX. Value Added Tax (VAT) is not included in the CLIN rates. Instead, it will be priced as a separate Line Item in the contract and on Invoices. Local law dictates that a 9% VAT is applied to the entire, total cost.

2.2 Base Year - The Contractor shall provide the services shown below for the base period of the contract, starting on the date stated in the Notice to Proceed. The fixed unit prices, estimated quantities, and ceiling for each category are:

Line

Item Description Unit Price/Service

No. Of

Service Total

Power quality analysis and electrical troubleshooting (see Attachment 1 for list of equipment to be inspected and tested)

One (1) time

Travel

One (1) time

TOTAL

Pricing must be in USD

This is a firm fixed price contract payable entirely in US Dollars. Prices for all Contract Line Item Numbers (CLIN) shall include proper disposal of toxic substances where applicable. No additional sums will be payable for any escalation in the cost of materials, equipment or labor, or because of the contractor's failure to properly estimate or accurately predict the cost or difficulty of achieving the results required.

3.0 NOTICE TO PROCEED

After contract award and submission of acceptable insurance certificates and copies of all applicable licenses and permits, the Contracting Officer will issue a Notice to Proceed. The Notice to Proceed will establish a date (a minimum of ten (10) days from date of contract award unless the Contractor agrees to an earlier date) on which performance shall start.

CONTINUATION TO SF-1449

RFQ NUMBER SFJ60016Q0005

SCHEDULE OF SUPPLIES/SERVICES, BLOCK 20

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

1.0 PERFORMANCE WORK STATEMENT

The US Embassy suffers from frequent shutdown of building Air Handler Units (AHU) that must be manually restarted after a loss of city power and power transfer. The AHUs are controlled via a Motor Control Center with built-in Schneider Electric (Square-D) Variable Frequency Drives (VFDs) as noted in section III. This intermittent problem does not occur on all power transfers, nor does it always affect the same VFD. Once an AHU shutdown occurs the VFD must be manually switched OFF/ON to reset the controls. This sequence occurs during both transfer from-utility-to-generator and back from-generator-to-utility. A higher percentage of shutdowns occur as a result of transfer back to utility (from generator). Occurring at irregular intervals some power transfers occur without VFD failure, while others shutdown multiple VFDs. The Automatic Transfer Switches (ATS) on the line side of the affected VFDs are installed with in-phase monitors that are activated. The entire electrical distribution system was installed in 2009/2010. The reoccurring problem with the VFD was noted during building commissioning and never thoroughly corrected. Description of equipment can be found in Attachment 1.

2.0 GENERAL REQUIREMENTS:

The Contractor under this SOW will be responsible for labor, tools, and materials required to carry out all inspection and testing as outlined in the SOW.

3.0 SCOPE OF WORK:

Perform power quality analysis and electrical equipment testing to identify the cause of an intermittent failure affecting the installed Variable Frequency Drives (VFD) located at the American Embassy in Suva, Fiji. Coordinate site visit service dates with the embassy Facility Manager (FM) and follow the travel requirements outlined in this work statement.

Prior to beginning any site work the contractor must submit a final work plan to the embassy Facility Manager for approval. The work plan must outline the planned work sequence, noting intended power transfers and switchgear outages.

Once FM approval is given the contractor shall proceed following their proposed troubleshooting and power quality analysis testing procedure. At a minimum the testing should include an infrared scan of the Variable Speed Drives and Automatic Transfer Switches; monitoring of voltage and current values, transient voltages, and harmonic distortion levels for each phase during power transfers. Inspect and test the associated electrical grounding system. Isolate circuits and equipment to identify actual or potential cause of the intermittent VFD shutdown and provide a full proposal detailing corrective measures. The Embassy FM must be made immediately aware of any condition discovered that could result in equipment failure, or inhibit the equipment from being put back into service.

4.0 PROJECT REQUIREMENTS:

Contractor shall provide all qualified labor, tools, test equipment, noted materials, and supervision to perform the tasks listed within this work statement. All personnel working in the vicinity of energized electrical gear shall wear/use the appropriate Personal Protective Equipment (PPE) in accordance with the 2009 NFPA-70e while performing tasks under this work statement. All safety concerns or injuries shall be brought to the attention of the Post Occupation Safety and Health Officer (POSHO). As applicable, Material Safety Data Sheets (MSDS) shall be provided by the contactor for all HAZMAT materials. Copies will be provided to the COR for approval.

Site visit the US Embassy in Suva and conduct power quality analysis and troubleshooting technics to identify actual or potential electrical deficiencies that may cause the intermittent VFD tripping. Provide an after visit report detailing proposed corrective measures. The report summary must outline suggested next steps to repair or modify the existing VFD installation to alleviate the nuisance tripping. While onsite the Embassy will provide the contractor with two locally employed staff to assist along with any temporary power, lighting, ladders, extension cords, and basic hand-tools requested. The contractor must clean up after each task and place all maintenance associated trash in the proper Embassy dumpster or approved trash container. All power transfers and system outage work must occur during non-Embassy work hours, such as Friday evening, Saturday or Sunday.

5.0 HOURS OF PERFORMANCE

The Contractor shall maintain work schedules. The schedules shall take into consideration the hours that the staff can effectively perform their services without placing a burden on the security personnel of the Post. The Contractor shall deliver standard services between the hours of 08:00 and 17:30 Monday through Thursday and 08:00 and 15:00 on Friday. No work shall be performed on US Government and local holidays. A list of the holidays can be found at 652.237-72 in this document.

6.0 ACCESS TO GOVERNMENT BUILDINGS AND STANDARDS OF CONDUCT

6.1 General. The Contractor shall designate a representative who shall supervise the Contractor’s technicians and be the Contractor’s liaison with the American Embassy. The Contractor’s employees shall be on-site only for contractual duties and not for any other business or purpose. Contractor employees shall have access to the equipment and equipment areas and will be escorted by Embassy personnel.

6.2 Personnel Security. The Government reserves the right to deny access to U.S.-owned and U.S.-operated facilities to any individual. The Contractor shall provide the names, biographic data and police clearance on all Contractor personnel who shall be used on this Contract prior to their utilization. Submission of information shall be made within 5 days of award of contract. No technician will be allowed on site without prior authorization. Note: this may include cleared personnel if advance notice of visit is not given at least one week before the scheduled visit.

6.3 Vehicles. Contractor vehicles will not be permitted inside the embassy compound without prior approval. If you need to have vehicle access please submit your vehicle information (Make, Model, License Plate #) along with a written justification as to why access is necessary. This should be submitted to the Facility Manager at least one (1) week prior to the visit.

Government shall issue identity cards to Contractor personnel, after they are approved. Contractor personnel shall display identity card(s) on the uniform at all times while providing services under this contract. These identity cards are the property of the US Government. The Contractor is responsible for their return at the end of the contract, when an employee leaves Contractor service, or at the request of the Government. The Government reserves the right to deny access to U.S.-owned and U.S.-operated facilities to any individual.

6.4 Security Requirements: No security clearance is required. The contractor will be escorted whenever/wherever necessary by appropriate Embassy personnel.

6.5 Overseas Travel. The terms and conditions of the Federal Travel Regulations (FTR) and Joint Travel Regulation (JTR) shall apply to all travel and travel-related matters authorized under this contract; travel and travel-related expenses shall not exceed the maximum allowable under the FTR and JTR. In connection with authorized travel, the following items may be included in the firm-fixed price of the contract line item in 2.2.2 and 2.3.2: (i) the cost of domestic and overseas economy-class (coach) air fare; (ii) the cost of hotel or housing accommodations, meals, and other incidentals when travel is undertaken; and (iii) miscellaneous expenses incurred in connection with the travel.

Miscellaneous travel items such as taxi fares and other ground transportation expenses incurred in connection with the travel, and, if applicable, passport/visa fees, passport/visa photographs, travelers check fees, and airport taxes may be included in the firm-fixed price of the contract line item 2.2.2 and 2.3.2.

6.6 Safety Requirements: Safety is the highest priority on this job. The contractor shall direct all of those under his/her charge to work safely. Strict adherence to 2009 NFPA70-E and applicable OSHA standards must be maintained at all times. Regular safety meetings shall be held among on-site contractor personnel. Safety concerns shall be brought to the attention of the COR.

6.7 Deliverable Requirements: The contractor shall provide one copy of a typed summary report within 45 days of site work statement completion. The report must be written in the English language. The after visit report should be presented in the following format:

1. Executive Summary of action taken and noted discrepancies.

2. Test results; provide photos of any infrared scan results that are outside of normal limits. Recorded voltage and current values during power transfers. Grounding inspection results. Noted transients or other power anomalies.

3. Proposal of corrective action required. Outline the proposed methods and include details of corrective actions, required equipment, and associated installation requirements.

4. List of materials/equipment to include component name, quantity, and part number.

The contractor performing these inspections and testing will be precluded from performing any work regarding any corrective action which may result from the final report.

6.8 STANDARDS OF CONDUCT

6.8.1 General. The Contractor shall maintain satisfactory standards of employee competency, conduct, cleanliness, appearance, and integrity and shall be responsible for taking such disciplinary action with respect to employees as may be necessary. Each Contractor employee shall adhere to standards of conduct that reflect credit on themselves, their employer, and the United States Government. The Government reserves the right to direct the Contractor to remove an employee from the worksite for failure to comply with the standards of conduct. The Contractor shall immediately replace such an employee to maintain continuity of services at no additional cost to the Government.

6.8.2 Neglect of Duties. Neglect of duties shall not be condoned. This includes sleeping while on duty, unreasonable delays or failures to carry out assigned tasks, conducting personal affairs during duty hours and refusing to render assistance or cooperate in upholding the integrity of the worksite security.

6.8.3 Disorderly Conduct. The Contractor shall not condone disorderly conduct, use of abusive or offensive language, quarreling, and intimidation by words, actions, or fighting. Also included is participation in disruptive activities that interfere with normal and efficient Government operations.

6.8.4 Intoxicants and Narcotics. The Contractor shall not allow its employees while on duty to possess, sell, consume, or be under the influence of intoxicants, drugs or substances which produce similar effects.

6.8.5 Criminal Actions. Contractor employees may be subject to criminal actions as allowed by law in certain circumstances. These circumstances include but are not limited to the following actions: falsification or unlawful concealment, removal, mutilation, or destruction of any official documents or records or concealment of material facts by willful omission from official documents or records; unauthorized use of Government property, theft, vandalism, or immoral conduct; unethical or improper use of official authority or credentials; security violations; organizing or participating in gambling in any form; and misuse of weapons.

6.8.6 Key Control. The Contractor will not be issued any keys. The keys will checked out from Post 1 by a “Cleared American” escort on the day of service requirements.

6.8.7 Notice to the Government of Labor Disputes. The Contractor shall inform the COR of any actual or potential labor dispute that is delaying or threatening to delay the timely performance of this contract.

7.0 QUALITY ASSURANCE AND SURVEILLANCE PLAN (QASP)

This plan provides an effective method to promote satisfactory contractor performance. The QASP provides a method for the Contracting Officer's Representative (COR) to monitor Contractor performance, advise the Contractor of unsatisfactory performance, and notify the Contracting Officer of continued unsatisfactory performance. The Contractor, not the Government, is responsible for management and quality control to meet the terms of the contract. The role of the

Government is to monitor quality to ensure that contract standards are achieved.

Performance Objective Scope of Work Paragraphs

Performance Threshold

Services.

Seeking contractor proposals to perform power quality analysis and electrical troubleshooting set forth in the scope of work.

As stated in this solicitation

All required services are performed and no more than one (1) customer complaint is received per month.

7.1 SURVEILLANCE. The COR will receive and document all complaints from Government personnel regarding the services provided. If appropriate, the COR will send the complaints to the Contractor for corrective action.

7.2 STANDARD. The performance standard is that the Government receives no more than one (1) customer complaint per month. The COR shall notify the Contracting Officer of the complaints so that the Contracting Officer may take appropriate action to enforce the inspection clause (FAR 52.212.4, Contract Terms and Conditions-

Commercial Items (May 2001), if any of the services exceed the standard.

7.3 PROCEDURES.

(a) If any Government personnel observe unacceptable services, either incomplete work or required services not being performed they should immediately contact the COR.

(b) The COR will complete appropriate documentation to record the complaint.

(c) If the COR determines the complaint is invalid, the COR will advise the complainant. The COR will retain the annotated copy of the written complaint for his/her files.

(d) If the COR determines the complaint is valid, the COR will inform the Contractor and give the

Contractor additional time to correct the defect, if additional time is available. The COR shall determine how much time is reasonable.

(e) The COR shall, as a minimum, orally notify the Contractor of any valid complaints.

(f) If the Contractor disagrees with the complaint after investigation of the site and challenges the validity of the complaint, the Contractor will notify the COR. The COR will review the matter to determine the validity of the complaint.

(g) The COR will consider complaints as resolved unless notified otherwise by the complainant.

(h) Repeat customer complaints are not permitted for any services. If a repeat customer complaint is received for the same deficiency during the service period, the COR will contact the Contracting Officer for appropriate action under the Inspection clause.

8.0 DELIVERABLES

The following items shall be delivered under this contract:

Description QTY Delivery Date Deliver to

Names, biographic data, police clearance on Contractor personnel

1 5 days after contract award COR

Certificate of Insurance 1 10 days after contract award CO

Checklist signed by Contractor’s employee 1 After completion of each inspection and test

COR

Invoice 1 After completion of all services COR

Inspection report and findings (see 6.7) 1 Maximum 45 days after completion of all inspections and testing

COR

9.0 INSURANCE REQUIREMENTS

Personal Injury, Property Loss or Damage (Liability). The Contractor assumes absolute responsibility and liability for any and all personal injuries or death and property damage or losses suffered due to negligence of the Contractor's personnel in the performance of this contract

The Contractor's assumption of absolute liability is independent of any insurance policies.

Insurance. The Contractor, at its own expense, shall provide and maintain during the entire period of performance of this contract, whatever insurance is legally necessary. The Contractor shall carry the following minimum insurance:

Comprehensive General Liability

Bodily Injury * per occurrence

Property Damage * per occurrence

Workers’ Compensation and Employer’s Liability

Workers’ Compensation and Occupational Disease * per occurrence

Statutory, as required by host country law

Employer’s Liability * per occurrence

Worker's Compensation Insurance. The Contractor agrees to provide all employees with worker's compensation benefits as required by the laws of either the country in which the employees are working or the employee's native country, whichever offers greater benefits, following FAR 52.228-4 “Worker’s Compensation and War-Hazard Insurance

Overseas”.

10.0 PERMITS

The Contractor shall maintain in full force and affect all permits, licenses, and appointments required for the prosecution of work under this contract at no additional cost to the Government. The Contractor shall obtain these permits, licenses, and appointments in compliance with host country laws.

11.0 LOCAL LAW REGISTRATION

If the local law or decree requires that one or both parties to the contract register the contract with the designated authorities to insure compliance with this law or decree, the entire burden of this registration shall rest upon the

Contractor. Any local or other taxes which may be assessed against the contract shall be payable by the Contractor without Government reimbursement.

ATTACHMENT 1

LIST OF EQUIPMENT TO BE INSPECTED AND TESTED (INCLUDING PICTURES)

The following power distribution equipment is installed and operational at the US Embassy in Suva. One-line power diagrams are available upon request. Refer to Attachment-A for equipment photos. All equipment and systems are available to the contractor for inspection, testing, and power quality analysis testing.

ATS: Two (2) total: ASCO Automatic Transfer Switches, 7000 Series Cat # HOA7ATSB31000K5XC, Serial # 631015

Switchgear: Square-D rack out breakers powered at 415/240 volts, 50 HZ located on the line side of the ATS units:

Four (4) total: Square-D MASTERPACT, NW 16 H1, Cat# WA4ECR74A3CCBBXXCA, 1600-Amp, rack out circuit breakers.

Switchgear: Square-D rack out breakers powered at 415/240 volts, 50 HZ located on the load side of the ATS units:

Eighteen (18) total: Square-D MASTERPACT, NW 08 H1, Cat# WA4ASR74A35XXXXXA, 800 Amp, rack out circuit breakers

Motor Control Center: Square-D, 6 Motor Control Centers Class 8998, equipment tag NOB MCCP -01. Serial/FO No:

24261078-003, Style/Model No: 6 MCC, System voltage 415/240, Main bus rating 600Amps, Location 2nd Floor.

VFD: Square-D, Four (6) total .Factory Order No:24261078, Class:8839 Circuit ID NOB-AHU-2.02, Voltage:415, Current rating 20Amps.

Circuit ID NOB-AHU-2.03, Voltage:415, Current rating 25Amps.

Circuit ID NOB-SCHP-2.01, Voltage:415, Current rating 12Amps.

Circuit ID NOB-SCHP-2.02, Voltage:415, Current rating 12Amps.

Circuit ID NOB-AHU-2.01, Voltage:415, Current rating 27Amps.

Circuit ID NOB-AHU-2.04, Voltage:415, Current rating 25Amps.

Main Breaker and ATS Input Breakers ASCO Automatic Transfer Switch (ATS)

Square-D switchgear, fed from ATS-1 Square-D switchgear, fed from ATS-2 (U – Side)

(E – Side)

Square-D, 6 Motor Control Centers MCCP Front Left view

Class 8998, Equipment Tag

NOB MCCP -01MCCP Front Right view

VFD units VFD units.

SECTION 2 - CONTRACT CLAUSES

FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERICAL ITEMS (MAY 2015), is incorporated by reference (see SF-1449, Block 27A)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial

Items.

As prescribed in 12.301(b)(4), insert the following clause:

CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS—COMMERCIAL

ITEMS (JUN 2016)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004)(Public Laws 108-77 and 108-78

(19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct

1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009

(June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and

Reinvestment Act of 2009.)

_X_ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2015)

(Pub. L. 109-282) (31 U.S.C. 6101 note).

__ (5) [Reserved].

_X_ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of

Div. C).

_X_ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014)

(Pub. L. 111-117, section 743 of Div. C).

_X_ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013)

(41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3.

__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT

2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2012_3.html#wp1084399 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1146366 https://www.acquisition.gov/sites/default/files/current/far/html/52_233_240.html#wp1113329 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+1665+30++%2831%29%20%20AND%20%28%2831%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_233_240.html#wp1113344 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137622 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1141983 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1144881 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1141649 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1151163 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1151299 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1140926 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1145644 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135955 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135955 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135970 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20

__ (ii) Alternate I (JAN 2011) of 52.219-4.

__ (13) [Reserved]

__ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644).

__ (ii) Alternate I (Nov 2011).

__ (iii) Alternate II (Nov 2011).

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

__ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Oct 2001) of 52.219-9.

__ (iii) Alternate II (Oct 2001) of 52.219-9.

__ (iv) Alternate III (Oct 2015) of 52.219-9.

__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

__ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15

U.S.C. 657 f).

__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged

Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business

Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

_X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X_ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Feb 2016) (E.O. 13126).

_X_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X_ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

_X_ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).

_X_ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

_X_ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

__ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010)

(E.O. 13496).

_X_ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O.

13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (34) 52.222-54, Employment Eligibility Verification (OCT 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items

(May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135970 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136004 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136017 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136017 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136017 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136032 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136174 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136175 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136186 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136387 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1139913 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1144950 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1144420 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147479 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147630 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147656 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147711 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1158632 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1162802 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+2+78++%2829%29%20%20AND%20%28%2829%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1148123 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1160019 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1151848 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1151848 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1156645 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2022_18.html#wp1089948 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168892 http://uscode.house.gov/

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons

(JUN 2016) (E.O. 13693).

__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air

Conditioners (JUN 2016) (E.O. 13693).

__ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and

13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b).

__ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s

13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

_X_ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011)

(E.O. 13513).

__ (43) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

__ (44) 52.223-21, Foams (JUN 2016) (E.O. 13693).

__ (45) 52.225-1, Buy American—Supplies (May 2014) (41 U.S.C. chapter 83).

__ (46)(i) 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act (May 2014) (41 U.S.C.

chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-

182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (47) 52.225-5, Trade Agreements (FEB 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

__ (48) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (49) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013)

(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302

Note).

__ (50) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (51) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42

U.S.C. 5150).

_X_ (52) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (53) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C.

2307(f)).

_X_ (54) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (Jul 2013)

(31 U.S.C. 3332).

https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168892 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168917 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168928 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168933 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168933 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1194330 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1194330 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1194323 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1179078 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1179078 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1188603 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1189174 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1197699 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1192900 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169151 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169608 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1192524 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t09t12+1445+65++%2810%20U.S.C.%202302%20Note%29%20%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t09t12+1445+65++%2810%20U.S.C.%202302%20Note%29%20%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1173773 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1173393 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153230 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153252 http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153351 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+1665+30++%2831%29%20%20AND%20%28%2831%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20

__ (55) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management

(Jul 2013) (31 U.S.C. 3332).

__ (56) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (57) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (58)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46

U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495).

__ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

__ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41

U.S.C. chapter 67).

__ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment

(Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards—Price Adjustment

(May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment—Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for

Certain Services—Requirements (May 2014) (41 U.S.C. chapter 67).

__ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C.

1792).

__ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records—Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller

General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153375 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+1665+30++%2831%29%20%20AND%20%28%2831%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153445 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_233_240.html#wp1113650 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t05t08+2+3++%285%29%20%20AND https://www.acquisition.gov/sites/default/files/current/far/html/52_247.html#wp1156217 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t45t48+351+1++%2846%29%20%20AND%20%28%2846%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t45t48+351+1++%2846%29%20%20AND%20%28%2846%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t09t12+37+408++%2810%29%20%252 https://www.acquisition.gov/sites/default/files/current/far/html/52_247.html#wp1156217 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147587 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1160021…