SF 18 - 70Z02924QNEWO0001 - ANT Colfax.pdf

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

THIS RFQ IS IS NOT A SMALL BUSINESS SET-ASIDE

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG. 1

RATING

5a. ISSUED BY 6. DELIVER BY (Date)

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

NAME TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANYa. NAME

c. STREET ADDRESS

d. CITY e. STATE f. ZIP CODE

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

c. CITY

d. STATE e. ZIP CODE

7. DELIVERY

FOB DESTINATION

OTHER

(See Schedule)

10. PLEASE FURNISH QUOTATIONS TO THE

ISSUING OFICE IN BLOCK 5a ON OR

BEFORE CLOSE OF BUSINESS (Date)

IMPORTANT: This is a request for information and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or service. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotation must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS

b. 20 CALENDAR DAYS

c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations are are not attached.

13. NAME AND ADDRESS OF QUOTER

a. NAME OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

b. TELEPHONE

AREA CODE

NUMBER

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA-FAR (48 CFR) 53.215-1(a)

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

504-253-4507

The United States Coast Guard is accepting quotes for qualified individuals or firms to repair a Case forklift (model 585E) for USCG ANT Colfax in Colfax, LA. Prior to submitting a quote, it is mandatory to examine the Performance Work Statement to become familiar with the required work. And it is recommended to visit the site to make evaluations, etc., and become familiar with existing conditions under which the work will be performed.

All work shall take place at:

USCG ANT Colfax 350 Control House Road Colfax, LA 71417

All work is to be completed in accordance with the performance work statement.

This will be a firm-fixed priced purchase order awarded to the lowest bidder.

This is set aside 100% for small business.

All contractors must be actively registered in SAM.gov.

Submit quotes to Joel.S.Ivy@uscg.mil.

Please submit quotes by 1:00pm CT 11/20/2023

Email; Joel.S.Ivy@uscg.mil.

70Z02924QNEWO0001

TABLE OF CONTENTS:

1. Listing of Incorporated Purchase Requisitions

2. Section B - Supplies or Services and Prices/Costs

3. Section C - Description/Specifications/Work Statement

4. Section D - Packaging and Marking

5. Section E - Inspection and Acceptance Terms

6. Section F - Delivery or Performance

7. Section G - Contract Administration Data

8. Section H - Special Contract Requirements

9. Section I - Contract Clauses

10. Section J - List of Documents, Exhibits, and other Attachments

11. Section K - Representations, Certifications, and Other Statements of Offerors

12. Section L - Instructions, Conditions and Notices to Offerors

13. Section M - Evaluation Factors for Award

1. Listing of Incorporated Purchase Requisitions

Incorporated Purchase Requisition Numbers:

37190PR240000001

2. Section B - Supplies or Services and Prices/Costs

Item Number Base Item Number

Supplies/Services Quantity Unit

0001 Forklift Repair for ANT Colfax 1 EA Contract Type:Firm Fixed Price

Unit Price Extended Price

Description:

Purchase Requisitions 37190PR240000001

IDC Type: Not Applicable

Clauses incorporated by reference

None

Clauses incorporated by full text

None

3. Section C - Description/Specifications/Work Statement

Clauses incorporated by reference

None

Clauses incorporated by full text

None

4. Section D - Packaging and Marking

None

Clauses incorporated by reference

Clauses incorporated by full text

5. Section E - Inspection and Acceptance Terms

Article Number Reference Text

52.246-2 52.246-2 INSPECTION OF SUPPLIES-FIXED-PRICE (AUG 1996)

52.246-4 52.246-4 INSPECTION OF SERVICES-FIXED-PRICE (AUG 1996)

52.246-15 52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984)

52.246-16 52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below.

Title Number Date Tailoring

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in-

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require-

(i) Control of such things as design, work operations, in-process control, testing, and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

6. Section F - Delivery or Performance

52.242-15 52.242-15 STOP-WORK ORDER (AUG 1989)

52.242-17 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

Clauses incorporated by full text

52.211-8 TIME OF DELIVERY (JUNE 1997)

(a) The Government requires delivery to be made according to the following schedule:

Required Delivery Schedule

Item No. Quantity Within Days After Date of Contract

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

Offeror's Proposed Delivery Schedule

Item No. Quantity Within Days After Date of Contract

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding

(1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S.

Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY (JUNE 1997)

(a) The Government desires delivery to be made according to the following schedule:

Desired Delivery Schedule

Item No. Quantity Within Days After Date of Contract

If the offeror is unable to meet the desired delivery schedule, it may, without prejudicing evaluation of its offer, propose a delivery schedule below. However, the offeror's proposed delivery schedule must not extend the delivery period beyond the time for delivery in the Government's required delivery schedule as follows:

Required Delivery Schedule

Item No. Quantity Within Days After Date of Contract

Offers that propose delivery of a quantity under such terms or conditions that delivery will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. If the offeror proposes no other delivery schedule, the desired delivery schedule above will apply.

Offeror's Proposed Delivery Schedule

Item No. Quantity Within Days After Date of Contract

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful offeror results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day the award is dated. Therefore, the offeror shall compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding

(1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S.

Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

52.211-16 VARIATION IN QUANTITY (APR 1984)

(a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b) of this clause.

(b) The permissible variation shall be limited to:

_________ Percent increase

_________ Percent decrease

This increase or decrease shall apply to _________.*

(End of clause)

7. Section G - Contract Administration Data

Requesting Office Address 41969 ANT COLFAX - Resource Management & Logistics

ANT COLFAX USCG

300 CONTROL HOUSE RD

COLFAX LA 71417-0000

Phone: 731/315-9701 Fax:

Contact Details:

BUTKEY, WILLIAM J.

William.J.Butkey@uscg.mil

Issuing Office Address 70Z029 Regional Support Team (RST-08) New Orleans Base New Orleans 1790 Saturn Street New Orleans LA 70129 Phone: Fax:

Contact Details:

IVY, Mr. JOEL S joel.s.ivy@uscg.mil

Clauses incorporated by reference

None

Clauses incorporated by full text

8. Section H - Special Contract Requirements

52.234-4 -EARNED VALUE MANAGEMENT SYSTEM (NOV 2016)

(a) The Contractor shall use an earned value management system (EVMS) that has been determined by the Cognizant

Federal Agency (CFA) to be compliant with the guidelines in Electronic Industries Alliance Standard 748 (EIA-748) (current version at the time of award) to manage this contract. If the Contractor's current EVMS has not been determined compliant at the time of award, see paragraph (b) of this clause. The Contractor shall submit reports in accordance with the requirements of this contract.

(b) If, at the time of award, the Contractor's EVM System has not been determined by the CFA as complying with EVMS guidelines or the Contractor does not have an existing cost/schedule control system that is compliant with the guidelines in EIA- 748 (current version at time of award), the Contractor shall-

(1) Apply the current system to the contract; and

(2) Take necessary actions to meet the milestones in the Contractor's EVMS plan approved by the Contracting Officer.

(c) The Government will conduct an Integrated Baseline Review (IBR). If a pre-award IBR has not been conducted, a post award IBR shall be conducted as early as practicable after contract award.

(d) The Contracting Officer may require an IBR at-

(1) Exercise of significant options; or

(2) Incorporation of major modifications.

(e) Unless a waiver is granted by the CFA, Contractor proposed EVMS changes require approval of the CFA prior to implementation. The CFA will advise the Contractor of the acceptability of such changes within 30 calendar days after receipt of the notice of proposed changes from the Contractor. If the advance approval requirements are waived by the CFA, the Contractor shall disclose EVMS changes to the CFA at least 14 calendar days prior to the effective date of implementation.

(f) The Contractor shall provide access to all pertinent records and data requested by the Contracting Officer or a an authorized representative as necessary to permit Government surveillance to ensure that the EVMS conforms, and continues to conform, with the performance criteria referenced in paragraph (a) of this clause.

(g) The Contractor shall require the subcontractors specified below to comply with the requirements of this clause:

9. Section I - Contract Clauses

52.202-1 52.202-1 DEFINITIONS (JUN 2020)

52.203-3 52.203-3 GRATUITIES (APR 1984)

52.203-5 52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN

2020)

52.203-7 52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (MAY 2014)

52.203-10 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (JUN 2020)

52.203-13 52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (NOV 2021)

52.203-14 52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-15 52.203-15 WHISTLEBLOWER PROTECTIONS UNDER THE AMERICAN RECOVERY AND

REINVESTMENT ACT OF 2009 (JUNE 2010)

52.203-16 52.203-16 PREVENTING PERSONAL CONFLICTS OF INTEREST (JUN 2020)

52.203-17 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT

TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (JUN 2020)

52.203-19 52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY

AGREEMENTS OR STATEMENTS (JAN 2017)

52.204-2 52.204-2 SECURITY REQUIREMENTS (MAR 2021)

52.204-4 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper.

52.204-9 52.204-9 Personal Identity Verification of Contractor Personnel.

52.204-10 52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (JUN 2020)

52.204-12 52.204-12 UNIQUE ENTITY IDENTIFIER MAINTENANCE (OCT 2016)

52.204-13 52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-14 52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016)

52.204-15 52.204-15 SERVICE CONTRACT REPORTING REQUIREMENTS FOR INDEFINITE-

DELIVERY CONTRACTS (OCT 2016)

52.204-18 52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS (DEC 2014)

52.204-23 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND

SERVICES DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED

ENTITIES (NOV 2021)

52.204-25 52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS

AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

52.204-27 52.204-27 Prohibition on a ByteDance Covered Application

52.207-3 52.207-3 RIGHT OF FIRST REFUSAL OF EMPLOYMENT (MAY 2006)

52.207-5 52.207-5 OPTION TO PURCHASE EQUIPMENT (FEB 1995)

52.208-9 52.208-9 CONTRACTOR USE OF MANDATORY SOURCES OF SUPPLY OR SERVICES

(MAY 2014)

52.209-6 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING

WITH CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT

(NOV 2021)

52.209-9 52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING

RESPONSIBILITY MATTERS (OCT 2018)

52.209-10 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (NOV 2015)

52.209-14 52.209-14 RESERVE OFFICER TRAINING CORPS AND MILITARY RECRUITING ON

CAMPUS (NOV 2021)

52.210-1 52.210-1 MARKET RESEARCH (NOV 2021)

52.211-15 52.211-15 DEFENSE PRIORITY AND ALLOCATION REQUIREMENTS (APR 2008)

52.212-4 52.212-4 Contract Terms and Conditions—Commercial Products and Commercial Services (Dec 2022)

52.212-5 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Products and Commercial Services.

52.213-4 52.213-4 Terms and Conditions—Simplified Acquisitions (Other Than Commercial Products and Commercial Services).

52.214-26 52.214-26 AUDIT AND RECORDS-SEALED BIDDING (JUN 2020)

52.214-27 52.214-27 PRICE REDUCTION FOR DEFECTIVE COST OR PRICING DATA-

MODIFICATIONS-SEALED BIDDING (JUN 2020)

52.214-28 52.214-28 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA-MODIFICATIONS-

SEALED BIDDING (JUN 2020)

52.214-29 52.214-29 ORDER OF PRECEDENCE-SEALED BIDDING (JAN 1986)

52.215-2 52.215-2 AUDIT AND RECORDS-NEGOTIATION (JUN 2020)

52.215-8 52.215-8 ORDER OF PRECEDENCE-UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-9 52.215-9 CHANGES OR ADDITIONS TO MAKE-OR-BUY PROGRAM (OCT 1997)

52.215-10 52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA

(AUG 2011)

52.215-11 52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA-

MODIFICATIONS (JUN 2020)

52.215-12 52.215-12 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA (JUN 2020)

52.215-13 52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA-MODIFICATIONS

(JUN 2020)

52.215-14 52.215-14 INTEGRITY OF UNIT PRICES (NOV 2021)

52.215-15 52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

52.215-17 52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

52.215-18 52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS

(PRB) OTHER THAN PENSIONS (JULY 2005)

52.215-19 52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.215-21 52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA

OTHER THAN CERTIFIED COST OR PRICING DATA-MODIFICATIONS (NOV 2021)

52.215-23 52.215-23 LIMITATIONS ON PASS-THROUGH CHARGES (JUN 2020)

52.216-4 52.216-4 ECONOMIC PRICE ADJUSTMENT-LABOR AND MATERIAL (JAN 2017)

52.216-5 52.216-5 PRICE REDETERMINATION-PROSPECTIVE (JAN 2022)

52.216-6 52.216-6 PRICE REDETERMINATION-RETROACTIVE (JAN 2022)

52.217-2 52.217-2 CANCELLATION UNDER MULTI-YEAR CONTRACTS (OCT 1997)

52.219-3 52.219-3 NOTICE OF HUBZONE SET-ASIDE OR SOLE-SOURCE AWARD (OCT 2022)

52.219-4 52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL

BUSINESS CONCERNS (OCT 2022)

52.219-6 52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (NOV 2020)

52.219-7 52.219-7 NOTICE OF PARTIAL SMALL BUSINESS SET-ASIDE (NOV 2020)

52.219-8 52.219-8 Utilization of Small Business Concerns.

52.219-9 52.219-9 Small Business Subcontracting Plan.

52.219-14 52.219-14 Limitations on Subcontracting (OCT 2022)

52.219-16 52.219-16 LIQUIDATED DAMAGES-SUBCONTRACTING PLAN (SEP 2021)

52.219-27 2.219-27 NOTICE OF SERVICE-DISABLED VETERAN-OWNED SMALL BUSINESS SET-

ASIDE (OCT 2022)

52.219-28 52.219-28 Post-Award Small Business Program Rerepresentation.

52.219-29 52.219-29 NOTICE OF SET-ASIDE FOR, OR SOLE-SOURCE AWARD TO,

ECONOMICALLY DISADVANTAGED WOMEN-OWNED SMALL BUSINESS CONCERNS

(OCT 2022)

52.219-30 52.219-30 NOTICE OF SET-ASIDE FOR, OR SOLE-SOURCE AWARD TO, WOMEN-

OWNED SMALL BUSINESS CONCERNS ELIGIBLE UNDER THE WOMEN-OWNED SMALL

BUSINESS PROGRAM (OCT 2022)

52.222-1 52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)

52.222-3 52.222-3 CONVICT LABOR (JUNE 2003)

52.222-4 52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME

COMPENSATION (MAY 2018)

52.222-21 52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

52.222-26 52.222-26 EQUAL OPPORTUNITY (SEP 2016)

52.222-29 52.222-29 NOTIFICATION OF VISA DENIAL (APR 2015)

52.222-37 52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

52.222-40 52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR

RELATIONS ACT (DEC 2010)

52.222-41 52.222-41 SERVICE CONTRACT LABOR STANDARDS (AUG 2018)

52.222-43 52.222-43 FAIR LABOR STANDARDS ACT AND SERVICE CONTRACT LABOR

STANDARDS-PRICE ADJUSTMENT (MULTIPLE YEAR AND OPTION CONTRACTS) (AUG

2018)

52.222-44 52.222-44 FAIR LABOR STANDARDS ACT AND SERVICE CONTRACT LABOR

STANDARDS-PRICE ADJUSTMENT (MAY 2014)

52.222-50 52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.222-51 52.222-51 EXEMPTION FROM APPLICATION OF THE SERVICE CONTRACT LABOR

STANDARDS TO CONTRACTS FOR MAINTENANCE, CALIBRATION, OR REPAIR OF

CERTAIN EQUIPMENT-REQUIREMENTS MAY 2014)

52.222-53 52.222-53 EXEMPTION FROM APPLICATION OF THE SERVICE CONTRACT LABOR

STANDARDS TO CONTRACTS FOR CERTAIN SERVICES-REQUIREMENTS (MAY 2014)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (MAY 2022)

52.222-55 52.222-55 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE

ORDER 14026 (JAN 2022)

52.223-2 52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE

AND CONSTRUCTION CONTRACTS (SEP 2013)

52.223-3 52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (FEB 2021)

52.223-5 52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2011)

52.223-6 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.223-10 52.223-10 WASTE REDUCTION PROGRAM (MAY 2011)

52.223-12 52.223-12 MAINTENANCE, SERVICE, REPAIR, OR DISPOSAL OF REFRIGERATION

EQUIPMENT (JUN 2016)

52.223-13 52.223-13 ACQUISITION OF EPEAT-REGISTERED IMAGING EQUIPMENT (JUN 2014)

52.223-14 52.223-14 ACQUISITION OF EPEAT-REGISTERED TELEVISIONS (JUN 2014)

52.223-15 52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (MAY 2020)

52.223-16 52.223-16 Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015)

52.223-17 52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE

AND CONSTRUCTION CONTRACTS (AUG 2018)

52.223-18 52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE

DRIVING (JUN 2020)

52.223-19 52.223-19 COMPLIANCE WITH ENVIRONMENTAL MANAGEMENT SYSTEMS (MAY 2011)

52.224-1 52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 52.224-2 PRIVACY ACT (APR 1984)

52.224-3 52.224-3 PRIVACY TRAINING (JAN 2017)

52.225-1 52.225-1 Buy American-Supplies (OCT 2022)

52.225-3 52.225-3 Buy American-Free Trade Agreements-Israeli Trade Act (Dec 2022)

52.225-13 52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.225-14 52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION OF

CONTRACT (FEB 2000)

52.225-19 52.225-19 CONTRACTOR PERSONNEL IN A DESIGNATED

OPERATIONAL AREA OR SUPPORTING A DIPLOMATIC OR CONSULAR MISSION

OUTSIDE THE UNITED STATES (MAY 2020)

52.225-26 52.225-26 CONTRACTORS PERFORMING PRIVATE SECURITY FUNCTIONS OUTSIDE

THE UNITED STATES (OCT 2016)

52.226-1 52.226-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN-OWNED ECONOMIC

ENTERPRISES (JUNE 2000)

52.226-5 52.226-5 RESTRICTIONS ON SUBCONTRACTING OUTSIDE DISASTER OR EMERGENCY

AREA (NOV 2007)

52.226-6 52.226-6 PROMOTING EXCESS FOOD DONATION TO NONPROFIT ORGANIZATIONS

(JUN 2020)

52.227-1 52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-3 52.227-3 PATENT INDEMNITY (APR 1984)

52.227-9 52.227-9 REFUND OF ROYALTIES (APR 1984)

52.227-10 52.227-10 FILING OF PATENT APPLICATIONS-CLASSIFIED SUBJECT MATTER (DEC

2007)

52.227-14 52.227-14 RIGHTS IN DATA-GENERAL (MAY 2014)

52.227-17 52.227-17 RIGHTS IN DATA-SPECIAL WORKS (DEC 2007)

52.227-18 52.227-18 RIGHTS IN DATA-EXISTING WORKS (DEC 2007)

52.227-19 52.227-19 COMMERCIAL COMPUTER SOFTWARE LICENSE (DEC 2007)

52.227-21 52.227-21 TECHNICAL DATA DECLARATION, REVISION, AND WITHHOLDING OF

PAYMENT-MAJOR SYSTEMS (MAY 2014)

52.228-2 52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-3 52.228-3 WORKERS' COMPENSATION INSURANCE (DEFENSE BASE ACT) (JULY 2014)

52.228-4 52.228-4 WORKERS' COMPENSATION AND WAR-HAZARD INSURANCE OVERSEAS

(APR 1984)

52.228-5 52.228-5 INSURANCE-WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 52.228-11 INDIVIDUAL SURETY-PLEDGE OF ASSETS (FEB 2021)

52.228-14 52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.229-3 52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.229-4 52.229-4 FEDERAL, STATE, AND LOCAL TAXES (STATE AND LOCAL ADJUSTMENTS)

(FEB 2013)

52.229-6 52.229-6 TAXES-FOREIGN FIXED-PRICE CONTRACTS (FEB 2013)

52.229-11 52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS - NOTICE AND

REPRESENTATION (JUN 2020)

52.229-12 52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

52.229-13 52.229-13 TAXES—FOREIGN CONTRACTS IN AFGHANISTAN (NOV 2021)

52.229-14 52.229-14 TAXES—FOREIGN CONTRACTS IN AFGHANISTAN (NORTH ATLANTIC

TREATY ORGANIZATION STATUS OF FORCES AGREEMENT) (NOV 2021)

52.230-2 52.230-2 COST ACCOUNTING STANDARDS (JUN 2020)

52.230-3 52.230-3 DISCLOSURE AND CONSISTENCY OF COST ACCOUNTING PRACTICES (JUN

2020)

52.230-4 52.230-4 DISCLOSURE AND CONSISTENCY OF COST ACCOUNTING PRACTICES-

FOREIGN CONCERNS (JUN 2020)

52.230-5 52.230-5 COST ACCOUNTING STANDARDS-EDUCATIONAL INSTITUTION (JUN 2020)

52.230-6 52.230-6 ADMINISTRATION OF COST ACCOUNTING STANDARDS (JUNE 2010)

52.232-1 52.232-1 PAYMENTS (APR 1984)

52.232-3 52.232-3 PAYMENTS UNDER PERSONAL SERVICES CONTRACTS (APR 1984)

52.232-8 52.232-8 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

52.232-9 52.232-9 LIMITATION ON WITHHOLDING OF PAYMENTS (APR 1984)

52.232-11 52.232-11 EXTRAS (APR 1984)

52.232-16 52.232-16 PROGRESS PAYMENTS (NOV 2021)

52.232-17 52.232-17 INTEREST (MAY 2014)

52.232-18 52.232-18 AVAILABILITY OF FUNDS (APR 1984)

52.232-23 52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-24 52.232-24 PROHIBITION OF ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-25 52.232-25 PROMPT PAYMENT (JAN 2017)

52.232-30 52.232-30 INSTALLMENT PAYMENTS FOR COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (NOV 2021)

52.232-33 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER-SYSTEM FOR AWARD

MANAGEMENT (OCT 2018)

52.232-36 52.232-36 PAYMENT BY THIRD PARTY (MAY 2014)

52.232-37 52.232-37 MULTIPLE PAYMENT ARRANGEMENTS (MAY 1999)

52.232-39 52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS

(NOV 2021)

52.233-1 52.233-1 DISPUTES (MAY 2014)

52.233-3 52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.237-2 52.237-2 PROTECTION OF GOVERNMENT BUILDINGS, EQUIPMENT, AND VEGETATION

(APR 1984)

52.237-3 52.237-3 CONTINUITY OF SERVICES (JAN 1991)

52.239-1 52.239-1 PRIVACY OR SECURITY SAFEGUARDS (AUG 1996)

52.242-1 52.242-1 NOTICE OF INTENT TO DISALLOW COSTS (APR 1984)

52.242-2 52.242-2 PRODUCTION PROGRESS REPORTS (APR 1991)

52.242-5 52.242-5 PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (JAN 2017)

52.242-13 52.242-13 BANKRUPTCY (JULY 1995)

52.244-5 52.244-5 COMPETITION IN SUBCONTRACTING (DEC 1996)

52.244-6 52.244-6 Subcontracts for Commercial Products and Commercial Services.

52.245-1 52.245-1 GOVERNMENT PROPERTY (SEP 2021)

52.245-9 52.245-9 USE AND CHARGES (APR 2012)

52.246-25 52.246-25 LIMITATION OF LIABILITY--SERVICES (FEB 1997)

52.246-26 52.246-26 REPORTING NONCONFORMING ITEMS (NOV 2021)

52.247-63 52.247-63 PREFERENCE FOR U.S.-FLAG AIR CARRIERS (JUN 2003)

52.247-64 52.247-64 PREFERENCE FOR PRIVATELY OWNED U.S.-FLAG COMMERCIAL VESSELS

(NOV 2021)

52.247-68 52.247-68 REPORT OF SHIPMENT (REPSHIP) (FEB 2006)

52.248-1 52.248-1 VALUE ENGINEERING (JUN 2020)

52.249-1 52.249-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE)

(SHORT FORM) (APR 1984)

52.249-2 52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE)

(APR 2012)

52.249-4 52.249-4 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (SERVICES)

(SHORT FORM) (APR 1984)

52.249-8 52.249-8 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (APR 1984)

52.249-12 52.249-12 TERMINATION (PERSONAL SERVICES) (APR 1984)

52.250-1 52.250-1 INDEMNIFICATION UNDER PUBLIC LAW 85-804 (APR 1984)

52.250-5 52.250-5 SAFETY ACT-EQUITABLE ADJUSTMENT (FEB 2009)

52.251-1 52.251-1 GOVERNMENT SUPPLY SOURCES (APR 2012)

52.253-1 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of _________ and shall not be binding until so approved.

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV

2021)

(a) Definitions. As used in this clause—

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information ( 44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial products or commercial services, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

52.209-1 QUALIFICATION REQUIREMENTS (FEB 1995)

(a) Definition. "Qualification requirement," as used in this clause, means a Government requirement for testing or other quality assurance demonstration that must be completed before award.

(b) One or more qualification requirements apply to the supplies or services covered by this contract. For those supplies or services requiring qualification, whether the covered product or service is an end item under this contract or simply a component of an end item, the product, manufacturer, or source must have demonstrated that it meets the standards prescribed for qualification before award of this contract. The product, manufacturer, or source must be qualified at the time of award whether or not the name of the product, manufacturer, or source is actually included on a qualified products list, qualified manufacturers list, or qualified bidders list. Offerors should contact the agency activity designated below to obtain all requirements that they or their products or services, or their subcontractors or their products or services, must satisfy to become qualified and to arrange for an opportunity to demonstrate their abilities to meet the standards specified for qualification.

(Name) _________

(Address) _________

(c) If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the relevant information noted below should be provided.

Offeror's Name _____________________________________

Manufacturer's Name______ __________________________

Source's Name _____________________________________

Item Name ________________________________________

Service Identification ________________________________

Test Number _______________________________________(to the extent known)

(d) Even though a product or service subject to a qualification requirement is not itself an end item under this contract, the product, manufacturer, or source must nevertheless be qualified at the time of award of this contract. This is necessary whether the Contractor or a subcontractor will ultimately provide the product or service in question. If, after award, the Contracting Officer discovers that an applicable qualification requirement was not in fact met at the time of award, the Contracting Officer may either terminate this contract for default or allow performance to continue if adequate consideration is offered and the action is determined to be otherwise in the Government's best interests.

(e) If an offeror, manufacturer, source, product or service has met the qualification requirement but is not yet on a qualified products list, qualified manufacturers list, or qualified bidders list, the offeror must submit evidence of qualification prior to award of this contract. Unless determined to be in the Government's interest, award of this contract shall not be delayed to permit an offeror to submit evidence of qualification.

(f) Any change in location or ownership of the plant where a previously qualified product or service was manufactured or performed requires reevaluation of the qualification. Similarly, any change in location or ownership of a previously qualified manufacturer or source requires reevaluation of the qualification. The reevaluation must be accomplished before the date of award.

52.211-11 LIQUIDATED DAMAGES-SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT

(SEPT 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $_________ per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

52.216-16 INCENTIVE PRICE REVISION-FIRM TARGET (JAN 2022)

(a) General. The supplies or services identified in the Schedule as Items _______ [Contracting Officer insert Schedule line item numbers] are subject to price revision in accordance with this clause; provided, that in no event shall the total final price of these items exceed the ceiling price of ________ dollars ($_____). Any supplies or services that are to be (1) ordered separately under, or otherwise added to, this contract and (2) subject to price revision in accordance with the terms of this clause shall be identified as such in a modification to this contract .

(b) Definition . "Costs," as used in this clause, means allowable costs in accordance with part 31 of the Federal Acquisition Regulation (FAR) in effect on the date of this contract .

(c) Data submission.

(1) Within __________________ [Contracting Officer insert number of days] days after the end of the month in which the Contractor has delivered the last unit of supplies and completed the services specified by item number in paragraph (a) of this clause, the Contractor shall submit in the format of Table 15-2, FAR 15.408, or in any other form on which the parties agree-

(i) A detailed statement of all costs incurred up to the end of that month in performing all work under the items;

(ii) An estimate of costs of further performance, if any, that may be necessary to complete performance of all work under the items;

(iii) A list of all residual inventory and an estimate of its value; and

(iv) Any other relevant data that the Contracting Officer may reasonably require.

(2) If the Contractor fails to submit the data required by paragraph (c)(1) of this clause within the time specified and it is later determined that the Government has overpaid the Contractor , the Contractor shall repay the excess to the Government immediately. Unless repaid within 30 days after the end of the data submittal period, the amount of the excess shall bear interest, computed from the date the data were due to the date of repayment, at the rate established in accordance with the Interest clause.

(d) Price revision. Upon the Contracting Officer 's receipt of the data required by paragraph (c) of this clause, the Contracting Officer and the Contractor shall promptly establish the total final price of the items specified in (a) of this clause by applying to final negotiated cost an adjustment for profit or loss, as follows:

(1) On the basis of the information required by paragraph (c) of this clause, together with any other pertinent information , the parties shall negotiate the total final cost incurred or to be incurred for supplies delivered (or services performed) and accepted by the Government and which are subject to price revision under this clause.

(2) The total final price shall be established by applying to the total final negotiated cost an adjustment for profit or loss, as follows:

(i) If the total final negotiated cost is equal to the total target cost, the adjustment is the total target profit.

(ii) If the total final negotiated cost is greater than the total target cost, the adjustment is the total target profit, less ______ [Contracting Officer insert percent] percent of the amount by which the total final negotiated cost exceeds the total target cost.

(iii) If the final negotiated cost is less than the total target cost, the adjustment is the total target profit plus _____ [ Contracting Officer insert percent] percent of the amount by which the total final negotiated cost is less than the total target cost.

(e) Contract modification . The total final price of the items specified in paragraph (a) of this clause shall be evidenced by a modification to this contract , signed by the Contractor and the Contracting Officer . This price shall not be subject to revision, notwithstanding any changes in the cost of performing the contract , except to the extent that-

(1) The parties may agree in writing , before the determination of total final price, to exclude specific elements of cost from this price and to a procedure for subsequent disposition of those elements; and

(2) Adjustments or credits are explicitly permitted or required by this or any other clause in this contract .

(f) Adjusting billing prices.

(1) Pending execution of the contract modification (see paragraph (e) of this clause), the Contractor shall submit invoices or vouchers in accordance with billing prices as provided in this paragraph. The billing prices shall be the target prices shown in this contract .

(2) If at any time it appears from information provided by the contractor under paragraph (g)(2) of this clause that the then-current billing prices will be substantially greater than the estimated final prices, the parties shall negotiate a reduction in the billing prices. Similarly, the parties may negotiate an increase in billing prices by any or all of the difference between the target prices and the ceiling price, upon the Contractor 's submission of factual data showing that final cost under this contract will be substantially greater than the target cost.

(3) Any billing price adjustment shall be reflected in a contract modification and shall not affect the determination of the total final price under paragraph (d) of this clause. After the contract modification establishing the total final price is executed, the total amount paid or to be paid on all invoices or vouchers shall be adjusted to reflect the total final price, and any resulting additional payments, refunds, or credits shall be made promptly.

(g) Quarterly limitation on payments statement. This paragraph (g) shall apply until final price revision under this contract has been completed.

(1) Within 45 days after the end of each quarter of the Contractor 's fiscal year in which a delivery is first made (or services are first performed) and accepted by the Government under this contract , and for each quarter thereafter, the Contractor shall submit to the contract administration office (with a copy to the contracting office and the cognizant contract auditor) a statement, cumulative from the beginning of the contract , showing-

(i) The total contract price of all supplies delivered (or services performed) and accepted by the Government and for which final prices have been established;

(ii) The total costs (estimated to the extent necessary) reasonably incurred for, and properly allocable solely to, the supplies delivered (or services performed) and accepted by the Government and for which final prices have not been established;

(iii) The portion of the total target profit (used in establishing the initial contract price or agreed to for the purpose of this paragraph (g)) that is in direct proportion to the supplies delivered (or services performed) and accepted by the Government and for which final prices have not been established-increased or decreased in accordance with paragraph (d)(2) of this clause, when the amount stated under subdivision (g)(1)(ii) of this clause differs from the aggregate target costs of the supplies or services; and

(iv) The total amount of all invoices or vouchers for supplies delivered (or services performed) and accepted by the Government (including amounts applied or to be applied to liquidate progress payments).

(2) Notwithstanding any provision of this contract authorizing greater payments, if on any quarterly statement the amount under subdivision (g)(1)(iv) of this clause exceeds the sum due the Contractor , as computed in accordance with subdivisions (g)(1)(i), (ii), and (iii) of this clause, the Contractor shall immediately refund or credit to the Government the amount of this excess. The Contractor may , when appropriate, reduce this refund or credit by the amount of previous refunds or credits effected under this clause. If any portion of the excess has been applied to the liquidation of progress payments, then that portion may , instead of being refunded, be added to the unliquidated progress payment account consistent with the Progress Payments clause. The Contractor shall provide complete details to support any claimed reductions in refunds.

(3) If the Contractor fails to submit the quarterly statement within 45 days after the end of each quarter and it is later determined that the Government has overpaid the Contractor , the Contractor shall repay the excess to the Government immediately. Unless repaid within 30 days after the end of the statement submittal period, the amount of the excess shall bear interest, computed from the date the quarterly statement was due to the date of repayment, at the rate established in accordance with the Interest clause.

(h) Subcontracts. No subcontract placed under this contract may provide for payment on a cost-plus-a-percentage-of-cost basis.

(i) Disagreements. If the Contractor and the Contracting Officer fail to agree upon the total final price within 60 days (or within such other period as the Contracting Officer may specify) after the date on which the data required by paragraph (c) of this clause are to be submitted, the Contracting Officer shall promptly issue a decision in accordance with the Disputes clause.

(j) Termination. If this contract is terminated before the total final price is established, prices of supplies or services subject to price revision shall be established in accordance with this clause for (1) completed supplies and services accepted by the Government and (2) those supplies and services not terminated under a partial termination . All other elements of the termination shall be resolved in accordance with other applicable clauses of this contract .

(k) Equitable adjustment under other clauses. If an equitable adjustment in the contract price is made under any other clause of this contract before the total final price is established, the adjustment shall be made in the total target cost and may be made in the maximum dollar limit on the total final price, the total target profit, or both. If the adjustment is made after the total final price is established, only the total final price shall be adjusted.

(l) Exclusion from target price and total final price. If any clause of this contract provides that the contract price does not or will not include an amount for a specific purpose, then neither any target price nor the total final price includes or will include any amount for that purpose.

(m) Separate reimbursement. If any clause of this contract expressly provides that the cost of performance of an obligation shall be at Government expense, that expense shall not be included in any target price or in the total final price, but shall be reimbursed separately.

(n) Taxes. As used in the Federal, State , and Local Taxes clause or in any other clause that provides for certain taxes or duties to be included in, or excluded from, the contract price, the term "contract price" includes the total target price or, if it has been established, the total final price. When any of these clauses requires that the contract price be increased or decreased as a result of changes in the obligation of the Contractor to pay or bear the burden of certain taxes or duties, the increase or decrease shall be made in the total target price or, if it has been established, in the total final price, so that it will not affect the Contractor 's profit or loss on this contract .

52.216-17 INCENTIVE PRICE REVISION-SUCCESSIVE TARGETS (JAN 2022)

(a) General. The supplies or services identified in the Schedule as Items _________ [Contracting Officer insert line item numbers] are subject to price revision in accordance with this clause; provided, that in no event shall the total final price of these items exceed the ceiling price of dollars ($__________________). The prices of these items shown in the Schedule are the initial target prices, which include an initial target profit of ___________ [Contracting Officer insert percent] percent of the initial target cost. Any supplies or services that are to be-

(1) Ordered separately under, or otherwise added to, this contract ; and

(2) Subject to price revision in accordance with this clause shall be identified as such in a modification to this contract .

(b) Definition . "Costs," as used in this clause, means allowable costs in accordance with part 31 of the Federal Acquisition Regulation (FAR) in effect on the date of this contract .

(c) Submitting data for establishing the firm fixed price or a final profit adjustment formula.

(1) Within ___________ [Contracting Officer insert number of days] days after the end of the month in which the Contractor has completed ___________ (see Note 1), the Contractor shall submit the following data :

(i) A proposed firm fixed price or total firm target price for supplies delivered and to be delivered and services performed and to be performed.

(ii) A detailed statement of all costs incurred in the performance of this contract through the end of the month specified above, in the format of Table 15-2, FAR 15.408 (or in any other form on which the parties may agree), with sufficient supporting data to disclose unit costs and cost trends for-

(A) Supplies delivered and services performed; and

(B) Inventories of work in process and undelivered contract supplies on hand (estimated to the extent necessary).

(iii) An estimate of costs of all supplies delivered and to be delivered and all services performed and to be performed under this contract , using the statement of costs incurred plus an estimate of costs to complete performance, in the format of Table 15-2, FAR 15.408 (or in any other form on which the parties may agree), together with-

(A)…