Section 01000 _ GENERAL REQUIRMENTS _ W50S8420B0001.pdf

Section 010000 Division 01 – General Requirements

**Where direct discrepancies arise, the General Requirements below take precedence over Specifications in Mead and Hunt’s Project Manual/Specs Dated 31 Mar 2020.

**Attempt has been made to NOT duplicate General Requirements, please review both.

1. INSURANCE - MINIMUM AMOUNTS

1.1. Reference Contract Clause titled, “Insurance -Work on a Government Installation (FAR 52.228-5). Kinds and minimum amounts are as follows:

KIND AMOUNTS

Workmen’s Compensation $100,000 (see paragraph 1.2, below)

Comprehensive General Liability $500,000 per occurrence for bodily injury

Comprehensive Automobile Liability $200,000 per person and $500,000 per accident for bodily injury and $20,000 for property damage

(If applicable) $200,000 per person and $500,000 per occurrence Aircraft Public and Passenger for bodily injury, other than passenger Liability liability and $200,000 per occurrence for property damage; coverage for passenger liability bodily injury shall be at least

$200,000 multiplied by the number of seats $200,000 multiplied by the number of seats or passengers, whichever is greater

1.2. Except in states with exclusive or monopolistic funds that do not permit workers’ compensation to be written by private carriers.

1.3. NOTE: Before commencing work under this contract, the Contractor shall certify to the Contracting

Officer, in writing, that the required insurance has been obtained. The policies referenced in the certification (s) shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government’s interest shall not be effective (1) for such period as the laws of the state in which this contract is to be performed prescribe or (2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer. The Contractor shall maintain a copy of proofs of required insurance, and shall make copies available to the Contracting Officer upon request. The Contractor shall maintain a copy of all subcontractors’ proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

2. Reserved.

3. SCHEDULING

See Mead and Hunt Specifications.

4. INVOICING AND PAYMENT

4.1. Properly prepared invoices, bearing the contract number, shall be emailed to the Contracting Officer and Contract Specialist, on designated invoice forms provided at the pre-construction meeting PRIOR to uploading in Wide Area Workflow (WAWF) the DFAS paying system. This submission will be for review prior to submitting an electronic invoice through Wide Area Workflow (WAWF). See end of this Section for important information and codes needed.). Payment will be made by in accordance with FAR Clause 52.232-5 Fixed-Price Construction Contracts and FAR Clause 52.232-27, Prompt Payment for Construction Contracts, All payments will be made by electronic transfer of funds (EFT).

4.2. To meet compliance with DFARS 252.232-7003, Electronic Submission of Payment Requests, you shall submit your request for payment (invoice) through WAWF. For more information on the WAWF system, including how to register, visit https://wawf.eb.mil. Payment will be made by paying office specified in the contract award in accordance with the clauses Payments under Fixed-Price Construction Contracts, FAR 52.232-5, and Prompt Payment for Construction Contracts, FAR 52.232-27.

4.3. The Government will make payment through WAWF upon satisfactory completion of work AND receipt of a proper certification for payment. Do not input invoice into WAWF until the pre-approval of invoice is received from the contracting officer. This will lessen the need for rejections in WAWF Payment may be withheld unless all contractual requirements including but not limited to: RECEIPT OF PROPER WEEKLY PAYROLLS IAW DAVIS BACON REQUIREMENTS, Small Business Subcontracting Reports, have been timely received.

4.4. All requests for payments through WAWF must include a Subcontractor Payment Register pursuant to

FAR Clause 52.232-5 and a contractor’s certification that reads as follows:

I hereby certify, to the best of my knowledge and belief that –

The amounts requested are only for performance in accordance with the specifications, terms and conditions of the contract; All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and requirements of Chapter 39 of Title 31, United States Code; This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from subcontractor or supplier in accordance with the terms and conditions of the subcontract; and This certification is not to be construed as final acceptance of a subcontractor’s performance.

4.5. The Government will make payment upon satisfactory completion of work AND receipt of a proper certification for payment. Payment may be withheld unless all contractual requirements, including but not limited to: RECEIPT OF PROPER WEEKLY PAYROLLS IAW CONSTRUCTION WAGE REQUIREMENTS FAR 52.222-6, have been timely received. Payrolls shall indicate CLIN to which they are applicable.

4.6. A release of claims is required for all final payment requests and shall be submitted by the contractor with the final invoice.

5. CONTRACT ADMINISTRATION

5.1. The contracting office of Michigan Consolidated Contracting (MACC) – 43200 Maple Street, Bldg. 105, Selfridge ANGB, MI 48045 is the office having administrative jurisdiction over this contract for all matters. A list of the names and telephone numbers of the Government team comprising the contract administrator, Contracting Officer’s Representative (COR), consultant, and point of contact at the project site will be provided at the post-award/pre-construction conference.

5.2. All correspondence shall be addressed to the Contracting Officer. A copy of all correspondence shall be furnished to the contracting officer’s representative. Enclosures attached to or transmitted with the correspondence shall also be furnished with an original and one copy. Each letter shall make reference to the contract name, contract number, project number, and project title, and shall have only one subject. For tracking purposes, a sequential numbering system should be used for all correspondence.

6. PAPERLESS CONTRACTING

6.1. The National Guard is fully committed to the Federal Government’s electronic commerce and paperless contracting initiatives. As such, it is anticipated that to the maximum extent possible to include but not limited to correspondence, modification distribution, etc., to include specifications and drawings, will be issued using electronic methods, i.e., electronic mail (e-mail). Contractors shall have and maintain capability to receive documents in this manner.

6.2. Additionally, it is anticipated that within the life of this contract, other electronic processes will be enacted.

These include, but are not limited to, electronic bidding/offers, change order proposals, and electronic invoicing.

When implemented by the Contracting Officer, contractors shall participate fully in any of these new requirements at no additional cost to the Government.

7. TELEPHONE COMMUNICATIONS SECURITY MONITORING

All communications with DOD organizations are subject to communications security (COMSEC) review. Contractor personnel must be aware that telephone communications networks are continually subject to intercept by unfriendly intelligence organizations. The DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls originating from, or terminating at, DOD organizations. Therefore, civilian contractor personnel are advised that any time they place a call to, or receive a call from, a DOD organization, they are subject to COMSEC procedures. The contractor shall assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with DOD information.

8. UTILITY SERVICES

The Contracting Officer has determined that Government-operated utilities are adequate and will be furnished to the contractor without charge where existing outlets are available. The contractor is responsible for installing temporary service outlets, backflow preventer, utility meter, as necessary, at its expense in accordance with the clause entitled “Availability and Use of Utility Services” (FAR Clause 52.236-14). Water and Electrical Utilities are available.

9. PREPARATION OF MATERIAL APPROVAL SUBMITTALS

See Mead and Hunt Plans and Specs.

10. WORK PROGRESS AND PREPARATION OF PROGRESS SCHEDULES AND REPORTS

10.1. A weekly meeting may be held with the Contractor, COR and Contracting Officer (KO), if necessary, to discuss work progress, problems and potential change orders. The Contractor shall attend these meetings at no additional cost to the Government. Prior to beginning work on specific work elements of a project, the contractor shall confer with the COR and agree on a sequence of procedures and means of access to premises and buildings;

space for storage of materials and equipment; delivery of materials; and use of approaches, use of corridors, stairways and similar means of passage.

10.1.1. In accordance with FAR Clause 52.236-15, “Schedules for Construction Contracts”, the contractor before work is to commences on the contract, or another period of time determined by the KO, prepare and submit to the KO for approval three copies of a practicable schedule showing the order in which the contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing features of work. A composite schedule for the overall contract shall also be provided. The schedule shall be on an AF Form 3064, Contract Progress Schedule, or an approved computer generated format similar to the AF Form 3064. The work shall be scheduled so that, upon the start of construction, work progresses in a continuous and diligent manner. A schedule which does not reflect steady and reasonable progress throughout the construction period will be rejected.

Both the Contractor and the COR are required to provide bi-weekly progress reports covering the period from notice to proceed through final inspection. Unless agreement cannot be made on the applicable percentage of progress a joint report will be submitted to the Contracting Officer. This reports shall be submitted on the NGB Contract Progress Report form (similar to an AF Form 3065), or an approved computer generated similar format. These reports shall track progress by CLIN, if contract contains multiple CLINs, multiple AF Form 3064 and NG Contract Progress Reports will also be required for payment purposes.

10.2. The Contractor shall prepare a work progress schedule required for completion of each of the various divisions of work. Updated plans and Form 3064 showing work progress (hardcopy and formatted diskette or CD, or e-mail file copy), unless otherwise directed by the Contracting Officer, shall be provided Bi-Weekly. If there are possible deviations from the original plan, those must be noted and approved by the Contracting Officer before work changes are implemented. The schedule shall be submitted to the Contracting Officer, in the number of copies as directed. Reference Contract Clause FAR 52.236-15, “Schedules for Construction Contracts”. The reports contemplated by the clause herein titled “Schedules for Construction Contracts” shall be accomplished on and in accordance with instructions pertaining to AF Form 3064, “Contract Progress Schedule” and a National Guard Contract Progress Report”.

11. NOTICE OF COMPLETION OF CONSTRUCTION/PRE-FINAL AND FINAL INSPECTION

11.1. The contractor shall conduct a pre-final inspection in the presence of the Contracting Officer’s Representative (COR) prior to the date scheduled for Final Inspection. Any discrepancies noted shall be corrected prior to Final Inspection.

11.2. The contractor shall request scheduling of a final inspection in writing to the Contracting Officer at least five (5) working days prior to the desired date or as otherwise negotiated with the Contracting Officer.

11.3. Civil Engineering personnel and the Contracting Officer will perform the Final Inspection in the presence of the contractor, and any discrepancies noted shall be corrected within the time specified by the Contracting Officer.

11.4. Final Inspection shall not constitute acceptance of a project unless so stipulated by issuance of a separate acceptance notice.

11.5. The contractor is cautioned to ensure they have completed adequate Quality Control reviews prior to scheduling pre-final or final inspections. In the event the Contracting Officer finds that the project is not ready for the applicable inspection, (too many discrepancies) the contractor may be held liable for the costs of a repeat inspection. If the inspection involves A/E personnel these costs may include additional labor, travel and miscellaneous expenses.

12. DESIGNATION OF TECHNICAL REPRESENTATIVE

The Contracting Officer will appoint a qualified Contracting Officer’s Representative (COR) for the purposes of technically administering the contract; however, all matters concerning this contract or any work ordered placed against this contract must first be approved by the Contracting Officer. This in no way authorizes anyone other than the Contracting Officer to commit the Government to changes in terms of the contract.

13. CONTRACTOR STAFF AND EMPLOYEES

13.1. Prior to commencing on-site construction, the contractor shall provide the Contracting Officer with a telephone number and FAX number at which the contractor or his representative may be contacted at any time during regular working hours and an emergency number at which the contractor may be contacted in situations requiring immediate attention.

13.2. Supervision. The Government shall not exercise any supervision or control over the contractor employees performing services under this contract; such employees shall be accountable not to the Government, but solely to the contractor, who in turn is responsible to the Government.

13.3. Contractor’s Employees. All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may, in writing, require the contractor to remove from the job site, any employee the Contracting Officer deems incompetent, careless or otherwise objectionable.

14. CONTRACTOR OFFICE AND STORAGE

14.1. Parking of contractor vehicles shall be restricted to the contractor’s designed on-site area or the work area. The company name shall be prominently displayed on all construction vehicles parked on the job site.

14.2. Security of material storage areas on the job site shall be the responsibility of the contractor. The area shall be kept neat and orderly and free of debris.

15. RECORD DRAWINGS

See Mead and Hunt Plans and Specifications.

16. VERIFICATION OF DIMENSIONS

The contractor shall be responsible for the coordination and proper relation of all aspects of the work. He/she shall field verify all dimensions and advise the Contracting Officer of any discrepancies prior to proceeding with any phase of the work. Where exact locations are not given for the positioning of equipment and devices, they shall be positioned to permit easy access for maintenance and for removal and replacement of component parts.

17. SECURITY REQUIREMENTS

17.1. The contractor shall comply with all security regulations imposed by the base/post commander and/or agency occupying the space where work is to be performed. Any necessary security clearances shall be obtained prior to commencement of work.

17.2. It is expected that new security requirements to satisfy contractor personal identification requirements in Homeland Security Presidential Directive (HSPD-12), ''Policy for a Common Identification Standard for Federal Employees and Contractors,'' and Federal Information Processing Standards Publication (FIPS PUB) Number 201, ''Personal Identity Verification (PIV) of Federal Employees and Contractors” are incorporated in the life of this contract. Contractor shall comply with all requirements, at no additional cost to the Government.

17.3. The contractor shall ensure that all parts of the facility where work is being performed are adequately protected against vandalism and theft.

17.4. Contractors shall follow instructions provided by the Security Forces for access to Battle Creek ANGB & Selfridge ANGB. If a gate pass is not granted to a contractor allowing the delivery of goods, execution of warranty support, or performance of services please contact the contracting officer. Be sure that all of your employees have the proper ID (drivers license, state ID, immigration card, U.S. Passport, etc.). If they do not have the proper ID, they will be turned away.

17.5. The Prime Contractor and all of its subcontractors will be required to wear orange or lime colored safety vests while performing work on the installation.

17.6. U.S. Government will not be held liable for any delays or breach of contract caused by refusal of the

Security Forces to allow entry.

17.7. All prospective contractors MUST be U.S. citizens or MUST have established and maintain legal residence in the U.S., and are authorized by the US government to work in the United States (i.e. Green card, worker authorization, etc.). All prospective contractors MUST have at least one form of U.S. government issued photo identification (drivers license, U.S. passport, U.S. work visa, etc.) for entry to the installation. Security Forces will review any questionable identification documents for determination as to whether or not said identification is authorized for access to the installation.

17.8. All prospective contractors/contractor employees, once it has been established that they maintain the appropriate credential as described in one above, are subject to a Criminal History Check.

17.9. Note: For the purposes of contracting services, it is implied that, that any and all parties agree to a

Criminal History Background Check once entered into any contract. Any documents that are provided and found fraudulent to include, but not limited to driver’s licenses, contracting licenses, etc., will result in an arrest and potential termination for default from the contract. All contractors are subject to search in order to obtain entry onto the installation and while working on the installation. Any refusal to submit to a search of their person or vehicle will be deemed as a violent act of aggression against the installation and will be cause for dismissal from the installation and revocation of future privileges and installation access.

17.10. AT OPSEC

17.10.1. Access and General Protection/Security Policy and Procedures. This standard language is for contractor employees with an area of performance within Government controlled installation, facility, or area. The contractor shall comply with all applicable installation/facility access and local security policies and procedures, which may be obtained from the Contracting Officer’s Representative (COR). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the local installation’s Security Forces, Director of Emergency Services or local Security Office. The contractor shall ensure compliance with all personal identity verification requirements as directed by DoD, HAF and/or local policy. Should the Force Protection Condition (FPCON) change, the Government may require changes in contractor security matters or processes.

17.10.2. For Contractors that do not require CAC, but require access to a DoD Facility and/or

Installation. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (AFI 31-101 and AFI 10-245), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

17.10.3. AT Level I Training. This standard language is for contractor employees with an area of performance within a Government controlled installation, facility or area. All contractor employees, to include subcontractor employees, requiring access Government Installations, Facilities and Controlled Access areas shall complete AT Level I awareness training within 10 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. Certificates of completion for each affected contractor employee and subcontractor employee will be maintained by the COR or Antiterrorism Representative. AT level I Awareness Training is available at the following website:

https://atlevel1.dtic.mil/at

18. REGULATIONS

18.1. The contractor shall comply with all applicable Federal, State, Local, DOD, National Guard Bureau, Army and Air Force regulations pertaining to safety, traffic control and fire prevention.

19. TRANSPORTATION, HANDLING AND STORAGE

19.1. The contractor shall coordinate with suppliers and shippers to ensure that incoming materials are properly identified with the contractor’s name, contract number and project title. The contractor shall designate an authorized individual to be available to receive shipment. The Government will not provide storage other than that available at the project site.

19.2. Storage of supplies, materials and equipment on the project site shall be accomplished in such a manner so as to prevent mechanical and climatic damage and loss due to vandalism or theft. Equipment temporarily removed in the performance of work and stored on the job site shall be stored and protected in accordance with previous paragraphs, and shall be replaced in a condition compatible with its original state. Security for equipment and material removed from the job site for temporary storage until reuse shall be the responsibility of the contractor.

20. CLEANUP AND DISPOSAL OF DEBRIS AND FILL MATERIALS

20.1. At the end of each workday, the contractor shall clean up the work and storage areas and stack all materials in a manner approved by the Contracting Officer or his designated representative. Upon completion of a project, the contractor shall ensure that all dirt, trash, and debris resulting from the construction operations are removed from the work area. Unless directed otherwise in the contract or by the Contracting Officer, disposal of debris shall be made at the contractor’s expense and shall be delivered to a state approved disposal site located off base. Debris shall not be left in such a manner that wind or other weather conditions can cause the debris to be scattered outside the work area (i.e., on nearby runways, ramps or taxiways).

20.2. The hauling and disposal of excess fill material including rock, gravel, sod, broken concrete or asphalt, plaster, etc., shall be the responsibility of the contractor. Disposal shall be in accordance with applicable state and local regulations.

21. ENVIRONMENTAL IMPACT

22. HAZARDOUS MATERIALS

See Mead and Hunt Specifications

23. POLLUTION ABATEMENT

24. COORDINATION WITH GOVERNMENT ACTIVITIES

24.1. If it becomes necessary to interrupt work activities in buildings and/or areas for construction purposes, permission to do so must be requested in writing to the Contracting Officer five working days prior to commencing work on the planned interruption and shall be subject to Civil Engineering approval. Written requests for street closing shall be submitted for approval of the Civil Engineer five working days prior to closing the street.

24.2. Work in connection with this contract which requires utility outages, including electrical, water, gas, steam, etc., which will close down or limit (as determined by the Contracting Officer) normal activities in the building, construction area or other affected areas, shall be performed by the contractor at a time other than the regular work period of the organization occupying the facility. Work required by the contractor on a non-standard basis or at premium pay shall be done at no additional cost to the Government. Request for utility outages shall be submitted to the Civil Engineer, in writing five working days prior to commencing work and shall be subject to his/her approval.

24.3. Any temporary construction for facilities used by the contractor for preventing interruption of normal work activity or loss of utility services shall be subject to Contracting Officer’s approval.

25. UNAUTHORIZED PERSONNEL

26. PERFORMANCE EVALUATION OF CONTRACTOR

26.1. As a minimum, the contractor’s performance will be evaluated upon final inspection. Any specific requirements for contract quality control and quality assurance by the Government personnel will be defined in the specifications. The contractor will be rated as outstanding, satisfactory or unsatisfactory in the areas of contract quality control, timely performance, effectiveness of management, compliance with labor standards, and compliance with safety standards. The contractor will be notified of any unsatisfactory rating, either in an individual element or in the overall rating, prior to completing the evaluation, and all contractor comments will be made a part of the official record. Performance evaluation reports will be available to all DoD Contracting Officers for their future use.

26.2 Past Performance evaluations will be posted via https://www.cpars.gov. It is the responsibility of the contractor to request access to this site.

27. CONTRACTOR QUALITY CONTROL

28. SAFETY ASSURANCE

1. PRE-CONSTRUCTION CONFERENCE

2. MILITARY REAL PROPERTY DATA – DD FORM 1354

2.1. Contractors shall furnish real property data to the Government for each new construction and/or renovation project awarded, unless otherwise notified. The real property data shall be furnished via DD Form 1354, Transfer and Acceptance of Military Real Property, or in a format prescribed on the DD Form 1354. The Contractor is responsible for accuracy of data current up to the time of submission.

2.2. For major renovation and/or complex projects, or those expected to exceed 12 months, the Contractor shall furnish real property data no less than on a quarterly basis. Frequency of submission shall be standard throughout the duration of the project. Contractors are advised to record information on the DD Form 1354 (or approved facsimile) as the project progresses, due to the volume of data required to be furnished. Upon completion of the project, the Contractor shall furnish a final, comprehensive DD Form 1354.

2.3. DD Form 1354 accounts for one percent 1% of the total contract amount and therefore, 1% must be shown on the AF Form 3065 or similar breakdown of costs submitted for payment purposes. Upon acceptance of data by the real property specialist, the contractor may invoice for submission of real property data.

2.4. Contractors should contact Major Nathan Finfrock or Jamison Taylor with questions pertaining to the DD

Form 1354. For construction data assistance, Contractors may consult the COR assigned to the project.

3. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

3.1. This Paragraph specifies the procedure for the determination of time extensions for unusually severe weather. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

3.1.1. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

3.1.2. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

3.1.3. Weather delays will be based on National Oceanic and Atmospheric Administration

(NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor’s progress schedule must reflect consideration of these anticipated adverse weather delays in all weather dependent activities.

3.1.4. Upon acknowledgment of the notice to proceed (NTP) and continuing throughout the contract, the contractor will record on the daily Contractor Quality Control (CQC) report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delays must prevent work on critical activities for 50 percent or more of the contractor’s scheduled workday.

3.1.5. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a bilateral modification.

Performance of Services During Crisis Declared by the National Command Authority. (September 2002)

4. Contractor Key Personnel Contractor’s Key personnel must be identified. Including, but not limited to: Site Superintendent, Project Manager, Quality Control Manger, and Safety Manager. (Key Personnel may hold more than one role.)

5. The Following is provided to assist in the subcontractor reporting required by 52.204-10 REPORTING

EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

AGENCY CODE______57________ TAS_________3840___________

6. The Following is provided to assist in submission of WAWF Invoices

PARTIAL PAYMENTS ARE AUTHORIZED FOR THIS ORDER

WIDE AREA WORKFLOW STATEMENT (FEB 2006)

IAW 252.232-7003, all invoices must be submitted via WAWF. It is mandatory that you use this E-Invoicing system to ensure timely payment of your invoice.

The web site for this system is https://wawf.eb.mil. There are no charges to use WAWF. All questions relating to system setup and vendor training can be directed to the help desk at Ogden. Their number is 1-866-618-5988.

THE FOLLOWING CODES WILL BE REQUIRED TO ROUTE YOUR INVOICES AND ADDITIONAL E-

MAILS CORRECTLY THROUGH WAWF.

TYPE OF INVOICE SUBMISSION:

_____ Invoice

_____ Invoice and Receiving Report (Combo)

_X___ Invoice as 2-in-1 (Services Only)

____ Construction Invoice

X CAGE Code*: Six (6) digit code in Block 14

X Pay DoDAAC*: F87700

X Issue DoDAAC: W50S85

X Admin DoDAAC*: W50S85

X Inspect By DODAAC*: F6DLCE

X Contracting Officer*: W50S85

Required Fields in WAWF

Contractor: WAWF will prompt asking for "additional E-mail submissions" after clicking "SIGNATURE".

The following E-Mail addresses MUST be input in order to prevent delays in processing:

Inspector (COR): As provided at the pre-construction conference

Buyer/Administrator: As provided at the pre-construction conference

Contracting Officer: As provided at the pre-construction conference

Invoices: As provided at the pre-construction conference

Failure to include email address will delay payment. The Government is not responsible for delays caused by improper submission and notification in WAWF.

The paying office DoDAAC and mailing address can be located on the front of your award. You can easily track your payment information on the DFAS website at http://myinvoice.csd.disa.mil/index.html. Your purchase order/contract number or invoice number will be required to inquire status of your payment.

END OF Division 01, Section 010000 Specifications.