SCOP CR 69A STAFFORD CREEK BRIDGE.pdf
PDF 109 KB Posted
- Attached to
- SCOP CR 69A Stafford Creek Bridge
- Solicitation number
- 2026-06
- Issued by
- Baker County, Melbourne Beach Town, Florida
About this file
This is an Advertisement for Bid issued by Calhoun County, Florida for construction services related to minor repair and rehabilitation improvements to the CR69A Stafford Creek Bridge located in Calhoun County. The project scope includes bridge rehabilitation work, guardrail installation, and traffic control services. Sealed bids will be received until 2:00 P.M. Central Standard Time on October 19, 2026 at Calhoun County, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, with public opening and reading of bids at 2:01 P.M. Central Time at the Clerk's office on the same date. The project has a completion deadline of 90 days from the Notice to Proceed, and all bids must remain firm for 90 days following the bid opening. Prospective bidders may obtain bidding documents by emailing adc@panhandleengineering.com, with the issuing office being Panhandle Engineering, Inc. No pre-bid conference or site visit is specified in the advertisement.
All bidders must be Florida Department of Transportation (FDOT) certified in the appropriate work group categories, specifically 30L-R&R Minor Bridges, 30C Guardrail, and Traffic Control/Maintenance of Traffic. Liquidated damages for failure to complete the project by the specified date are set at $500.00 per day. All bidders must comply with applicable state and local laws concerning licensing, registration, and regulation of contractors in Florida. Calhoun County reserves the right to waive informalities, accept and/or reject any or all bids, and select the bid deemed in their best interest. The project is funded by the Florida Department of Transportation. Bid Identification Number is 2026-06, and all questions should be directed to Austin Childree at adc@panhandleengineering.com.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SCOP CR69A STAFFORD CREEK BRIDGE PE FILE NO. 1271.33
SECTION 00100 ADVERTISEMENT FOR BID 1
INVITATION FOR BIDS
Calhoun County, (OWNER), will receive sealed bids from any qualified person, company, or corporation interested in providing construction services for the following project:
SCOP CR 69A STAFFORD CREEK BRIDGE
This project consists of minor repair and rehabilitation improvements to the CR69A Stafford Creek Bridge, which is located in Calhoun County, Florida.
The issuing office for the bidding documents is Panhandle Engineering, Inc. Prospective bidders may obtain copies of the bidding documents from the issuing office by emailing adc@panhandleengineering.com.
Completion date for this project will be 90 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.
Please indicate on the envelope that this is a sealed bid for “(SCOP CR 69A STAFFORD
CREEK BRIDGE BID # 2026-06)”.
Bids will be received until 2:00 P.M. (CST), on October 19th , 2026 at Calhoun County 20859 Central Avenue East, Room 130 Blountstown, FL 32424, and will be opened and read aloud at 2:01 P.M. Central Time at the Clerks office. Calhoun County is an Equal Opportunity Employer/Handicapped Accessible/Fair House Jurisdiction.
Calhoun County reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of ninety (90) days after the opening.
All bidders shall comply with all applicable state and local laws concerning licensing registration and regulation of contractors doing business in the State of Florida.
For all questions, please contact Austin Childree adc@panhandleengineering.com.
The project is funded by the Florida Department of Transportation, therefore, all bidders must be FDOT Certified in the appropriate work group categories. Required work classes include:
• 30L-R&R Minor Bridges
• 30C – Guardrail
• Traffic Control/Maintenance of Traffic
Advertisement Date: September 16th, 2026.
mailto:adc@panhandleengineering.com mailto:adc@panhandleengineering.com
File details come from the government source that posted it. Updated .