Schedule of work.pdf

Schedule of work

(1) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents at the arrival conference for dockside availabilities:

a. Production Schedule.

b. Work Package Network.

c. Total Manpower Loading Curve.

d. Trade Manning Curves.

e. Subcontracting List.

(2) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors.

(3) Growth work ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than two (2) calendar days) from the Production Schedule shall be immediately brought to the attention of the Contracting Officer and COR.

(4) Any deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance under subparagraph

(f) of this clause titled Excusable delays.

Access to the Vessel

(1) As authorized by the Contracting Officer, a reasonable number of officers, employees and personnel designated by the Government, or representatives of other contractors and their subcontractors shall have admission to the facility and access to the vessel at all reasonable times to perform and fulfill their respective obligations to the Government on a noninterference basis. The contractor shall make reasonable arrangements to provide access for these personnel to office space, work areas, storage or shop areas, and other facilities and services reasonable and necessary to perform their duties. All such personnel shall comply with contractor rules and regulations governing personnel at its shipyard, including those regarding safety and security.

(2) The contractor further agrees to allow a reasonable number of officers, employees, and designated personnel of contractors on other contemplated work, the same privileges of admission to the contractor's facility and access to the vessel(s) on a noninterference basis, subject to contractor rules and regulations governing personnel in its shipyard, including those regarding safety and security.

Temporary Services

(1) Temporary services are services incidental to the performance of work, which are required in the schedule or specifications to be provided by the contractor. Temporary services may include the furnishing of water, electricity, telephone service, toilet facilities, garbage removal, office space, parking places or similar facilities.

(2) If performance time is extended due to Government-caused delay, the contractor may request an equitable adjustment for providing temporary services at the rate stated in the Schedule.