RFQ no. 19TH2026Q0044 - Septic Tank Replacement.pdf

Embassy of the United States of America

Bangkok, Thailand

July 13, 2026

Dear Prospective Offeror:

Subject: Request for Quotes 19TH2026Q0044

Enclosed is a Request for Quotes (RFQ) for septic tank replacement. If you would like to submit a quotation, follow the instructions in Section J of the solicitation, complete the required portions of the attached document, and submit it to the address shown on this letter.

The U.S. government intends to award a contract/purchase order to the responsible company submitting an acceptable offer at the lowest price. We intend to award a contract/purchase order based on initial proposals, without holding discussions, although we may hold discussions with companies in the competitive range if there is a need to do so.

Direct any questions regarding this solicitation in writing to Ramon Menendez-Carreira, Contracting Officer, email: BangkokGSOProcurement@state.gov. Questions must be written in English. Closing date for question submission will be July 20, 2026 at 4:00 PM (Bangkok local time).

The Embassy intends to conduct a site visit. The site visit be held on July 17, 2026 at 10:00 AM (Bangkok local time) at Rajdamri Compound.

Vehicles are not allowed access to Rajdamri Compound. The Government will not be responsible for the participants’ vehicle parking fee. The completed site visit agenda and site visit instructions will be provided upon request. Prospective offerors/quoters must provide company’s name, participant full names in English which match the identification cards or passports, email address and mobile phone number of company’s point of contact to email:

BangkokGSOProcurement@state.gov by July 15, 2026 at 12:00 PM (Bangkok local time) for the site visit instruction and to arrange entry to the building. Attendance at the site visit is limited to three personnel per offeror/quoter.

Quotations are due by July 23, 2026 at 12:00 PM (Bangkok local time). No quotations will be accepted after this time. Quotations must be in English and incomplete quotations will not be accepted.

Your quotation must be submitted electronically to BangkokGSOProcurement@state.gov. It is important to make sure the submission is made in specific size and format; in MS-Word 2007/2010 or MS-Excel 2007/2010 or Adobe Acrobat (pdf) file format. The file size must not exceed 25MB. If the file size should exceed 25MB, the submission must be made in separate files and attached to separate emails with less than 25MB each.

mailto:BangkokGSOProcurement@state.gov mailto:BangkokGSOProcurement@state.gov

In order for a quotation to be considered, you must also complete and submit the following:

1. SF-18

2. Section A, Pricing

3. Section L, Representations and Certifications

4. Additional information as required in Section J

5. Proof of SAM Registration

Offerors shall be registered in the SAM (System for Award Management) database at https://www.sam.gov prior to submittal of their offer/proposal as prescribed under RFO FAR 4.203-1. Failure to be registered at time of proposal submission may deem the offeror’s proposal to be considered non-responsible and no further consideration will be given. Therefore, offerors are highly encouraged to register immediately if they are interested in submitting a response to this requirement.

Sincerely, Ramon Menendez-Carreira Contracting Officer

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

THIS RFQ IS IS NOT A SMALL BUSINESS SET-ASIDE

15. DATE OF QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

b. TELEPHONE

AREA CODE

NUMBER

STANDARD FORM 18 (REV. 6/1995)

Prescribed by GSA-FAR (48 CFR) 53.215-1(a)

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

8. TO:

b. COMPANYa. NAME

c. STREET ADDRESS

d. CITY e. STATE f. ZIP CODE

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

c. CITY

d. STATE e. ZIP CODE

7. DELIVERY

FOB DESTINATION

OTHER

(See Schedule)

IMPORTANT: This is a request for information and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or service. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotation must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

ITEM NUMBER

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations are are not attached.

13. NAME AND ADDRESS OF QUOTER

a. NAME OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

PAGE OF PAGES

1. REQUEST NUMBER 2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NUMBER 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG. 1

RATING

5a. ISSUED BY 6. DELIVER BY (Date)

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

NAME TELEPHONE NUMBER

AREA CODE NUMBER

19TH2026Q0044

U.S. Embassy Bangkok, 120-122 Wireless Rd., Lumpini, Pathumwan, Bangkok 10330

Ramon Menendez-Carreira

To provide materials and labor for replacement of a septic tank at Rajdamri Compound.

Pricing breakdown is provided separately

The total amount paid in Thai Baht VAT excluded

662-205-5320 U.S. Embassy Bangkok

120-122 Wireless Rd,Lumpini,Pathumwan

Bangkok

10330

07/13/2026

10. PLEASE FURNISH QUOTATIONS TO THE

ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS (Date)

07/23/2026 (See Attached)

TABLE OF CONTENTS

SF-18 COVER SHEET

A. PRICING

B. STATEMENT OF WORK

C. PACKAGING AND MARKING

D. INSPECTION AND ACCEPTANCE

E. DELIVERIES AND PERFORMANCE

F. CONTRACT ADMINISTRATION DATA

G. SPECIAL TERMS AND CONDITIONS

H. CLAUSES

I. LIST OF ATTACHMENTS

J. INSTRUCTIONS ON HOW TO SUBMIT A QUOTATION

K. EVALUATION CRITERIA

L. REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS

SECTION A - PRICING

The U.S. Embassy intends to award a contract to replace a septic tank located at Rajdamri Compound, Rajdamri Road, Lumpini, Pathumwan, Bangkok 10330, Thailand.

A. PRICE

The Contractor shall complete all work, including furnishing all labor, material, equipment, and services required under this purchase order for the following firm fixed price and within the time specified. This price shall include all labor, materials, all insurances, overhead and profit.

Total Price (including all labor, materials, overhead and profit)

The agreed upon cost of this work shall be a firm fixed price inclusive of all labor, equipment, materials, shipping, etc. The Design and Implementation cost will be based on a contractor’s accepted cost proposal.

Description Quantity Unit Price Total Price

Site Preparation Work 1 sum. ________ ________ Excavation and Piling Works 1 sum. ________ ________ Waste Disposal Work 1 sum. ________ ________ Septic Tank Materials 1 sum. ________ ________ Site Restoration Work 1 sum. ________ ________ Miscellaneous 1 sum. ________ ________ Overhead & Profit 1 sum. ________ ________ DBA Insurance 1 sum. ________ ________

Total Contract Price: ________________

(Paid in Thai Baht)

The above items are a summary of prices. Detailed pricing shall be submitted in the form of a Bill of Quantity (BOQ), which consists of descriptions, quantities, and unit prices for each item.

A.1 VALUE ADDED TAX

VALUE ADDED TAX (VAT). The Government will not reimburse the Contractor for VAT under this contract. The Contractor shall not include a line item for VAT on invoices as the U.S.

Embassy has a tax exemption certificate with the host government.

SECTION B - STATEMENT OF WORK

The character and scope of the work are set forth in the contract. The Contractor shall furnish and install all materials required by this contract.

In case of differences between small and large-scale drawings, the latter will govern. Where a portion of the work is drawn in detail and the remainder of the work is indicated in outline, the parts drawn in detail shall apply also to all other portions of the work.

A. GENERAL REQUIREMENTS

The U.S. Embassy intends to award a contract to replace a broken septic tank located at Rajdamri Compound, 33 Rajdamri road, Lumpini, Pathumwan, Bangkok, 10330 Thailand. The Contractor shall be responsible for the removal of the existing tank, installation of a new septic system, and proper disposal of waste materials in compliance with local regulations. The contract type shall be firm-fixed price.

B. SCOPE OF WORK

The Contractor shall provide certified equipment, certified labor, and tools to replace the septic tank.

The Contractor shall perform following services but not limited to:

• Inspect the current septic system to confirm the extent of damage and assess site conditions for the replacement. Provide a report detailing the condition of the existing system and the recommended new tank specifications.

• The Contractor shall submit shop drawings and material approval requests to the Post Engineer for review and approval prior to ordering or installing any materials. All materials shall comply with the approved specifications before proceeding with installation.

• The Contractor shall submit an AHA safety document for approval prior to commencing the project to ensure that work procedures meet safety requirements and that personnel, materials and components are protected from damage and deterioration.

• The Contractor shall provide temporary fencing, barricades, and ventilation as required to protect existing property, adjacent properties, and personnel. The contractor shall submit a proposed plan, details, and required certificates for the staging area.

• The Contractor shall pump out and properly dispose of all waste materials in the broken septic tank. Safely remove and dispose of the old septic tank following local environmental regulations.

• The Contractor shall install sheet piles or equivalent materials around the septic tank to protect the surrounding soil from landslides. Ensure all necessary protection measures are in place to prevent soil erosion or land subsidence during and after installation.

• The Contractor shall excavate the area for the new septic tank according to the approved site plan and depth requirements. The brand and model of the current septic tank is Premier Product GK-100, the Contractor shall replace the septic tank which has the same specifications and requirements as the current septic tank. Replace piping, fittings and accessories to ensure all connections to the existing plumbing system are secure and tested for proper functionality.

• The Contractor shall backfill the excavated area after the installation, ensuring that the soil is properly compacted. Restore the site to its original condition, including landscaping if required.

• The Contractor shall conduct a full test of the new septic system to ensure proper functionality. Arrange for final inspection and approval from the relevant authorities.

Upon request, the Contractor shall provide a full-time experienced and certified Project Leader on site. The Contractor’s Project Leader and other designated representatives will work closely and collaboratively with the Embassy on the replacement. If requested, the Project Leader may be requested to be on site throughout the duration of each move.

The Embassy reserves the right to approve/or reject the Project Leader designated to work with the Embassy. The Embassy also reserves the right to direct the Contractor to remove an employee of the Contractor’s team from the site. The Contractor shall immediately replace such an employee to maintain continuity of services at no additional costs to the Government.

Site Survey: The Contractor shall visit the U.S. Embassy accompanied by U.S. Embassy’s Engineer to survey the site and its conditions including gather additional data during the site survey.

Site Restoration: The Contractor shall restore the area around the construction area to the conditions before the construction. The work includes all utilities, and landscape.

Disposal of Materials Removed: The Contractor shall be responsible for the disposal of all removed materials that the Embassy does not want to maintain possession of. The Contractor shall meet with the Embassy prior to commencement of work to determine where to dispose materials or temporarily store them on site. The Contractor shall ensure that all items removed through this work are disposed of properly.

Safety: Safety is the highest priority on this and all OBO/OM/FAC projects. The Contractor shall direct all of those under his charge to work safely. Regular safety meetings shall be held among on-site contractor personnel, and safety concerns shall immediately be brought to the attention of the Embassy.

The Contractor agrees and warrants that it and its workforce shall comply with applicable safety regulations. Further, all equipment used shall meet all requirements identified by the Embassy.

C. DELIVERABLES

• Installation of sheet piles and landslide protection as specified.

• A new genuine septic tank is installed and fully operational.

• All required permits and inspection approvals obtained.

• Shop drawings and material approvals submitted prior to material procurement.

• Detailed report documenting the work, including as-built drawings completed and submitted to post engineer, and system functionality.

D. TIMELINE

The Contractor shall submit required documents for approval within 10 business days after award. The project shall be completed within 5 calendar days from the start date. The tentative start date is October 1, 2026. Any delays shall be communicated promptly.

E. COMPLIANCE

The Contractor shall adhere to all local, state, and environmental regulations for septic system installation, waste disposal, and landslide protection.

F. WARRANTY

The Contractor shall provide a one-year warranty on the materials and workmanship for the new septic system. The Contractor shall provide on-site repairs when there is a problem or failure and the Contractor is notified.

G. SAFETY REQUIREMENTS

The contractor is responsible for ensuring all work is conducted safely and that the worksite is secure. Activity Hazard Analysis (AHA) documents shall be submitted for approval prior to commencing the work.

H. ADMINISTRATION

Contracting Officer Representative (COR):

All work will be performed to the satisfaction of the Contracting Officer Representative or COR.

Authorized Representative:

The Embassy and the Contractor shall, during the award of the contract, designate authorized representatives as mentioned. Any changes in the authorized representatives shall be submitted in writing.

The Contractor is cautioned not to perform work requested by persons other than the Contracting Officer.

Security Requirements and Procedures for Contractors:

Contractors who require access to any of the Embassy offices or facilities are required to comply with the security procedures:

Security regulations require a valid identification card or a work-permit documentation for all workers to be submitted to the COR five days in advance and the same valid identification card or a work-permit documentation shall be presented to enter the compound.

All trucks or vehicles that will require access to the Embassy shall be notified to the RSO including vehicle make type, model, color and license plate number. All vehicles with cargo will be screened at the guard search areas.

To comply with the security requirements and procedures, the Contractor shall be escorted by a guard(s) or other personnel with escort privileges at all times. Guard numbers requirement will be determined by the RSO depending on the number of contract personnel, areas of construction and other considerations.

SECTION C - PACKAGING AND MARKING

Mark materials delivered to the site as follows:

Septic Tank Replacement at House #1 – Staff Quarter at Rajdamri Compound

SECTION D - INSPECTION AND ACCEPTANCE

The COR, or his/her authorized representatives, will inspect from time to time the services being performed and the supplies furnished to determine whether work is being performed in a satisfactory manner, and that all supplies are of acceptable quality and standards.

The Contractor shall be responsible for any countermeasures or corrective action, within the scope of this contract, which may be required by the Contracting Officer as a result of such inspection.

D.1 SUBSTANTIAL COMPLETION

(a) "Substantial Completion" means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

(1) do not interfere with the intended occupancy or utilization of the work, and

(2) can be completed or corrected within the time period required for final completion.

(b) The "date of substantial completion" means the date determined by the Contracting Officer or authorized Government representative as of which substantial completion of the work has been achieved.

Use and Possession upon Substantial Completion - The Government shall have the right to take possession of and use the work upon substantial completion. Upon notice by the Contractor that the work is substantially complete (a Request for Substantial Completion) and an inspection by the Contracting Officer or an authorized Government representative (including any required tests), the Contracting Officer shall furnish the Contractor a Certificate of Substantial Completion. The certificate will be accompanied by a Schedule of Defects listing items of work remaining to be performed, completed, or corrected before final completion and acceptance.

Failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The Government's possession or use upon substantial completion shall not be deemed an acceptance of any work under the contract.

D.2 FINAL COMPLETION AND ACCEPTANCE

D.2.1 "Final completion and acceptance" means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

D.2.2 The "date of final completion and acceptance" means the date determined by the Contracting Officer when final completion of the work has been achieved, as indicated by written notice to the Contractor.

D.2.3 FINAL INSPECTION AND TESTS. The Contractor shall give the Contracting Officer at least five (5) days advance written notice of the date when the work will be fully completed and ready for final inspection and tests. Final inspection and tests will be started not later than the date specified in the notice unless the Contracting Officer determines that the work is not ready for final inspection and so informs the Contractor.

D.2.4 FINAL ACCEPTANCE. If the Contracting Officer is satisfied that the work under the contract is complete (with the exception of continuing obligations), the Contracting Officer shall issue to the Contractor a notice of final acceptance and make final payment upon:

• Satisfactory completion of all required tests,

• A final inspection that all items by the Contracting Officer listed in the Schedule of Defects have been completed or corrected and that the work is finally complete (subject to the discovery of defects after final completion), and

• Submittal by the Contractor of all documents and other items required upon completion of the work, including a final request for payment (Request for Final Acceptance).

SECTION E - DELIVERIES AND PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

(APR 1984)

The Contractor shall be required to:

(a) commence work under this contract within seven (7) calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and,

(c) complete the entire work ready for use not later than 90 days after NTP issuance.

The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor shall pay liquidated damages to the Government in the amount of 3,000 Thai Baht for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Default clause.

CONTRACTOR'S SUBMISSION OF CONSTRUCTION SCHEDULES

(a) The time for submission of the schedules referenced in FAR 52.236-15, "Schedules for Construction Contracts", paragraph (a), is hereby modified to reflect the due date for submission as "seven (7) calendar days after receipt of an executed contract".

(b) These schedules shall include the time by which shop drawings, product data, samples and other submittals required by the contract will be submitted for approval.

(c) The Contractor shall revise such schedules (1) to account for the actual progress of the work, (2) to reflect approved adjustments in the performance schedule, and (3) as required by the Contracting Officer to achieve coordination with work by the Government and any separate contractors used by the Government. The Contractor shall submit a schedule, which sequences work so as to minimize disruption at the job site.

(d) All deliverables shall be in the English language and any system of dimensions (English or metric) shown shall be consistent with that used in the contract. No extension of time shall be allowed due to delay by the Government in approving such deliverables if the Contractor has failed to act promptly and responsively in submitting its deliverables. The

Contractor shall identify each deliverable as required by the contract.

(e) Acceptance of Schedule: When the Government has accepted any time schedule;

it shall be binding upon the Contractor. The completion date is fixed and may be extended only by a written contract modification signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:

(1) Extend the completion date or obligate the Government to do so,

(2) Constitute acceptance or approval of any delay, or

(3) Excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

NOTICE OF DELAY

If the Contractor receives a notice of any change in the work, or if any other conditions arise which are likely to cause or are actually causing delays which the Contractor believes may result in late completion of the project, the Contractor shall notify the Contracting Officer. The Contractor’s notice shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule, or the completion date should be revised. The Contractor shall give such notice promptly, not more than ten (10) days after the first event giving rise to the delay or prospective delay. Only the Contracting Officer may revise the approved time schedule.

NOTICE TO PROCEED

(a) After receiving and accepting any bonds or evidence of insurance, the Contracting Officer will provide the Contractor a Notice to Proceed. The Contractor must then prosecute the work, commencing and completing performance not later than the time period established in the contract.

(b) It is possible that the Contracting Officer may elect to issue the Notice to Proceed before receipt and acceptance of any bonds or evidence of insurance. Issuance of a Notice to Proceed by the Government before receipt of the required bonds or insurance certificates or policies shall not be a waiver of the requirement to furnish these documents.

WORKING HOURS

All work shall be performed during Monday to Saturday from 7:00 AM to 6:00 PM. Other hours, if requested by the Contractor, may be approved by the Contracting Officer's Representative (COR). The Contractor shall give 24 hours in advance to COR who will consider any deviation from the hours identified above. Changes in work hours, initiated by the Contractor, will not be a cause for a price increase.

PRECONSTRUCTION CONFERENCE

A preconstruction conference will be held 10 days after contract award with the COR, Facility Management office at U.S. Embassy Bangkok to discuss the schedule, submittals, notice to proceed, mobilization and other important issues that effect construction progress.

DELIVERABLES - The following items shall be delivered under this contract:

Description Quantity Deliver Date Deliver To

Section G. Securities/Insurance 1 10 days after award CO Section E. Construction Schedule 1 10 days after award COR Section E. Preconstruction Conference 1 10 days after award COR Section G. Personnel Biographies 1 10 days after award COR

Section F. Payment Request 1 Last calendar day of each month COR

Section D. Request for Substantial Completion 1 15 days before inspection COR

Section D. Request for Final Acceptance 1 5 days before inspection COR

SECTION F – CONTRACT ADMINISTRATION DATA

652.242-70 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (AUG 1999)

(a) The Contracting Officer may designate in writing one or more Government employees, by name or position title, to take action for the Contracting Officer under this contract. Each designee shall be identified as a Contracting Officer’s Representative (COR).

Such designation(s) shall specify the scope and limitations of the authority so delegated;

provided, that the designee shall not change the terms or conditions of the contract, unless the COR is a warranted Contracting Officer, and this authority is delegated in the designation.

(b) The COR for this contract is Facility Management Officer.

Payment: The Contractor's attention is directed to Section H, 52.232-5, "Payments Under Fixed-Price Construction Contracts". The following elaborates on the information contained in that clause.

Requests for payment, may be made no more frequently than monthly. Payment requests shall cover the value of labor and materials completed and in place, including a prorated portion of overhead and profit.

After receipt of the Contractor's request for payment, and on the basis of an inspection of the work, the Contracting Officer shall make a determination as to the amount, which is then due. If the Contracting Officer does not approve payment of the full amount applied for, less the retainage allowed by in 52.232-5, the Contracting Officer shall advise the Contractor as to the reasons.

Under the authority of 52.232-27(a), the 14 day period identified in FAR 52.232-27(a)(1)(i)(A) is hereby changed to 30 days.

The Contractor shall submit invoices electronically to email usembbkkdbo@state.gov. To constitute a proper invoice, the invoice shall include all the items required by FAR 32.905(e).

The invoices shall be issued by using following address:

U.S. Embassy Bangkok

ATTN: FMO

120 – 122 Wireless Road Lumpini, Pathumwan Bangkok 10330

The payment shall be made by electronic fund transfer (EFT) within 30 days after receiving the proper invoice.

mailto:usembbkkdbo@state.gov

SECTION G - SPECIAL TERMS AND CONDITIONS

G.1.0 PERFORMANCE/PAYMENT PROTECTION - The Contractor shall furnish some form of payment protection as described in 52.228-13 in the amount of 20% of the contract price. The Contractor shall submit one of the following payment protections: bond, irrevocable letter of credit, or bank letter guarantee.

G.1.1 The Contractor shall provide the information required by the paragraph above within ten

(10) calendar days after award. Failure to timely submit the required security may result in rescinding or termination of the contract by the Government. If the contract is terminated, the Contractor will be liable for those costs as described in FAR 52.249-10, Default (Fixed-Price Construction), which is included in this purchase order.

G.1.2 The bonds or alternate performance security shall guarantee the Contractor's execution and completion of the work within the contract time. This security shall also guarantee the correction of any defects after completion, the payment of all wages and other amounts payable by the Contractor under its subcontracts or for labor and materials, and the satisfaction or removal of any liens or encumbrances placed on the work.

G.1.3 The required securities shall remain in effect in the full amount required until final acceptance of the project by the Government. Upon final acceptance, the penal sum of the performance security shall be reduced to 10% of the contract price. The security shall remain in effect for one year after the date of final completion and acceptance, and the Contractor shall pay any premium required for the entire period of coverage.

G.2.0 INSURANCE - The Contractor is required by FAR 52.228-5, "Insurance - Work on a Government Installation" to provide whatever insurance is legally necessary. The Contractor shall at its own expense provide and maintain during the entire performance period the following insurance amounts:

G.2.1 GENERAL LIABILITY (includes premises/operations, collapse hazard, products, completed operations, contractual, independent contractors, broad form property damage, personal injury):

(1) BODILY INJURY, ON OR OFF THE SITE, IN THAI BAHT

Per Occurrence Thai Baht 300,000

Cumulative Thai Baht 1,000,000

(2) PROPERTY DAMAGE, ON OR OFF THE SITE, IN THAI BAHT

Per Occurrence Thai Baht 300,000

Cumulative Thai Baht 1,000,000

G.2.2 The foregoing types and amounts of insurance are the minimums required. The Contractor shall obtain any other types of insurance required by local law or that are ordinarily or customarily obtained in the location of the work. The limit of such insurance shall be as provided by law or sufficient to meet normal and customary claims.

G.2.3 The Contractor agrees that the Government shall not be responsible for personal injuries or for damages to any property of the Contractor, its officers, agents, servants, and employees, or any other person, arising from and incident to the Contractor's performance of this contract. The Contractor shall hold harmless and indemnify the Government from any and all claims arising therefrom, except in the instance of gross negligence on the part of the Government.

G.2.4 The Contractor shall obtain adequate insurance for damage to, or theft of, materials and equipment in insurance coverage for loose transit to the site or in storage on or off the site.

G.2.5 The general liability policy required of the Contractor shall name "the United States of America, acting by and through the Department of State", as an additional insured with respect to operations performed under this contract.

G.3.0 DOCUMENT DESCRIPTIONS

G.3.1 SUPPLEMENTAL DOCUMENTS: The Contracting Officer shall furnish from time to time such detailed drawings and other information as is considered necessary, in the opinion of the Contracting Officer, to interpret, clarify, supplement, or correct inconsistencies, errors or omissions in the Contract documents, or to describe minor changes in the work not involving an increase in the contract price or extension of the contract time. The Contractor shall comply with the requirements of the supplemental documents, and unless prompt objection is made by the Contractor within 20 days, their issuance shall not provide for any claim for an increase in the Contract price or an extension of contract time.

G.3.1.1. RECORD DOCUMENTS. The Contractor shall maintain at the project site:

(1) a current marked set of Contract drawings and specifications indicating all interpretations and clarification, contract modifications, change orders, or any other departure from the contract requirements approved by the Contracting Officer; and,

(2) a complete set of record shop drawings, product data, samples and other submittals as approved by the Contracting Officer.

G.3.1.2 . "As-Built" Documents: After final completion of the work, but before final acceptance thereof, the Contractor shall provide:

(1) a complete set of "as-built" drawings, based upon the record set of drawings, marked to show the details of construction as actually accomplished; and,

(2) record shop drawings and other submittals, in the number and form as required by the specifications.

G.4.0 LAWS AND REGULATIONS - The Contractor shall, without additional expense to the Government, be responsible for complying with all laws, codes, ordinances, and regulations applicable to the performance of the work, including those of the host country, and with the lawful orders of any governmental authority having jurisdiction. Host country authorities may not enter the construction site without the permission of the Contracting Officer. Unless otherwise directed by the Contracting Officer, the Contractor shall comply with the more stringent of the requirements of such laws, regulations, and orders and of the contract. In the event of a conflict between the contract and such laws, regulations and orders, the Contractor shall promptly advise the Contracting Officer of the conflict and of the Contractor's proposed course of action for resolution by the Contracting Officer.

G.4.1 The Contractor shall comply with all local labor laws, regulations, customs, and practices pertaining to labor, safety, and similar matters, to the extent that such compliance is not inconsistent with the requirements of this contract.

G.4.2 The Contractor shall give written assurance to the Contracting Officer that all subcontractors and others performing work on or for the project have obtained all requisite licenses and permits.

G.4.3 The Contractor shall submit proper documentation and evidence satisfactory to the Contracting Officer of compliance with this clause.

G.5.0 CONSTRUCTION PERSONNEL - The Contractor shall maintain discipline at the site and at all times take all reasonable precautions to prevent any unlawful, riotous, or disorderly conduct by or among those employed at the site. The Contractor shall ensure the preservation of peace and protection of persons and property in the neighborhood of the project against such action. The Contracting Officer may require, in writing that the Contractor remove from the work any employee that the Contracting Officer deems incompetent, careless, insubordinate or otherwise objectionable, or whose continued employment on the project is deemed by the Contracting Officer to be contrary to the Government's interests.

G.5.1 If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer.

G.5.2 After award, the Contractor has ten calendar days to submit to the Contracting Officer a list of workers and supervisors assigned to this project for the Government to conduct all necessary security checks. It is anticipated that security checks will take 10 – 15 days to perform. For each individual, the list shall include:

Full Name Place and Date of Birth Current Address Identification number

Failure to provide any of the above information may be considered grounds for rejection and/or resubmittal of the application. Once the Government has completed the security screening and approved the applicants a badge will be provided to the individual for access to the site. This badge may be revoked at any time due to the falsification of data, or misconduct on site.

Security requirements and procedure for the Contractor’s temporary employees working on this contract with an estimated project duration exceed ten (10) days per year, are required to comply with the following security procedures:

Criminal Background Checks – Required Documents: Police Certificate Company Cover Letter Name Check Form Copy of ID Card with signature

Fingerprint Check – Required Documents: Fingerprint Certificate Company Cover Letter Original Thai Identification Card or Passport

Work Permits – The Contractor shall provide copies of valid employee work permits for all non-Thai workers to the COR, before commencing work.

The Contractor is responsible for obtaining and submitting official Police Certificate, Fingerprint Certificate and Work Permit documents to the Contracting Officer Representative (COR).

These background checks shall be obtained at the Royal Thai Police, Criminal Records Division Building 7, Rama 1 Road., Pathumwan, Bangkok 10330

Police Certificate:

Website: http://www.criminal.police.go.th/ Telephone Numbers: 02-205-1247, 02-205-2390 & 02-205-1315

Fingerprint Certificate:

Website: http://www.criminal.police.go.th/documentfiles.php Telephone Numbers: 02-205-2200 & 02-205-2201

Certification will be good of one year from the date on the certificate.

G.5.3 The Contractor shall provide an English speaking supervisor on site at all times. This position is considered as key personnel under this purchase order.

G.6.0 Materials and Equipment - All materials and equipment incorporated into the work shall be new and for the purpose intended, unless otherwise specified. All workmanship shall be of http://www.criminal.police.go.th/ http://www.criminal.police.go.th/documentfiles.php good quality and performed in a skillful manner that will withstand inspection by the Contracting Officer.

G.7.0 SPECIAL WARRANTIES

G.7.1 Any special warranties that may be required under the contract shall be subject to the stipulations set forth in 52.246-21, "Warranty of Construction", as long as they are not in conflict.

G.7.2 The Contractor shall obtain and furnish to the Government all information required to make any subcontractor's, manufacturer's, or supplier's guarantee or warranty legally binding and effective. The Contractor shall submit both the information and the guarantee or warranty to the Government in sufficient time to permit the Government to meet any time limit specified in the guarantee or warranty, but not later than completion and acceptance of all work under this contract.

G.8.0 EQUITABLE ADJUSTMENTS

Any circumstance for which the contract provides an equitable adjustment that causes a change within the meaning of paragraph (a) of the "Changes" clause shall be treated as a change under that clause; provided, that the Contractor gives the Contracting Officer prompt written notice (within 20 days) stating:

(a) the date, circumstances, and applicable contract clause authorizing an equitable adjustment and

(b) that the Contractor regards the event as a changed condition for which an equitable adjustment is allowed under the contract

The Contractor shall provide written notice of a differing site condition within 10 calendar days of occurrence following FAR 52.236-2, Differing Site Conditions.

G.9.0 ZONING APPROVALS AND PERMITS

The Government shall be responsible for:

- obtaining proper zoning or other land use control approval for the project

- obtaining the approval of the Contracting Drawings and Specifications

- paying fees due for the foregoing; and,

- for obtaining and paying for the initial building permits.

SECTION H - CLAUSES

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. In addition, the full text of a clause may be accessed electronically at: Acquisition.gov this address is subject to change.

If the Federal Acquisition Regulation (FAR) is not available at the location indicated above, use the Department of State Acquisition website at e-CFR to see the links to the FAR. You may also use an Internet “search engine” (for example, Google, Yahoo or Excite) to obtain the latest location of the most current FAR.

THE FOLLOWING FEDERAL ACQUISITION REGULATION CLAUSE(S) IS/ARE

INCORPORATED BY REFERENCE (48 CFR CH. 1):

CLAUSE TITLE AND DATE

52.202-1 DEFINITIONS (JUN 2020)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY

AGREEMENTS OR STATEMENTS (JAN 2017)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL

(JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER

SUBCONTRACT AWARDS (JAN 2026)

52.204-13 SYSTEM FOR AWARD MANAGEMENT—MAINTENANCE (JAN 2026)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS (DEC 2014)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN

SUBCONTRACTING WITH CONTRACTORS DEBARRED, SUSPENDED,

PROPOSED FOR DEBARMENT, OR VOLUNTARILY EXCLUDED (JAN

2026)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (JAN 2026)

52.216-7 ALLOWABLE COST AND PAYMENT (FEB 2026)

https://acquisition.gov/browse/index/far https://gov.ecfr.io/cgi-bin/text-idx?SID=d9a7851186785ba2b1896db79b1b6b29&mc=true&tpl=/ecfrbrowse/Title48/48tab_02.tpl

52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 2026)

52.222-19 CHILD LABOR-COOPERATION WITH AUTHORITIES AND REMEDIES

(FEB 2026)

52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2026)

52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION

OF CONTRACT (FEB 2000)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING

WHILE DRIVING (MAY 2024)

52.228-3 WORKERS’ COMPENSATION INSURANCE (DEFENSE BASE ACT) (JUL

2014)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 INDIVIDUAL SURETY—PLEDGE OF ASSETS (FEB 2021)

52.228-13 ALTERNATIVE PAYMENT PROTECTION (JULY 2000)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY

2014)

52.232-8 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

52.232-11 EXTRAS (APR 1984)

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

52.232-22 LIMITATION OF FUNDS (FEB 2026)

52.232-25 PROMPT PAYMENT (JAN 2017)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER - SYSTEM FOR AWARD

MANAGEMENT (OCT 2018)

52.233-1 DISPUTES (MAY 2014) ALTERNATE I (DEC 1991)

52.233-3 PROTEST AFTER AWARD (JAN 2026)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (JAN 2026)

52.236-2 DIFFERING SITE CONDITIONS (AUG 2025)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (AUG

2025)

52.236-5 MATERIAL AND WORKMANSHIP (AUG 2025)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (AUG 2025)

52.236-7 PERMITS AND RESPONSIBILITIES (AUG 2025)

52.236-8 OTHER CONTRACTS (AUG 2025)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS (AUG 2025)

52.236-10 OPERATIONS AND STORAGE AREAS (AUG 2025)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (AUG 2025)

52.236-12 CLEANING UP (AUG 2025)

52.236-13 ACCIDENT PREVENTION (AUG 2025)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (AUG 2025)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (AUG 2025)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (AUG 2025)

52.240-93 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION

SYSTEMS (JAN 2026)

52.242-14 SUSPENSION OF WORK (APR 1984)

52.243-4 CHANGES (JUL 2025)

52.243-5 CHANGES AND CHANGED CONDITIONS (JUL 2025)

52.245-2 GOVERNMENT PROPERTY INSTALLATION OPERATION SERVICES

(APR 2012)

52.245-9 USE AND CHARGES (APR 2012)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

52.246-17 WARRANTY OF SUPPLIES OF A NONCOMPLEX NATURE (JUN 2003)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.246-26 REPORTING NONCONFORMING ITEMS (AUG 2024)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-

PRICE) (APR 2012)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.249-14 EXCUSABLE DELAYS (APR 1984)

I. FAR CLAUSES INCORPORATED IN FULL TEXT

52.213-4 TERMS AND CONDITIONS—SIMPLIFIED ACQUISITIONS

(NONCOMMERCIAL) (JAN 2026)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post acceptance rights—

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence. Examples of occurrences include acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. When an excusable delay occurs, the Contractor shall—

(1) Notify the Contracting Officer in writing as soon as possible;

(2) Remedy the delay as quickly as possible; and

(3) Notify the Contracting Officer when the occurrence is over.

(c) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(d) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. The Government will send a cure notice to the Contractor, unless the reason for the termination is late delivery. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(e) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of clause)

52.240-91 SECURITY PROHIBITIONS AND EXCLUSIONS (JAN 2026)

(a) Definitions. As used in this clause—

American Security Drone Act-covered foreign entity means an entity included on a list that the Federal Acquisition Security Council (FASC) develops and maintains and publishes in the System for Award Management (SAM) at https://www.sam.gov (section 1822 of Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

https://www.sam.gov/

Covered article, as defined in 41 U.S.C. 4713(k), means:

(1) Information technology, as defined in 40 U.S.C. 11101, including cloud computing services of all types;

(2) Telecommunications equipment or telecommunications service, as those terms are defined in section 3 of the Communications Act of 1934 (47 U.S.C. 153);

(3) The processing of information on a Federal or non-Federal information system, subject to the requirements of the Controlled Unclassified Information program (see 32 CFR part 2002); or

(4) Hardware, systems, devices, software, or services that include embedded or incidental information technology.

Covered foreign country means The People’s Republic of China.

Covered telecommunications equipment or services means—

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications…