RFQ N0018925QZ518_Static Display Move.pdf

SEE ADDENDUM

(No Collect Calls)

N0018925QZ518 28-Aug-2025

b. TELEPHONE NUMBER

215-697-9813

8. OFFER DUE DATE/LOCAL TIME

03:00 PM 04 Sep 2025

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

N001899. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

JACOB A. SEGAL

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

N0038320250859

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED ORX

SMALL BUSINESS

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

NAVSUP FLC NORFOLK PHILADELPHIA OFFICE

ATTN: JACOB SEGAL 700 ROBBINS AVENUE, BLDG. 2

PHILADELPHIA PA 19111-5083

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

FAX:

TEL: 215-697-9813

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$34,000,000

NAICS:

484121

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF49

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

N0018925QZ518

Section SF 30 - BLOCK 14 CONTINUATION PAGE

RFQ N0018925QZ518 NOTES:

This commercial acquisition is being solicited under a full and open competitive basis. Each Offeror will need to submit a Price quote in accordance with the CLIN structure (Labor/service CLIN and Transportation CLIN) detailed on the following page(s). These CLINs shall be Firm Fixed Price and the contracting team will evaluate each quote based on the total amount for both CLINs (i.e. total contract price). In addition, the offeror will need to submit two past performance references that show relevant experience relating to disassembly and assembly of aircraft, truck transportation of large vehicles/aircraft and static display set-up. The Past Performance Reference Sheet will be attached to the Sam.gov posting. This is an SCA covered contract, therefore, the applicable Wage determinations for both Pax River and Philadelphia will be included as attachments on the Sam.gov posting. The details of what is expected to be submitted and how they will be evaluated for an award is shown below.

SUBMISSION OF QUOTATIONS:

TRADEOFF PROCESS – IN ACCORDANCE WITH THE BEST VALUE CONTINUUM

All quotes – including past performance and price submission – shall be submitted electronically through email to

Mr. Jacob Segal at Jacob.a.segal.civ@us.navy.mil by the closing date/time of 04 September 2025 at 3:00 PM Eastern

Standard Time (EST). Questions can be submitted to Mr. Jacob Segal via email at jacob.a.segal.civ@us.navy.mil before 12:00 PM (noon) EST 02 September 2025.

Quotations submitted in response to this solicitation shall be valid for a minimum of 30 days from the closing date.

Quote shall be broken down into two (2) separate submissions:

➢ Past Performance Reference Sheets

➢ Price Quote

Past Performance:

The quoter shall demonstrate relevant past performance or affirmatively state that it possesses no relevant past performance. Relevant past performance is performance under contacts or efforts (within the past five years) that is of similar scope and magnitude to that which is described in the solicitation. Only a single set of up to Two (2) references shall be submitted.

To demonstrate its past performance, the quoter shall identify up to Two (2) of its most relevant contracts or efforts within the past five (5) years, and provide any other information the quoter considers relevant to the requirements of the solicitation. Quoters shall provide a detailed explanation demonstrating the relevance of the contracts or efforts to the requirements of the solicitation. If subcontractor experience is provided as part of the Two (2) of its most relevant contracts or efforts, the subcontractor experience will be given weight relative to the scope and magnitude of the aspects of the work under the solicitation that the subcontractor is proposed to perform. Therefore, the quoter’s submission shall detail clearly the aspects of the work in the solicitation that the subcontractor is proposed to perform.

The past performance references will be evaluated in the aggregate in order to allow quoters who may not have the entire scope and magnitude of the requirement under one (1) individual contract or effort to still be considered acceptable if past performance with the full scope and magnitude of the requirement can be demonstrated within the allotted number of references as described above.

The quoter should complete a “Past Performance Information Form” – which is included as a separate attachment to the solicitation – for each reference submitted. The forms will count toward the non-price submission page limit described above. For additional information regarding a particular reference beyond that which will fit on the form, the quoter may continue onto another sheet of paper. Such continuation sheet(s) for submitted references will count toward the non-price submission page limit. Only a single set of up to Two (2) references shall be submitted.

mailto:jacob.a.segal.civ@us.navy.mil

Price Quote:

Each Offeror will need to submit a Price quote in accordance with the CLIN structure (Labor/service CLIN and

Transportation CLIN) detailed on the following page(s). These CLINs are Firm Fixed Price and the contracting team will evaluate each quote based on the total amount for both CLINs (i.e. total contract price). The prices will be evaluated for price reasonableness.

EVALUATION CRITERIA AND THE BASIS FOR AWARD:

(1) The Government intends to award a single contract resulting from this solicitation to the responsible quoter whose submission represents the best value after evaluation in accordance with the factors and subfactors in the solicitation. The quoter’s non-price submission shall be in the form prescribed by, and shall contain a response to each of the areas identified in the solicitation provision entitled “SUBMISSION OF QUOTATIONS”. The evaluation of quotes will consider the quoter’s Past Performance submission be more important than the quoter’s price submission. Prices will be evaluated on the basis of price reasonableness.

The Contracting Officer reserves the right to determine that a quoter’s overall fixed price submission represents an unacceptable level of risk, based on the information submitted by the quoter, and/or based on the overall quote assessment described above.

In determining the rating for the Past Performance evaluation factor, the Government will give greater consideration to the contracts or efforts which the Government feels are most relevant to the requirements detail in this RFQ.

The Government reserves the right to obtain information for use in the evaluation of past performance from any and all sources including sources outside of the Government. A quoter determined to have no record of relevant past performance (or in an instance where no information on the quoter’s past performance is available), will not be evaluated favorably or unfavorably for the Past Performance factor. However, the submission of a quoter with no relevant past performance history, while not rated favorably or unfavorably for past performance, may not represent the most advantageous submission to the Government and thus, may be an unsuccessful submission when compared to the submission of other quoters. The quoter should provide the information requested above for past performance evaluation, or affirmatively state that it possesses no relevant directly related or similar past performance. If a quoter fails to provide any past performance information which is similar in scope and magnitude to that which is detailed in the RFQ or fails to affirmatively state that it possesses no relevant directly related or similar past performance, the submission may not be awardable. The Government will consider the quality of a quoter’s past performance. This consideration is separate and distinct from the Contracting Officer’s responsibility determination.

The assessment of the quoter’s past performance will be used as a means of evaluating the relative capability of the quoter and other competitors to successfully meet the requirements of the RFQ.

When a quoter is determined to have relevant past performance, the quality of its past performance will be evaluated; a quoter whose past performance demonstrates either a low expectation or no expectation that the quoter will be able to successfully perform the required effort will be considered ineligible for award.

The method of evaluation used by the Contracting Officer is solely within the discretion of the Contracting Officer.

The Government reserves the right to award the contract to other than the lowest priced quoter.

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot Services Related to the PWS

FFP

Services related to the disassembly, reassembly and positioning and harnessing the static display at NSA Philadelphia in accordance with the PWS.

FOB: Destination

PURCHASE REQUEST NUMBER: N0038320250859

PSC CD: V119

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Lot Transportation Cost

FFP

Transportation cost related to moving the AH-1Z from Pax River to NSA

Philadelphia in accordance with the PWS.

FOB: Destination

PURCHASE REQUEST NUMBER: N0038320250859

PSC CD: V119

NET AMT

PERFORMANCE WORK STATEMENT

NAVSUP WSS Aircraft Static Display (AH-1Z Cobra)

Performance Work Statement

Disassembly, transport, and reassembly of one (1) AH-1Z Cobra aircraft and associated engines bureau number

166760, from HX-21 at Patuxent River Air Station (Pax River) in Maryland to NSA Philadelphia in Pennsylvania.

Contract should include all labor, transportation, oversize permits, cranes, materials, and other miscellaneous costs related to the transport of the static display.

1. Contractor shall coordinate and arrange pickup, disassembly and loading of AH-1Z Cobra Aircraft from Pax

River. The Point of Contact for this requirement is John Tantoco, SARDIP and Display Manager for NAVSUP WSS, Philadelphia.

2. Contractor shall disassemble aircraft as required to make safe for transport and reassemble at final destination as required. Contractor will:

• Provide all labor, materials, and equipment for the disassembly, loading and assembly of the AH-1Z aircraft.

• Perform all work using established commercial practices for moving museum aircraft.

• Inspect aircraft for presence of charged fire bottles or other pyrotechnics. Report findings to COR.

• Disassemble AH-1Z aircraft into transportable sections for ground transportation or movement. Contractor is responsible for the safe transportation of the aircraft from Point A to Point B.

• Build any special jigs or fixtures necessary to secure parts for shipment.

• Plug and bag lines that may contain residual oil or hydraulic fluid to prevent leakage.

• Cover and secure with plastic sheeting any interior parts that will be exposed to the elements.

• Ensure that aircraft structural integrity is maintained.

• Ensure that disassembly is performed so as to preserve the historic material of the aircraft. Rivets are expendable; nuts, bolts and hardware should be preserved and kept with related assemblies whenever possible.

• Once transported to the final destination, the contractor is responsible for gaining base access, with the help of the NAVSUP POC, and reconstructing the AH-1Z aircraft back to its original form in the designated space shown below in Section 9.

• Due to the metal gate between the static display location and the nearby parking lot, the contractor may need a crane to lift the large aircraft pieces over the fence to be reconstructed at the final location. A walk-through before actual shipment may be needed to find the best path to transport and rebuild the aircraft while limiting disruption of the base activity.

• Ensure that all parts and identified and tagged or marked with noninvasive markers.

• Comply with US Navy and EPA regulations for disposal of fluids.

3. The US Navy will:

• Be responsible for final inspection and acceptance upon completion of work and prior to invoice submission.

4. The contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are damaged or broken during contract performance, or by careless operation of equipment, or by workmen, the contractor shall trim those limbs or branches with a clean cut and paint the tree with a tree-pruning compound.

5. The contractor shall also protect from damage all existing improvements and utilities both at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the contractor. The contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from the performance of work.

6. The contractor shall be responsible for obtaining any necessary licenses and permits, and for complying with any federal, state, and municipal laws, codes, and regulations applicable to the performance of work. The contractor shall also be responsible for all damages to persons or property as a result of the work being performed

7. The contractor shall at all times keep the work area, including storage areas, free from accumulations of waste materials. Before completing the work, the contractor shall remove from the premises any rubbish, tools, scaffolding, equipment, and materials that are not the property of the Government. Upon completing the work, the contractor shall leave the work area in a clean, neat, and orderly condition satisfactory to the contracting officer or his representative.

8. The contractor shall provide and maintain work environments and procedures which will:

a) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to the contractor operations and activities.

b) Avoid interruptions of Government operations and delays in project completion dates

c) Control costs in the performance of this contract.

9. Place of performance: Pick up location: Patuxent River Naval Air Station in St. Mary’s County, Maryland. Final

Destination of AH-1Z Cobra aircraft is to be positioned in front of NAVSUP WSS main office building (Building

#1) on concrete and rock pad (next to SH-60B) and safely secured. NAVSUP WSS in located at 700 Robbins Street in Philadelphia, PA 19111. The existing aircraft) in spot, pictured below, will be removed prior to arrival of AH-1Z

Cobra and the pad will be expanded to allow for the large display.

10 Period of performance: The work is expected to take place within 60-days from contract award.

ACCESS TO FEDERAL FACILITIES

Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Command’s Security Manager upon arrival to the Command and shall out-process prior to their departure at the completion of the individual’s performance under the contract.

START-UP PERIOD

All contractor resource onboarding documents must be submitted via the prime contractor. The prime contractor shall make all necessary preparations to assume full responsibility for productive performance of the performance start date.

Definition of “productive”:

a. Visit Authorization Request (VAR)

b. Contractor Information Sheet (CIS)

c. Completed EQIP (Electronic Investigation)

d. All contractor resource(s) must have an active JPAS profile.

e. Common Access Card (CAC)

Note (1): Invoicing by the contractor will begin as of the commencement of the performance period of services and no reimbursement will be paid by the government for efforts expended during the start-up period.

Note (2): Foreign Nationals are not allowed access to the functional/system side of Enterprise Resource Planning

(ERP).

ACCESS TO DOD INFORMATION TECHNOLOGY ( IT) SYSTEMS

In accordance with (IAW) Secretary of the Navy (SECNAV) M-5510.30, contractor employees who require access to DoN or DoD networks are categorized as IT-I, IT-II, or IT-III. The IT-II level, defined in detail in SECNAV M-

5510.30, includes positions which require access to sensitive information. Sensitive information includes information protected under the Privacy Act, to include Protected Health Information (PHI). All contractor employees under this contract who require access to Privacy Act protected information are therefore categorized no lower than IT-II. IT Levels are determined by the requiring activity’s Command Information System Security

Manager (ISSM)/Information Assurance Manager (IAM).

Contractor employees requiring privileged or IT-I level access, (when specified by the terms of the contract) require a Single Scope Background Investigation (SSBI) or T5 or T5R equivalent investigation , which is a higher level investigation than the National Agency Check with Law and Credit (NACLC)/T3/T3R described below. Due to the privileged system access, an investigation suitable for High Risk national security positions is required. Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain.

Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee’s duties, such employees shall in-process with the Navy Command’s CSM and ISSM/IAM upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Completion and approval of a

System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy

Information Technology resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-N; therefore, the government employee with knowledge of the system/network access required or the COR shall sign the SAAR-N as the “supervisor”.

The SAAR-N shall be forwarded to the Command’s Security Manager at least thirty (30) days prior to the individual’s start date. Failure to provide the required documentation at least thirty (30) days prior to the individual’s start date may result in delaying the individual’s start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all employees requiring access complete annual Cyber Awareness training, and maintain a current requisite background investigation. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

INTERIM ACCESS

The Command's Security Manager may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform.

DENIAL OR TERMINATION OF ACCESS

The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release.

CONTRACTOR’S SECURITY REPRESENTATIVE

The contractor shall designate an employee to serve as the Contractor’s Security Representative. Within three (3) working days after contract award, the contractor shall provide to the requiring activity’s Security Manager and the

Contracting Officer, in writing, the name, title, address and phone number for the Contractor’s Security

Representative. The Contractor’s Security Representative shall be the primary point of contact on any security matter. The Contractor’s Security Representative shall not be replaced or removed without prior notice to the

Contracting Officer and Command Security Manager.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR

CONTRACTORS ASSIGNED TO NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE

DUTIES

Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. Contractor employees under this contract are recognized as Non-

Critical Sensitive [ADP/IT-II] positions when the contract scope of work require physical access to a federally controlled base, facility or activity and/or requiring access to a DoD computer/network, to perform unclassified sensitive duties. This designation is also applied to contractor employees who access Privacy Act and Protected

Health Information (PHI), provide support associated with fiduciary duties, or perform duties that have been identified as National Security Positions. At a minimum, each contractor employee must be a US citizen and have a favorably completed NACLC or T3 or T3R equivalent investigation to obtain a favorable determination for assignment to a non-critical sensitive or IT-II position. The investigation consists of a standard NAC and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or IT-II position is required to complete:

• SF-86 Questionnaire for National Security Positions (or equivalent OPM investigative product)

• Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission)

• Original Signed Release Statements

Failure to provide the required documentation at least thirty (30) days prior to the individual’s start date shall result in delaying the individual’s start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than ten (10) years) throughout the contract performance period. The

Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the CSM upon arrival to the command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy

Command’s ISSM/IAM. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The SAAR-N shall be forwarded to the Navy Command’s Security Manager at least thirty (30) days prior to the individual’s start date.

Failure to provide the required documentation at least thirty (30) days prior to the individual’s start date shall result in delaying the individual’s start date.

The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual

Cyber Awareness training, and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the Command Security Manager. The

Command’s Security Manager will review the submitted documentation for completeness prior to submitting it to the Office of Personnel Management (OPM); Potential suitability or security issues identified may render the contractor employee ineligible for the assignment. An unfavorable determination is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract. The Command’s Security Manager will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DoD Central Adjudication Facility (CAF) for a determination.

If the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Authorization Request (VAR) via the Joint Personnel Adjudication System (JPAS) or a hard copy

VAR directly from the contractor’s Security Representative. Although the contractor will take JPAS “Owning” role over the contractor employee, the Navy command will take JPAS "Servicing" role over the contractor employee during the hiring process and for the duration of assignment under that contract. The contractor shall include the IT

Position Category per SECNAV M-5510.30 for each employee designated on a VAR. The VAR requires annual renewal for the duration of the employee’s performance under the contract.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR

CONTRACTORS ASSIGNED TO OR PERFORMING NON-SENSITIVE DUTIES

Contractor employee whose work is unclassified and non-sensitive (e.g., performing certain duties such as lawn maintenance, vendor services, etc. ...) and who require physical access to publicly accessible areas to perform those duties shall meet the following minimum requirements:

• Must be either a US citizen or a US permanent resident with a minimum of three (3) years of legal residency in the United States (as required by The Deputy Secretary of Defense DTM 08-006 or its subsequent DoD instruction); and

• Must have a favorably completed National Agency Check with Written Inquiries (NACI) or T1 investigation equivalent including a FBI fingerprint check prior to installation access.

To be considered for a favorable trustworthiness determination, the Contractor’s Security Representative must submit for all employees each of the following:

• SF-85 Questionnaire for Non-Sensitive Positions

• Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission)

• Original Signed Release Statements

The contractor shall ensure each individual employee has a current favorably completed National Agency Check with Written Inquiries (NACI) or T1 equivalent investigation, or ensure successful FBI fingerprint results have been gained and investigation has been processed with OPM

Failure to provide the required documentation at least thirty (30) days prior to the individual’s start date may result in delaying the individual’s start date.

* Consult with your CSM and ISSM/IAM for local policy when IT-III (non-sensitive) access is required for non-US citizens outside the United States.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.204-7 System for Award Management NOV 2024

52.204-13 System for Award Management Maintenance OCT 2018

52.204-16 Commercial and Government Entity Code Reporting AUG 2020

52.204-18 Commercial and Government Entity Code Maintenance AUG 2020

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.204-29 Federal Acquisition Supply Chain Security Act Orders--

Representation and Disclosures.

DEC 2023

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.212-4 Contract Terms and Conditions--Commercial Products and

Commercial Services

NOV 2023

52.222-41 Service Contract Labor Standards AUG 2018

52.222-44 Fair Labor Standards And Service Contract Labor Standards-

Price Adjustment

MAY 2014

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.237-1 Site Visit APR 1984

52.242-13 Bankruptcy JUL 1995

52.247-35 F.O.B. Destination, Within Consignee's Premises APR 1984

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023

252.204-7012 (Dev) Safeguarding Covered Defense Information and Cyber

Incident Reporting (DEVIATION 2024-O0013 REVISION

1)

MAY 2024

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

JAN 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense

Telecommunications Equipment or Services

JAN 2023

252.225-7048 Export-Controlled Items JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006

252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JAN 2023

252.243-7002 Requests for Equitable Adjustment DEC 2022

252.244-7000 Subcontracts for Commercial Products or Commercial

Services

NOV 2023

252.247-7023 Transportation of Supplies by Sea OCT 2024

CLAUSES INCORPORATED BY FULL TEXT

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services--

Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-

Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph

(d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause

52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or

Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ___ ] will, [ ___ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The

Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as

OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered

(include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as

OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered

(include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT

2020)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain

Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

https://www.sam.gov/

(c) Representations.

(1) The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

(SEP 2023)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code(s) and small business size standard(s) for this acquisition appear elsewhere in the solicitation. However, the small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(1) Is set aside for small business and has a value above the simplified acquisition threshold;

(2) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(3) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at Federal Acquisition Regulation (FAR) 52.212-3

(see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with FAR subpart 4.10), or alternative commercial products or commercial services for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a…