RFQ 12760424Q0065.pdf

Request for Quote #12760424Q0065

Software for Bridge Management

USDA Forest Service

Table of Contents

SECTION I: INTRODUCTION

1.1 Purpose

1.2 Contract Type

1.3 Pricing Structure

SECTION II: PRICING SCHEDULE

SECTION III – CONTRACT ADMINISTRATION DATA

3.1 Contracting Officer (CO)

3.2 Administrative Contract Specialist

3.3 Contracting Officer’s Representative (COR)

3.4 Commitment to Protect Sensitive Information

3.5 Data Rights

3.6 Invoicing

3.7 Non-personal Services

3.8 Government Down Time for Various Authorities Including the President, USDA Forest Service

SECTION IV- APPLICABLE CLAUSES/PROVISIONS

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998) 52.204-26 Covered Telecommunications Equipment or Services-Representation. (OCT 2020)

SECTION V - CONTRACT ADMINISTRATION DATA

5.1 Invoice Submission Procedures

SECTION VI--LIST OF ATTACHMENTS

PART II--REPRESENTATIONS AND INSTRUCTIONS

SECTION VII--REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF

OFFERORS OR RESPONDENTS

AGAR 452.219-70 Size Standard and NAICS Code Information (SEP 2001)

SECTION VIII--INSTRUCTIONS, CONDITIONS, AND NOTICES TO QUOTERS

8.1 FAR 52.216-1 Type of Contract (APR 1984)

8.2 AGAR 452.204-70 Inquiries (FEB 1988)

8.3 FAR 52.212-1 Instructions to Offerors – Commercial Products and Commercial Services

8.4 General Instructions for Responses

8.5 Submission of Offers/Delivery Instructions:

8.6 Preparation Instructions:

8.7 Restrictions on Disclosure and Use of Data

8.8 Submission of Written Questions:

8.9 General Instructions:

SECTION IX – DETAILED SUBMISSION INSTRUCTIONS

9.1 Table of Factors

SECTION X – EVALUATION FACTORS FOR AWARD

10.1 Method of Award

10.2 Evaluation Plan

A. Evaluation Factors and Relative Order Of Importance B. Responsibility Determination C. Adjectival Ratings:

D. Non-Price Factors E. Price Factor

10.3 Evaluation of Options

SECTION I: INTRODUCTION

1.1 Purpose

The purpose of this request for quote (RFQ) is for the procurement of a commercial off the shelf software for bridge management that is fully configured for the Specification for National Bridge Inventory

(SNBI).

1.2 Contract Type

This is for a firm-fixed-price purchase order placed under NAICS 541519 as a 100% Small Business set-aside. Must be an authorized reseller or partner if applicable.

1.3 Pricing Structure

Pricing will be based on the total price offered for each period of performance relative to the identified contract line-item structure listed below.

SECTION II: PRICING SCHEDULE

*Pricing can be on schedule of items provided

SECTION III – CONTRACT ADMINISTRATION DATA

3.1 Contracting Officer (CO)

The CO for this requirement is currently identified as follows:

Cree Prevost

CLIN Description Type Qty Unit Unit Price

Amount

Base Period – May 1, 2024 through April 30, 2025 0001 Base Year: FFP 12 Mo $ $

Option Period 1 – May 1, 2025 through April 30, 2026 1001 Option Year 1 FFP 12 Mo $ $

Option Period 2 – May 1, 2026 through April 30, 2027 2001 Option Year 2 FFP 12 Mo $ $

Option Period 3 – May 1, 2027 through April 30, 2028 3001 Option Year 3 FFP 12 Mo $ $

Option Period 4 – May 1, 2028 through April 30, 2029 4001 Option Year 4 FFP 12 Mo $ $

Procurement & Property Services (PPS) National Procurement Operations Information Technology Contracting Branch (ITCB) 4000 Masthead ST NE Albuquerque, NM 87109 Phone: 707-562-8897 E-mail: cree.prevost@usda.gov

3.2 Administrative Contract Specialist

The Administrative Contract Specialist (ACS) for this requirement is currently identified as follows:

Troy Boudro

Procurement & Property Services (PPS) National Procurement Operations Information Technology Contracting Branch (ITCB) 4000 Masthead ST NE Albuquerque, NM 87109 Phone: 530-560-5619 E-mail: troy.boudro@usda.gov

The CO has the overall responsibility for the administration of this contract. The Contracting Officer, without delegation, is authorized to take actions on behalf of the Government to amend, modify or deviate from the contract terms, conditions, requirements, specifications, details and/or delivery schedules. However, the Contracting Officer may delegate certain other responsibilities to his/her authorized representative.

3.3 Contracting Officer’s Representative (COR)

The Primary COR for this requirement is currently identified as follows:

Roger Garza

Chief Information Office 4000 Masthead ST NE Albuquerque, NM 87109 Phone: 505-563-7408 E-mail: rogelio.garza@usda.gov

The COR monitors all technical aspects of the contract and assists in contract administration. The COR is authorized to perform the following functions:

• Assure that the Contractor performs the technical requirements of the contract: perform inspections necessary in connection with contract performance;

• Maintain written and oral communications with the Contractor concerning technical aspects of the contract;

• Issue written interpretations of technical requirements to the Contracting Officer, including applicable Government drawings, designs, specifications;

• Monitor Contractor's performance and notifies both the Contracting Officer and Contractor of any deficiencies; and

• Coordinate availability of government furnished property, and provide site entry of Contractor personnel.

mailto:cree.prevost@usda.gov mailto:troy.boudro@usda.gov mailto:rogelio.garza@usda.gov

A letter of designation issued to the COR, a copy of which is sent to the Contractor, states the responsibilities and limitations of the COR, especially with regard to changes in cost or price, estimates or changes in delivery dates.

The COR is not authorized to change any of the terms and conditions of the resulting contract or order.

3.4 Commitment to Protect Sensitive Information

The Contractor must not release, publish, or disclose sensitive information to unauthorized personnel, and shall protect such information in accordance with provisions of the following laws and any other pertinent laws and regulations governing the confidentiality of sensitive information: 18 U.S. C. 641 (Criminal Code: Public Money, Property or Records)

The Contractor agrees to maintain the confidentiality of any information regarding project-related data and artifacts. Data includes personally identifiable information (PII), disclosure of which is regulated by the Privacy Act of 1974, PL 93-579, amended.

3.5 Data Rights

The Government will retain rights to all intellectual property and data produced in the course of this award instrument.

3.6 Invoicing

Invoice Processing Platform (IPP) is added to this order. The Invoice submission is changed to require the use of the online Invoice Processing Platform (IPP). The Invoice Processing Platform (IPP) is a Web-based system that more efficiently manages government invoicing from purchase order (PO) through payment notification. IPP is a secure online platform outside federal agencies' core financial systems that centralizes all invoice transaction data and documents in one place. The U.S. Department of the Treasury's Financial Management Service offers IPP, and the Federal Reserve Bank of Boston manages its implementation and operations. The National Finance Center (NFC) began notifying USDA existing contractors that IPP online registration is required for doing business with USDA. Visit https://www.ipp.gov/ to enroll. The Contractor must now submit invoices online via the Invoice Processing Platform (IPP) for existing and new awards.

Invoice Details: The Contractor’s invoice must be completely detailed to include, but not be limited to: Order number; period of service (i.e. January 1-31, 2018), full description of services provided; labor category (if applicable); contract line item billed against; number of hours billed against the specific line item; unit price;

extended price; invoice total; Contractor name, address, telephone and contact person; invoice number and date; and GSA Federal Supply Schedule Contract number. Incorrect invoices will be rejected and returned to the Contractor.

Invoice against Line Item: The Contractor must identify and invoice against each individual line item in accordance with the applicable order for service.

Invoice Billing Schedule: The Contract must identify an Invoice Billing Schedule in each proposal. The Contractor shall not bill in advance of services being performed. The Contractor shall submit no more than one (1) invoice per month for the previous month’s services. The Contractor must note in the price proposal whether the contractor intends to bill monthly or upon completion of all services for the applicable order.

Final Invoice, Release of Claims Required To Closeout Orders and the Contract Completion Statement: The Contractor must complete and submit Release of Claim & Contract Completion Statement (signed by the COR/TPM) to the Order COR and Order Contracting Officer not later than 15 business days, after submission of the Contractor’s final invoice (which completes services) through the online Invoice Processing Platform (IPP) and after all remaining unliquidated balances have been deobligated by the Order Contracting Officer via modification, which is needed for the closeout process.

https://www.ipp.gov/

3.7 Non-personal Services

(a) The services to be performed under this contract do not require the contractor or his/her personnel to exercise personal judgment and discretion on behalf of the Government.

(b) The Government will neither supervise Contractor employees nor control the method by which the

Contractor performs the required tasks. Under no circumstances shall the Government assign tasks to, or prepare work schedules for individual Contractor employees. It shall be the responsibility of the Contractor to manage their employees and to guard against any actions that are of the nature of personal services, or give the perception of personal services. If the Contractor feels that any actions constitute, or are perceived to constitute personal services, it shall be the Contractor’s further responsibility to notify the CO immediately.

(c) These services shall not be used to perform work which are inherently Government functions. All decisions relative to programs supported will be the sole responsibility of the Government.

3.8 Government Down Time for Various Authorities Including the President, USDA Forest Service

(a) Facility Closures Due to Emergencies. From time to time, the Forest Service may decide to close all or part of a facility in response to an unforeseen emergency or similar occurrence. Sample emergencies include, but are not limited to, adverse weather such as snow or flood, an act of God such as a tornado or earthquake, acts of war or terrorism, computer failures or a base disaster such as a natural gas leak or fire. Contractor personnel are "non-essential personnel" for purposes of any instructions regarding the emergency.

(1) Contractor shall be officially dismissed upon notification of a facility closure in accordance with paragraph b. Contractor shall promptly secure all government furnished property appropriately and evacuate in an expedient but safe manner.

(2) With regard to work under the contract, the government shall retain the following options:

(i) Government may grant a time extension in the contract, delayed by the closure equal to the time of the closure, subject to the availability of funds.

(ii) Government may forego the work. The contractor will not be paid for work not performed.

(iii) Government may reschedule the work on any day satisfactory to both parties.

(iv) The government may, in its discretion, permit the contractor to perform at an off-site location during the period of facility closure if meaningful work can be accomplished. Contractor shall certify to the government by letter within 5 businesses days of returning to work the nature and scope of the work completed off-site. Contractor shall be permitted to bill the government at the labor rates identified in the contract.

(v) In rare instances, Government may request that the Contractor continue on-site performance during the facility closure period. Such a request shall be subject to agreement by Contractor.

(b) Facility Closure Notification Procedures.

(1) After an official decision to close the facility has been made by the USFS, local television and radio stations will be notified of the closure.

(2) The Contractor is directed to listen or watch one of the local radio or television stations for notification of a facility closure. Contractor should follow instructions intended for non-essential personnel.

(3) The contractor will not receive any other form of notification of a facility closure from the government. The Contractor is responsible for notification of his or her employees.

(4) If the decision to close all or part of the agency is made during the duty day, and the USFS or

Chief’s decision is transmitted through official notification channels, the Contractor shall follow the instructions as given. Contractor personnel shall notify their COR and act in accordance with the Contract Officer Representative’s (COR) instruction.

(c) Agency Closure Due to Non-Emergencies. The USFS or USDA FS may elect to close all or part of the facility for non-emergency reasons such as time-off award, open house, etc. In the event of a non-emergency closure, the COR and the Contractor shall jointly choose a course of action within the following options:

(1) If there is a need for the service during the closure the Contractor may continue on-site work.

Contractor shall bill the Government in accordance with the contract.

(2) If there is a need for work during the closure but access will not be available, the Contractor may work off-site provided meaningful work may be accomplished. Contractor shall certify to the government by letter within 5 business days or returning on-site the nature and scope of the work completed off-site. Contractor shall bill the Government at the labor rates specified in the contract.

If there is no need for the service during a scheduled closure, contractor shall not work on or off-site.

Government may grant a time extension by the closure equal to the amount of time of the closure, subject to the availability of funds. The government will not be liable for time not worked.

SECTION IV- APPLICABLE CLAUSES/PROVISIONS

All applicable clauses and provisions as per the GSA Schedule and corresponding Federal Supply Schedule (FSS) are in effect for this Order.

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR: www.acquisition.gov/far AGAR: https://www.dm.usda.gov/procurement/policy/agar.htm

AGAR 452.211-5 PERIOD OF PERFORMANCE (FEB 1988)

Base Period: Months 1-12 Option Period 1: Months 13-24 Option Period 2: Months 25-36

Option Period 3: Months 37-48 Option Period 4: Months 49-60

(x) Representations and Certifications (complete highlighted items in this section and return with your offer)

VENDOR NAME: _____________________________________________

VENDOR UEI: _____________________________________________

https://www.acquisition.gov/far/52.252-2 http://www.acquisition.gov/far https://www.dm.usda.gov/procurement/policy/agar.htm

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021) (Provision)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Products or Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(d) Representation. The Offeror represents that—

(1) It ☐ will, ☐ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It ☐ does, ☐ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number;

and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number;

and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26 Covered Telecommunications Equipment or Services-Representation. (OCT 2020)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

https://www.acquisition.gov/far/52.204-25#FAR_52_204_25

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) ( https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c)

(1) Representation. The Offeror represents that it □ does, □ does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it □ does, □ does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

(End of provision)

(a) This solicitation sets forth the Government’s known delivery requirements for data (as defined in the clause at 52.227-14, Rights in Data--General). Any resulting contract may also provide the Government the option to order additional data under the Additional Data Requirements clause at 52.227-16, if included in the contract. Any data delivered under the resulting contract will be subject to the Rights in Data--General clause at 52.227-14 included in this contract. Under the latter clause, a Contractor may withhold from delivery data that qualify as limited rights data or restricted computer software, and deliver form, fit, and function data instead. The latter clause also may be used with its Alternates II and/or III to obtain delivery of limited rights data or restricted computer software, marked with limited rights or restricted rights notices, as appropriate. In addition, use of Alternate V with this latter clause provides the Government the right to inspect such data at the Contractor’s facility.

(b) By completing the remainder of this paragraph, the offeror represents that it has reviewed the requirements for the delivery of technical data or computer software and states [offeror check appropriate block]—

[ ] (1) None of the data proposed for fulfilling the data delivery requirements qualifies as limited rights data or restricted computer software; or

[ ] (2) Data proposed for fulfilling the data delivery requirements qualify as limited rights data or restricted computer software and are identified as follows:

(c) Any identification of limited rights data or restricted computer software in the offeror's response is not determinative of the status of the data should a contract be awarded to the offeror.

https://www.sam.gov/

(End of provision)

52.204-29 Federal Acquisition Supply Chain Security Act Orders—Representation and Disclosures (Dec 2023)

(a) Definitions. As used in this provision, Covered article, FASCSA order, Intelligence community, National security system, Reasonable inquiry, Sensitive compartmented information, Sensitive compartmented information system, and Source have the meaning provided in the clause 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition.

(b) Prohibition. Contractors are prohibited from providing or using as part of the performance of the contract any covered article, or any products or services produced or provided by a source, if the prohibition is set out in an applicable Federal Acquisition Supply Chain Security Act (FASCSA) order, as described in paragraph (b)(1) of FAR 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition.

(c) Procedures.

(1) The Offeror shall search for the phrase “FASCSA order” in the System for Award Management (SAM)(https://www.sam.gov) for any covered article, or any products or services produced or provided by a source, if there is an applicable FASCSA order described in paragraph (b)(1) of FAR 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition.

(2) The Offeror shall review the solicitation for any FASCSA orders that are not in SAM, but are effective and do apply to the solicitation and resultant contract (see FAR 4.2303(c)(2)).

(3) FASCSA orders issued after the date of solicitation do not apply unless added by an amendment to the solicitation.

(d) Representation. By submission of this offer, the offeror represents that it has conducted a reasonable inquiry, and that the offeror does not propose to provide or use in response to this solicitation any covered article, or any products or services produced or provided by a source, if the covered article or the source is prohibited by an applicable FASCSA order in effect on the date the solicitation was issued, except as waived by the solicitation, or as disclosed in paragraph (e).

(e) Disclosures. The purpose for this disclosure is so the Government may decide whether to issue a waiver. For any covered article, or any products or services produced or provided by a source, if the covered article or the source is subject to an applicable FASCSA order, and the Offeror is unable to represent compliance, then the Offeror shall provide the following information as part of the offer:

(1) Name of the product or service provided to the Government;

(2) Name of the covered article or source subject to a FASCSA order;

https://www.acquisition.gov/far/part-52#unique_629880050 https://www.acquisition.gov/far/part-52#unique_629880050 https://www.sam.gov/ https://www.acquisition.gov/far/part-52#unique_629880050 https://www.acquisition.gov/far/part-4#FAR_4_2303

(3) If applicable, name of the vendor, including the Commercial and Government Entity code and unique entity identifier (if known), that supplied the covered article or the product or service to the Offeror;

(4) Brand;

(5) Model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

(6) Item description;

(7) Reason why the applicable covered article or the product or service is being provided or used;

(f) Executive agency review of disclosures. The contracting officer will review disclosures provided in paragraph (e) to determine if any waiver may be sought. A contracting officer may choose not to pursue a waiver for covered articles or sources otherwise subject to a FASCSA order and may instead make an award to an offeror that does not require a waiver.

52.209-7 Information Regarding Responsibility Matters (OCT 2018) ) (Provision)

(a)Definitions. As used in this provision—

Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b)The offeror ☐ has ☐does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c)If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i)In a criminal proceeding, a conviction.

(ii)In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii)In an administrative proceeding, a finding of fault and liability that results in–

(A)The payment of a monetary fine or penalty of $5,000 or more; or

(B)The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv)In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d)The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov. See 52.204-7.

52.212-3 Offeror Representations and Certifications – Commercial Products and Commercial Services (NOV 2023) (DEVIATION NOV 2022) (Provision)

[If Offeror Representations and Certifications are not complete in SAM the offeror shall submit a completed copy of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Products and Commercial Services, with your offer. The full provision is available from http://www.acquisition.gov/far/.

If Offeror Representations and Certifications are complete in SAM, the offeror shall complete the following:]

(b)(1) Annual Representations and Certifications. Any changes provided by the Offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications in SAM.

(2) The offeror has completed the annual representations and certifications electronically in SAM accessed through http://www.sam.gov. After reviewing SAM information, the Offeror https://www.sam.gov/ file:///C:%5CUsers%5Cmelissaajohnson%5CDownloads%5C(DEVIATION%20NOV%202022)%20%E2%80%93%20Offerors%20that%20are%20representing%20as%20joint%20ventures%20should%20submit%20their%20socio-economic%20status%20in%20the%20space%20provided%20above%20until%20such%20time%20that%20SAM.gov%20has%20been%20updated%20to%20include%20the%20joint%20venture%20representations%20contained%20within http://www.acquisition.gov/far/ http://www.sam.gov/ verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Products and Commercial Services, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard(s) applicable to the NAICS code(s) referenced for this solicitation), at the time this offer is submitted and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________.

[Offeror to identify the applicable paragraphs at (c) through (v) of this provision that the offeror has completed for the purposes of this solicitation only, if any. Write “None” if there are no changes needed to your online reps and certs.

DEVIATION NOV 2022] Offerors that are representing as joint ventures should submit their socio-economic status in the space provided above until such time that SAM.gov has been updated to include the joint venture representations contained within provision 52.212-3 paragraph (c).

52.212-4 Contract Terms and Conditions – Commercial Products and Commercial Services (NOV 2023)

52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders– Commercial Products and Commercial Services (DEC 2023)[DEVIATION JAN 2024]

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31

U.S.C.3903 and 10 U.S.C. 3801)

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-

78 (19 U.S.C. 3805note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] ☒ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (June 2020), with Alternate I

(Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

☐ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1060550 https://www.acquisition.gov/content/part-4-administrative-and-information-matters#i1121876 https://www.usda.gov/sites/default/files/documents/far-class-deviation-regarding-threshold-small-disadvantaged-business.pdf https://www.usda.gov/sites/default/files/documents/far-class-deviation-regarding-new-trade-agreements-thresholds.pdf

☐ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

☐ (4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) (Whistleblower Guidance to Contractor Employees)

☒ (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note).

☐ (6) [Reserved].

☒ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of

Div. C).

☐ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016)

(Pub. L. 111-117, section 743 of Div. C).

☒ (9) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division

R of Pub. L. 117-328).

☐ (10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders – Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts (Dec 2023) (Pub. L. 115-390) ☒ (11)(i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders – Prohibition. (Dec 2023)

(Pub. L. 115-390, title II) ☐ (ii) Alternate I (Dec 2023) of 52.204-30.

☒ (12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Nov 2021) (31 U.S.C. 6101note).

☒ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

☐ (14) [Reserved].

☐ (15) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) (15 U.S.C.657a).

☐ (16) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct

2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

☐ (17) [Reserved] ☒ (18) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C.644).

☐ (ii) Alternate I (Mar 2020) of 52.219-6.

☐ (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

☐ (ii) Alternate I (Mar 2020) of 52.219-7.

☒ (20) 52.219-8, Utilization of Small Business Concerns (Sep 2023) (15 U.S.C. 637(d)(2) and (3)).

☐ (21) (i) 52.219-9, Small Business Subcontracting Plan (Sep 2023) (15 U.S.C. 637(d)(4)).

☐ (ii) Alternate I (Nov 2016) of 52.219-9.

☐ (iii) Alternate II (Nov 2016) of 52.219-9.

☐ (iv) Alternate III (Jun 2020) of 52.219-9.

☐ (v) Alternate IV (Sep 2023) of 52.219-9.

☐ (22) (i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

☐ (ii) Alternate I (MAR 2020) of 52.219-13

☒ (23) 52.219-14, Limitations on Subcontracting (Oct 2022) (15 U.S.C.637s) [Contracting Officer check as appropriate.]

☐ By the end of the base term of the contract and then by the end of each subsequent option period; or https://view.officeapps.live.com/op/view.aspx?src=https%3A%2F%2Fcontent.govdelivery.com%2Fattachments%2FUSDAPSD%2F2023%2F04%2F04%2Ffile_attachments%2F2456937%2FWhistleblower%2520Guidance.docx&wdOrigin=BROWSELINK https://view.officeapps.live.com/op/view.aspx?src=https%3A%2F%2Fcontent.govdelivery.com%2Fattachments%2FUSDAPSD%2F2023%2F04%2F04%2Ffile_attachments%2F2456937%2FWhistleblower%2520Guidance.docx&wdOrigin=BROWSELINK

☐ By the end of the performance period for each order issued under the contract.

☐ (24) 52.219-16, Liquidated Damages-Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)).

☐ (25) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Oct 2022) (15

U.S.C. 657f).

☐ (26) (i) 52.219-28, Post Award Small Business Program Rerepresentation (Sep 2023) (15 U.S.C.

632(a)(2)).

☐ (ii) Alternate I (MAR 2020) of 52.219-28.

☐ (27) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

☐ (28) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C.

637(m)).

☐ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C.

644(r)).

☐ (30) 52.219-33, Nonmanufacturer Rule (Sep 2021) (15 U.S.C. 637(a)(17)).

☒ (31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

☒ (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Nov 2023) (E.O.13126).

[DEVIATION JAN 2024]

☒ (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

☒ (34) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

☐ (ii) Alternate I (Feb 1999) of 52.222-26.

☒ (35) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

☐ (ii) Alternate I (Jul 2014) of 52.222-35.

☒ (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C.793).

☐ (ii) Alternate I (Jul 2014) of 52.222-36.

☒ (37) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

☒ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010)

(E.O. 13496).

☒ (39) (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O.

13627).

☐ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter78 and E.O. 13627).

☒ (40) 52.222-54, Employment Eligibility Verification (May 2022). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

☐ (41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

☐ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

☐ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

☐ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693).

https://www.usda.gov/sites/default/files/documents/far-class-deviation-regarding-new-trade-agreements-thresholds.pdf

☐ (44) (i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

☐ (ii) Alternate I (Oct 2015) of 52.223-13.

☐ (45) (i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

☐ (ii) Alternate I (Jun 2014) of 52.223-14.

☐ (46) 52.223-15, Energy Efficiency in Energy-Consuming Products (May 2020) (42 U.S.C. 8259b).

☐ (47) (i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015)

(E.O.s 13423 and 13514).

☐ (ii) Alternate I (Jun 2014) of 52.223-16.

☒ (48) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Jun 2020) (E.O. 13513).

☐ (49) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

☐ (50) 52.223-21, Foams (Jun 2016) (E.O. 13693).

☐ (51) (i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

☐ (ii) Alternate I (Jan 2017) of 52.224-3.

☐ (52)(i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83).

☐(ii) Alternate I (Oct 2022) of 52.225-1 ☐ (53) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) (19 U.S.C.

3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

☐(ii) Alternate I [Reserved] ☐(iii) Alternate II (Dec 2022) of 52.225-3.

☐(iv) Alternate III (Nov 2023) of 52.225-3 [DEVIATION JAN 2024].

☐(v) Alternate IV (Oct 2022) of 52.225-3.

☐ (54) 52.225-5, Trade Agreements (Nov 2023) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

☒ (55) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

☐ (56) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct

2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

☐ (57) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

☐ (58) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42

U.S.C. 5150).

☐ (59) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

☐ (60) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services

(Nov 2021) (41 U.S.C.4505, 10 U.S.C.3805).

☐ (61) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov

2021) (41 U.S.C.4505, 10 U.S.C.3805).

☒ (62) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2018)

(31 U.S.C. 3332).

☐ (63) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management

(Jul 2013) (31 U.S.C.3332).

https://www.usda.gov/sites/default/files/documents/far-class-deviation-regarding-new-trade-agreements-thresholds.pdf

☐ (64) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C.3332).

☒ (65) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

☐ (66) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

☐ (67) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46

U.S.C. 55305 and 10 U.S.C. 2631).

☐ (ii) Alternate I (Apr 2003) of 52.247-64.

☐ (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

Contracting Officer check as appropriate.] ☐ (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

☐ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41

U.S.C. chapter 67).

In compliance with the Service Contract Labor Standards statute and the regulations of the Secretary of Labor (29 CFR Part 4), this clause identifies the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C.5341 or 5 332.

☐ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

☐ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

☐ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C.

chapter 67).

☐ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

☐ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

☐ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

☐ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C.

1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized…