Amend_0001_Final.pdf

(x)

R14PS00615

x x

7 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Boise ID 83706-1234 1150 N. Curtis Road, Ste. 100

R10

Acquisition Management Division Regional Office Pacific Northwest Region Bureau of Reclamation

10/03/2014000001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

10/03/2014

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

A. Project Title: P/G 7-12 Unit Switchgear Replacements, John W. Keys III Pump-Generating

Plant, Columbia Basin Project, WA

B. The time and date for receipt of proposals has been EXTENDED 2:00 PM Mountain Time, December 12, 2014.

C. Acknowledgment: See block 11 above regarding how to acknowledge this amendment. The acknowledgment must be received at the place designated for receipt of offers (see block 8 of "Solicitation, Offer and Award" Standard Form 1442).

Note: The SF-30 indicates it is only one page, however, it is actually 4 pages in length.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Rebecca L. Thomson

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

R14PS00615/000001

----Con't on Page 3----

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

D. Offer Modification: See block 11 above if you have submitted your offer and now desire to modify or withdraw it.

E. Third Party: If you have given your copy of the solicitation to someone else, please forward this amendment accordingly.

For Information Only: See attached List of Site Visit Attendees; site visit held October 28, 2014.

NOTE: An additional site visit is scheduled for November 20, 2014, at 9:00 AM, PT.

Participants will meet at Grand Coulee Power Office, Industrial Area, Grand Coulee, WA 99133. The meeting will be held in the Property Office Conference Room. (Map will be sent to those that sign up.)

All participants MUST sign up No Later Than 2:00 PM PT on November 18, 2014. Limit of 3 people per company. The point of contact for registration is Danny Moyer at (509) 633-3952, email dmoyer@usbr.gov. You must provide the following information to register: Company Name, Phone Number, List of Attendees (Name(s)), (e-mail address optional), and state if anyone is a Foreign National. If any Foreign Nationals will be in attendance, submit a copy of their passport information no later than 2:00 PM on November 12, 2014. PPE will be required Hard Hat, Safety Shoes, Safety Glasses with side shields, Photography is not allowed. Do not provide any Personnel Identification Information (i.e. Social Security Numbers).

NOTE: The following changes are hereby incorporated into the solicitation. Single-sided replacement pages are provided following this Standard Form 30 and changes are shown with left side bar or shaded. Offerors who¿ve prepared 2-sided copies of the solicitation may wish to attach the one-sided revised pages to the original version in order to preserve the reverse side of the original page.

F. In the SF-1442, "Solicitation, Offer, and Award" form -- Clarification: Page 3 column "A" titled "Item No'". the term "item no." is synonymous with the term "Contract Line Item Number".

G. In Table of Contents, the following page is deleted and the attached revised page is substituted therefore:

Remove Page Insert Revised Page ii, iv, vi, vii, and viii ii, iv , vi, vii, and viii

H. In Section C, Description/Specifications/Statement of Work, the following pages are deleted and the attached revised pages are substituted therefore:

Remove Pages Insert Revised Pages 013119-1 013119-1 013300-1 013300-1 013300-4 and -5 013300-4 and -5 013300-7 thru -12 013300-7 thru -12 260502-2 260502-2 260504-1 thru 260504-6 260504-1 thru 260504-6 and new page 260504-7 260506-1 thru 260506-11 260506-1 thru 260506-11 260520-1 260520-1 260520-5 and -6 260520-5 and -6 261721-7 261721-7 and new page 261721-7a 261721-18 261721-18 and new page 261721-18a 261721-22 261721-22 520000-1 thru 520000-7 520000-1 thru 520000-7 and new pages 520000-8 thru -12 Add Appendix A - Photographs (pgs 1 - 33)

In Drawings the following drawings are deleted and the attached revised drawings are substituted therefore:

Remove Drawings Insert Revised Drawings None 2a. 222-D-52788

None 2b. 222-D-52788 None 32a. 222-D-25065 None 36a. 222-D-24556 None 39a. 222-D-25110 None 39b. 222-D-25115 40a. 222-D-25110 40a. 222-D-25368

Solicitation No.R14PS00615 P/G 7-12 Unit Switchgear Replacements, John W. Keys III Pump-Generating Plant

Amendment 001

Remove Drawings (con’t) Insert Revised Drawings (con’t) None 53a. 222-D-24346 63a. 222-D-24806 62a. 222-D-24806 63b. 222-D-24807 62b. 222-D-24807 63c. 222-D-24808 62c. 222-D-24808 63d. 222-D-24809 62d. 222-D-24809 63e. 222-D-24810 62e. 222-D-24810

I. In Section F, Deliveries and Performance, the following page is deleted and the attached revised pages are substituted therefore:

Remove Page Insert Revised Page F-1 F-1

J. In Section H, Special Contract Requirements, the following pages are deleted and the attached revised pages are substituted therefore:

Remove Page Insert Revised Page H-1 and H-2 H-1 and H-2

K. In Section I, Contract Clauses, the following pages are deleted and the attached revised pages are substituted therefore:

Remove Page Insert Revised Page I-34 thru -47 I-34 thru -47 I-122 I-122 I-150 and -151 I-150 and -151

L. In Section J, List of Documents, Exhibits, and Other Attachments,the following pages are deleted and the attached pages are substituted therefore:

Remove Page Insert Revised Page J-1 J-1

General Wage Decision General Wage Decision

WA140070, dated 8/12/2014 WA140070, dated October 17, 2014) (Pgs 1-7)

M. In Section K, Representations, Certifications and Other Statements of Offerors or Respondents,the following pages are deleted and the attached pages are substituted therefore:

Remove Page Insert Revised Page K-1 thru -5 K-1 thru -5

N. In Section L, Instructions, Conditions, and Notices to Offerors or Respondents, the following page is deleted and the attached page is substituted therefore:

Remove Page Insert Revised Page L-12 thru -17 L-12 thru - 17

Solicitation No. R14PS00615 P/G 7-12 Unit Switchgear Replacements, John W. Keys, III Pump-Generating Plant

Amendment No. 001

Contents (Revised) ii

DIVISION 26 - ELECTRICAL

26 05 02 Basic Electrical Materials and Method 26 05 04 Electrical Demolition Modification and Removal 26 05 06 Repair of Unit PG12 Circuit 26 05 20 Conductors and Cables 26 05 26 Grounding and Bonding 26 05 33 Electrical Conduit 26 05 80 Wiring Checkout and Tests 26 17 21 13.8kV Pump-Generator Unit Switchgear Assemblies

DIVISIONS 27 THROUGH 50 – NOT USED

DIVISION 51 INFORMATION AVAILABLE TO OFFERORS

51 00 00 Information Available to Offerors 51 02 83 Hazardous Material Results

DIVISION 52 - DRAWINGS

52 00 00 Drawings

APPENDIX A – PHOTOGRAPHS

SECTION D PACKAGING AND MARKING .......................................................................... D-1

SECTION E INSPECTION AND ACCEPTANCE ................................................................... E-1 E.1. 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984) ................................. E-1 E.2. 52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996) .............................. E-1 E.3. 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994) .............................. E-3

SECTION F DELIVERIES OR PERFORMANCE .................................................................. F-1

F.1. 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION

OF WORK (APR 1984) ............................................................................................ F-1

F.2. 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEPT 2000) ............. F-1

F.3. 52.242-14 SUSPENSION OF WORK (APR 1984) .................................................. F-1

SECTION G CONTRACT ADMINISTRATION DATA ......................................................... G-1

G.1. 1452.201-70 AUTHORITIES AND DELEGATIONS--DEPARTMENT OF

THE INTERIOR (MAY 2010) ................................................................................. G-1

G.2. ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS-

INVOICE PROCESSING PLATFORM (IPP) (APRIL 2013) ................................ G-2

SECTION H SPECIAL CONTRACT REQUIREMENTS ....................................................... H-1 H.1. DELETE ................................................................................................................... H-1

H.2. AUTHORIZED WORKERS NOTICE TO POTENTIAL BUREAU OF

RECLAMATION CONTRACTORS (SEP 2002) ................................................... H-2

H.3. CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (JULY 2010) ............................................................................................ H-4

Amendment No. 001

Contents (Revised) iv

I.23. 52.215-2 AUDIT AND RECORDS--NEGOTIATION (OCT 2010) ........... I-27

I.24. 52.215-8 ORDER OF PRECEDENCE--UNIFORM CONTRACT

FORMAT (OCT 1997) ................................................................................. I-29

I.25. 52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED

COST OR PRICING DATA--MODIFICATION (AUG 2011) ................... I-29

I.26. 52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING

DATA--MODIFICATIONS (OCT 2010) ..................................................... I-31

I.27. 1452.215-70 EXAMINATION OF RECORDS BY THE

DEPARTMENT OF THE INTERIOR (AUG 1996) (DEVIATION) ........... I-32

I.28. 52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING

DATA AND DATA OTHER THAN CERTIFIED COST OR

PRICING DATA—MODIFICATIONS (OCT 2010) .................................. I-32

I.29. CONTRACTOR'S TECHNICAL PROPOSAL INCORPORATED

INTO CONTRACT - BUREAU OF RECLAMATION - PN REGION

(MAR 2001) .................................................................................................. I-33

I.30. 52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR

HUBZONE SMALL BUSINESS CONCERNS (OCT 2014) ...................... I-34

I.31. 52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (OCT

2014) ............................................................................................................. I-36

I.32. 52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (OCT

2014) – ALTERNATE I (OCT 2001) ........................................................... I-38

I.33. 52.219-16 LIQUIDATED DAMAGES--SUBCONTRACTING PLAN

(JAN 1999).................................................................................................... I-47

I.34. 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM

REREPRESENTATION (JUL 2013) ........................................................... I-48

I.35. 52.222-3 CONVICT LABOR (JUNE 2003) ................................................ I-50

I.36. 52.222-4 CONTRACT WORK HOURS AND SAFETY

STANDARDS -OVERTIME COMPENSATION (MAY 2014) ................. I-51

I.37. 52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS

(MAY 2014).................................................................................................. I-52 I.38. 52.222-7 WITHHOLDING OF FUNDS (MAY 2014) ................................ I-54

I.39. 52.222-8 PAYROLLS AND BASIC RECORDS (MAY 2014) ................... I-55

I.40. 52.222-9 APPRENTICES AND TRAINEES (JULY 2005) ........................ I-56

I.41. 52.222-10 COMPLIANCE WITH COPELAND ACT

REQUIREMENTS (FEB 1988) .................................................................... I-58

I.42. 52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014) ..... I-58

I.43. 52.222-12 CONTRACT TERMINATION--DEBARMENT (MAY

2014) ............................................................................................................. I-59

I.44. 52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE

REQUIREMENTS AND RELATED REGULATIONS (MAY 2014) ........ I-60

I.45. 52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB

1988) ............................................................................................................. I-60

I.46. 52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014) .................. I-60

I.47. 52.222-21 PROHIBITION OF SEGREGATED FACILITIES (FEB

1999) ............................................................................................................. I-60 I.48. 52.222-26 EQUAL OPPORTUNITY (MAR 2007) ..................................... I-61

Amendment No. 001

Contents (Revised) vi

I.75. 52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999) ............... I-94

I.76. 52.228-15 PERFORMANCE AND PAYMENT BONDS-

CONSTRUCTION (OCT 2010) ................................................................... I-97

I.77. 1452.228-70 LIABILITY INSURANCE-DEPARTMENT OF THE

INTERIOR (JUL 1996) ................................................................................ I-99

I.78. WBR 1452.228-84 CERTIFICATION OF REPRESENTATIVES

FOR CORPORATE SURETIES--BUREAU OF RECLAMATION

(SEP 1996) .................................................................................................... I-99

I.79. 52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013) ............ I-99

I.80. WBR 1452.231-81 EQUIPMENT OWNERSHIP AND OPERATING

EXPENSE -- BUREAU OF RECLAMATION (JUL 1998) ...................... I-101

I.81. 52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION

CONTRACTS (MAY 2014) ....................................................................... I-103 I.82. 52.232-17 INTEREST (MAY 2014) .......................................................... I-106

I.83. WBR 1452.232-80 LIMITATION OF FUNDS (FIXED-PRICE

CONTRACT) -- BUREAU OF RECLAMATION (SEPT 2003) .............. I-107

I.84. 52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014) ............................. I-109

I.85. 52.232-27 PROMPT PAY FOR CONSTRUCTION CONTRACTS

(MAY 2014)................................................................................................ I-109

I.86. 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER-

SYSTEM FOR AWARD MANAGEMENT (JUL 2013) .......................... I-118

I.87. 52.232-39 UNENFORCEABILITY OF UNAUTHORIZED

OBLIGATIONS (JUN 2013) ...................................................................... I-119

I.88. 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL

BUSINESS SUBCONTRACTORS (DEC 2013) ....................................... I-120

I.89. WBR 1452.232-81 PAYMENT FOR MOBILIZATION AND

PREPARATORY WORK --BUREAU OF RECLAMATION (MAY

2000) ........................................................................................................... I-120

I.90. WBR 1452.232-82 OTHER INVOICE REQUIREMENTS --

BUREAU OF RECLAMATION (DEC 2002) ........................................... I-122

I.91. WBR 1452.232-83 PAYMENT FOR TECHNICAL DATA --

BUREAU OF RECLAMATION (DEC 1994) ........................................... I-122

I.92. 52.233-1 DISPUTES (MAY 2014) ALTERNATE I (DEC 1991) ............. I-123

I.93. 52.233-3 PROTEST AFTER AWARD (AUG 1996) ................................. I-124

I.94. 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT

CLAIM (OCT 2004) ................................................................................... I-125

I.95. WBR 1452.233-81 CLAIMS ACCOUNTING -- BUREAU OF

RECLAMATION (JUL 1993) .................................................................... I-125

I.96. 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR

(APR 1984) ................................................................................................. I-125 I.97. 52.236-2 DIFFERING SITE CONDITIONS (APR 1984) ......................... I-125

I.98. 52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING

THE WORK (APR 1984) ........................................................................... I-126

I.99. 52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR

1984) ........................................................................................................... I-126

I.100. 52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991) ................. I-127

Amendment No. 001

Contents (Revised) vii

I.101. 52.236-8 OTHER CONTRACTS (APR 1984) (DEVIATION) ................. I-127

I.102. 52.236-9 PROTECTION OF EXISTING VEGETATION,

STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)................................................................. I-127

I.103. 52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984) ........... I-127

I.104. 52.236-11 USE AND POSSESSION PRIOR TO COMPLETION

(APR 1984) ................................................................................................. I-128 I.105. 52.236-12 CLEANING UP (APR 1984) .................................................... I-128

I.106. 52.236-13 ACCIDENT PREVENTION (NOV 1991) - ALTERNATE

I (NOV 1991) .............................................................................................. I-129

I.107. 52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES

(APR 1984) ................................................................................................. I-130

I.108. 52.236-21 SPECIFICATIONS AND DRAWINGS FOR

CONSTRUCTION (FEB 1997)- ALTERNATE I (APR 1984) ................. I-130

I.109. 52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995) .............. I-131

I.110. WBR 1452.236-84 PRESERVATION OF CULTURAL

RESOURCES – BUREAU OF RECLAMATION (FEB 2000) ................. I-131

I.111. WBR 1452.237-80 SECURITY REQUIREMENTS – BUREAU OF

RECLAMATION (FEBRUARY 2011) ALTERNATE III (OCT 2006) ... I-133

I.112. PN REGION IMPLEMENTATION OF SECURITY

REQUIREMENTS – CONSTRUCTION CONTRACTS .......................... I-144

I.113. 52.242-13 BANKRUPTCY (JUL 1995)..................................................... I-145 I.114. 52.243-4 CHANGES (JUNE 2007) ............................................................ I-145

I.115. 52.243-6 CHANGE ORDER ACCOUNTING (APR 1984) ...................... I-146

I.116. WBR 1452.243-80 MODIFICATION PROPOSALS -- BUREAU OF

RECLAMATION (DEC 2001) ALTERNATES IV (JUL 1998) ............... I-146

I.117. 52.244-2 SUBCONTRACTS (OCT 2010) ................................................. I-147

I.118. 52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (OCT

2014) ........................................................................................................... I-150

I.119. 52.247-64 PREFERENCE FOR PRIVATELY OWNED U.S.-FLAG

COMMERCIAL VESSELS (FEB 2006) ................................................... I-151

I.120. 52.248-3 VALUE ENGINEERING—CONSTRUCTION (OCT 2010)

- ALTERNATE I (APR 1984) .................................................................... I-154

I.121. 52.249-2 TERMINATION FOR CONVENIENCE OF THE

GOVERNMENT (FIXED-PRICE) (APR 2012)-ALTERNATE I (SEP

1996) ........................................................................................................... I-157

I.122. 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR

1984) ........................................................................................................... I-160

I.123. 52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984) ...... I-161

I.124. 52.253-1 COMPUTER GENERATED FORMS (JAN 1991) .................... I-161

PART III

LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J LIST OF ATTACHMENTS ....................................................................... J-1

Amendment No. 001

Contents (Revised) viii

PART IV

REPRESENTATIONS AND INSTRUCTIONS

SECTION K REPRESENTATIONS, CERTIFICATIONS, AND OTHER

STATEMENTS OF OFFERORS OR RESPONDENTS ........................ K-1

K.1. 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS

(OCT 2014) ................................................................................................... K-1

K.2. 52.209-7 INFORMATION REGARDING RESPONSIBILITY

MATTERS (JUL 2013) ................................................................................ K-5

K.3. NOTICE TO HUBZONE SMALL BUSINESS CONCERNS

REGARDING WAIVER OF PRICE EVALUATION PREFERENCE

ADJUSTMENT - BUREAU OF RECLAMATION - PN REGION

(APR 2001) ................................................................................................... K-7

SECTION L INSTRUCTIONS, CONDITIONS, AND NOTICES TO

OFFERORS OR RESPONDENTS ............................................................L-1

L.1. 52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE

GSA INDEX OF FEDERAL SPECIFICATIONS, STANDARDS

AND COMMERCIAL ITEM DESCRIPTIONS, FPMR PART 101-29

(AUG 1998) ................................................................................................... L-1

L.2. 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN

THE GSA INDEX OF FEDERAL SPECIFICATIONS,

STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS (JUN

1988) .............................................................................................................. L-1

L.3. 52.211-6 BRAND NAME OR EQUAL (AUG 1999) (DEVIATION) ......... L-1

L.4. WBR 1452.211-80 NOTICE OF INTENT TO ACQUIRE METRIC

PRODUCTS AND SERVICES - BUREAU OF RECLAMATION

(MAR 1993) ................................................................................................... L-2

L.5. 52.215-1 INSTRUCTIONS TO OFFERORSBCOMPETITIVE

ACQUISITION (JAN 2004) .......................................................................... L-3

L.6. 52.215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING

DATA OR INFORMATION OTHER THAN CERTIFIED COST OR

PRICING DATA (OCT 2010) ....................................................................... L-7

L.7. 1452.215-71 USE AND DISCLOSURE OF PROPOSAL

INFORMATION--DEPARTMENT OF THE INTERIOR (APR 1984) ....... L-8

L.8. WBR 1452.215-80 SOURCE EVALUATION AND SELECTION

PROCEDURES--BUREAU OF RECLAMATION (MAY 2005) .............. L-10

L.9. WBR 1452.215-81 GENERAL PROPOSAL INSTRUCTIONS--

BUREAU OF RECLAMATION (JAN 1998)-ALTERNATE I .................. L-12

L.10. WBR 1452.215-82 TECHNICAL PROPOSAL INSTRUCTIONS--

BUREAU OF RECLAMATION (APR 2001) ............................................ L-14

L.11. WBR 1452.215-83 PRICING PROPOSAL INSTRUCTIONS--

BUREAU OF RECLAMATION (JAN 1998) ............................................. L-17

Amendment No. 001

(Revised) Project Management and Coordination

01 31 19 - 1

SECTION 01 31 19

PROJECT MANAGEMENT AND COORDINATION

PART 1 GENERAL

1.01 COST

A. Include in prices offered in the schedule for other items of work.

B. If the Contractor fails to attend a required meeting, an equitable adjustment will be made to the contract price.

1.02 REFERENCE STANDARDS

A. Bureau of Reclamation (USBR)

1. RSHS-2009 Reclamation Safety and Health Standards

1.03 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals:

1. RSN 01 31 19-1, Pre-Design Meeting Notification:

a. Provide confirmation regarding requested date and time of meeting and indicate who will be attending and affiliations.

1) Provide copies of preliminary layout drawings.

2. RSN 01 31 19-2, Design and Progress Review Meetings Notification:

a. Provide confirmation regarding requested date and time of meeting and indicate who will be attending and affiliations.

1.04 PROJECT COORDINATION

A. The following meetings are considered significant, but do not relieve the Contractor from the responsibility of attending other meetings required by the specifications. The Preconstruction Conference described in clause 52.236-26 is a separate meeting requirement from the meetings listed in this section.

1. Contractor Safety Program Review: See RSHS Section 3 for requirements.

a. This meeting will take place in conjunction with the pre-design meeting.

2. Pre-Design Meeting:

a. Date: No later than forty-five (45) days after receipt of Notice to Proceed and prior to performing work on the required RSNs for the equipment listed below:

1) PG7-PG12 Unit Switchgear Replacements

Amendment No. 001

(Revised) Submittals

01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 COST

A. Include in prices offered in the schedule for other items of work unless otherwise specified.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-2012 Decimal Inch Drawing Sheet Size and Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-2011 United States National CAD Standards, Version 5

1.03 DEFINITIONS

A. Days: Calendar days.

B. PMWFS: Project Management Work Flow System. See Section 01 31 30 – Internet Based Project Management Work Flow System.

C. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

D. Submittal Types, as listed in Table 01 33 00A – List of Submittals:

1. A – Approval:

a. Government will approve or disapprove these submittals.

b. Approval submittals are considered to be “shop drawings” within the terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction.

2. I – Informational:

a. The Government will acknowledge receipt of these submittals.

b. The Government may reject an Informational submittal when the submittal does not comply with the contract. The Contractor shall correct mistakes or deficiencies in rejected Informational submittals and resubmit.

c. Informational submittals are considered to be “shop drawings” within the terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by the Government is not required, Amendment No. 001

(Revised) Submittals

01 33 00 - 4

B. Submit complete sets of required materials for each RSN as specified in "Submittals Required" column in Table 01 33 00A - List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit number of sets specified in "Sets to be sent:" columns in Table 01 33 00A - List of Submittals.

1. Submittals identified with “PMWFS” in the “Sets to be sent” column shall be submitted electronically in accordance with Section 01 31 30 – Internet Based Project Management Work Flow System.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 28 days after receiving the comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

F. More than one RSN may be submitted under a transmittal letter, provided the responsible code is the same.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 28 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through PMWFS response data or return mailing postmark date, as applicable.

B. Time in Excess of Specified:

1. The CO may extend the contract completion date to allow additional time for completing work affected by excess review time.

Amendment No. 001

(Revised) Submittals

01 33 00 - 5

a. The time extension will be to the extent that excess review time caused delay to the contract completion date.

b. The time extension will not exceed the time used in excess of the specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of two or more separate submittals or resubmittals will be counted only once in extending the contract completion date.

2. No time extension will be allowed if the Contractor fails to make complete approval submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to the extent that:

a. Approval was required under the contract, and

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR 52.242-14, Suspension of Work, however, no such delay shall be deemed to be a "suspension order" as the term is used in that clause.

C. Return of Submittals:

1. Return of submittals will be by PMWFS response or hard copy, as applicable.

2. Action Submittals: One set of submittals required for action will be returned either approved, approved subject to identified changes, or not approved

a. Revise and resubmit submittals not approved.

b. Do not change designs without approval of the CO after drawings, documentation, and technical data have been approved.

3. Informational Submittals: The Government will acknowledge Informational submittals.

a. Informational submittals will not be returned when they comply with the specifications.

b. Informational submittals that do not comply with the specifications may be returned for resubmittal or additional information may be requested.

1.07 TRANSMITTAL

A. PMWFS, (electronic), submittals:

1. Download complete submittal and transmittal in accordance with Section 01 31 30 – Internet Based Project Management Work Flow System.

2. Send copy of transmittal letter to CO via e-mail. E-mail address will be provided after award.

Submittals

01 33 00 - 7

Table 01 33 00A - List of Submittals

* Submittal types: A – Approval, I – Information ** Y indicates the submittal is required to be shown on the Construction Schedule - see the Clause at

WBR 1452.242.93 - Construction Program *** CO indicates Contracting Officer, FE indicates Field Engineer, PM indicates Project Manager, TSC indicates

Technical Service Center, and PMWFS indicates Project Management Work Flow System.

RSN

Clause or

Section Title

Submittals required

Due date or Delivery time

Type

CP

Respon- Sible code

Sets to be sent:

CO FE PM TSC

1 Release of claims (1452.204-70)

Release of claims (DI-137) against United States

After completion of work and prior to final payment

I FE PMWFS

2 Payroll and Basic Records (52.222-8)

Certified payrolls Weekly for each week any contract work is performed on site

I FE PMWFS

3 Labor standards data (52.222-11)

(1) List of subcontractors

(2) Statement and Acknowledgment Form (SF-1413) for each subcontract

Within 14 days after award of contract, and within 14 days after award of any subcontract

I FE PMWFS

4 Bonds (52.222-15)

Performance and payment bonds

Within 10 calendar days after award

I CO 1 0 0 0

5 Equal opportunity (52.222-26)

Information required by Executive Order

11246 (SF-100)

Within 30 days following award

I FE PMWFS

Deleted

7 Safety and Health (WBR 1452.223-81)

Monthly accident summary report

First day of month.

See paragraph 3.8 of RSHS

I FE PMWFS

8 Liability insurance (1452.228-70)

Acceptable evidence showing that insurance has been obtained

Prior to commencement of work under the contract

I FE 1 1 0 0

9 Security Requirements

(WBR

1452.237-80)

List of employees requiring access to Government facility.

(See para. (c)(3))

Before start of contract performance, and before start of individual employee performance when there is a change.

01 33 00 - 8

Table 01 33 00A - List of Submittals

* Submittal types: A – Approval, I – Information ** Y indicates the submittal is required to be shown on the Construction Schedule - see the Clause at

WBR 1452.242.93 - Construction Program *** CO indicates Contracting Officer, FE indicates Field Engineer, PM indicates Project Manager, TSC indicates

Technical Service Center, and PMWFS indicates Project Management Work Flow System.

RSN

Clause or

Section Title

Submittals required

Due date or Delivery time

Type

CP

Respon- Sible code

Sets to be sent:

CO FE PM TSC

10 Security Requirements

(WBR

1452.237-80)

List of onsite employees. (See para. (c)(4)(iii))

At least 10 days before employee arrival onsite

I FE PMWFS

01 14 10-1 Use of Site Land use and landscape rehabilitation plan

At least 28 days before use of Government land

A FE PMWFS

01 14 30-1 Interruption of Service

Interruption of Service Request

At least 14 days before interruption of service

I FE PMWFS

01 31 19-1 Project Management and Coordination

Pre-Design Meeting notification

At least 14 days before meeting

A FE PMWFS

01 31 19-2 Project Management and Coordination

Design and progress review meeting notification

At least 48 hours before meeting

A FE PMWFS

01 31 30-1 Internet Based Project Management Work Flow System

Qualifications Within 7 days after Notice to Proceed

A FE 1 2 1 1

01 31 30-2 Internet Based Project Management Work Flow System

System Documentation

Within 7 days after Notice to Proceed

A FE 1 2 1 1

01 35 10-1 Material Safety Data Sheets

Complete LHM and

MSDS

At least 14 days before starting on site work

I FE PMWFS

01 35 10-2 Material Safety Data Sheets

Updated LHM and

MSDS

At least 14 days before jobsite delivery of each hazardous material

I FE PMWFS

01 35 20-1 Safety and Health

Emergency action plans written program and training records

Submitted and accepted before starting onsite work.

01 33 00 - 9

Table 01 33 00A - List of Submittals

* Submittal types: A – Approval, I – Information ** Y indicates the submittal is required to be shown on the Construction Schedule - see the Clause at

WBR 1452.242.93 - Construction Program *** CO indicates Contracting Officer, FE indicates Field Engineer, PM indicates Project Manager, TSC indicates

Technical Service Center, and PMWFS indicates Project Management Work Flow System.

RSN

Clause or

Section Title

Submittals required

Due date or Delivery time

Type

CP

Respon- Sible code

Sets to be sent:

CO FE PM TSC

01 35 20-2 Safety and Health

General safety and health provisions, written safety program, and regular safety inspection records

Submitted and accepted before starting onsite work.

A FE PMWFS

01 35 20-3 Safety and Health

Job hazard analysis Submitted and accepted before starting onsite work.

A FE PMWFS

01 35 30-1 Contractor’s Onsite Safety Representative

Resume At least 28 days before starting onsite work

I FE PMWFS

01 35 30-2 Contractor’s Onsite Safety Representative

Safety Inspection Reports.

At least once each week

I FE PMWFS

01 54 20-1 Use of Government Cranes and Elevators

Crane Operator Qualifications

At least 14 days before disassembly

I FE PMWFS

01 54 20-2 Use of Government Cranes and Elevators

Crane Use Schedule Monthly I FE PMWFS

01 56 10-1 Protection of Existing Installations

Plan for protecting existing installations

At least 28 days before starting onsite work

A FE PMWFS

01 56 10-2 Protection of Existing Installations

Survey of existing floors

At least 28 days before starting work in pump generating plant

I FE PMWFS

01 74 00-1 Cleaning and Waste Management

Waste management and disposal plan

At least 28 days before starting onsite work

A FE PMWFS

01 74 00-2 Cleaning and Waste Management

Waste production and disposal records

Within 5 days of waste disposal

01 33 00 - 10

Table 01 33 00A - List of Submittals

* Submittal types: A – Approval, I – Information ** Y indicates the submittal is required to be shown on the Construction Schedule - see the Clause at

WBR 1452.242.93 - Construction Program *** CO indicates Contracting Officer, FE indicates Field Engineer, PM indicates Project Manager, TSC indicates

Technical Service Center, and PMWFS indicates Project Management Work Flow System.

RSN

Clause or

Section Title

Submittals required

Due date or Delivery time

Type

CP

Respon- Sible code

Sets to be sent:

CO FE PM TSC

01 74 00-3 Cleaning and Waste Management

Environmental consultant resume

At least 28 days before beginning environmental assessment

I FE PMWFS

01 74 00-4 Cleaning and Waste Management

Environmental site assessment

Within 14 days of completion of work

I FE PMWFS

01 78 30-1 Project Record Documents

As-Built drawings Within 14 days after completion of onsite work

A FE 0 2 0 0

01 79 20-1 Training Training materials:

1) Hard copies 2)CD-Rom or DVD

At least 14 days before start of training

I FE

02 83 33-1 Removal and Disposal of Coatings Containing Heavy Metals

Resumes At least 30 days before beginning onsite work

I FE PMWFS

02 83 33-2 Removal and Disposal of Coatings Containing Heavy Metals

Written compliance program for worker protection

At least 30 days before beginning onsite work

A FE PMWFS

02 83 33-3 Removal and Disposal of Coatings Containing Heavy Metals

Plans At least 30 days before beginning onsite work

A FE PMWFS

02 83 33-4 Removal and Disposal of Coatings Containing Heavy Metals

Certificate of disposal or recycling documentation

Within 14 days after disposal

I FE PMWFS

03 62 20-1 Nonshrink Grout

Packaged nonshink grout data

At least 28 days before placing grout

A FE PMWFS

26 05 04-1 Electrical Demolition and Removal

Electrical Outage and Demolition Request

At least 10 days before outage.

A FE PMWFS

01 33 00 - 11

Table 01 33 00A - List of Submittals

* Submittal types: A – Approval, I – Information ** Y indicates the submittal is required to be shown on the Construction Schedule - see the Clause at

WBR 1452.242.93 - Construction Program *** CO indicates Contracting Officer, FE indicates Field Engineer, PM indicates Project Manager, TSC indicates

Technical Service Center, and PMWFS indicates Project Management Work Flow System.

RSN

Clause or

Section Title

Submittals required

Due date or Delivery time

Type

CP

Respon- Sible code

Sets to be sent:

CO FE PM TSC

26 05 06-1 Repair of Unit PG12 Circuit

Report of Equipment Condition

Within 60 days of Notice to Proceed

A 86-68430 PMWFS

26 05 06-2 Repair of Unit PG12 Circuit

Isolated-Phase Bus Approval Drawings and Data

Within 60 days after approval of

RSN 26 05 06-1

A 86-68430 PMWFS

26 05 06-3 Repair of Unit PG12 Circuit

Power and Control Cable Approval Data

Within 120 days after Notice to Proceed

A 86-68430 PMWFS

26 05 06-4 Repair of Unit PG12 Circuit

Final Drawings and Data

At least 60 days prior to installation

A 86-68430 PMWFS

26 05 06-5 Repair of Unit PG12 Circuit

Removal Plan and Procedures

At least 90 days before removal

A 86-68430 PMWFS

26 05 06-6 Repair of Unit PG12 Circuit

Isolated-Phase Bus Factory Test Reports

Within 10 days after tests are completed

A 86-68430 PMWFS

26 05 06-7 Repair of Unit PG12 Circuit

Field Test Reports Within 10 days after tests are completed

A FE PMWFS

26 05 20-1 Conductors and Cables

Approval Data Within 120 days after receipt of Notice to Proceed

A 86-68430 PMWFS

26 05 20-2 Conductors and Cables

Field Test Reports Within 10 days after tests are completed

A FE PMWFS

26 05 80-1 Wiring Checkout and Tests

Test Reports Within 10 days after tests are completed

A FE PMWFS

26 17 21-1 13.8-kV Pump Generator Unit Switchgear Assemblies

Paint sample Within 90 days after receipt of Notice to Proceed

A FE 0 1 0 0

26 17 21-2 13.8-kV Pump Generator Unit Switchgear Assemblies

Approval Drawings and Data

Within 90 days after receipt of Notice to Proceed

A 86-68430 PMWFS

26 17 21-3 13.8-kV Pump Generator Unit Switchgear Assemblies

Factory Test Notification

At least 14 days before factory tests

I 86-68430 PMWFS

01 33 00 - 12

Table 01 33 00A - List of Submittals

* Submittal types: A – Approval, I – Information ** Y indicates the submittal is required to be shown on the Construction Schedule - see the Clause at

WBR 1452.242.93 - Construction Program *** CO indicates Contracting Officer, FE indicates Field Engineer, PM indicates Project Manager, TSC indicates

Technical Service Center, and PMWFS indicates Project Management Work Flow System.

RSN

Clause or

Section Title

Submittals required

Due date or Delivery time

Type

CP

Respon- Sible code

Sets to be sent:

CO FE PM TSC

26 17 21-4 13.8-kV Pump Generator Unit Switchgear Assemblies

Factory Test Reports

Within 10 days after tests are completed

I 86-68430 PMWFS

26 17 21-5 13.8-kV Pump Generator Unit Switchgear Assemblies

Training Notification and Data

At least 45 days before first installation

A FE PMWFS

26 17 21-6 13.8-kV Pump Generator Unit Switchgear Assemblies

Field Test Notification

At least 14 days before field tests

I 86-68430 PMWFS

26 17 21-7 13.8-kV Pump Generator Unit Switchgear Assemblies

Field Test Reports Within 10 days after tests are completed

A FE PMWFS

26 17 21-8 13.8-kV Pump Generator Unit Switchgear Assemblies

Final Documentation

Within 28 days after is completion of installation of each unit

A 86-68430 0 2 1 2

END OF SECTION

Basic Electrical Materials and Methods

26 05 02 - 2

1. NETA ATS-2013 Acceptance Testing Specifications for Electrical Power Equipment and Systems

E. National Fire Protection Association (NFPA)

1. NFPA 70-2014 National Electrical Code (NEC)

1.03 SYSTEM DESCRIPTION

A. Contractor shall be responsible for completely integrating equipment control and station service associated with the new equipment into the existing Plant control and station service systems.

1. Refer to specifications drawings for existing Plant electrical systems and associated wiring diagrams (also see Project Conditions below).

2. Work shall include wiring, including terminations, to the existing Plant electrical systems and ‘as-building’ specifications drawings (not including manufacturer’s drawings), as directed by COR, in accordance with Section 01 78 30 – Project Record Documents.

1.04 QUALIFICATIONS

A. Welder Qualifications: In accordance with ASME BPVC-IX.

B. Field Installation Electrician(s): Current state electrician license, any U.S. state.

C. Field Testing Organization and Personnel: As specified in NETA ATS, Section 3, except may be accredited by other than NETA.

1.05 PROJECT CONDITIONS

A. This facility is over 40 years old and as such the drawings, especially layout drawings, included in these specifications, may not truly represent existing conditions. Contractor shall be responsible for assessing actual conditions and applying them to their designs, work, and equipment as opposed to relying solely on conditions shown on the drawings.

1.06 EXTRA MATERIALS

A. Furnish Government with special tools and equipment necessary to properly install, adjust, test, and check operation of electrical equipment.

B. Deliver to Grand Coulee Power Office (GCPO) as directed by COR.

C. Extra materials shall be onsite prior to installation of equipment.

Electrical Demolition and Removal

26 05 04 - 1

SECTION 26 05 04

ELECTRICAL DEMOLITION, MODIFICATION, AND REMOVAL

PART 1 GENERAL

1.01 PAYMENT

A. Demolition and Removal of Unit 7 Switchgear Assembly:

1. Payment: Lump sum price offered in the Schedule.

a. Includes cost of removal and disposal of equipment and low-voltage cable.

1) Does not include compressed air system.

B. Demolition and Removal of Unit 8 Switchgear Assembly :

1. Payment: Lump sum price offered in the Schedule.

a. Includes cost of removal and disposal of equipment and low-voltage cable.

1) Does not include compressed air system.

C. Demolition and Removal of Unit 9 Switchgear Assembly:

1. Payment: Lump sum price offered in the Schedule.

a. Includes cost of removal and disposal of equipment and low-voltage cable.

1) Does not include compressed air system.

D. Demolition and Removal of Unit 10 Switchgear Assembly:

1. Payment: Lump sum price offered in the Schedule.

a. Includes cost of removal and disposal of equipment and low-voltage cable.

1) Does not include compressed air system.

E. Demolition and Removal of Unit 11 Switchgear Assembly:

1. Payment: Lump sum price offered in the Schedule.

a. Includes cost of removal and disposal of equipment and low-voltage cable.

1) Does not include compressed air system.

F. Demolition and Removal of Unit 12 Switchgear Assembly:

1. Payment: Lump sum price offered in the Schedule.

a. Includes cost of removal and disposal of equipment and low-voltage cable.

1) Does not include compressed air system.

26 05 04 - 2

G. Modification of Ground Switch ZY6A-5380:

1. Cost: Include in work for furnishing and installing switchgear UP7A and UP12A.

1.02 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 26 05 04-1, Electrical Outage and Demolition Request:

1. Include following in request:

a. Area where work will be done (by number or other description).

b. Outline procedures for accomplishing work including specific safety precautions to be taken, type and location of barricades, warning signs, and protective grounds and devices to be used.

c. Commencement time of work.

d. Duration of work.

e. Number of personnel and their classification.

f. Description of equipment to be used.

g. Information indicating that required materials are on site or data indicating shipping dates of materials not on site.

h. For the outage for units 10-11-12, indicate coordination with PG12 circuit repair work indicating when the equipment associated with Section 26 05 06 – Repair of Unit PG12 Circuit will be removed and installed

1.03 PROJECT CONDITIONS

A. Contractor shall provide crane or specialized lifting equipment as needed. Power plant traveling crane may be used to move equipment to/from the installation location in accordance with Section 01 54 20 - Use of Government Crane.

B. Existing Unit Switchgear:

1. Manufacturers:

a. Westinghouse Electric Company (P/G Units 7 & 8).

b. General Electric Company (P/G Units 9 thru 12).

2. Type: Station-type cubicles.

a. Breaker: Air-blast

b. Switches: 3-pole manually-group-operated

c. Potential Transformers: Drawout

3. Rated Maximum Voltage: 15-kV

26 05 04 - 3

4. Year of Manufacturer: 1970’s.

5. Sizes and weights: See drawings.

Figure 26 05 04A – Unit Switchgear Photographs

C. Existing Compressed Air System:

1. Compressed air system for unit circuit breakers does not match the drawings.

26 05 04 - 4

2. Compressors are not located on El. 1256.50 as indicated on the drawings, instead, they are located on El. 1290.

3. Therefore, the Contractor will not be responsible for removing any part of the air system but shall coordinate with Project forces in capping the piping going to each breaker cubicle, as noted in Part 3 below.

D. Existing Isolated-Phase Bus:

1. Manufacturers:

a. Hitachi, Ltd. (Units P/G 7 & 8).

b. General Electric Company (Units P/G 9 thru 12).

E. Existing Ground Switch ZY6A-5380:

1. Refer to Figure 26 05 04B below.

2. Note, there is an existing key interlock on this switch which operates to prevent more than one of the following switches to be closed at the same time: 5382, 5389, and 5380. The modifications required below shall not alter the function of this existing key interlock.

26 05 04 - 5

Figure 26 05 04B – Ground Switch ZY6A-5380

26 05 04 - 6

SEQUENCING

F. New switchgear shall be onsite with approval drawings and factory test reports approved and complete before removal of existing equipment.

G. Install and complete each new unit switchgear assemblies before proceeding to the next, unless otherwise directed by the COR.

H. The unit switchgear assemblies are connected together on a transformer bus, two buses, three units per bus. Therefore, it should be noted three units will be required to be on outage when one switchgear assembly is being removed and replaced.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 PREPARATION

A. Government will perform a thermographic survey using an infrared detector with the equipment under load, viewing connection points of the isolated phase bus to the switchgear, before work begins. Contractor shall be present and assist during the survey.

1. No survey will be performed on Unit PG12 circuit since it is out of service.

B. Request outage in accordance with Section 01 14 30 - Interruption of Service.

C. Follow instructions related to the Special Work Permit (SWP) that will be issued by the COR to ensure that the equipment is safely de-energized, such as:

1. Sources of electrical and mechanical energy shall be defined and locked out in accordance with the facility Hazardous Energy Control Program.

2. Procedures to be implemented by the COR in conjunction with contractor.

3. After sources of electrical energy have been locked-out and disconnected, feeder conductors shall be removed from conduits feeding structure.

D. When hazardous electrical energy sources have been isolated and removed then removal work may begin.

E. Coordinate with COR before contractor removal work begins for the removal of breaker arc chutes. Government forces will remove the arc chutes.

26 05 04 - 7

3.02 REMOVAL

A. Coordinate with COR to locate air piping feeder isolation valve to unit breaker that is being removed. Isolation valves will be part of the SWP and will be in the locked, closed position.