PWS - REPAIR B5008 Training Room.pdf

PERFORMANCE WORK STATEMENT (PWS)

FOR

REPAIR, B5008 Training Room

VDYD 25####

SCOTT AIR FORCE BASE, ILLINOIS

25 June 2025

1. REQUIREMENT:

a. BACKGROUND: The 126th Operations Group has a lack of common use office space needed for part-time members to utilize for general office tasks and classroom activities.

b. OBJECTIVES: The objective of this project is to renovate an existing room to maximize workstations for general office use. The room layout should also accommodate group discussions and presentations in a classroom-like manner.

c. PROJECT LOCATION: All work will be at the 126ARW, Scott AFB, Illinois, B5008, Rm135

2. PROJECT ADMINISTRATION:

a. SITE VISIT: Contractor is responsible to verify all measurements and conditions pre-bid.

The Government intends to only hold one official site visit. Requests for additional site access must go through the 126th Contracting Squadron (126 CONS) point of contact (POC) listed in the Request for Proposal (RFP) letter. Any additional site access will be made available to all Contractors solicited for this project.

3. PROJECT SCOPE:

a. BASE BID (CLIN 001): Bldg 5008, Rm135 Workstations and Presentation AV

i. Conduct site inspection to verify site conditions. Contractor to coordinate all utility locates and permits (Hot work, dig, etc.) as needed.

ii. Remove existing furniture

iii. Install NIPR and electrical to support the new furniture configuration (min 12 workstations + 1 for presentation capabilities) and 1 wall mounted monitor

iv. Install network cabling, as required, for printing capability to existing printer in adjacent aircrew briefing room

v. Install new furniture and tie in NIPR and electrical as required.

(1) Workstation should be UNICOR IRK42DKSH or similar

(2) Chairs should be UNICOR WXO5800BLK0301 or similar

(3) Configuration should be as shown below or similar

(4) Workstation IT and wall mounted display requirements per Attachment A

4. DELIVERABLES: Contractor shall provide all material submittals to the contracting office for review using the Air Force Form 3000 (AF3000).

5. SCHEDULE:

a. Performance period: The period of performance (PoP) for this project shall be proposed by the contractor and negotiated with the government from the date that Notice to Proceed (NTP) is issued. All work must be scheduled to be complete within this timeframe. Any modifications or extensions must be requested through the 126th Civil Engineer Squadron (126 CES) and the Contracting Officer for review and discussion. Contractor must provide construction milestones to 126 CES and the Contracting Officer.

6. SPECIFICATIONS:

a. All work performed shall comply with all applicable UFC, NFPA, NEC and other local and federal regulations and code. This includes but is not limited to:

i. Unified Facilities Criteria (UFC) 1-200-01 General Building Requirements

ii. Air Force Corporate Facilities Standards

iii. Scott AFB Installation Facilities Standards (IFS)

(1) https://www.wbdg.org/airforce/ifs/scott-afb-ifs

7. GENERAL CONDITIONS:

a. An alternative method can be proposed for any of the above tasks and will be reviewed.

Any alternative methods or deviations from the requested work shall be called out or highlighted in the Contractor’s proposal in a manner that is clearly identifiable. Any approved alternate methods will result in a SOW modification prior to the commencement of work. The Government will assume any additional design or construction costs associated with the approved alternatives but will not assume any costs associated with the Contractor processing this required modification.

b. A phased approach is to be used in the construction of these projects to minimize disruptions.

c. Contractor must ensure that all accesses to the building be left clear of construction materials when not on the worksite. Ensure material/tools/equipment do not hamper operations during operating hours.

d. Contractor shall supply any dumpsters required to properly dispose of any construction materials.

e. Contractor shall coordinate with CE for enter/exit points to access job site, for this facility. Contractor to coordinate with CE for location of dumpster.

f. Contractor shall site verify all dimensions and/or existing site conditions prior to the commencement of work. Commencement of work shall begin within ten (10) calendar days upon the receipt of the NTP issued by the Contracting Officer.

g. Contractor shall be completed within the agreed upon PoP as stated within the contract issued by the Contracting Officer.

8. FIELD CONDITIONS:

The Contractor shall be responsible for all field measurements to accomplish work.

Quantity and sizes of materials shall be determined from site visits and drawings. The Contractor shall carefully examine the entire site and building and shall make all necessary investigations to become thoroughly aware of the existing conditions and all difficulties involved in the completion of the work in accordance with the contract documents.

9. ACCOMPLISHMENT OF WORK:

The work areas of the existing building will be in occupied and unoccupied areas. The Contractor must ensure that all access to the existing building always remains clear for occupants and emergency access during the construction period. All temporary closures, barriers, and protective procedures shall be coordinated with the Contracting Officer. All work shall be accomplished during the standard 8-hour day, 5-day week, Monday through Friday, between the hours of 7:30 A.M. and 4:30 P.M. local time, excluding Federal Legal holidays and nonwork days resulting from holidays occurring on weekends.

However, power outages shall be accomplished on weekends or 126ARW down days (calendar provided). The 126ARW has a compressed schedule and does have roughly two down days per month, typically on Fridays. Please reference the 126ARW calendar to coordinate the construction schedule to not work on scheduled down days unless required.

10. WORK CONDITIONS:

The Contractor shall coordinate work with the Contracting Officer, in conjunction with the User and 126 CES. The Contractor shall notify the Contracting Officer or the 126 CES inspection representative the day before he/she moves onto the work site to commence work.

The Contractor shall again provide notification the day he moves back to the work site after an interruption of work of two or more days in duration. The Contractor shall also provide an original work schedule and updates if required. This schedule shall describe major work items and projected completion dates.

11. PROTECTION OF BUILDING PROPERTY:

The Contractor shall protect from damage all building property located in or adjacent to the building and shall repair, replace, or otherwise be held liable for all such damage. Building properties include but are not limited to, furniture, vehicles, or items of supplies. Exercise control measures of all dust and toxic fumes associated with construction operations, to prevent hazards or illness to base and Contractor personnel.

12. CLEANUP:

The Contractor shall cleanup each work site at the end of each workday to the satisfaction of the Contracting Officer. Upon completion of the work, all construction equipment and debris shall be removed from the site and the area shall be left in a neat and completely acceptable condition as required by the General Provisions. Contractor must always recycle materials, such as, but not limited to cardboard and paper. The Contractor will use whatever means necessary to store all recyclable materials and is responsible for turning in recyclable materials to the Base Recycling Center.

13. PATCHING AND REPAIRING:

After the work has been completed, holes, cuts, and damages made in the finished surfaces of the work site and adjacent areas shall be properly repaired and restored to match the existing finishes. Any abrasion or disfigurement of the finish work or any portion of the building where any such abrasion or disfigurement is caused by the activities of the Contractor shall be repaired and neatly refinished to match the adjacent work to the satisfaction of the Contracting Officer. Contractor shall maintain integrity of all fire walls/barriers.

14. PRODUCTS:

All products shall conform to their respective manufacturing and performance publications.

All materials and equipment used in the work area shall be the products of manufacturers regularly engaged in the manufacture of construction products.

16. SPECIFICATIONS:

Work shall be performed in strict accordance with these contract general specifications, as well as all applicable local, state, and national Building and Life Safety Codes, American Society for Testing and Materials (ASTM) specifications. Safety plans and procedures issues must adhere to all applicable Occupational Safety and Health Act (OSHA) regulations.

17. PROJECT POINTS OF CONTACT:

The project points of contact for this project are:

Contracting Specialist/Officer MSgt Benjamin James 126th Contracting Office P: 618-222-5112 Email: benjamin.james.1@us.af.mil

Project Manager Capt Brett Luithly 126th Civil Engineer Squadron P: 618-222-4886 Cell: 260-615-5492 Email: brett.luithly@us.af.mil

Construction Inspector/Manager Mr. Larry Fuller 126th Civil Engineer Squadron P: 618-222-4889 Cell: 217-313-1023 Email: larry.fuller@us.af.mil

Real Property Manager Mr. Eric Bennett 126th Civil Engineer Squadron P: 618-222-4890 Email: eric.bennett.11@us.af.mil