Past_Performance_Survey.docx
DOCX document 24 KB Posted
- Attached to
- SC-FWS CAROLINA SANDHILLS-HERBICIDE
- Solicitation number
- 140FS326Q0113
About this file
This is a Past Performance Survey template designed to collect information about a contractor's relevant experience with completed or in-progress contracts. The survey requests general business information including company name, address, date established, company leadership, and SAM.gov Unique Entity Identifier (UEI), along with confirmation of business structure (partnership, separate entity, or division).
The core of the survey focuses on documentation of up to three past contracts or subcontracts, whether government or commercial. For each contract, respondents must provide contracting agency or company name, point of contact information, contract number, dollar amount, project title and location, general scope, and the respondent's role (prime, joint venture partner, or subcontractor). Additionally, the survey requests details on subcontracted work, period of performance, scheduled versus actual completion dates, percentage of work completed, termination history, and implementation of quality control and safety plans. Respondents must also document any quality control or safety problems encountered and explain how those issues were resolved. The completed survey must be signed and dated by the survey preparer with their contact information and title provided.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| B03_-_Service_Contract_Act_WD_2015-4453.pdf | ||
| Sol_140FS326Q0113.pdf | ||
| B08_-_CSNWR_Scope_of_Work_2026_Understory_Control.pdf |
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PAST OR PRESENT PERFORMANCE SURVEY
Your Company Name:
Street Address:
City, State and ZIP Code:
1. GENERAL BUSINESS INFORMATION
Date Firm Organized/Established:
| Company President: | Vice President: | |
| SAM.gov Unique Entity Identifier (UEI): | __ |
Is company a ; Partnership [ ] Separate entity [ ] Division [ ] N/A [ ]
2. CONTRACTS/SUBCONTRACTS COMPLETED OR IN PROGRESS
Complete and submit the information requested on page 2-4 below on prime contracts or subcontracts completed or in progress. Government contracts are preferred; but, if you have not performed Government contracts, indicate any other contracts completed or in progress.
a. First Contract:
Contracting Agency or Company:
| Point of Contact: | Telephone Number: | ||
| Contract Number: | Contract/Subcontract Amount: $ | _____ |
Project Title and Location:
General Scope of Project: ____________
Your Role (Prime [ ], Joint Venture [ ], or Subcontractor [ ]) and the work your firm performed:
Describe any Work You Subcontracted to Others:
Total Amount of Subcontract(s): $ Period of Performance: days Scheduled Completion Date:
Actual Completion Date: Percentage of Work Completed: % Were You Terminated?
Did you use a Quality Control Plan? _________ Did you use a Safety Plan?_______________
Quality Control or Safety Problems encountered (if any):
How were the problems resolved? _____
b. Second Contract:
Contracting Agency or Company:
| Point of Contact: | Telephone Number: | ||
| Contract Number: | Contract/Subcontract Amount: $ | _____ |
Project Title and Location:
General Scope of Project: ____________
Your Role (Prime [ ], Joint Venture [ ], or Subcontractor [ ]) and the work your firm performed:
Describe any Work You Subcontracted to Others:
Total Amount of Subcontract(s): $
Scheduled Completion Date:
Actual Completion Date: Percentage of Work Completed: % Were You Terminated?
Quality Control or Safety Problems encountered (if any):
How were the problems resolved? _____
c. Third Contract:
Contracting Agency or Company:
| Point of Contact: | Telephone Number: | ||
| Contract Number: | Contract/Subcontract Amount: $ | _____ |
Project Title and Location:
General Scope of Project: ____________
Your Role (Prime [ ], Joint Venture [ ], or Subcontractor [ ]) and the work your firm performed:
Describe any Work You Subcontracted to Others:
Total Amount of Subcontract(s): $
Scheduled Completion Date:
Actual Completion Date: Percentage of Work Completed: % Were You Terminated?
Quality Control or Safety Problems encountered (if any):
How were the problems resolved? _____
Type or Print Information Name of Survey Preparer
Phone:_________________ E-Mail;___________________________ Title Signature Date )4. Certification of Past Performance Information:
File details come from the government source that posted it. Updated .