2013_12_13_Specification_Sections_Final_Submittal_(2).pdf

NATIONAL PARK SERVICE

U.S. DEPARTMENT OF THE INTERIOR

NATIONAL CAPITAL REGION

LANDS PLANNING AND DESIGN

WASHINGTON, D.C.

Provide Access to and Rehabilitate Interior of

Thomas Farm Tenant House for Visitor Use

Specifications

National Park Service Monocacy National Battlefield (MONO)

Frederick, MD

FINAL SUBMISSION

December 2013

Prepared by:

Protection Engineering Group

Chantilly, VA

Contract No. P09PC60802

Task Order No. 21

PMIS No. 150348

Thomas Farm Tenant House/National Park Service /2009

TABLE OF CONTENTS

PROVIDE ACCESS TO AND REHABILITATE INTERIOR OF THOMAS FARM TENANT HOUSE DEC 2013

DIVISION 1 – GENERAL REQUIREMENTS

011000 SUMMARY

013100 PROJECT MANAGEMENT AND COORDINATION

013200 CONSTRUCTION PROGRESS DOCUMENTATION

013300 SUBMITTALS

013591 HISTORIC TREATMENT PROCEDURES

014200 REFERENCES

015000 TEMPORARY SERVICES, FACILITIES AND CONTROLS

017300 EXECUTION AND CLOSEOUT REQUIREMENTS

017900 DEMONSTRATION AND TRAINING

DIVISION 2 – EXISTING CONDITIONS

024119 SELECTIVE DEMOLITION – SITE

024120 SELECTIVE DEMOLITION – BUILDING

DIVISION 3 – CONCRETE

033000 CAST-IN-PLACE CONCRETE

033350 DECORATIVE CONCRETE

DIVISION 4 – MASONRY

NOT APPLICABLE

DIVISION 5 – METALS

055213 PIPE AND TUBE RAILINGS

DIVISION 6 – WOOD AND PLASTICS

064600 WOOD TRIM

066700 SOLID SURFACE MATERIALS

DIVISION 7 – THERMAL AND MOISTURE PROTECTION

072100 THERMAL INSULATION

079200 JOINT SEALANTS

DIVISION 8 – OPENINGS

081613 FIBERGLASS DOORS AND FRAMES

087100 DOOR HARDWARE

087150 HARDWARE SET SCHEDULE

088000 GLAZING

DIVISION 9 – FINISHES

092216 NON-STRUCTURAL METAL FRAMING

092400 REPAIR OF CEMENT PLASTERING

092900 GYPSUM BOARD

099123 INTERIOR PAINTING

DIVISION 10 – SPECIALITIES

101400 SIGNAGE

101423 PANEL SIGNAGE

102800 TOILET ACCESSORIES

DIVISION 11 – DIVISION 21

DIVISION 22 – PLUMBING

220523 GENERAL-DUTY VALVES FOR PLUMBING PIPING

220529 HANGERS AND SUPPORTS FOR PLUMBING PIPING AND EQUIPMENT

220719 PLUMBING PIPING INSULATION

221116 DOMESTIC WATER PIPING

221119 DOMESTIC WATER PIPING SPECIALTIES

221316 SANITARY WASTE AND VENT PIPING

221319 SANITARY WASTE PIPING SPECIALTIES

221343 FACILITY PACKAGED SEWAGE PUMPING STATIONS

223300 ELECTRIC, DOMESTIC-WATER HEATERS

DIVISION 23 – HEATING VENTILATING AND AIR CONDITIONING

230593 TESTING, ADJUSTING, AND BALANCING FOR HVAC

233113 METAL DUCTS

233423 HVAC POWER VENTILATORS

238236 FINNED-TUBE RADIATION HEATERS

DIVISION 24 – DIVISION 25

DIVISION 26 – ELECTRICAL

260519 LOW-VOLTAGE ELECTRICAL POWER CONDUCTORS AND CABLES

260526 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS

260529 HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS

260533 RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS

260544 SLEEVES AND SLEEVE SEALS FOR ELECTRICAL RACEWAYS AND CABLING

260553 IDENTIFICATION FOR ELECTRICAL SYSTEMS

262726 WIRING DEVICES

265100 INTERIOR LIGHTING

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

280513 CONDUCTORS AND CABLES FOR ELECTRONIC SAFETY AND SECURITY

218600 INTRUSION DETECTION

283111 DIGITAL, ADDRESSABLE FIRE-ALARM SYSTEM

DIVISION 29 – DIVISION 30

DIVISION 31 – EARTHWORK

311000 CLEARING, GRUBBING, SELECTIVE THINNING AND TREE REMOVAL

312000 EARTH MOVING

312319 DEWATERING

DIVISION 32 – EXTERIOR IMPROVEMENTS

321243 POROUS PAVING

321313 CONCRETE PAVING

321713 PARKING BUMPERS

321723 PAVEMENT MARKINGS

329200 TURF AND GRASSES

DIVISION 33 – UTILITIES

330500 COMMON WORK RESULTS FOR UTILITIES

330523 TRENCHLESS UTILITY INSTALLATION

333000 SANITARY SEWARAGE UTILITIES

334100 STORM UTILITY DRAINAGE PIPING

APPENDICES

Appendix A NPS-NCR FIRE PROTECTION SYSTEM REQUIREMENTS (rev September 28, 2011)

SUMMARY OF WORK 011000-1

SECTION 011000 – SUMMARY OF WORK

PART 1 - GENERAL

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, and other Division 1 Specification Sections, apply to this Section.

1.2 DESCRIPTION: This section covers the following:

A. Location and Description of Work

B. Coordination

C. Project Meetings

D. Construction Facilities and Temporary Controls

E. Materials and Equipment

F. Quality Requirements

G. Accident Prevention

H. Archeological Protection

I. Work under other Contracts

1.3 LOCATION AND DESCRIPTION OF WORK

A. The work of this contract is located at: Monocacy National Battlefield, 4632 Araby Church

Road, Frederick, Maryland

B. The work of this contract includes, but not limited to the following work, as detailed in the specification sections and as shown on the attached drawings:

1. Base Bid

a. Provide two ADA parking spaces regarding entrance to parking area.

b. Provide ADA pathway from parking spaces to the Tenant Farm House.

c. Provide sanitary connection from Tenant Farm House to existing septic tank adjacent to Main House.

d. Extend telecommunications through existing underground conduit from Main

House to Tenant Farm House.

e. Provide addressable fire alarm system throughout Tenant Farm House.

f. Provide security intrusion detection system in Tenant Farm House extended off existing Main House security panel.

g. Remove existing partitions on Ground Floor of Tenant Farm House.

SUMMARY OF WORK 011000-2

h. Remove existing brick floor in area of new restrooms.

i. Provide new concrete floor throughout area of new restrooms.

j. Provide two restrooms, storage closet, electrical closet and fire alarm closet on

Ground Floor of Tenant Farm House.

k. Provide water fountain on Ground Floor of Tenant Farm House.

1.4 OTHER REQUIREMENTS

A. Obtain and pay for all construction permits.

B. Provide as-built drawings prepared in AutoCAD (release 2010 minimum).

C. Provide all investigative aids and equipment to facilitate execution of the work: personal protective equipment (PPE), scaffolds, ladders, temporary lighting, soil boring equipment, monitoring devices, and other such equipment. Provide and maintain barriers to prevent public entry into the area while work is being performed or any equipment is in place. All barricading shall be approved by the COR prior to installation.

D. A temporary security fence (on footers) shall be installed to prevent access to excavated areas and other areas of investigation.

E. Overnight storage of supplies or materials on-site shall be approved by the COR.

F. Contractor shall be responsible for all damages to persons or property that occurs as a result of

Contractor’s fault or negligence. The contractor shall take proper safety and health precautions to protect work, workers, the public and property of others.

G. Utility Marking: Notify Miss Utility or other qualified utility locating service prior to commencement of on-site work. Contractor(s) shall be responsible for contacting Miss Utility or private utility locating service, in advance, for marking of all underground utilities within work zones where digging, test pits, probes, etc. are anticipated. Notify COR a minimum of 72 hours in advance of boring, digging and/or locating work so that NPS Archeologist and/or Cultural

Resource Manager may observe work in progress.

H. All work shall be in accordance with standard Occupational Safety and Health Administration

(OSHA) guidelines and regulations.

1.5 COORDINATION

A. Full Occupancy: Thomas Farm Tenant House will not be occupied during construction however the Main House will remain occupied. Cooperate with COR during construction operations to minimize conflicts and facilitate adjacent site usage. Perform the Work so as not to interfere with building day-to-day operations.

1. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission and approval from COR.

2. Notify COR not less than 72 hours in advance of activities that will affect the Main

House’s operations.

SUMMARY OF WORK 011000-3

B. Project involves coordinating work daily with COR and Monocacy park staff. Contractor is to provide safe working conditions for all contractor’s workers, park staff and the general public.

C. Coordinate construction operations included in various sections of these specifications to assure efficient and orderly installation of each part of the work. Coordinate construction operations included under different sections that depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in the sequence required to obtain the best results where installation of one part of the work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components to assure maximum accessibility for required maintenance, service, and repair.

3. Make provisions to accommodate items scheduled for later installation.

D. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities to avoid conflicts and assure orderly progress of the work. Such administrative activities include, but are not limited to, the following:

1. Preparation of contractor’s construction schedule.

2. Installation and removal of temporary facilities.

3. Progress meetings.

4. Project closeout activities.

1.6 PROJECT MEETINGS

A. General: Contracting Officer’s Representative (COR) will schedule and conduct meetings and conferences at project site, unless otherwise indicated.

1. Attendees: Authorized representatives of Acquisition Division and park staff; Contractor and its superintendent; major subcontractors; manufacturers; suppliers; and other concerned parties shall attend the conference shall be familiar with project and authorized to conclude matters relating to work.

B. Pre-Construction Conference: Contracting Officer’s Representative will schedule a Pre-

Construction Conference before starting construction, at a time convenient to park staff and contractor. The conference will be held at project site or another convenient location.

1. Agenda: Subjects to be discussed will include the following:

a. Correspondence – General Procedure.

b. Contracting Officer’s Authorized Representatives.

c. Changes.

d. Submittals for Approval (General).

e. Submittals for Approval (Shop Drawings and Samples).

f. Subcontractors.

SUMMARY OF WORK 011000-4

g. Labor Standards.

h. Payroll Reports.

i. Working Hours

j. Plans and Specifications.

k. Accident Prevention.

l. Park Rules and Regulations.

m. Contractor Parking and Personnel Passes

n. Payments to Contractor.

o. Liquidated Damages – Construction.

p. Tentative Construction Schedule.

C. Pre-Installation Conferences: If required, conduct a pre-installation conference at project site before each construction activity that requires coordination with other construction.

D. Progress Meetings: If necessary, the Contracting Officer’s Representative will schedule and conduct progress meetings at designated intervals. Coordinate dates of meetings with preparation of payment requests.

1.7 CONSTRUCTION FACILITIES AND TEMPORARY CONTROLS (See Section 01560)

A. References:

1. FAR Clause: 52.236-9 – Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

2. FAR Clause: 52.236-10 – Operations and Storage Areas

3. FAR Clause: 52.236-14 – Availability and Use of Utility Services

1.8 MATERIALS AND EQUIPMENT

A. Reference: FAR Clause: 52.236-5 – Material and Workmanship

1.9 QUALITY REQUIREMENTS

A. Testing and inspecting services may be required to verify compliance with requirements specified or indicated. These services do not relieve the Contractor of responsibility for compliance with the Contract requirements.

1. Specific quality-control requirements for individual construction activities as specified in the Sections may also cover production of standard products.

2. Requirements for Contractor to provide quality-control services as directed by

Contracting Officer’s Representative or authorities having jurisdictions are not limited by provisions of this Section.

SUMMARY OF WORK 011000-5

B. Submittals

1. Qualification Data: For testing agencies specified in “Quality Assurance” Article to demonstrate their capabilities and experience. Include proof of qualifications in the form of a recent report on the inspection of the testing agency by a recognized authority.

2. Delegated-Design Submittal: In addition to Shop Drawings, Product Data, and other required submittals, submit a statement, signed and sealed by the responsible design professional, for each product and system specifically assigned to Contractor to be designed or certified by a design professional, confirming that the products and systems are in compliance with performance and design criteria indicated. Include list of codes, loads, and other factors used in performing these services.

3. Reports: Prepare and submit certified written reports that include the following:

a. Date of issue.

b. Project title and number. Contract number.

c. Name, address, and telephone number of testing agency.

d. Dates and locations of samples and tests or inspections.

e. Names of individuals making tests or inspections.

f. Description of the Work and test and inspection method.

g. Identification of product and Specification Section.

h. Complete test or inspection data.

i. Test and inspection results and an interpretation of test results.

j. Ambient conditions at time of sample taking and testing and inspecting.

k. Comments or professional opinion on whether tested or inspected Work complies with the Contract Document requirements.

l. Name and signature of laboratory inspector.

m. Recommendations on testing reinspecting.

4. Permits, licenses, and Certificates: For Contracting Officer’s Representative’s records submit copies of permits, licenses, certifications, inspection reports, releases, jurisdictional settlements, notices, receipts for fee payments, judgments, correspondence, records, and similar documents, established for compliance with standards and regulations bearing on performance of the Work.

C. Quality Assurance

1. Fabricator Qualification: A firm experienced in producing products similar to those indicated for this Project and with a record of successful in-service performance, as well as sufficient production capability to produce required units.

2. Factory-Authorized Service Representative Qualifications: An authorized representative of manufacturer who is trained and approved manufacturer to inspect installation of manufacturer’s products that are similar in material, design, and extent to those indicated for this Project.

3. Installer Qualifications: A firm or individual experienced in installing, erecting, or assembling work similar in material, design, and extent to that indicated for this Project, whose work has resulted in construction with a record of successful in-service performance.

SUMMARY OF WORK 011000-6

4. Manufacturer Qualifications: A firm experienced in manufacturing products or systems similar to those indicated for this Project and with a record of successful in-service performance.

5. Professional Engineer Qualifications: A professional engineer who is legally qualified to practice in jurisdiction where Project is located and who is experienced in providing engineering services of the kind indicated. Engineering services are defined as those performed for installations of the system, assembly, or products that are similar to those indicated for this Project in material design, and extent.

6. Specialists: Certain sections of the Specifications require that specific construction activities shall be performed by entities that are recognized experts in those operations.

Specialists shall satisfy qualification requirements indicated and shall be engaged for the activities indicated.

a. Requirement for specialists shall not supersede building codes and similar regulations governing the Work, nor interfere with local trade-union jurisdictional settlements and similar conventions.

7. Testing Agency Qualifications: An agency with the experience and capability to conduct testing and inspecting indicated, as documented by ASTM E 548, and that specializes in types of tests and inspections to be performed.

8. Pre-construction Testing: Testing agency shall perform pre-construction testing for compliance with specified requirements for performance and test methods.

a. Contractor responsibilities include the following:

• Provide test specimens and assemblies representative of proposed materials and construction. Provide sizes and configurations of assemblies to adequately demonstrate capability of product to comply with performance requirements.

• Submit specimens in a timely manner with sufficient time for testing and analyzing results to prevent delaying work.

b. Testing Agency Responsibilities: Submit a certified written report of each test, inspection, and similar quality-assurance service to Contracting Officer’s

Representative, with copy to Contractor. Interpret tests and inspections and state in each report whether tested and inspected work complies with or deviates from the

Contract Documents.

D. Quality Control

1. Contractor Responsibilities: Unless otherwise indicated, provide quality-control services specified and required by these contract documents.

SUMMARY OF WORK 011000-7

a. Contractor shall engage a qualified-independent testing agency to perform these quality-control services.

2. Manufacturer’s Field Services: Where indicated, engage a factory authorized service representative to inspect field-assembled components and equipment installation, including service connections. Report results in writing.

3. Testing Agency Responsibilities: Cooperate with Contracting Officer’s Representative and

Contractor in performance of duties. Provide qualified personnel to perform required tests and inspections.

a. Notify Contracting Officer’s Representative and Contractor promptly of irregularities or deficiencies observed in the Work during performance of its services.

b. Interpret tests and inspections and state in each report whether tested and inspected work complies with or deviates from requirements.

c. Submit a certified written report, in duplicate, of each test, inspections, and similar quality-control service through Contractor.

d. Do not release, revoke, alter, or increase requirements of the Contract Documents or approve or accept any portion of the work.

4. Coordination: Coordinate sequence of activities to accommodate required quality-assurance and quality-control services with a minimum of delay and to avoid necessity of removing and replacing construction of accommodate testing and inspecting.

1.10 ACCIDENT PREVENTION

A. Reference: FAR Clause: 52.236-13 Alt. I – Accident Prevention (Nov. 1991) – Alternate I

1.11 ARCHEOLOGICAL PROTECTION

A. Reference: DOI Clause: 1489.236-73 – Archeological Findings

1. Archeological Discovery: In the event that unanticipated archeological resources are uncovered during construction operations, the contractor will suspend operations at the discovery site, notify the Contracting Officer, who shall contact the Regional

Archeologist or his representative, and continue operations in other areas, until such time as the National Park Service has completed its compliance responsibilities under Section

106 of the 1966 National Historic Preservation Act, as amended.

2. Anthropic Discovery: Should any human remains be encountered, excavations will stop and the Contracting Officer will be notified immediately. The Contracting Officer, in consultation with the Regional Archeologist or his representative, and the Park

Superintendent shall determine the appropriate course of action, following the

Department of the Interior’s guidelines on the treatment of human remains and appropriate Federal legislation.

SUMMARY OF WORK 011000-8

1.12 WORK UNDER OTHER CONTRACTS

A. General: Cooperate fully with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate the

Work of this Contract with work performed under separate contracts.

PART 2 - PRODUCTS (Not Applicable)

PART 3 - EXECUTION (Not Applicable)

END OF SECTION 011000

PROJECT MANAGEMENT AND COORDINATION 013100 - 1

SECTION 013100 – PROJECT MANAGEMENT AND COORDINATION

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary

Conditions and other Division 1 Specification Sections, apply to this Section.

1.2 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. General coordination procedures.

2. Coordination drawings.

3. Requests for Information (RFIs).

4. Project meetings.

B. Each contractor shall participate in coordination requirements. Certain areas of responsibility are assigned to a specific contractor.

C. Related Requirements:

1. Division 1 Section "Construction Progress Documentation" for preparing and submitting

Contractor's construction schedule.

2. Division 1 Section "Closeout Procedures" for coordinating closeout of the Contract.

1.3 DEFINITIONS

A. RFI: Request from COR seeking information required by or clarifications of the Contract

Documents.

1.4 INFORMATIONAL SUBMITTALS

A. Subcontract List: Prepare a written summary identifying individuals or firms proposed for each portion of the Work, including those who are to furnish products or equipment fabricated to a special design. Use CSI Form 1.5A. Include the following information in tabular form:

1. Name, address, and telephone number of entity performing subcontract or supplying products.

2. Number and title of related Specification Section(s) covered by subcontract.

3. Drawing number and detail references, as appropriate, covered by subcontract.

PROJECT MANAGEMENT AND COORDINATION 013100 - 2

B. Key Personnel Names: Within 15 days of starting construction operations, submit a list of key personnel assignments, including superintendent and other personnel in attendance at Project site. Identify individuals and their duties and responsibilities; list addresses and telephone numbers, including home, office, and cellular telephone numbers and e-mail addresses. Provide names, addresses, and telephone numbers of individuals assigned as alternates in the absence of individuals assigned to Project.

1. Post copies of list in project meeting room, in temporary field office, and by each temporary telephone. Keep list current at all times.

1.5 GENERAL COORDINATION PROCEDURES

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, that depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

B. Coordination: Each contractor shall coordinate its construction operations with those of other contractors and entities to ensure efficient and orderly installation of each part of the Work.

Each contractor shall coordinate its operations with operations, included in different Sections, that depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other contractors to ensure maximum performance and accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

C. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

1. Prepare similar memoranda for COR and separate contractors if coordination of their

Work is required.

D. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's construction schedule.

PROJECT MANAGEMENT AND COORDINATION 013100 - 3

2. Preparation of the schedule of values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Preinstallation conferences.

7. Project closeout activities.

8. Startup and adjustment of systems.

E. Conservation: Coordinate construction activities to ensure that operations are carried out with consideration given to conservation of energy, water, and materials. Coordinate use of temporary utilities to minimize waste.

1. Salvage materials and equipment involved in performance of, but not actually incorporated into, the Work. See other Sections for disposition of salvaged materials that are designated as COR's property.

1.6 COORDINATION DRAWINGS

A. Coordination Drawings, General: Prepare coordination drawings according to requirements in individual Sections, and additionally where installation is not completely shown on Shop

Drawings, where limited space availability necessitates coordination, or if coordination is required to facilitate integration of products and materials fabricated or installed by more than one entity.

1. Content: Project-specific information, drawn accurately to a scale large enough to indicate and resolve conflicts. Do not base coordination drawings on standard printed data. Include the following information, as applicable:

a. Use applicable Drawings as a basis for preparation of coordination drawings.

Prepare sections, elevations, and details as needed to describe relationship of various systems and components.

b. Coordinate the addition of trade-specific information to the coordination drawings by multiple contractors in a sequence that best provides for coordination of the information and resolution of conflicts between installed components before submitting for review.

c. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

d. Indicate space requirements for routine maintenance and for anticipated replacement of components during the life of the installation.

e. Show location and size of access doors required for access to concealed dampers, valves, and other controls.

f. Indicate required installation sequences.

g. Indicate dimensions shown on the Drawings. Specifically note dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to COR indicating proposed resolution of such conflicts. Minor dimension changes and difficult installations will not be considered changes to the Contract.

PROJECT MANAGEMENT AND COORDINATION 013100 - 4

B. Coordination Drawing Organization: Organize coordination drawings as follows:

1. Floor Plans and Reflected Ceiling Plans: Show architectural and structural elements, and mechanical, plumbing, fire-protection, fire-alarm, and electrical Work. Show locations of visible ceiling-mounted devices relative to acoustical ceiling grid. Supplement plan drawings with section drawings where required to adequately represent the Work.

2. Plenum Space: Indicate subframing for support of ceiling and wall systems, mechanical and electrical equipment, and related Work. Locate components within ceiling plenum to accommodate layout of light fixtures indicated on Drawings. Indicate areas of conflict between light fixtures and other components.

3. Mechanical Rooms: Provide coordination drawings for mechanical rooms showing plans and elevations of mechanical, plumbing, fire-protection, fire-alarm, and electrical equipment.

4. Structural Penetrations: Indicate penetrations and openings required for all disciplines.

5. Slab Edge and Embedded Items: Indicate slab edge locations and sizes and locations of embedded items for metal fabrications, sleeves, anchor bolts, bearing plates, angles, door floor closers, slab depressions for floor finishes, curbs and housekeeping pads, and similar items.

6. Mechanical and Plumbing Work: Show the following:

a. Sizes and bottom elevations of ductwork, piping, and conduit runs, including insulation, bracing, flanges, and support systems.

b. Dimensions of major components, such as dampers, valves, diffusers, access doors, cleanouts and electrical distribution equipment.

c. Fire-rated enclosures around ductwork.

7. Electrical Work: Show the following:

a. Runs of vertical and horizontal conduit 1-1/4 inches in diameter and larger.

b. Light fixture, exit light, emergency battery pack, smoke detector, and other fire-alarm locations.

c. Panel board, switch board, switchgear, transformer, busway, generator, and motor control center locations.

d. Location of pull boxes and junction boxes, dimensioned from column center lines.

8. Fire-Protection System: Show the following:

a. Locations of standpipes, mains piping, branch lines, pipe drops, and sprinkler heads.

9. Review: COR will review coordination drawings to confirm that the Work is being coordinated, but not for the details of the coordination, which are Contractor's responsibility. If COR determines that coordination drawings are not being prepared in sufficient scope or detail, or are otherwise deficient, COR will so inform Contractor, who shall make changes as directed and resubmit.

10. Coordination Drawing Prints: Prepare coordination drawing prints according to requirements in Division 1 Section "Submittal Procedures."

PROJECT MANAGEMENT AND COORDINATION 013100 - 5

C. Coordination Digital Data Files: Prepare coordination digital data files according to the following requirements:

1. File Preparation Format: Same digital data software program, version, and operating system as original Drawings.

2. File Preparation Format: DWG, Version, operating in Microsoft Windows operating system.

3. File Submittal Format: Submit or post coordination drawing files using format same as file preparation format.

4. COR will furnish Contractor one set of digital data files of Drawings for use in preparing coordination digital data files.

a. COR makes no representations as to the accuracy or completeness of digital data files as they relate to Drawings.

b. Digital Data Software Program: Drawings are available in AutoCAD.

1.7 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI in the form specified.

1. COR will return RFIs submitted to COR by other entities controlled by Contractor with no response.

2. Coordinate and submit RFIs in a prompt manner so as to avoid delays in Contractor's work or work of subcontractors.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. Project name.

2. Project number.

3. Date.

4. Name of Contractor.

5. Name of COR.

6. RFI number, numbered sequentially.

7. RFI subject.

8. Specification Section number and title and related paragraphs, as appropriate.

9. Drawing number and detail references, as appropriate.

10. Field dimensions and conditions, as appropriate.

11. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

12. Contractor's signature.

13. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

PROJECT MANAGEMENT AND COORDINATION 013100 - 6

C. RFI Forms: Software-generated form with substantially the same content as indicated above, acceptable to COR.

1. Attachments shall be electronic files in Adobe Acrobat PDF format.

D. COR Action: COR will review each RFI, determine action required, and respond. Allow seven working days for COR response for each RFI. RFIs received by COR’s after 1:00 p.m. will be considered as received the following working day.

1. The following Contractor-generated RFIs will be returned without action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract

Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of COR’s actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. COR action may include a request for additional information, in which case COR's time for response will date from time of receipt of additional information.

3. COR action on RFIs that may result in a change to the Contract Time or the Contract

Sum may be eligible for Contractor to submit Change Proposal according to Division 1

Section "Contract Modification Procedures."

a. If Contractor believes the RFI response warrants change in the Contract Time or the Contract Sum, notify COR in writing within 10 days of receipt of the RFI response.

E. RFI Log: Prepare, maintain, and submit a tabular log of RFIs organized by the RFI number.

Submit log weekly. Software log with not less than the following:

1. Project name.

2. Name and address of Contractor.

3. Name and address of COR.

4. RFI number including RFIs that were returned without action or withdrawn.

5. RFI description.

6. Date the RFI was submitted.

7. Date COR response was received.

F. On receipt of COR action, update the RFI log and immediately distribute the RFI response to affected parties. Review response and notify COR within seven days if Contractor disagrees with response.

1. Identification of related Minor Change in the Work, Construction Change Directive, and

Proposal Request, as appropriate.

2. Identification of related Field Order, Work Change Directive, and Proposal Request, as appropriate.

PROJECT MANAGEMENT AND COORDINATION 013100 - 7

1.8 PROJECT MEETINGS

A. General: Schedule and conduct meetings and conferences at Project site unless otherwise indicated.

1. Attendees: Inform participants and others involved, and individuals whose presence is required, of date and time of each meeting. Notify COR of scheduled meeting dates and times.

2. Agenda: Prepare the meeting agenda. Distribute the agenda to all invited attendees.

3. Minutes: Entity responsible for conducting meeting will record significant discussions and agreements achieved. Distribute the meeting minutes to everyone concerned, including COR, within three days of the meeting.

B. Preconstruction Conference: Schedule and conduct a preconstruction conference before starting construction, at a time convenient to COR, but no later than 15 days after execution of the

Agreement.

1. Conduct the conference to review responsibilities and personnel assignments.

2. Attendees: Authorized representatives of COR; Contractor and its superintendent; major subcontractors; suppliers; and other concerned parties shall attend the conference.

Participants at the conference shall be familiar with Project and authorized to conclude matters relating to the Work.

3. Agenda: Discuss items of significance that could affect progress, including the following:

a. Phasing schedule and coordination for required installations to minimize disruption.

b. Tentative construction schedule.

c. Phasing.

d. Critical work sequencing and long-lead items.

e. Designation of key personnel and their duties.

f. Lines of communications.

g. Procedures for processing field decisions and Change Orders.

h. Procedures for RFIs.

i. Procedures for testing and inspecting.

j. Procedures for processing Applications for Payment.

k. Distribution of the Contract Documents.

l. Submittal procedures.

m. Preparation of record documents.

n. Use of the premises and existing building.

o. Work restrictions.

p. Working hours.

q. COR’s occupancy requirements.

r. Responsibility for temporary facilities and controls.

s. Procedures for moisture and mold control.

t. Procedures for disruptions and shutdowns.

u. Construction waste management and recycling.

v. Parking availability.

w. Office, work, and storage areas.

PROJECT MANAGEMENT AND COORDINATION 013100 - 8

x. Equipment deliveries and priorities.

y. First aid.

z. Security.

aa. Progress cleaning.

4. Minutes: Entity responsible for conducting meeting will record and distribute meeting minutes.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise COR of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of COR.

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

y. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

PROJECT MANAGEMENT AND COORDINATION 013100 - 9

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the

Work and reconvene the conference at earliest feasible date.

D. Project Closeout Conference: Schedule and conduct a project closeout conference, at a time convenient to COR, but no later than 90 days prior to the scheduled date of Substantial

Completion.

1. Conduct the conference to review requirements and responsibilities related to Project closeout.

2. Attendees: Authorized representatives of COR, and their consultants; Contractor and its superintendent; major subcontractors; suppliers; and other concerned parties shall attend the meeting. Participants at the meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

3. Agenda: Discuss items of significance that could affect or delay Project closeout, including the following:

a. Preparation of record documents.

b. Procedures required prior to inspection for Substantial Completion and for final inspection for acceptance.

c. Submittal of written warranties.

d. Requirements for preparing operations and maintenance data.

e. Requirements for delivery of material samples, attic stock, and spare parts.

f. Requirements for demonstration and training.

g. Preparation of Contractor's punch list.

h. Procedures for processing Applications for Payment at Substantial Completion and for final payment.

i. Submittal procedures.

j. Coordination of separate contracts.

k. COR's partial occupancy requirements.

l. Installation of COR’s furniture, fixtures, and equipment.

m. Responsibility for removing temporary facilities and controls.

4. Minutes: Entity conducting meeting will record and distribute meeting minutes.

E. Progress Meetings: Conduct progress meetings at weekly intervals.

1. Coordinate dates of meetings with preparation of payment requests.

2. Attendees: In addition to representatives of COR, each contractor, subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

3. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. Include topics for discussion as appropriate to status of Project.

a. Contractor's Construction Schedule: Review progress since the last meeting.

Determine whether each activity is on time, ahead of schedule, or behind schedule, PROJECT MANAGEMENT AND COORDINATION 013100 - 10 in relation to Contractor's construction schedule. Determine how construction behind schedule will be expedited; secure commitments from parties involved to do so. Discuss whether schedule revisions are required to ensure that current and subsequent activities will be completed within the Contract Time.

1) Review schedule for next period.

b. Review present and future needs of each entity present, including the following:

1) Interface requirements.

2) Sequence of operations.

3) Resolution of BIM component conflicts.

4) Status of submittals.

5) Deliveries.

6) Off-site fabrication.

7) Access.

8) Site utilization.

9) Temporary facilities and controls.

10) Progress cleaning.

11) Quality and work standards.

12) Status of correction of deficient items.

13) Field observations.

14) Status of RFIs.

15) Status of proposal requests.

16) Pending changes.

17) Status of Change Orders.

18) Pending claims and disputes.

19) Documentation of information for payment requests.

4. Minutes: Entity responsible for conducting the meeting will record and distribute the meeting minutes to each party present and to parties requiring information.

a. Schedule Updating: Revise Contractor's construction schedule after each progress meeting where revisions to the schedule have been made or recognized. Issue revised schedule concurrently with the report of each meeting.

F. Coordination Meetings: Conduct Project coordination meetings at regular intervals. Project coordination meetings are in addition to specific meetings held for other purposes, such as progress meetings and preinstallation conferences.

1. Attendees: In addition to representatives of COR, each contractor, subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meetings shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of the previous coordination meeting.

Review other items of significance that could affect progress. Include topics for discussion as appropriate to status of Project.

PROJECT MANAGEMENT AND COORDINATION 013100 - 11

a. Combined Contractor's Construction Schedule: Review progress since the last coordination meeting. Determine whether each contract is on time, ahead of schedule, or behind schedule, in relation to combined Contractor's construction schedule. Determine how construction behind schedule will be expedited; secure commitments from parties involved to do so. Discuss whether schedule revisions are required to ensure that current and subsequent activities will be completed within the Contract Time.

b. Schedule Updating: Revise combined Contractor's construction schedule after each coordination meeting where revisions to the schedule have been made or recognized. Issue revised schedule concurrently with report of each meeting.

c. Review present and future needs of each contractor present, including the following:

1) Interface requirements.

2) Sequence of operations.

3) Resolution of BIM component conflicts.

4) Status of submittals.

5) Deliveries.

6) Off-site fabrication.

7) Access.

8) Site utilization.

9) Temporary facilities and controls.

10) Work hours.

11) Hazards and risks.

12) Progress cleaning.

13) Quality and work standards.

14) Change Orders.

3. Reporting: Record meeting results and distribute copies to everyone in attendance and to others affected by decisions or actions resulting from each meeting.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 013100

CONSTRUCTION PROGRESS DOCUMENTATION 013200 - 1

PMIS No. 150348

SECTION 013200 – CONSTRUCTION PROGRESS DOCUMENTATION

PART 1 - GENERAL

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary

Conditions and other Division 1 Specification Sections, apply to this Section.

1.2 SUMMARY

A. Section includes administrative and procedural requirements for documenting the progress of construction during performance of the Work, including the following:

1. Startup construction schedule.

2. Contractor's construction schedule.

3. Construction schedule updating reports.

4. Daily construction reports.

5. Material location reports.

6. Site condition reports.

7. Special reports.

B. Related Requirements:

1. Division 1 Section "Submittal Procedures" for submitting schedules and reports.

1.3 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical Activity: An activity on the critical path that must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the schedule of values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum unless otherwise approved by COR.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

CONSTRUCTION PROGRESS DOCUMENTATION 013200 - 2

PMIS No. 150348

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Event: The starting or ending point of an activity.

F. Float: The measure of leeway in starting and completing an activity.

1. Float time is not for the exclusive use or benefit of either COR, but is a jointly owned, expiring Project resource available to both parties as needed to meet schedule milestones and Contract completion date.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

G. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

1.4 INFORMATIONAL SUBMITTALS

A. Format for Submittals: Submit required submittals in the following format:

1. Working electronic copy of schedule file, where indicated.

2. PDF electronic file.

3. Two paper copies.

B. Startup construction schedule.

1. Approval of cost-loaded, startup construction schedule will not constitute approval of schedule of values for cost-loaded activities.

C. Startup Network Diagram: Of size required to display entire network for entire construction period. Show logic ties for activities.

D. Contractor's Construction Schedule: Initial schedule, of size required to display entire schedule for entire construction period.

1. Submit a working electronic copy of schedule, using software indicated, and labeled to comply with requirements for submittals. Include type of schedule (initial or updated) and date on label.

E. CPM Reports: Concurrent with CPM schedule, submit each of the following reports. Format for each activity in reports shall contain activity number, activity description, cost and resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of all activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of preceding and succeeding activities for all activities, sorted in ascending order by activity number and then early start date, or actual start date if known.

CONSTRUCTION PROGRESS DOCUMENTATION 013200 - 3

PMIS No. 150348

3. Total Float Report: List of all activities sorted in ascending order of total float.

4. Earnings Report: Compilation of Contractor's total earnings from the Notice to Proceed until most recent Application for Payment.

F. Construction Schedule Updating Reports: Submit with Applications for Payment.

G. Daily Construction Reports: Submit at weekly intervals.

H. Material Location Reports: Submit at weekly intervals.

I. Site Condition Reports: Submit at time of discovery of differing conditions.

J. Special Reports: Submit at time of unusual event.

K. Qualification Data: For scheduling consultant.

1.5 QUALITY ASSURANCE

A. Scheduling Consultant Qualifications: An experienced specialist in CPM scheduling and reporting, with capability of producing CPM reports and diagrams within 24 hours of COR’s request.

B. Prescheduling Conference: Conduct conference at Project site to comply with requirements in

Division 1 Section "Project Management and Coordination." Review methods and procedures related to the preliminary construction schedule and Contractor's construction schedule, including, but not limited to, the following:

1. Review software limitations and content and format for reports.

2. Verify…