NGIC Artifact RC PWS DRAFT.pdf

Performance Work Statement (PWS) National Ground Intelligence Center (NGIC)

Artifact Restoration and Conservation (R&C) Effort

PART 1: GENERAL INFORMATION

1.1 Introduction/Purpose

This is a non-personal services contract to obtain restoration and conservation services for a historical T-64 tank owned by the National Ground Intelligence Center (NGIC), hereinafter referred to as "the artifact." The U.S. Government shall neither supervise contractor employees nor control the method by which the contractor performs the required tasks. Under no circumstances shall the Government assign tasks to, or prepare work schedules for, individual contractor employees. It shall be the responsibility of the contractor to manage its employees and to guard against any actions that are of the nature of personal services or give the perception of personal services. If the contractor believes that any actions constitute, or are perceived to constitute personal services, it shall be the contractor's responsibility to notify the procuring contracting officer (PCO) immediately.

1.2 Description of Services

1.2.1 The contractor shall provide services related to the cosmetic restoration, condition stabilization, hazardous materials abatement (if required), and limited general repair of the artifact located on Rivanna Station, Charlottesville, VA 22911. All such work shall be performed in accordance with (IAW) actions defined in the PWS, governing Army Regulation such as AR 870-20 and AR 870-5, and in keeping with best museum practices. The contractor shall furnish, upon receipt of contract award, all the necessary services to restore the artifact at an off-site location and return to the current display location on Rivanna Station. The contractor shall perform all work to the standards of the current museum industry pertaining to restoration of such artifacts.

1.2.2 Work will include the complete exterior cosmetic refurbishment and restoration of the artifact. This will require the preparation of exterior surfaces for repainting and re-marking through the removal of failed paint and coatings. New primer, paint and markings of period-correct color, material formulation, and application scheme will only be applied to the artifact once all surfaces to be refinished have been prepared properly. The contractor will commit to preserving and re-using as much original historical material from the artifact as possible in order to preserve the artifact’s historical integrity to the greatest extent possible. Purpose-made and period-manufactured replacement parts may be considered on a per-case basis, with prior notification and authorization received from NGIC contracting officer's representative (COR) and NGIC subject matter expert (SME) personnel. Exceptions may be made in the case of rubber components, natural materials, or any other perishable material type that may no longer exist as replacement parts or materials. Such exceptions will only be authorized on a per-case basis.

1.2.3 As part of the restoration and stabilization process, additional work may be required to abate and remove hazardous materials and/or elements from the artifact's materials and subsystems. Such abatable materials may include petroleum, oil, and/or lubricants (POLs); lead acid or other batteries; ionizing radiological sources and materials, such as CARC Paint, Radium paint, Tritium, and/or Cesium; pressurized fire suppression systems and elements; main and support weapons systems; and other materials that could pose a hazard. As a result, all restoration work will be performed off-site and all environmental and hazardous materiel handling/disposition will be the responsibility of the vendor.

1.3 Background

The NGIC T-64 exhibit is an artifact associated with the Nicholson Building on Rivanna Station.

Due to the deteriorating effects of exhibition and outside display environments, restoration and refurbishment is required to maintain the artifact and professional display appearance.

1.4 Objectives

1.4.1 The objective of this contract is to provide for the exterior cosmetic restoration of the artifact. This artifact is located on Rivanna Station outside of the Nicholson Building. The tasks required to complete this identified refurbishment/restoration project by the contractor include surface cleaning; abatement of all fluids such as petroleum/oil/lubricants (to include fuel and hydraulic fluids); removal and disposal of any/all hazmat material (if present); removal, refurbishment and reinstallation of parts and components as required and as authorized; photo-document all markings, colors and schemes present on the exterior prior to surface preparation and failed coating/paint removal, and repainting and re-marking the artifact using period-correct materials, methods and marking schemes.

1.4.2 The contractor shall identify any radiation sources which will need to be fully encapsulated and clearly marked as posing a radiation hazard or, if authorized, removed and disposed of in accordance with all Occupational Safety and Health Administration (OSHA) and any applicable US Army regulations and requirements, such as OSHA Standard for Disposal of Ionizing Radiation 1910.1096 and US Army Regulation 11-9.

1.4.3 Any/all hazardous material removed from the artifacts as part of surface preparation and abatement processes must be collected and disposed of in accordance with appropriate regulations such as OSHA Standard for General Industry (29 CFR 1910) and US Army Technical Manual TM 38-410. Once surface preparation and abatement are complete the contractor will repaint and re-mark the artifact using appropriate methods and materials. If previously authorized, the contractor may repair or replace any parts or systems that are heavily deteriorated, though such removals and repairs will only take place after thorough review by NGIC COR and SME. If present, contractor shall service or replace tires, similar rubber components, or natural material components only with prior NGIC COR and SME authorization.

Once completed, these services will restore the artifact to its original period appearance and cosmetic condition.

1.5 Scope. The contractor shall work closely with NGIC CoR and SME during the refurbishment and restoration process of the artifact(s) being restored. The contractor shall provide all tasks defined in the PWS while observing all local State and Federal regulatory requirements for the abatement and removal of toxic and/or hazardous materials and paint. The contractor shall also adhere to pertinent installation requirements IAW with applicable DoD and Army regulatory requirements and ensure accordance with requirements as written in AR 870-20 and AR 870-5.

A site visit shall take place to evaluate and inspect the conditions of the artifact to be restored.

All restoration work will be performed off-site.

1.5.1 Quality Control. The contractor shall develop and maintain an effective quality control (QC) program to ensure services are performed IAW this PWS. The contractor shall develop and maintain an effective quality control program to ensure services are performed in accordance with this PWS. The contractor's quality control program is the means by which it will assure that performed work complies with the requirements of the contract. The contractor shall deliver a quality control plan (QCP) for this effort within five days after contract award. Changes to the QCP shall be submitted to the contracting officer (KO) and COR within five working days when changes are made thereafter. After acceptance of the quality control plan, the contractor shall obtain the KO's written acceptance of any proposed changes to its quality control (QC) system prior to implementation.

1.5.2 Quality Assurance. The Government shall monitor and evaluate the contractor's progress and performance under this contract IAW the Quality Assurance Surveillance Plan (QASP). This plan is primarily focused on what the Government must do to ensure the contractor has performed IAW the performance standards. It defines how the performance standards will be applied, the frequency of surveillance, and the minimum acceptable defect rate(s).

1.5.3 Recognized Holidays. The contractor is not required to perform services on the following Federal holidays.

New Year’s Day Labor Day Martin Luther King Jr.’s Birthday Columbus Day President’s Day Veteran’s Day Memorial Day Thanksgiving Day Juneteenth National Independence Day Christmas Day Independence Day

1.5.4 Hours of Operation. Typical Rivanna Station operating days are Monday through Friday except federal holidays or when the Government facility is closed due to local or national emergencies, administrative closings, or similar Government-directed facility closings. To avoid conflict with local traffic, the contractor is responsible for providing transportation services (removal and re-installation) of the artifact on a Saturday between the hours of operation of 0900-1500. Transportation shall be coordinated 14 days in advance of the planned event.

1.5.5 Place of Performance. Vendor off-site location.

1.5.6 Security Requirements

1.5.6.1 Personnel Security.

(a) The contractor and all associated subcontractors’ employees shall comply with applicable installation, facility, and area commander installation and facility access and local security policies and procedures (provided by the Government representative). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the installation Provost Marshal Office, Director of Emergency Services, or Security Office. The contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9 “Personal Identity Verification of Contractor Personnel”) as directed by DOD, HQDA, and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

(b) For contractors that do not require CAC, but require access to a DOD facility or installation:

Contractor and all associated sub-contractor employees shall comply with adjudication standards, and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190- 13), applicable installation, facility and area commander installation/facility access and local security policies and procedures elsewhere in this PWS.

1.5.6.2 Key Control. Not Applicable.

1.5.6.3 Physical Security. The contractor shall be responsible for safeguarding the artifact until such time that the artifact is returned to the display location on Rivanna Station.

1.5.7 Special Qualifications. The contractor shall be prepared to provide information on personnel performing the delivery and installation at the military installation in keeping with Rivanna Station's regulatory requirements governing access and security.

1.5.8 Post Award Conference/Periodic Progress Meetings. The contractor agrees to attend any post award/ kick off meeting conference convened by the contracting activity or contract administration office IAW Federal Acquisition Regulation (FAR) Subpart 42.5. The PCO, Contracting Officers Representative (COR), and other Government personnel, as appropriate, may meet periodically with the contractor to review the contractor's performance. At these meetings, the PCO will apprise the contractor of how the government views the contractor's performance and the contractor will apprise the Government of problems, if any, being experienced. Appropriate action shall be taken to resolve outstanding issues. These meetings shall be at no additional cost to the government.

1.5.9 Contracting Officer’s Representative (COR). The (COR) will be identified by a separate letter. The COR monitors all aspects of the contract and assists in contract administration. The

COR is authorized to perform the following functions: assure that the contractor performs the technical requirements of the contract; perform inspections necessary in connection with contract performance; maintain written and oral communications with the contractor concerning technical aspects of the contract; issue written interpretations of technical requirements, including Government drawings, designs, specifications; monitors the contractor's performance and notifies both the Contracting Officer and contractor of any deficiencies; coordinate availability of government furnished property; and provide site entry of contractor personnel. A letter of designation issued to the COR, a copy of which is sent to the contractor, states the responsibilities and limitations of the COR, especially with regard to changes in cost or price, estimates or changes in delivery dates. The COR is not authorized to change any of the terms and conditions of the resulting contract.

1.5.10 Key Personnel. The contractor shall provide a lead technician/macro artifact restoration specialist who shall be responsible for the performance of the work. The name of this person and an alternate who shall act for the contractor when the lead is unavailable shall be designated in writing to the PCO and COR. The lead technician/macro artifact restoration specialist or alternate shall have full authority to act for the contractor on all contract matters relating to daily operations on this contract.

1.5.11 Identification of Contractor Employees. Not Applicable.

1.5.12 Contractor Travel. Contractor travel to and from the established work location will be the responsibility of the contractor.

1.6 Period of Performance. 12 months from award of contract.

PART 2: DEFINITIONS AND ACRONYMS

2.1 Definitions

ARTIFACT RESTORATION- A process by which a three-dimensional artifact is restored to a previous state, condition or appearance. Restoration is most often required when artifact preservation and/or conservation efforts have failed or proven inadequate, and there is a need to physically restore the condition or appearance of an artifact to an identified previous state.

CONTRACTOR- A supplier or vendor awarded a contract to provide specific supplies or service to the government. The term used in this contract refers to the prime.

CONTRACTING OFFICER- A person with authority to enter into, administer, and or terminate contracts, and make related determinations and findings on behalf of the government. Note: The only individual who can legally bind the government.

CONTRACTING OFFICER'S REPRESENTATIVE (COR)- An employee of the U.S.

Government appointed by the contracting officer to administer the contract. Such appointment shall be in writing and shall state the scope of authority and limitations. This individual has authority to provide technical direction to the contractor as long as that direction is within the scope of the contract, does not constitute a change, and has no funding implications. This individual does NOT have authority to change the terms and conditions of the contract.

DEFECTIVE SERVICE- A service output that does not meet the standard of performance associated with the Performance Work Statement.

DELIVERABLE- Anything that can be physically delivered but may include non-manufactured things such as meeting minutes or reports.

KEY PERSONNEL- Contractor personnel who are considered essential to the successful performance of the work hereunder and are identified in the PWS as key personnel.

MACRO ARTIFACT- Any object that is too large for 1-2 Soldiers to move by hand, or else an object meant to be driven, flown, manned, controlled, or operated in some manner.

PHYSICAL SECURITY- Actions that prevent the loss or damage of Government property.

QUALITY ASSURANCE- The government procedures to verify that services being performed by the contractor are performed according to acceptable standards.

QUALITY ASSURANCE SURVEILLANCE PLAN (QASP)- An organized written document specifying the surveillance methodology to be used for surveillance of contractor performance.

QUALITY CONTROL- All necessary measures taken by the contractor to assure that the quality of an end product or service shall meet contract requirements.

SUBCONTRACTOR - One that enters into a contract with a prime contractor.

WORK DAY-The number of hours per day the contractor provides services in accordance with the contract; typically, between the hours of 0900-1500 IAW this PWS.

WORK WEEK- Monday through Friday, unless specified otherwise.

2.2 Acronyms

AR Army Regulation CDRL Contract Data Requirements List CFR Code of Federal Regulations CMH U.S. Army Center of Military History CONUS Continental United States (excludes Alaska and Hawaii) COR Contracting Officer's Representative COTR Contracting Officer's Technical Representative DOD Department of Defense FAR Federal Acquisition Regulation FPCON Force Protection Condition GFP Government Furnished Property HMD Historic Materiel Division KO Contracting Officer OCI Organizational Conflict of Interest OCONUS Outside Continental United States OSHA Occupational Safety Health Act PCO Procuring Contracting Officer POC Point of Contact POL Petroleum, Oil, and Lubricants PRS Performance Requirements Summary PWS Performance Work Statement QA Quality Assurance QAP Quality Assurance Program QASP Quality Assurance Surveillance Plan QC Quality Control QCP Quality Control Program SME Subject Matter Expert TE Technical Exhibit

PART 3: GOVERNMENT FURNISHED PROPERTY, EQUIPMENT, AND SERVICES

3.1 Equipment. All equipment, personnel, and services necessary to accomplish artifact restoration IAW this PWS will be furnished by the contractor. See also Part 4.

3.2 Materials. The only physical materials that will be furnished to the Contractor will be the historical artifact. Additionally, manuals and other documents to support approved repaint, re-marking, parts fabrication or purchase of materials and supplies may be provided by the Government, if requested and available.

3.3 Utilities. None.

3.4 Facilities. The Government will coordinate base access for approved contract personnel to Rivanna Station in Charlottesville, Virginia, to (a) transport the artifact off site for restoration and (b) transport back on site for reinstallation. See also 1.5.6.1(b) for security requirements of all personnel accessing Rivanna Station.

PART 4: CONTRACTOR FURNISHED ITEMS AND SERVICES

4.1 General. The contractor shall furnish all supplies, equipment, facilities, and services required to perform work under this contract that are not listed under Part 3 of this PWS.

4.2 Materials. The contractor shall furnish all materials required to complete work as outlined, in Part 5 below and/elsewhere in this PWS. Any additional materials for EPA mandated response kits, cleaning supplies, residue storage, paints, and any other materials deemed necessary to complete work are also to be supplied by the contractor. Examples include all paint/coating removal media and materials, cleaning supplies, paint reapplication tools, marking masks/stencils/templates, all materials required to collect abated fluids, disposal containers for removed batteries, radiation source encapsulation containers, spill and accident clean-up materials, and other similar or related materials.

4.3 Equipment. The contractor shall furnish all equipment and tools required to complete work outlined in this PWS. Of particular note, paints/coatings currently covering artifacts may contain lead, barium, hexavalent chromium, cadmium, or other known carcinogens (such as CARC paint). The contractor must provide to all workers any and all necessary equipment to follow Occupational Safety Health Act (OSHA) regulations for preventing exposure to heavy metals and toxic materials as part of any paint/coating removal process. Additionally, all hazmat materials must be properly disposed of IAW Government requirements utilizing appropriate collection equipment and storage/disposal containers.

PART 5: SPECIFIC TASKS

5.1 Basic Services. The contractor shall provide services for:

5.1.1 Project Schedule

The contractor shall prepare and present to COR a proposed project schedule, complete with meeting and milestone dates. The contractor shall, during the course of the project, track the project to see that the project remains on schedule.

5.1.2 Artifact Photo-documentation

The contractor shall fully and comprehensively photo-document all surfaces to be prepared and restored as part of the restoration process. This will ensure that any remnants of original markings or paint/coatings will be recorded and available for reference once surface preparation has been completed. These reference photos may assist greatly with the later re- application or paint/coatings and markings once that process has commenced. All such photos and documentary records created as part of this process will be provided to the NGIC contract COR as part of a comprehensive post-restoration report for the artifact restored. This report will become part of the artifact's historical property record and will therefore be available for reference and review for any future restoration projects.

5.1.3 Artifact Surface Cleaning and Preparation

The contractor shall undertake the full cleaning of all exterior artifact surfaces in advance of any required coating removal. Initial surface cleaning and preparation will be performed prior to any succeeding steps in order to best determine the physical condition of the artifact, locate and note any areas of particular challenge related to deterioration or other issue, and to ensure that historic materials will be preserved to the greatest extent possible during the surface coating removal and repainting preparation processes.

5.1.4 Artifact Abatement

The contractor shall undertake the abatement of all hazardous materials. This may include the removal and capture of potentially toxic fluids such as petroleum/oil/lubricants (POLs); the removal and proper disposal of batteries of all types; the removal and/or depressurization of pressurized fire suppression systems (determined on a per- case basis); encapsulation and marking (or removal if authorized) of all radiological sources and materials, such as Radium paint, Tritium, and/or Cesium; the demilitarization and safing of main and support weapons systems (if present); and removal or identification of other materials that could pose a hazard.

5.1.5 Artifact Failed Coating Removed

The contractor shall fully and properly prepare all exterior surfaces for repainting and re-marking through the removal of failed paint and coatings, as well as surface corrosion and debris, if present. While it is desirable to retain as much original materials and components as possible, it is also understood that the failure of original or replacement paint and coatings often leads to the need for cosmetic restoration. This being the case, the contractor shall use a method(s) of surface paint/coating removal and preparation appropriate to the task to fully prepare the underlying substrate material for the re-application and re-marking of paint, coatings and markings. It should be noted that artifacts of this type are very rare, often one-of-a-kind, and great care must be taken to induce no damage to any part of the artifact. All work must be completed in accordance with all Federal, State, and local environmental and safety regulations. All work must be completed in a manner which allows for 100% material collection upon removal. Any method used should fully remove all paint/coatings and properly prepare all surfaces for new coating application.

5.1.6 Limited Parts Removal and Refurbishment

If parts or components are deemed to be too deteriorated to be reasonably restored, period-manufactured replacement parts of the exact same fit, finish and construction may be considered on a per-case basis. If no such original purpose-made replacement parts or components are available, alternatives may be considered to include new fabrication of parts/components to replicate the original historic material as closely as possible (in-kind repair), assuming original materials and fabrication methods are replicated as closely as possible to the original. All such fabricated parts must be created using as close to original materials and methods of manufacture as possible, and all must be clearly marked as non-original and documented in the artifact's permanent record. In rare cases, damaged parts or components may be considered for use as a positive mold for resin casting as part of the creation of a 1-for-1 replica part that can be made to appear exactly like the original. No such repair or replacement will be performed unless explicitly authorized by the contract COR and NGIC SME personnel. Replacement of tires, rubber components, plastic, or other natural or synthetic materials may be considered on a per-case basis, though only after consultation with and approval of the contract COR. Only period-original or, if unavailable, period-correct replacement materials may be used if replacement is authorized. Under no circumstances will the contractor undertake any part/component/material removal without first notifying the COR and SMEs of the need to do so and receiving authorization to proceed.

5.1.7 Primer, Surface Coating and Marking Reapplication

Once all surfaces to be cosmetically restored have been prepared, the contractor shall apply new paint and markings of period-correct color, material formulation, and application scheme to all surfaces being cosmetically restored. Correct Federal Standard colors and markings appropriate for the era being represented by the artifact must be used, and all primer and paint formulations must similarly match paint formulations used when the artifact was in active Army service.

Authenticity and historical integrity are paramount as part of any cosmetic restoration, and as such only original materials and methods will be authorized. Deviations or substitutions may be considered on a per-case basis, though no such change or substitution is to be performed with express authorization from the contract COR.

5.1.8 Final Written and Photographic Completion Report

Upon completion and approval of all restoration work performed, the contractor shall provide to the COR a detailed photographic and written report to fully document restoration of the artifact.

As work progresses, photos must be taken to document the process and progress made, and all such photos and written reports will be included in the final post- restoration report provided by the contractor to NGIC. All such photographs and written records will become part of the restored artifact's permanent historical property record so that all work performed, and methods and materials used, will be preserved for review by future restoration projects.

PART 6: LABOR CATEGORIES AND MINIMUM QUALIFICATIONS

The following labor categories and minimum qualifications must be met by any personnel used by the contractor to fulfill the requirements of work undertaken as part of this contract.

6.1 Lead Technician/Macro Artifact Restoration Specialist

A minimum of seven years’ experience performing all aspects of work associated with the cosmetic restoration and limited structural repair necessary for all phases of the restoration process for high-technology, primarily metal-based artifacts. This will include work related to the documentation, surface preparation, repainting/re-marking, and final detail phases of any cosmetic restoration project. This work may also include the removal, repair, replacement, and reinstallation of component elements of such artifacts on a per-case basis as authorized by the COR and/or SME curatorial personnel. The lead technician have full authority to act for the contractor on all matters related to the contract and shall serve as the primary point of contact to the USG.

6.2 Paint Technician/Macro Artifact Restoration Specialist

A minimum of five years’ experience performing all aspects of work associated with the surface preparation, failed coatings removal, paint coating re-application, and historic markings re-application needed for the limited cosmetic restoration of high-technology, primarily metal-based artifacts. Such work will require a great deal of care and attention to detail, and all such work must be performed to the highest level of quality utilizing historical research and provided applicable historical reference photos and documents (if available), as well as in keeping with established best museum practices for the cosmetic restoration of such technological artifacts.

6.3 Macro Artifact Abatement Specialist

A minimum of five years’ experience performing all aspects of work associated with the abatement of hazardous and/or toxic materials from high-technology artifacts of various types.

Such work may include the removal petroleum-based materials (e.g., POLs, fuel, hydraulic fluid, etc.), removal and safing of pressurized fire suppression systems, removal or encapsulation of materials that are a source of ionizing radiation (Radium paint, Tritium, Cesium, etc.), removal of batteries, and removal of other types of hazardous materials that may be present as part of an artifact being restored. This specialist will need to ensure that all abatement work is performed safely and completely, in accordance with all pertinent safety and regulatory requirements, and will be responsible for all compliance documentation and assurance as part of their work.

PART 7: APPLICABLE PUBLICATIONS

The contractor shall comply with all applicable regulations, publications, manuals, and local policies and procedures depicted below:

Army Regulations AR 870-20 and AR 870-5.

National Park Service HABS/HAER/HALS Photography Guidelines AIC Guide To Digital Photography & Conservation Documentation AIC PMG Examination and Documentation Federal Standards 595 (use appropriate version to correspond with service time period.)

General Services Acquisition Manual (GSAM) 552.236-15

TECHNICAL EXHIBIT 1: Performance Requirements Summary (PRS)

The contractor service requirements are summarized into performance objectives that relate directly to mission essential items. The performance threshold briefly describes the minimum acceptable levels of service required for each requirement. These thresholds are critical to mission success.

Performance Objective Performance Indicator Performance Threshold

PRS # 1.

The work to be performed under this Performance Work Statement (PWS) consists of the contractor furnishing all labor, materials, supplies, equipment and professional supervision to accomplish all requirements as listed in PWS Part 5 pertaining to the cosmetic restoration and abatement of the artifact.

PWS Para. 5

Complete all restoration work as described in PWS Part 5. Work must be completed within the time frame stated in the submitted and approved Project Schedule (PRS #2).

Complete 100% of restoration tasks as listed in this PWS. All work must be inspected by NGIC CoR and SME and, in instances where deficiencies in performance or quality are found, any such deficiencies shall be corrected by the contractor at contractor’s expense.

PRS # 2 Project Schedule Submission

PWS Para. 5.1.1

Contractor shall prepare and present a proposed project schedule, complete with planned meetings, milestone dates, and progress tracking methods, within 14 days of contract award.

Provide a Project Schedule listing requirements, materials, and completion milestones. Final performance evaluation will be based upon the quality and completeness of work as laid out in the submitted and approved schedule. Any deviation or deficiency shall be corrected by the contractor before any approved work performed.

PRS # 3 Original surface coating photo-documentation

PWS Para. 5.1.2

Fully photo-document all artifact surfaces to be prepared and restored as part of the cosmetic restoration process. All such work must occur within the agreed-upon time frame as established in the submitted Project Schedule

Complete 100% of surface preparation work as listed in the contract PWS.NGIC COR will review photos created as part of this PRS to ensure the necessary original marking and coloration information is captured. Failure to fully document all original paint schema and markings present prior to the commencement of restoration work may result in delays to work proceeding until all identified deficiencies are corrected.

PRS # 4 Surface cleaning in preparation to remove all failed exterior coatings.

PWS Para. 5.1.3

All surfaces prepared for removal of old paint and markings as described in PWS para.5.1.3. All such work must occur within the agreed-upon time frame as established in the submitted Project Schedule

Complete 100% of surface cleaning and preparation work as listed in the PWS. Failure to complete this PRS may cause poor results in the removal of failed coatings, leading to poor results in the re-application of primer, paint coating and markings materials, This would then result in the requirement to remove and re-apply deficient or incorrect paint and markings at the contractor’s expense.

PRS # 5 Abate all hazardous materials retained by the artifact(s) being restored

PWS Para. 5.1.4

Complete all abatement procedures required.

Complete 100% of abatement work to remove hazardous materials

PRS # 6 Fully prepare all exterior surfaces to allow for repainting and reapplication of markings

PWS Para. 5.1.5

Fully remove all exterior coatings and markings in order to allow the repainting and reapplication of markings as described in PWS para. 5.1.5. All such work must occur within the agreed-upon time frame as established in the submitted Project Schedule

Complete 100% of surface preparation work as listed in the PWS. Failure to complete the work may result in poor paint/marking reapplication results, necessitating the removal/reapplication of materials in noted deficiency areas at the contractor’s expense, up to and including the complete removal/reapplication of cosmetically restored surfaces on the artifact.

PRS # 7 Complete all required parts removal, refurbishment, and restoration

PWS Para. 5.1.6

Fully remove, as authorized and required, all parts requiring removal, refurbishment, and restoration. Fully ensure all such removed/restored parts are re-installed prior to commencement of work as part of PWS para. 5.1.7. All such work must occur within the agreed-upon time frame as established in the submitted Project Schedule

Complete 100% of parts preparation and re-installation work as listed in the PWS. All surface or part repair work, if required and authorized, must be completed. Failure to complete the work may result in poor paint/marking reapplication results, necessitating the removal/reapplication of materials in noted deficiency areas at the contractor’s expense.

PRS # 8 Re-apply period-correct primer, paint and markings using correct color, formulations, and marking schemes.

PWS Para. 5.1.7

Reapply period-correct primer, paint coatings, and markings to ensure proper cosmetic appearance and historical integrity. All work must be completed within the agreed-upon time frame as established in the submitted Project Schedule and must be completed to the level of quality stipulated by best museum practices and industry standards.

Complete 100% of repainting and re-marking work as scheduled.

Completed work will be fully inspected by NGIC CoR and SME and any documented areas of coating materials/markings application issues or deficiency shall be repaired or corrected at the contractor’s expense.

PRS # 9 Create and submit a detailed photographic and written report to document all work performed on the artifact.

PWS Para. 5.1.8

Provide the contract COR the required photographic and written report documenting all cosmetic restoration and parts repair/refurbishment work performed in the restoration.

Submit completed report documenting the cosmetic restoration work as scheduled and required. Any deficiency corrections or changes required shall be completed by the contractor at contractor’s expense.

TECHNICAL EXHIBIT 2: Deliverables Schedule

CDRL

Deliverable Frequency

# of Copies Medium/Format

Submit To

A001 Contractor shall provide a list of known hazardous materials to be addressed as part of the proposed artifact restoration work

PWS Para. 1.2.1

Once 1 Word document supplied as electronic file.

COR

A002 Contractor shall submit its quality control plan (QCP) withing five days after contract award.

Contractor shall submit any proposed quality control plan (QCP) changes or revisions prior to implementation.

PWS Para. 1.5.1

Initial QCP once.

Proposed

QCP

changes as required.

1 Word document supplied as electronic file.

KO &

COR

A003 Contractor shall submit to the COR a proposed project schedule, complete with meeting/ milestone dates.

PWS Para. 5.1.1

Once 1 PDF document or other appropriate format.

A004 Contractor shall submit a comprehensive pre-restoration photo-documentation portfolio for the artifact. PWS Para. 5.1.2

Once 1 PDF, Word document and/or photographs supplied as electronic files.

COR &

SME

A005 Contractor shall provide a final written and photographic restoration report for the artifact restored under this contract. This will include results from initial original surface coating photo-

Once 1 PDF, Word document and/or photographs supplied as electronic files.

CDRL

Deliverable Frequency

# of Copies Medium/Format

Submit To documentation. PWS Para. 5.1.8