N6945022C0050 EHW2 Stairwell.pdf

PDF 1 MB Posted Aug 25, 2022

Attached to: EHW2 Stairwell
Solicitation number: N6945022C0050
Issued by: Department of the Navy Naval Facilities Engineering Command

View the file

On GovTribe

Work with this file

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

This Request for Proposal (RFP) N69450-22-R-0087, EHW2 Stairw ell, Naval Submarine Base (NSB) Kings Bay, Georgia is being offered as an 8(a) procurement under the SBA and DoD Partnering Agreement. The project is being offered to Miami Tribal Systems Integrators, L.L.C, SAM Unique Entity ID XBMKBMFHALD7: CAGE 8BSY3. The Contractor is Active in Sam and in good standing w ith the SBA.

The Assigned SBA Requirement Number is QW1651085004T.

The North American Industry Classif ication Code System (NAICS) is 236220 Commercial and Institutional Building Construction. The small business size standard is $39,500,000.

The Attached PPI log w ith current PPI'S and Government responses is incorporated in Attachment B In accordance w ith FAR 36.204, the magnitude of Construction is betw een $1,000,000 and $5,000,000.

All Correspondence regarding this solicitation shall be directed tow ard the Contracting Off icer at nicole.r.riffe.civ@us.navy.mil and the Contract Specialist at anthony.mcavoy.civ@us.navy.mil.

Instructions to Offerors can be found in section 00100 of this solicitation.

NICOLE R. RIFFE 912-573-4365

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

25-Aug-2022

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________25 May 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

N6945022C0050

7. ISSUED BY CODE

NAVFAC ENGINEERING SYSTEMS COMMAND SE

PWD KINGSBAY

910 USS HUNLEY AVE

NSB KINGSBAY

KINGSBAY GA 31547

N69450

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

N6945022R0087 26

See Item 7

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE

8BSY3

FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

SEE SCHEDULE

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

$2,380,613.00 See Schedule

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified) 1

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

X 10 U.S.C. 2304(c) (5) 41 U.S.C. 253(c) ()

CODE N6873227. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

DEFENSE FINANCE & ACCOUNTING SERVICE

PO BOX 998022

CLEVELAND OH 44199

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR

MIAMI TRIBAL SYSTEMS INTEGRATORS LLC

1950 ROLAND CLARKE PL STE 210H

RESTON VA 20191-1414

15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.)1 Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract. REF: KTR Proposal dated 06 Aug 2022

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENTX

(M ust be fully completed by offeror)OFFER

Patrick D. Miller, General Manager

08/24/2022

The Assigned SBA Requirement Number is QW1651085004T.

The North American Industry Classif ication Code System (NAICS) is 236220 Commercial and Institutional Building Construction. The small business size standard is $39,500,000.

The Attached PPI log w ith current PPI'S and Government responses is incorporated in Attachment B In accordance w ith FAR 36.204, the magnitude of Construction is betw een $1,000,000 and $5,000,000.

All Correspondence regarding this solicitation shall be directed tow ard the Contracting Officer at nicole.r.rif fe.civ@us.navy.mil and the Contract Specialist at anthony.mcavoy.civ@us.navy.mil.

Instructions to Offerors can be found in section 00100 of this solicitation.

NICOLE R. RIFFE 912-573-4365

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

25-Aug-2022

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________25 May 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

N6945022C0050

7. ISSUED BY CODE

NAVFAC ENGINEERING SYSTEMS COMMAND SE

PWD KINGSBAY

910 USS HUNLEY AVE

NSB KINGSBAY

KINGSBAY GA 31547

N69450

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

N6945022R0087 26

See Item 7

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE

8BSY3

FACILITY CODE

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

SEE SCHEDULE

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

$2,380,613.00 See Schedule

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified) 1

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

X 10 U.S.C. 2304(c) (5) 41 U.S.C. 253(c) ()

CODE N6873227. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

DEFENSE FINANCE & ACCOUNTING SERVICE

PO BOX 998022

CLEVELAND OH 44199

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR

MIAMI TRIBAL SYSTEMS INTEGRATORS LLC

1950 ROLAND CLARKE PL STE 210H

RESTON VA 20191-1414

15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print) Nicole R. Riffe / Contract Specialist

TEL: 912-573-8176 EMAIL: nicole.riffe@navy.mil

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY 25-Aug-2022

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENTX

(M ust be fully completed by offeror)OFFER

N6945022C0050

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Project $2,380,613.00 $2,380,613.00 EHW 2 Stairwell to Crane Rail

FFP

This is a DB FFP contract for work that includes constructing a staircase that meets code requirements of rise/run from the finished floor to the Crane rail structure, as well as the roof access. Additional requirements can be found in the statement of work.

FOB: Destination

PSC CD: Z1ED

NET AMT $2,380,613.00

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

000101 $0.00

FUND ACRN AA

FFP

Funding Doc. No. N6470922RX00023 Customer ACRN: AA

MILSTRIP: N6470922RX00023

NET AMT $0.00

ACRN AA

CIN: 000000000000000000000000000000

$2,380,613.00

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 25-AUG-2023 1 PWD KINGS BAY

INSPECTOR OF RECORD

910 USS HUNLEY

NSB KINGS BAY

KINGS BAY GA 31547-2613

912-573-4610 FOB: Destination

N68248

000101 N/A N/A N/A N/A

ACCOUNTING AND APPROPRIATION DATA

AA: 97X8242 3080 254 68733 0 050120 2D 000000

COST CODE: A00006979431

AMOUNT: $2,380,613.00

ACRN CLIN/SLIN CIN AMOUNT

AA 000101 000000000000000000000000000000 $2,380,613.00

INSTRUCTIONS TO OFFERORS

This acquisition is anticipated to result in a Firm-Fixed Price (FFP) contract to perform Construction of a staircase that meets code requirements of rise/run, in the Waterfront Restricted Area (WRA) onboard Naval Submarine Base (NSB) Kings Bay, GA. Additional details on this project can be located in the KB RFP EHW2 Stair to Crane Rail Final (attachment A).

System for Award Management (SAM):

Contractors must be registered in SAM prior to award of a Department of Defense (DoD) contract. For more information and to complete the electronic representations and certifications, see the Sam.gov website at https://sam.gov. A contract cannot be awarded to a contractor that is not registered in SAM. Remember to review the NAICS codes listed in your SAM record and make sure that you have listed the NAICS code for this procurement:

Federal Contractor Program:

In accordance with Federal Acquisition Regulation (FAR) 22.1303, any contractor or subcontractor with a contract of $150,000 or more with the Federal Government MUST take affirmative action to hire and promote qualified targeted veterans. This includes, special disabled veterans, veterans of the Vietnam-era, recently separated veterans, and any other veterans who served on active duty during a war or in a campaign or expedition for which a campaign badge has been authorized. Companies MUST file an annual VETS-4212 report, which shows the number of targeted veterans in their work force by job category, hiring location, and number of new hires, including targeted veterans hired during the reporting period and the maximum number and minimum number of employees of such contractor during the period covered by the report. Instructions, information and follow-up assistance is provided at VETS-4212 Internet site at https://www.dol.gov/vets/vets4212.htm or employers may contact the VETS- 4212 Processing Center at (866) 237-0275 or e-mail at https://www.dol.gov/agencies/vets/programs/vets4212

Overhead Rates:

Home Office Overhead – The Contractor shall provide a current Defense Contract Audit Agency audit report (no more than three years old) or the firms previous three years of expenses utilizing the HOOH Accounting Data Spreadsheet (attachment C). Submit normal HOOH rates for proposed subcontractor overhead rates.

Field Office Overhead (FOOH). You may choose either Percent Based or Daily Rate Methods: The contractor shall provide actual costs for field office overhead utilizing the FOOH spreadsheet (attachment D).

The method chosen by the Contractor shall be incorporated in the attached Proposal Price Breakdown sheet (attachment E). If the Contractor chooses the Percent Based Method, the pre-negotiated rates shall be applied to all modifications. If the Contractor chooses the Daily Rate Method, the daily rate will only be applied to compensable time extension modifications.

All pricing and overhead attachments shall submitted in MS Excel format, it is acceptable to submit a second copy in PDF format to preserve proposal integrity if desired.

Your choice of a Percent Based or Daily Rate Method rate for Field Office Overhead will be used for the entirety of this contract in addition to your agreed upon HOOH percentages.

Contractor negotiated a 12.00% HOOH rate and 10.00% FOOH rate for this contract and all modifications.

Home Office Overhead (HOOH) Change After Award:

In the event the contractor receives an audit by Defense Contract Audit Agency (DCAA) during the term of the contract, the HOOH rate may be adjusted to reflect the DCAA recommended HOOH. The contractor shall provide a complete copy of the DCAA audit and shall include the audit enclosures/documentation to facilitate the establishment of the HOOH.

Authority:

(a). No person other than the Contracting Officer has authority to bind the Government with respect to this contract.

(b). No action or omission of any government employee or representative other than the Contracting Officer shall increase or decrease the scope of this contract or shall otherwise modify the terms and conditions of this contract.

(c). In no event shall any of the following be effective or binding on the Government or imputed to the Contracting Officer with respect to this contract:

(i) An understanding or agreement between the Contractor and anyone other than the Contracting Officer;

(ii) A purported modification or change order issued by anyone other than the Contracting Officer;

(iii) A promise by anyone other than the Contracting Officer to provide additional funding or make payments;

(iv) An order, direction, consent, or permission from anyone other than the Contracting Officer to:

(A) Incur costs in excess of a specified estimated cost, allotment of funds, or other ceiling; or

(B) Expend hours in excess of a specified level of effort.

Installation Access:

The Contractor is to start the process indicated in the Division 01 General Requirements specifications to request badging for personnel within 10 days of contract award to ensure they have access to the site.

Subcontracts:

In accordance with FAR Clause 52.222-11 the contractor shall

(a) Within 14 days after award of the contract, the Contractor shall deliver to the Contracting Officer a completed Standard Form (SF) 1413, Statement and Acknowledgment, for each subcontract for construction within the United States, including the subcontractor’s signed and dated acknowledgment that the clauses set forth in paragraph (b) of this clause have been included in the subcontract.

(b)Within 14 days after the award of any subsequently awarded subcontract the Contractor shall deliver to the Contracting Officer an updated completed SF 1413 for such additional subcontract.

Wage Rate Requirements (Construction) Wage Determination

The following Department of Labor, Wage Rate Requirements (Construction) are hereby incorporated and are applicable to this contract. This list of wage determinations is based on the primary locations of work anticipated under this contract.

Wage Determination GA20220087 dated 02/25/2022 Mod 02: Georgia, Construction Type Building Camden

County, (attachment H).

Defense Priority and Allocation:

In accordance with FAR Clause 52.211-15 this contract is a DO C2 rated order certified for national defense, emergency preparedness, and energy program use, and the Contractor shall follow all the requirements of the Defense Priorities and Allocations System regulation (15 CFR 700).

Contractor Pricing for Proposal and Modifications:

Negotiations may be held to obtain fair and reasonable pricing. Changes to line items will be transparent and all proposals will be submitted using the attached Proposal Price Breakdown sheet (attachment E) in MS Excel format at a minimum, to enable efficient proposal analysis by the Government. Subtotals and back-end calculations for each line item, as well as major category of work; Labor, Material and Equipment, shall be visible on the submitted proposal. It is acceptable to submit a second copy in PDF format to preserve proposal integrity if desired.

Proposals for modifications shall be priced using the same Proposal Price Breakdown sheet as the awarded contract and include all pre negotiated overhead rates as indicated in the above paragraph titled Overhead Rates. In the event that a deductive modification is negotiated, the basis for pricing shall be the same as submitted under the proposal for the work.

Prices for construction materials, services, and work:

The Contractor shall submit their cost using the following methods:

Items/prices identified in R.S. MEANS or the CostWorks Database (or similar) are preferred due to the ease of comparison with the Government Estimate for the determination of fair and reasonable pricing. The contractor shall break down the work into individual work items selecting the applicable Bare Cost Unit Pricing for material, labor, and equipment from R.S. Means or CostWorks.

For Items/prices which are not listed by in a commonly utilized commercial construction estimating software such as R.S. Means or CostWorks Database. The Contractor and/or subcontractor shall provide a cost breakdown when utilizing subcontractor quotes. The Contractor shall provide competitive quotes if the work cannot be performed by the 8(a) Contractor or if the government is not satisfied with the Contractor’s proposed pricing and/or methodology for accomplishment of the scope. The Contractor shall submit to the Contracting Officer, a detailed quote abstract reflecting the quotes received and the Contractor’s analysis performed to determine the winning quote including a copy of the quote. The Contractor shall maintain complete supporting documentation (including responsibility and responsiveness checks) necessary to provide a complete and accurate audit trail of all actions in accordance with FAR 15.404-3 for the Contracting Officer’s review. Upon receipt and review of the abstract by the Contracting Officer, a coordination meeting may be initiated with the Contractor to resolve any discrepancies.

The negotiated price for each work item shall include the accepted bare costs for material, labor, and equipment multiplied by the quantity or required man hours for each task. Reasonable subcontractor overhead and profit rates are allowable markups when applicable and subject to mutual agreement of the parties. Prime mark-up will be at the negotiated Home Office and Field Office Overhead rates with a profit determined fair and reasonable.

Submissions must be provided in sufficient detail as to enable a determination of fair and reasonable pricing.

In the event that the contractor is unable to find more than one Offeror the Contractor shall submit sufficient detail to permit an analysis, to include but not limited to: quotes for material, quotes for equipment, and payroll.

Per Diem: All per diem costs shall be separately broken out in the attached Proposal Price Breakdown sheet (attachment E). Per-diem shall not be included in labor costs. Per-diem shall be a separate line item on the schedule of values and proper receipts/invoices shall be provided for the prime and all subcontractors prior to payment.

Section 00 21 16 - Instructions to Proposers

CLAUSES INCORPORATED BY REFERENCE

252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements MAR 2022 252.215-7013 Supplies and Services Provided by Nontraditional Defense

Contractors.

JAN 2018

CLAUSES INCORPORATED BY FULL TEXT

52.211-14 NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

Any contract awarded as a result of this solicitation will be DO-C2 rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation.

(End of provision)

Section 00 22 16 - Supplementary Instructions to Proposers

52.215-22 Limitations on Pass-Through Charges--Identification of

Subcontract Effort

OCT 2009

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government N/A Government 000101 N/A N/A N/A N/A

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

JUN 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-2 Alt I Security Requirements (MAR 2021) - Alternate I APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

NOV 2021

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities

NOV 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.211-15 Defense Priority And Allocation Requirements APR 2008 52.215-2 Audit and Records--Negotiation JUN 2020 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011 52.215-12 (Dev) Subcontractor Certified Cost or Pricing Data (DEVIATION

2022-O0001)

OCT 2021

52.215-15 Pension Adjustments and Asset Reversions OCT 2010 52.215-17 Waiver of Facilities Capital Cost of Money OCT 1997 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997 52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

NOV 2021

52.215-21 Alt III Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data -- Modifications (NOV 2021) - Alternate III

OCT 1997

52.215-23 Limitations on Pass-Through Charges JUN 2020 52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-28 Post-Award Small Business Program Rerepresentation SEP 2021 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021 52.222-54 Employment Eligibility Verification DEC 2021 52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001 52.223-9 Estimate of Percentage of Recovered Material Content for

EPA-Designated Items

MAY 2008

52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons.

JUN 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.223-20 Aerosols JUN 2016 52.223-21 Foams JUN 2016 52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 (Dev) Individual Surety--Pledge of Assets (DEVIATION 2020-

O0016)

FEB 2021

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 (Dev) Performance and Payment Bonds-Construction. (Deviation

2020-O0016)

JUN 2020

52.228-17 Individual Surety--Pledge of Assets (Bid Guarantee) FEB 2021 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-25 Prompt Payment JAN 2017 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

NOV 2021

52.233-1 Disputes MAY 2014 52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-2 Subcontracts JUN 2020 52.244-5 Competition In Subcontracting DEC 1996 52.244-6 Subcontracts for Commercial Products and Commercial

Services

JAN 2022

52.246-12 Inspection of Construction AUG 1996 52.246-13 Inspection--Dismantling, Demolition, or Removal of

Improvements

AUG 1996

52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2020 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-2 Alt I Termination for Convenience of the Government (Fixed- Price) (Apr 2012) - Alternate I

SEP 1996

52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984 52.249-10 Alt I Default (Fixed-Price Construction) (Apr 1984) Alternate I APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

252.204-7020 NIST SP 800-171 DoD Assessment Requirements MAR 2022 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.219-7011 Notification to Delay Performance JUN 1998 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic MAR 2022 252.225-7002 Qualifying Country Sources As Subcontractors MAR 2022 252.225-7012 Preference For Certain Domestic Commodities MAR 2022

252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7004 (Dev) DoD Progress Payment Rates (DEVIATION 2020-O0010) MAR 2020 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.236-7006 Cost Limitation JAN 1997 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JAN 2021 252.244-7001 Contractor Purchasing System Administration MAY 2014 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for

Military Operations

OCT 2010

252.247-7023 Transportation of Supplies by Sea FEB 2019

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

(a) Definition.

United States, as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

(b) Display of fraud hotline poster(s). Except as provided in paragraph (c)--

(1) During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites--

(i) Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and

(ii) Any DHS fraud hotline poster subsequently identified by the Contracting Officer.

(2) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.

(3) Any required posters may be obtained as follows:

Poster(s) Obtain from https://www.dhs.gov/blue-campaign/materials/posters-general-awareness—

(i) Appropriate agency name(s) and/or title of applicable Department of Homeland Security fraud hotline poster);

and

(ii) The website(s) or other contact information for obtaining the poster(s).)

(c) If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

(d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed the threshold specified in Federal Acquisition Regulation 3.1004(b)(1) on the date of subcontract award, except when the subcontract--

(1) Is for the acquisition of a commercial product or commercial service; or

(2) Is performed entirely outside the United States.

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365 Calendar days. The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $345.62 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-14 LIMITATIONS ON SUBCONTRACTING (SEP 2021)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that--

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are--

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are--

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 19.504(c)(1)(ii); and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for--

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause--

[Contracting Officer check as appropriate.]

X By the end of the base term of the contract and then by the end of each subsequent option period; or

By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph

(e) of this clause will be performed by the aggregate of the joint venture participants.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

22.2 6.9

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Georgia, Camden County, Kings Bay.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (NOV 2021)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial product (as defined in paragraph (1) of the definition of "commercial product" at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if--

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 55 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or…

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it. Updated Aug 25, 2022.