N50054-18-R-0004_USNS_HUGO_(TSV-2).pdf

CODE

(Hour)

PAGE(S)

until 01:00 PM local time 26 Feb 2018

X

A

X B

X C X D

EX

X

G

F 60 - 71

72 - 86

X H 87 - 91 blair.allen@navy .mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

1 91

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N50054 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

NSN BLDG LF-18 QuarterDeck conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

BLAIR ALLEN 757-400-0327

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 3

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

4 - 23

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

26 - 28 X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 29 - 33 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 34 - 38 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

39 - 58

PART II - CO NTRACT CLAUSES

MID-ATLANTIC REGIONAL MAINTENANCE CENTER

CODE 411,

9727 AVIONICS LOOP

NORFOLK VA 23511-2124 (757) 396-5041

(757) 396-1762FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.

N5005418HUGO

5. DATE ISSUED

20 Dec 2017

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N5005418R0004

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

CLIN

Number

USNS HUGO (TSV-2) DPMA

FFP

Job

Prepare for and accomplish the Drydock Phased Maintanence Availability for USNS

HUGO (TSV-2), SSP No. NSSA-501-18.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a

DoD recognized unique identification equivalent.

FOB: Destination

PURCHASE REQUEST NUMBER: N5005418HUGO

SIGNAL CODE: J

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

CLIN

Number

CDRLs

FFP

Job

Data for CLIN 0001 (see DD1423 Exhibits A and B hereto) Price to be included in the price of CLIN 0001.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a

DoD recognized unique identification equivalent.

FOB: Destination

PURCHASE REQUEST NUMBER: N5005418HUGO

SIGNAL CODE: J

NET AMT

CLAUSES INCORPORATED BY FULL TEXT

HQ B-2-0004 EXPEDITING CONTRACT CLOSEOUT (NAVSEA) (DEC 1995)

(a) As part of the negotiated fixed price or total estimated amount of this contact, both the Government and the

Contractor have agreed to waive any entitlement that otherwise might accrue to either party in any residual dollar amount of $500 or less at the time of final contract closeout. The term “residual dollar amount” shall include all money that would otherwise be owed to either party at the end of the contract, except that, amounts connected in any way with taxation, allegations of fraud and/or antitrust violations shall be excluded. For purposes of determining residual dollar amounts, offsets of money owed by one party against money that would otherwise be paid by that party may be considered to the extent permitted by law.

(b) This agreement to waive entitlement to residual dollar amounts has been considered by both parties. It is agreed that the administrative costs for either party associated with collecting such small dollar amounts could exceed the amount to be recovered.

HQ B-2-0022 CONTRACT SUMMARY FOR PAYMENT OFFICE (FIXED PRICE) (FEB 1997)

This entire contract is fixed price.

TOTAL FOR CLIN 0001 _____________________

TOTAL FOR CLIN 0002 _____________________

TOTAL FOR CLIN 0001 THROUGH CLIN 0002 _____________________

PROGRESS PAYMENT RATES

The progress payment rate for this contract is 90 percent for large business and 95 percent for small business.

Section C - Descriptions and Specifications

SECTION C

CONTRACT LINE ITEM NUMBER (CLIN) DECRIPTIONS

CLIN 0001 Prepare for and accomplish the Drydock Phased Maintenance Availability (DPMA) of USNS

HUGO (TSV-2) as delineated in the specification package NSSA-501-18 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed data provided by the government in accordance with Section J.

CLIN 0001

042-00-001 Accountability of Manhour and Material Reservation; accomplish

042-10-002 Work Completion Certification Data for Chief of Naval Operations (CNO) Availabilities;

provide

077-10-001 Hazardous Waste Produced on Naval Vessels; control

110-11-001 American Bureau of Shipping (ABS) Survey of Hull Plating and appendages; accomplish

110-11-002 Underwater Hull and Freeboard; repair and preservation

113-10-001 American Bureau of Shipping (ABS) 5 Year Gauging Main Deck, Superstructure and all associated appendages and components; accomplish

113-10-002 Main Deck, Forecastle, Bridge Deck, and Pilot House Deck above; repair

123-11-001 American Bureau of Shipping (ABS) Survey of Tanks and Voids; accomplish

123-11-002 Tank and Void; repair and preserve

168-10-001 Quick Acting Watertight Door and Frame; replace

233-11-001 Diesel Engine and Bow Thruster Engine; overhaul

243-11-001 Propulsion Shafting; inspect and repair

245-11-001 Propeller; inspect and repair

311-22-001 Ship Service Diesel Generator (SSDG); clean, repair and test

508-11-001 Lagging and Insulation, Inside Machinery Space; inspect and replace

508-12-001 Lagging and Insulation, Outside Machinery Space; replace

520-11-001 Sea Valve; inspect and repair

528-11-001 Galley Drain Piping; inspect and repair

529-10-001 Bilge/Ballast Piping System; inspect and repair

562-11-001 Rudder and Steering Gear; inspect and repair

581-11-002 Anchor, and Anchor Chain Inspection and Preservation; accomplish

634-11-001 Interior Deck Covering System; install

980-11-001 Light Off Assistance (LOA); provide

980-31-001 Office Space Without Computer for In-Plant Availability; provide

982-31-001 Dock Trial, Fast Cruise, and Sea Trial; accomplish

992-11-001 Temporary Services; provide

992-11-002 Fuel Assistance and Towboat Service for Fuel Barge; provide

992-31-001 Cleaning, Pumping and Gas Free; accomplish

997-11-001 Drydocking and Undocking; accomplish

CLIN 0002 CONTRACT DATA REQUIREMENTS LIST (CDRLs) FOR ITEMS 0001 (SEE EXHIBITS A and B –CDRLs ATTACHED)

The Contractor shall furnish data required hereunder in accordance with the Contract Data Requirements List

(CDRL), DD Form 1423, Exhibit A and B attached hereto. The CDRLs form a part of the schedule of this solicitation.

NAVSEA Standard Items have been furnished to each MSRA and ABR Contractor under separate cover for retention. The current NAVSEA Standard Items applicable to work items of this specification are listed in the Index of Specifications, contained in the Specification Package, Attachment J-1 of Section J.

Category I NAVSEA FY-18 Standard Items are applicable to all items without further reference. Category II

NAVSEA FY-18 Standard Items are part of the specification package when invoked and/or referenced in individual work items specified in SSP No. NSSA-501-18. NAVSEA Standard Items may be found at http://www.navsea.navy.mil/Home/RMC/CNRMC/Our-Programs/SSRAC/NSI/FY18-NSI/

ADDITIONAL ALLOWANCES

(a) Offerors are required to include allowance of an additional 10% for electrical /electronic cable lengths and associated hardware for material ordering and shipboard installation over and above the drawing requirements in their price.

(b) Offerors are required to include allowance of an additional 10% for piping and associated fittings for material ordering and shipboard installation over and above the drawing requirements in their price.

NON SMOKING POLICY

Contractors are advised that in light of the Navy's policy regarding smoke-free facilities, the entire vessel, topside and below decks, is to be considered a "No Smoking Area" unless otherwise indicated by shipboard policy.

PERSONAL PROTECTIVE EQUIPMENT

Whenever work is performed aboard U.S. Naval Ships or vessels at piers or drydocks of a Naval Shipyard or Naval

Station, Contractor employees (including management personnel) shall have and use at all times the following personal protective equipment:

(a) Protective hard hats that meet the following specifications:

(1) Protective helmets purchased after July 5, 1994 shall comply with ANSI Z89.1-1986, "American National Standard for Personnel Protection-Protective Headware for Industrial

Workers-Requirements," or shall be demonstrated to be equally effective.

(2) Protective helmets purchased before July 5, 1995 shall comply with ANSI Standard "American

National Standard Safety requirements for Industrial Head Protection," Z89.1-1969, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CFR 1910.135 Head Protection]

(b) Approved type plano or prescription glasses meeting the following specifications:

(1) Protective eye and face devices purchased after July 5, 1994 shall comply with ANSI standard

Z87.1-1989, "American National Standard Practice for Occupational and Educational Eye and

Face Protection", or shall be demonstrated by the employer to be equally effective.

(2) Protective eye and face devices purchased before July 5, 1994 shall comply with ANSI "USA standard for Occupational and Educational Eye and Face Protection", Z87.1-1968, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CRF 1910.133 Protective eye and face devices.]

(c) Safety toe shoes, with built-in protective toe box that meet the following specifications:

(1) Protective footwear purchased after July 5, 1994 shall comply with ANSI Standard Z41-1991, "American National Standard for Personal Protection-Protective Footwear", or shall be demonstrated by the employer to be equally effective.

(2) Protective footwear purchased before July 5, 1994 shall comply with the ANSI standard "USA

Standard for Men's Safety Toe Footwear", Z41.1 1967, or shall be demonstrated by the employer to be equally effective [Ref. 29 CFR 1910.136 Protective eye and face devices.] http://www.navsea.navy.mil/Home/RMC/CNRMC/Our-Programs/SSRAC/NSI/FY18-NSI/

SAFETY INSPECTOR / FIRE MARSHALL

The Contractor is responsible for providing an experienced Safety Inspector/Fire Marshall who will accomplish daily inspections of the Contractor's entire work area on the ship, together with the Contracting Office’s Safety

Representative. This Inspector or Fire Marshall shall not be one of the Contractor's supervisors or superintendents normally assigned to the ship.

USE OF BLACK OXIDE COATED BRASS THREADED FASTENERS (BOCBTFs)

Due to safety concerns, use of BOCBTFs is not authorized when installing or replacing threaded fasteners in the accomplishment of any work required by any Work Item in this contract.

COSAL CONFIGURATION CHANGE DOCUMENTATION (NAVSEA) (JUN 1992)

The contractor shall document all changes to the ship's configuration and prepare all documentation required to bring the ship's COSAL and SPCC Weapons Systems Files (WSF) into agreement with the actual end of availability configuration. Perform COSAL/WSF maintenance action on all planned and actual equipments/components/equipage, whether furnished by the Government or the Contractor.

PICK-UP OF GOVERNMENT FURNISHED MATERIAL (GFM) BY CONTRACTOR

(a) Upon notification of job order award by a Mid-Atlantic Regional Maintenance Center (MARMC) Contract

Department representative, the contractor will accept delivery of the (GFM) Government Furnished Material cited in the solicitation package from any and all locations within a 65-mile radius of MARMC, Norfolk, VA. Please contact the cognizant Project Manager to coordinate the pickup of GFM.

(b) The contractor will be required to make an initial pickup of all available GFM at the start of availability and no more than six (6) additional trips for the pickup of GFM for ship availabilities. After initial pickup, growth GFM will be included in the six (6) trips. MARMC Material Department will notify the contractor when additional GFM will be available for pickup, the approximate number of pieces, and the size of the GFM.

(c) These requirements do not supersede specific requirements stated in the work specifications.

LABOR AND MATERIAL RESERVATIONS IN SPECIFICATION ITEMS

Whenever a specification item includes a reservation work scope which requires that a specified amount of labor mandays and material be provided, the requirements for recordkeeping, approvals, and reconciliations are provided in Specification Item 042-00-001, Accountability of Manhour and Material Reservation.

DELIVERY OF GOVERNMENT PROPERTY

(a) All Government property as designated by the Government Property Administrator (GPA) will be delivered or shipped by the Contractor to one or more location(s) designated by the GPA. The designated location shall be within a 65-mile radius of MARMC (Norfolk Naval Base, Norfolk, VA).

(b) The contractor will be required to make up to five (5) such deliveries with no increase in the Job Order price. A delivery is defined as a designation of specific property to a specific place, but may require multiple loads.

(c) These requirements do not supersede requirements stated in work specifications.

POST-AWARD SUBMISSION

After receipt of award and prior to starting work aboard the vessel, the contractor must submit a list of employees who will work aboard ship to the Commanding Officer of the ship VIA the Project Manager. The list should be on company letterhead, include each employee's name, social security number, and security clearance when required, and bear the signature of a company official.

CITIZENSHIP REQUIREMENTS

The contractor shall comply with the Department of Defense Industrial Security Manual (DoD 5220.22), and any revisions to that manual as of the Bid Opening Date prescribed, for verification of all U. S. Citizens.

Prospective offerors shall refer all questions pertaining to the above to MARMC Security Manager (Code 1123, 757-400-0357).

ADDITIONAL DEFINITIONS

Wherever the term “Job Order” is used in this solicitation/award, it also means “Contract.”

Wherever SUPERVISOR OF SHIPBUILDING, C&R, USN, SUPSHIP PORTSMOUTH, SUPERVISOR or

NORFOLK SHIP SUPPORT ACTIVITY (NSSA) is used in this solicitation/award, all attachments and documents incorporated by reference, it also means MID-ATLANTIC REGIONAL MAINTENANCE CENTER (MARMC).

THREAT CONDITIONS

A Threat Condition has been set for this area. We are currently in force protection Bravo for the Hampton Roads area. Any changes to the FPCON level will be provide when necessary by MARMC security to the private shipyards or effected contractors. The parking of vehicles will be away from the immediate vicinity of the ship.

When submitting a proposal for this solicitation, consider that delays will be normal for gaining access onto the installation and/or facility where the ships may be located. Any costs associated with delays, disruptions, or security precautions associated with Bravo shall be included in your proposal. Contractors will not receive additional compensation for delays, disruptions, or security precautions associated with Bravo. Please direct any inquiries to

MARMC Security Manager, telephone (757) 400-0357.

USE/POSSESSION OF PERSONAL ELECTRONIC DEVICES (PEDS)

The possession and use of portable electronic devices (PEDs) within the confines of any naval vessel, or in the contractor's facility where equipment removed from the vessel is being worked, is strictly controlled.

PEDs include:

mobile computing devices such as personal digital assistants (PDAs);

hand-held or laptop computers;

mobile telephone devices such as data-enabled cellular telephones;

two-way pagers, including those with e-mail capability;

WI-FI Routers

Stand Alone Computers analog and digital sound recorders; and digital cameras, including cellular phones with digital imaging capabilities.

Cellular phones with digital imaging capabilities are strictly prohibited. PEDs may not be connected to any Navy-owned or controlled network. PEDs may not be used to store or process any digital information associated with the conduct of the contract without written authorization from the Naval Supervising Activity (NSA).

SUBMISSION OF POST AWARD INFORMATION

When requested by the Contracting Officer, offerors shall submit within 3 days after such request, any or all of the post award information below. Data required by paragraph (a) shall be submitted to the Administrative Contracting

Officer. Data required by paragraph (b) shall be submitted directly to the designated Project Manager and the

Administrative Contracting Officer. Contact Code 300A at (757) 602-2650, for applicable telephone/fax number.

(a). A procedure and schedule for accomplishing the requirements of the DELIVERY/REDELIVERY SCHEDULE

(B) in Section F, of this solicitation, to permit coordinating the necessary preparations with the ship's force.

(b). A breakdown of the total proposed price by specification item. Each work specification item should show the specification work item number, the specification work item title, the applicable contract line item number (CLIN), mandays (prime and subcontractor), labor dollars (prime and subcontractor), and material dollars (prime and subcontractor). The contractor shall not create any additional work items and costs shall not be shown for standard items. This data may be provided by hard copy or on an executable disk formatted and provided by the Government.

For ships worked in contractors’ facilities, contractors shall submit the heavy weather plan, including engineering calculations, in accordance with NAVSEA Standard Item 009-69 fifteen days prior to the start of the contract availability and anytime an update or change is required (e.g. change in mooring location or arrangement).

UTILIZATION OF THE NAVY MAINTENANCE DATABASE (NMD)

1. The successful offeror shall utilize the Navy Maintenance Database (NMD) program to perform administrative functions with the Government. The Contractor shall be responsible for submitting electronic reports, retrieving answered reports, and retrieving requests for contract changes (RCC’s) using NMD. Each individual needing access to NMD will require a PKI certificate and AISC User Account Request Form. The successful offeror must have access within 10 days of contract award.

a. Contractor is required to have internet access for connectivity to NMD and each company personnel using NMD shall acquire a PKI certificate.

b. Each individual needing access to NMD will require approval. The Access Request and Non-Disclosure

Forms may be obtained by sending an email request to Sean Williams at

MARMC_NRFK_NMD_helpdesk@navy.mil.

2. The contractor will identify needed repairs and recommend corrective action during contract performance for those deficiencies discovered which are not covered by the work specifications. Needed repairs and corrective action reported will be submitted to the Government in the form of a Condition Found Report (CFR).

3. CFR’s supporting data will be submitted via NMD within five workings days of identification of the requirement.

As a minimum, the CFR will include the following:

a. Identify contract number, ship, and hull number

b. Serialized by CFR number

c. Identification of the applicable Work Item number

d. Date requirement was discovered

e. Description of work requirement

f. Specific location of the work

g. Recommendation for corrective action

h. Recommendation for the appropriate/best time to accomplish the work (with or without schedule change). Provide supporting rational for the recommendation, such as price efficiencies, availability of the work force, availability of material, premium expenditures etc.

mailto:MARMC_NRFK_NMD_helpdesk@navy.mil

i. Identification of related changes, if any, to the internal milestones and production and contract completion dates. If none, so state.

j. The surveillance of the contract resulting from this solicitation may be accomplished in part, by contractor personnel.

k. After the Project Manager has approved a Request for Contract Change (RCC), Contractor shall provide a Class

“F” estimate within three (3) business days and/or followed by a Class “C” estimate within five (5) business days for a total of eight (8) estimating days. Contractor’s proposal shall be submitted in Four-E-format, paragraph and sub-paragraph estimating using labor hours and material dollars for each.

SPECIAL REQUIREMENTS

The place of performance is restricted to the Norfolk, VA Homeport Area.

PAST PERFORMANCE

The contractor, in performing this Contract, will be subject to a past performance assessment in accordance with

FAR 42.15 and the Department of the Defense Contractor Performance Assessment Reporting System (CPARS)

Policy Guide in effect on the date of award. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the Government for future source selection in acordance with FAR 15.304 when past performance is an evaluation factor for award.

HQ C-2-0003 ACCESS TO THE NAVY SUPPLY SYSTEM (NAVSEA) (MAR 2011)

(a) In compliance with the comparability requirement of 10 U.S.C. 7314, Public and Private Shipyards will be provided equal access to the Naval Supply System. Use by private yards is permissive, not mandatory.

(b) Pursuant to the clause of this contract entitled "GOVERNMENT SUPPLY SOURCES" (FAR 52.251-1) the

Contracting Officer hereby authorizes the Contractor to place orders with the Navy Supply System for materials and equipment or other supplies necessary to perform the required work. The Naval Supply System shall process such orders in the same manner as it would for any other Navy supply user, and the Contractor shall make payment on account of materials and equipment and other supplies ordered and/or received in accordance with the normal requirements of the Naval Supply Systems Command, but in no event shall payment in full be any later than 30 days after receipt by the Contractor of each order. The Contractor shall pay the Naval Supply System any costs for materials, equipments, or other supplies obtained including any surcharges normally charged to any other Naval

Supply System user.

(c) This job order has been priced on the basis that, except as specifically provided elsewhere in this contract with regards to Government furnished property, the Contractor shall provide all necessary materials, equipments and supplies for performance of this contract. If the Contractor uses the Naval Supply System, it has elected to use the system for its own convenience to meet its contractual obligations to perform the work under this contract. The

Naval Supply System is considered to be an alternate source or vendor of contractor furnished material; therefore materials, equipments, or other supplies ordered and/or obtained from the Naval Supply System are specifically not considered to be Government furnished material, but are considered to be contractor furnished material. The

Government makes no representation as to the availability of materials, equipments, or other supplies for the performance of the work required under this contract, nor shall unavailability, late delivery, delivery of non-conforming supplies, higher costs of the Naval Supply System (if any), or any failure of the Naval Supply System to meet the expectations or requirements of the Contractor constitute excusable delay or grounds for equitable or any other adjustment to the contract or relief from the requirement to perform in accordance with the terms of the contract.

ACCESS TO THE VESSEL(S) (NAVSEA) (SEP 2016)

Officers, employees and associates of other prime Contractors with the Government and their subcontractors, shall, as authorized by the Supervisor, have, at all reasonable times, admission to the plant, access to the vessel(s) where and as required, and be permitted, within the plant and on the vessel(s) required, to perform and fulfill their respective obligations to the Government. The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Supervisor to be given admission to the plant and access to the vessel(s) for office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of the respective responsibilities involved, and reasonable to their performance.

HQ C-2-0005 ACCESS TO THE VESSELS BY NON-U.S. CITIZENS (NAVSEA) (SEP 2016)

(a) No person not known to be a U.S. citizen shall be eligible for access to naval vessels, work sites and adjacent areas when said vessels are under construction, conversion, overhaul, or repair, except upon a finding by

COMNAVSEA or his designated representative that such access should be permitted in the best interest of the

United States. The Contractor shall establish procedures to comply with this requirement and NAVSEAINST

5510.3 (series) in effect on the date of this contract or agreement.

(b) If the Contractor desires to employ non-U.S. citizens in the performance of work under this contract or agreement that requires access as specified in paragraph (a) of this requirement, approval must be obtained prior to access for each contract or agreement where such access is required. To request such approval for non-U.S. citizens of friendly countries, the Contractor shall submit to the cognizant Contract Administration Office (CAO), an Access

Control Plan (ACP) which shall contain as a minimum, the following information:

(1) Badge or Pass oriented identification, access, and movement control system for non-U.S. citizen employees with the badge or pass to be worn or displayed on outer garments at all times while on the Contractor's facilities and when performing work aboard ship.

(i) Badges must be of such design and appearance that permits easy recognition to facilitate quick and positive identification.

(ii) Access authorization and limitations for the bearer must be clearly established and in accordance with applicable security regulations and instructions.

(iii) A control system, which provides rigid accountability procedures for handling lost, damaged, forgotten or no longer required badges, must be established.

(iv) A badge or pass check must be performed at all points of entry to the Contractor's facilities or by a site supervisor for work performed on vessels outside the Contractor's plant.

(2) Contractor's plan for ascertaining citizenship and for screening employees for security risk.

(3) Data reflecting the number, nationality, and positions held by non-U.S. citizen employees, including procedures to update data as non-U.S. citizen employee data changes, and pass to cognizant CAO.

(4) Contractor's plan for ensuring subcontractor compliance with the provisions of the Contractor's ACP.

(5) These conditions and controls are intended to serve as guidelines representing the minimum requirements of an acceptable ACP. They are not meant to restrict the Contractor in any way from imposing additional controls necessary to tailor these requirements to a specific facility.

(c) To request approval for non-U.S. citizens of hostile and/or communist-controlled countries (listed in Department of Defense Industrial Security Manual, DOD 5220.22-M or available from cognizant CAO), Contractor shall include in the ACP the following employee data: name, place of birth, citizenship (if different from place of birth), date of entry to U.S., extenuating circumstances (if any) concerning immigration to U.S., number of years employed by

Contractor, position, and stated intent concerning U.S. citizenship. COMNAVSEA or his designated representative will make individual determinations for desirability of access for the above group. Approval of ACP's for access of non-U.S. citizens of friendly countries will not be delayed for approval of non-U.S. citizens of hostile communist-controlled countries. Until approval is received, Contractor must deny access to vessels for employees who are non-

U.S. citizens of hostile and/or communist-controlled countries.

(d) The Contractor shall fully comply with approved ACPs. Noncompliance by the Contractor or subcontractor serves to cancel any authorization previously granted, in which case the Contractor shall be precluded from the continued use of non-U.S. citizens on this contract or agreement until such time as the compliance with an approved

ACP is demonstrated and upon a determination by the CAO that the Government's interests are protected. Further, the Government reserves the right to cancel previously granted authority when such cancellation is determined to be in the Government's best interest. Use of non-U.S. citizens, without an approved ACP or when a previous authorization has been canceled, will be considered a violation of security regulations. Upon confirmation by the

CAO of such violation, this contract, agreement or any job order issued under this agreement may be terminated or default in accordance with the clause entitled "DEFAULT (FIXED-PRICE SUPPLY AND SERVICE)" (FAR

52.249-8), "DEFAULT (FIXED-PRICE RESEARCH AND DEVELOPMENT)" (FAR 52.249-9) or

"TERMINATION (COST REIMBURSEMENT)" (FAR 52.249-6), as applicable.

(e) Prime Contractors have full responsibility for the proper administration of the approved ACP for all work performed under this contract or agreement, regardless of the location of the vessel, and must ensure compliance by all subcontractors, technical representatives and other persons granted access to U.S. Navy vessels, adjacent areas, and work sites.

(f) In the event the Contractor does not intend to employ non-U.S. citizens in the performance of the work under this contract, but has non-U.S. citizen employees, such employees must be precluded from access to the vessel and its work site and those shops where work on the vessel's equipment is being performed. The ACP must spell out how non-U.S. citizens are excluded from access to contract work areas.

(g) The same restriction as in paragraph (f) above applies to other non-U.S. citizens who have access to the

Contractor's facilities (e.g., for accomplishing facility improvements, from foreign crewed vessels within its facility, etc.) except that, with respect to access to the vessel and worksite, the restrictions shall not apply to uniformed U.S.

Navy personnel who are non-U.S. citizens and who are either assigned to the ship or require access to the ship to perform their duties.

HQ C-2-0006 ADDITIONAL PROVISIONS RELATING TO GOVERNMENT PROPERTY (NAVSEA)

(SEP 2009)

(a) For purposes of paragraph (h) of the clause entitled "GOVERNMENT PROPERTY" (FAR 52.245-1) in addition to those items of property defined in that clause as Government Property, the following shall also be included within the definition of Government Property:

(1) the vessel;

(2) the equipment on the vessel;

(3) movable stores;

(4) cargo; and

(5) other material on the vessel

(b) For purposes of paragraph (b) of the clause entitled "GOVERNMENT PROPERTY", notwithstanding any other requirement of this contract, the following shall not be considered Government Property:

(1) the vessel;

(2) the equipment on the vessel;

(3) movable stores; and

(4) other material on the vessel

HQ C-2-0007 APPROVAL BY THE GOVERNMENT (AT) (NAVSEA) (JAN 1983)

Approval by the Government as required under this contract and applicable specifications shall not relieve the

Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

HQ C-2-0014 CONTRACTOR'S PROPOSAL (NAVSEA) (MAR 2001)

(a) Performance of this contract by the Contractor shall be conducted and performed in accordance with detailed obligations to which the Contractor committed itself in Proposal dated in response to NAVSEA

Solicitation No. N50054-18-R-0004.

(b) The technical volume(s) of the Contractor's proposal is incorporated by reference and hereby made subject to the provisions of the "ORDER OF PRECEDENCE" (FAR 52.215-8) clause of this contract. Under the "ORDER OF

PRECEDENCE" clause, the technical volume of the Contractor's proposal referenced herein is hereby designated as item

(f) of the clause, following "the specification" in the order of precedence.

HQ C-2-0016 DEPARTMENT OF LABOR SAFETY AND HEALTH STANDARDS FOR SHIP REPAIR (NAVSEA)

(APR 2015)

Attention of the Contractor is directed to the Occupational Safety and Health Act of 1970 (29 USC 651-678), and to the Safety and Health Regulations for Ship Repairing (29 CFR 1915), promulgated under Public Law 85-742, amending Section 41 of the Longshoremen's and Harbor Workers' Compensation Act (33 USC 941), and adopted by the Department of Labor as occupational safety or health standards under Section 6(a) of the Occupational Safety and Health Act of 1970 (See 29 CFR 1910.15). These regulations apply to all ship repair and related work, as defined in the regulations performed under this contract on the navigable waters of the United States including any dry dock and marine railway. Nothing contained in this contract shall be construed as relieving the Contractor from any obligations, which it may have for compliance with the aforesaid regulations.

HQ C-2-0017 DEPARTMENT OF LABOR SAFETY AND HEALTH STANDARDS FOR SHIPBUILDING (AT)

(NAVSEA) (JAN 1990)

Attention of the Contractor is directed to Public Law 91 596, approved December 29, 1970 (84 Stat. 1590, 29 USC

655) known as the "OCCUPATIONAL SAFETY AND HEALTH ACT OF 1970" and to the "OCCUPATIONAL

SAFETY AND HEALTH STANDARDS FOR SHIPYARD EMPLOYMENT" promulgated thereunder by the

Secretary of Labor (29 CFR. 1910 and 1915). These regulations apply to all shipbuilding and related work, as defined in the regulations. Nothing contained in this contract shall be construed as relieving the Contractor from any obligations which it may have for compliance with the aforesaid regulations.

HQ C-2-0018 DISPOSAL OF SCRAP (NAVSEA) (JAN 2008)

(a) All Government scrap resulting from accomplishment of any job order is the property of the Contractor to be disposed as it sees fit. Scrap is defined as property that has no reasonable prospect of being sold except for the recovery value of its basic material content. The determination as to which materials are scrap and which materials are salvage, will be made, or concurred in, by the duly appointed Property Administrator for the cognizant SUPSHIP or RMC Office.

(b) As consideration for retaining the Government's scrap, the Contractor's price for the performance of the work required herein shall be a net price reflecting the value of the Government scrap.

(c) This requirement is not intended to conflict in any way with the clauses of this contract entitled

"PERFORMANCE" (DFARS 252.217-7010) or "GOVERNMENT PROPERTY" (FAR 52.245-1) under the Master

Contract in effect at the time of job order award, nor does it relieve the Contractor of any other requirement under such clauses.

HQ C-2-0020 DOCK TRIALS AND FAST CRUISE (NAVSEA) (MAY 1993)

(a) Dock Trials. The purpose of this trial is to conduct preliminary tests necessary to ensure that the ship is ready for operating at sea. Ship's personnel will conduct all tests and perform all operational functions; however, Contractor personnel will observe tests, record data, and make minor repairs and adjustments as necessary. The dock trial shall be scheduled in accordance with Work Item 982-31-001. Contractor personnel are not to interfere with functions of ship's personnel.

(b) Fast Cruise. The "fast cruise" is a simulated underway period. The purpose of fast cruise is to test to the maximum extent possible, the ship's material and operational readiness condition. This includes normal watch stations and engineering casualty control procedures. Contractor personnel will not be allowed onboard during this period unless specifically requested by the Supervisor. Fast cruise shall be scheduled after dock trials and prior to sea trials as cited in Specification Item 982-31-001.

HQ C-2-0021 DRYDOCK CERTIFICATION (NAVSEA) (APR 2015)

The drydocking of all vessels on or after 1 January 1980 shall be accomplished in dry docks certified in accordance with MIL-STD-1625D(SH) dated 27 August 2009 as invoked by NAVSEA Standard Item 009-01.

HQ C-2-0022 DRYDOCKING FACILITIES AND SHIPBUILDING WAYS CERTIFICATION (AT) (NAVSEA)

(APR 2015)

Drydocking facilities and shipbuilding ways employed in the performance of this contract shall be certified in accordance with MIL-STD-1625D (SH) dated 27 August 2009, Safety Certification Program for Drydocking

Facilities and Shipbuilding Ways for U.S. Navy Ships. The "Facility Certification Report" shall be submitted to

NAVSEA Code 04 via the cognizant Supervisor of Shipbuilding not less than twelve (12) months prior to the scheduled launching of the first vessel constructed under this contract*.

HQ C-2-0023 EXCLUSION OF MERCURY (NAVSEA) (MAY 1998)

Mercury or mercury containing compounds shall not be intentionally added or come in direct contact with hardware or supplies furnished under this contract.

HQ C-2-0024 EXTENSION OF COMMERCIAL WARRANTY (NAVSEA) (NOV 1996)

The Contractor shall extend to the Government the full coverage of any standard commercial warranty normally offered in a similar commercial sale, provided that such warranty is available at no additional cost to the

Government. The Contractor shall provide a copy of the standard commercial warranty with the item. The standard commercial warranty period shall begin upon the final acceptance of the applicable material or software.

Acceptance of the standard commercial warranty does not waive the Government’s rights under the “Inspection” clause, nor does it limit the Government’s rights with regard to other terms and conditions of the contract. In the event of a conflict, the terms and conditions of the contract shall take precedence over the standard commercial warranty.

HQ C-2-0028 GOVERNMENT SURPLUS PROPERTY (NAVSEA) (SEP 1990)

No former Government surplus property or residual inventory resulting from terminated Government contracts shall be furnished under this contract unless (i) such property is identified in the Special Contract Requirements or (ii) is approved in writing by the Contracting Officer. Notwithstanding any such identification in the Special Contract

Requirements or approval by the Contracting Officer, the Contractor agrees all items or components described in this requirement shall comply in all respects with the specifications contained herein.

HQ C-2-0029 HEAVY WEATHER PLAN (NAVSEA) (JUN 1999)

In order to ensure that Naval vessels and material are protected during gales, storms, hurricanes and destructive weather, the Contractor is required to have a written Heavy Weather Plan (HWP) which assigns responsibilities and prescribes actions to be taken on the approach of and during heavy weather conditions as delineated in NAVSEA

Standard Item (SI) 009-69. In accordance with SI 009-69, the Contractor shall furnish to the cognizant

Shipbuilding, Conversion and Repair, U.S. Navy, a copy of such HWP, and shall make such changes in the plan as the Supervisor considers necessary and reasonable to protect and care for vessels and machinery and equipment to be installed therein.

In the event the Supervisor directs the Contractor to implement the HWP pursuant to SI 009-69 the Contractor may submit to the Contracting Officer a request for reimbursement for costs resulting from such actions together with any documentation that the Contracting Officer may reasonably require. The Government shall reimburse the

Contractor for all reasonable, allowable and allocable costs resulting from the Contractor's implementation of the

HWP based on such Government direction.

HQ C-2-0030 INFORMATION AND DATA FURNISHED BY THE GOVERNMENT (FIXED-PRICE)

(NAVSEA) (SEP 2009)

(a) Contract Specifications. The Government will furnish, if not included as an attachment to the contract, any unique contract specifications set forth in Section C.

(b) Contract Drawings and Data. The Government will furnish contract drawings, design agent drawings, ship construction drawings, and/or other design or alteration data cited or referenced in Section C or in the contract specification as mandatory for use or for contract performance.

(c) Government Furnished Information (GFI). GFI is defined as that information essential for the installation, test, operation, and interface support of all Government Furnished Material enumerated on NAVSEA Form 4205/19 or

Schedule A, as applicable, attached to the contract. The Government shall furnish only the GFI identified on the

NAVSEA Form 4340/2 or Schedule C, as applicable, attached to the contract. The GFI furnished to the contractor need not be in any particular format. Further, the Government reserves the right to revise the listing of GFI on the

NAVSEA Form 4340/2 or Schedule C, as applicable, as follows:

(1) The Contracting Officer may at any time by written order:

(i) delete, supersede, or revise, in whole or in part, data listed or specifically referenced in NAVSEA

Form 4340/2 or Schedule C, as applicable; or

(ii) add items of data or information to NAVSEA Form 4340/2 or Schedule C, as applicable; or

(iii) establish or revise due dates for items of data or information in NAVSEA Form 4340/2 or Schedule

C, as applicable.

(2) If any action taken by the Contracting Officer pursuant to subparagraph (1) immediately above causes an increase or decrease in the costs of, or the time required for, performance of any part of the work under this contract, the contractor may be entitled to an equitable adjustment in the contract price and delivery schedule in accordance with the procedures provided for in the clause of this contract entitled "CHANGES--FIXED-PRICE"

(FAR 52.243-1).

(d) Except for the Government information and data specified by paragraphs (a), (b), and (c) above, the

Government will not be obligated to furnish the Contractor any specification, standard, drawing, technical documentation, or other publication, notwithstanding anything to the contrary in the contract specifications, the GFI listed on the NAVSEA Form 4340/2 or Schedule C, as applicable, the clause of this contract entitled

"GOVERNMENT PROPERTY" (FAR 52.245-1) or "GOVERNMENT PROPERTY INSTALLATION

OPERATION SERVICES " (FAR 52.245-2), as applicable, or any other term or condition of this contract.

(e) Referenced Documentation. The Government will not be obligated to furnish Government specifications and standards, including Navy standard and type drawings and other technical documentation, which are referenced directly or indirectly in the contract specifications set forth in Section C and which are applicable to this contract as specifications. Such referenced documentation may be obtained:

(1) From the ASSIST database via the internet at http://assist.dla.mil/

; or

(2) By submitting a request to the

Department of Defense Single Stock Point (DoDSSP)

Building 4, Section D

700 Robbins Avenue

Philadelphia, Pennsylvania 19111-5094

Telephone (215) 697-6396

Facsimile (215) 697-9398.

Commercial specifications and standards, which may be referenced in the contract specification or any sub-tier specification or standard, are not available from Government sources and should be obtained from the publishers.

HQ C-2-0037 ORGANIZATIONAL CONFLICT OF INTEREST (NAVSEA) (JUL 2000)

(a) "Organizational Conflict of Interest" means that because of other activities or relationships with other persons, a person is unable or potentially unable to render impartial assistance or advice to the Government, or the person's objectivity in performing the contract work is or might be otherwise impaired, or a person has an unfair competitive advantage. "Person" as used herein includes Corporations, Partnerships, Joint Ventures, and other business enterprises.

(b) The Contractor warrants that to the best of its knowledge and belief, and except as otherwise set forth in the contract, the Contractor does not have any organizational conflict of interest(s) as defined in paragraph (a).

(c) It is recognized that the effort to be performed by the Contractor under this contract may create a potential organizational conflict of interest on the instant contract or on a future acquisition. In order to avoid this potential conflict of interest, and at the same time to avoid prejudicing the best interest of the Government, the right of the

Contractor to participate in future procurement of equipment and/or services that are the subject of any work under this contract shall be limited as described below in accordance with the requirements of FAR 9.5.

(d) (1) The Contractor agrees that it shall not release, disclose, or use in any way that would permit or result in disclosure to any party outside the Government any information provided to the Contractor by the Government during or as a result of performance of this contract. Such information includes, but is not limited to, information submitted to the Government on a confidential basis by other persons. Further, the prohibition against release of

Government provided information extends to cover such information whether or not in its original form, e.g., where the information has been included in Contractor generated work or where it is discernible from materials incorporating or based upon such information. This prohibition shall not expire after a given period of time.

(2) The Contractor agrees that it shall not release, disclose, or use in any way that would permit or result in disclosure to any party outside the Government any information generated or derived during or as a result of performance of this contract. This prohibition shall expire after a period of three years after completion of performance of this contract.

(3) The prohibitions contained in subparagraphs (d)(1) and (d)(2) shall apply with equal force to any affiliate of the Contractor, any subcontractor, consultant, or employee of the Contractor, any joint venture involving the Contractor, any entity into or with which it may merge or affiliate, or any successor or assign of the Contractor.

The terms of paragraph (f) of this Special Contract Requirement relating to notification shall apply to any release of information in contravention of this paragraph (d).

(e) The Contractor further agrees that, during the performance of this contract and for a period of three years after completion of performance of this contract, the Contractor, any affiliate of the Contractor, any subcontractor, consultant, or employee of the Contractor, any joint venture involving the Contractor, any entity into or with which it may subsequently merge or affiliate, or any other successor or assign of the Contractor, shall not furnish to the

United States Government, either as a prime contractor or as a subcontractor, or as a consultant to a prime contractor or subcontractor, any system, component or services which is the subject of the work to be performed under this contract. This exclusion does not apply to any recompetition for those systems, components or services furnished pursuant to this contract. As provided in FAR 9.505-2, if the Government procures the system, component, or services on the basis of work statements growing out of the effort performed under this contract, from a source other than the contractor, subcontractor, affiliate, or assign of either, during the course of performance of this contract or before the three year period following completion of this contract has lapsed, the Contractor may, with the authorization of the cognizant Contracting Officer, participate in a subsequent procurement for the same system, component, or service.