N4425519R7004_Wood_Recycling.pdf

SEE ADDENDUM

(No Collect Calls) N4425519R7004 15-Aug-2019

b. TELEPHONE NUMBER 360-396-4184

8. OFFER DUE DATE/LOCAL TIME

03:00 PM 16 Sep 2019

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

N44255 9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

SYLVA KABUANSEYA

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR: SET ASIDE: UNRESTRICTED OR X

SMALL BUSINESS X

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

NAVFAC NORTHWEST

PUBLIC WORKS DEPT. BANGOR

T-075 SKATE STREET

SILVERDALE WA 98315-1101

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A X

13b. RATING

DO-C3

CODE 15. DELIVER TO CODE N46060 16. ADMINISTERED BY

12. DISCOUNT TERMS 11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFP X

NAVFAC NORTHWEST (SHIP TO)

INSPECTOR OF RECORD

PUBLIC WORKS DEPT BANGOR

FACILITIES ENGINEERING AND ACQUISITION DIVISI

T-075 SKATE STREET

SILVERDALE WA 98315-1101

TEL: 360-396-5036 FAX:

360-396-4066 FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$38,500,000

NAICS:

562111

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICES ITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24. 22. 21. 19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF58

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

N4425519R7004

Section SF 1449 - CONTINUATION SHEET

PART B CONTINUATION SHEET

INDEX OF CONTENTS

Part Description

I Standard Form 1449, Solicitation/Contract/Order for Commercial Items

II Statement of Work

II Instruction to Offerors/ with addenda

IV Evaluation for Contract Award

V List of Attachments/Exhibits

STATEMENT OF WORK

NAVAL FACILITES ENGINEERING COMMAND NORTHWEST

1101 TAUTOG CIRCLE

SILVERDALE, WA 98315

Wood Recycling and Organic Materials Composting, NBK and Various locations, Washington

1.0 Introduction and Background

The Contractor shall provide all labor, management, supervision, tools, transportation, materials, facilities, and equipment to provide recycling and/or composting services for post-industrial wood, related products, marine growth and VAC truck debris composting/disposal that are to be delivered to the Contractor’s processing facility or receiving point by various Navy installations within Navy Region Northwest (NBK-Silverdale, NBK-Bremerton, NBK-Keyport, NAVMAG Indian Island, NAVHOSP, & Puget Sound Naval Shipyard, Bremerton, WA).

Naval Facilities Engineering Command (NAVFAC) Northwest Public Works Department will administer this

Contract. Coordination between contractors and Government shall go through Public Works Department, specifically the Government Project Manager and Technical Point of Contact (POC) Les W. Hastings, 360-396-

0125 les.w.hastings@navy.mil. Contractor’s questions for the Government (pre-award) shall follow the Pre-

Proposal Inquire (PPI) process prior to award.

2.0 Performance Requirements

The Contractor shall ensure compliance with all federal, state, and local laws or regulations related to recycling and composting operations. Material will be delivered by Government-operated trucks and government contractor operated trucks. Contractor’s facility or receiving point shall be located within 50 road miles of Naval Base Kitsap.

The Contractor will not require NBK base access. All materials will be transported. Protection of Government

Property: The Contractor shall use every means at their disposal to prevent any damage to Government vehicles or other Government property during execution of this work. If property becomes damaged, contact the Contracting

Officer immediately. If the damage is caused by the work being administered, the Contractor shall stop work immediately until the issue can be resolved. All work shall conform to commercial recycling and composting industry standards and/or industry quality standards for the type of work indicated. This volume of materials will include, but not be limited to; wood dunnage, sawdust, marine growth, land-clearing debris, dirt (non-petroleum mailto:les.w.hastings@navy.mil contaminated), sod, green waste, leaves and grass Navy generated industrial wood waste will have undetectable, large metal fasteners which have been proven to cause significant damage to commercial shredding and chipping machines.

2.1 Procedures

The Contractor shall have procedures in place for Organic Sorting. These procedures shall include technical processes to screen and sort incoming, mixed loads of Navy material (fire-retardant, treated wood; non-fire-retardant, treated wood; metal-contaminated wood; sawdust; shredded paper; and composting material. The organic sorting procedure and processes shall comply with State, County, and local laws and regulations. The Government may inspect the organic sorting procedure at any time during performance of this contract. The Navy industrial wood waste stream contains about 500 tons per year of fire retardant coated wood blocking from dry-dock operations. This material is not hazardous waste, but it does impact the pollution control equipment of the facilities that purchase wood chips for use as fuel. The total projected tonnage for postindustrial wood waste including fire retardant wood is approximately 3500 tons.. The Contractor shall have procedures in place for Marine Growth and

Composting – Navy material may include marine growth arising from cleaning spill and security containment booms.

The Contractors composting processes shall meet or exceed the EPA standard for the process to further reduce pathogens (PFRP). This waste stream is approximately500 tons per year. The Contractor shall have procedures in place for Contaminated Materials – VAC Truck Waste, Street Sweeping Debris. A portion of Navy solid waste is generated from maintaining streets and cleaning storm drains. This material may have high concentrations of sand, petroleum, and minor quantities of other contaminants, such as heavy metals leaves, etc. The Offeror will provide documentation that they have the proper permits to compost this material. This waste stream is approximately 150 tons per year. The Contractor shall prevent Co-Mingling of Bio Solid (sewage) Compost and Regular Compost. The

Contractor shall have procedures and processes in place to ensure composted bio solids are kept separately from non-bio solids. Processes shall be in place that prevents cross-contamination of material handling and processing equipment and shall comply with State, County, and local laws and regulations.

3.0 Licenses

The Contractor shall maintain the following licenses. All licenses and permits shall be current valid and current and in the name of the Contractor. Licenses and Permits required handling and composting Navy material:

- Valid Washington State Business License

- Department of Ecology Storm Water Permit

- Air Pollution Control Authority Permit

- County Health Department Solid Waste Handling Permit

- County Health Department Contaminated Materials Permit

- County Health Department Composting permits for Types I, II and III material

4.0 Environmental

Contractor will demonstrate compliance with environmental regulations including: air pollution control permit;

storm water discharge/control permit; county health permit; and state department of ecology permits to operate a certified food and organics composting facility. The Contractor must maintain certified pollution control equipment in order to accept and process materials identified in this scope of work.

5.0 Quality Control

The Contractor shall be responsible for all quality control measures. The Contractor shall comply with all performance and safety requirements, including any applicable laws, regulations, codes, and standards.

All work done in accomplishment of this contract shall be in accordance with all applicable requirements and latest revisions of OSHA regulations. Chain of Custody for Industrial Wood Waste – The Navy industrial wood waste stream contains fire retardant coated wood blocking from dry-dock operations. This material is not hazardous waste, but it does impact the pollution control equipment of the facilities that purchase wood chips for use as fuel.

6.0 Deliverables: Reporting and Data Transfer Requirements

Deliverable Date

Monthly Report 10th Day of each month

Reporting – The Contractor shall submit an electronic report on a monthly basis that includes a copy of every

Transaction for the month. The transaction detail shall include date, time, net load weight in tons, commodity delivered, truck’s identification number, installation (Bangor, Bremerton, Naval Magazine Indian Island, Naval

Hospital Bremerton, or Naval Undersea Warfare Center Division Keyport) origin, and a summary for the month relative to the number of loads delivered, the average weight in tons per load, and the total tons delivered each month. The electronic report should be emailed to:

Financial Analyst FM3 NWCF Lead

Naval Facilities Engineering Command Northwest

1101 Tautog Circle

Silverdale WA 98315

360-396-1932 DSN: 744 1932 FAX: 360-396-0972

7.0 Acquisition Regulations. The contractor shall be responsible for complying with applicable Federal Acquisition

Regulations (FAR), Defense Acquisition Regulations Supplement (DFARS), Navy Marine Corps Acquisition

Regulation Supplement (NMCARS), and NAVFAC Acquisition Supplement (NFAS).

Duration of the contract: One base year with four option years.

8.0 Tonnage Projection:

Industrial Wood Waste – 3,500 tons /year

Contaminated Waste - 150 tons’ year

The Navy will provide refuse roll off containers to back haul trash to the local transfer station.

PROVIDE ALL REPS AND CERTS

Offerors are reminded that not all representations and certifications (reps & certs) may be available for completion in the System for Award Management (SAM), previously known as ORCA. Offerors must complete all reps & certs required by this solicitation. Should any reps & certs not be available in SAM, the offeror must complete the reps & certs outside SAM and submit with their proposal.

Offerors must keep their reps & certs up-to-date in SAM through the final proposal revision for all reps & certs available in SAM. Final proposal revisions should include an up-to-date and complete reps and certs submission.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 Job Wood Recycling Services Base Year

FFP

This CLIN is for Firm Fixed-Price recycling services for wood and related products, delivered by various Navy installations within Navy Region Northwest in accordance with the Statement of Services and the Schedule of Prices. Period of

Performance is 01 October 2019 to 30 September 2020.

FOB: Destination

PSC CD: S222

NET AMT

0002 Job OPTION Wood Recycling Option Year One

FFP

This CLIN is for Firm Fixed-Price recycling services for wood and related products, delivered by various Navy installations within Navy Region Northwest in accordance with the Statement of Services and the Schedule of Prices. Period of

Performance is 01 October 2020 to 30 September 2021.

0003 Job OPTION Wood Recycling Option Year Two

FFP

This CLIN is for Firm Fixed-Price recycling services for wood and related products, delivered by various Navy installations within Navy Region Northwest in accordance with the Statement of Services and the Schedule of Prices. Period of

Performance is 01 October 2021 to 30 September 2022.

0004 Job OPTION Wood Recycling Option Year Three

FFP

This CLIN is for Firm Fixed-Price recycling services for wood and related products, delivered by various Navy installations within Navy Region Northwest in accordance with the Statement of Services and the Schedule of Prices. Period of

Performance is 01 October 2022 to 30 September 2023.

0005 Job OPTION Wood Recycling Option Year Four

FFP

This CLIN is for Firm Fixed-Price recycling services for wood and related products, delivered by various Navy installations within Navy Region Northwest in accordance with the Statement of Services and the Schedule of Prices. Period of

Performance is 01 October 2023 to 30 September 2024.

0006 Job OPTION Up to 6 Months Extension Clause 52.217-8

FFP

This CLIN is for Firm Fixed-Price recycling services for wood and related products, delivered by various Navy installations within Navy Region Northwest in accordance with the Statement of Services and the Schedule of Prices. Period of

Performance is 01 October 2024 to 31 March 2025.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 01-OCT-2019 TO

30-SEP-2020

N/A NAVFAC NORTHWEST (SHIP TO)

INSPECTOR OF RECORD

PUBLIC WORKS DEPT BANGOR

FACILITIES ENGINEERING AND

ACQUISITION DIVISI

T-075 SKATE STREET

SILVERDALE WA 98315-1101

360-396-5036

N46060

0002 POP 01-OCT-2020 TO

30-SEP-2021

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 01-OCT-2021 TO

30-SEP-2022

N/A (SAME AS PREVIOUS LOCATION)

0004 POP 01-OCT-2022 TO

30-SEP-2023

N/A (SAME AS PREVIOUS LOCATION)

0005 POP 01-OCT-2023 TO

30-SEP-2024

N/A (SAME AS PREVIOUS LOCATION)

0006 31-MAR-2025 (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-18 Prohibition on Contracting With Entities That Require Certain

Internal Confidentiality Agreements or Statements--

Representation

JAN 2017

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-2 Security Requirements AUG 1996

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-20 Predecessor of Offeror JUL 2016

52.204-21 Basic Safeguarding of Covered Contractor Information

Systems

JUN 2016

52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other

Covered Entities.

JUL 2018

52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.209-13 Violation of Arms Control Treaties or Agreements --

Certification.

JUN 2018

52.212-4 Contract Terms and Conditions--Commercial Items OCT 2018

52.214-4 False Statements In Bids APR 1984

52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

AUG 2011

52.215-13 (Dev) Subcontractor Certified Cost or Pricing Data - Modifications

(Deviation 2018-O0015)

JUL 2018

52.215-14 Integrity of Unit Prices OCT 2010

52.215-15 Pension Adjustments and Asset Reversions OCT 2010

52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997

52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.217-5 Evaluation Of Options JUL 1990

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011

52.219-8 Utilization of Small Business Concerns OCT 2018

52.219-9 Small Business Subcontracting Plan AUG 2018

52.219-14 Limitations On Subcontracting JAN 2017

52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013

52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-17 Nondisplacement of Qualified Workers MAY 2014

52.222-19 Child Labor -- Cooperation with Authorities and Remedies JAN 2018

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-24 Preaward On-Site Equal Opportunity Compliance Evaluation FEB 1999

52.222-26 Equal Opportunity SEP 2016

52.222-35 Equal Opportunity for Veterans OCT 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014

52.222-37 Employment Reports on Veterans FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-43 Fair Labor Standards Act And Service Contract Labor

Standards - Price Adjustment (Multiple Year And Option

Contracts)

AUG 2018

52.222-50 Combating Trafficking in Persons JAN 2019

52.222-54 Employment Eligibility Verification OCT 2015

52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-6 Drug-Free Workplace MAY 2001

52.223-10 Waste Reduction Program MAY 2011

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.224-1 Privacy Act Notification APR 1984

52.224-1 Privacy Act Notification APR 1984

52.224-2 Privacy Act APR 1984

52.224-2 Privacy Act APR 1984

52.224-3 Privacy Training JAN 2017

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-1 Payments APR 1984

52.232-8 Discounts For Prompt Payment FEB 2002

52.232-9 Limitation On Withholding Of Payments APR 1984

52.232-11 Extras APR 1984

52.232-17 Interest MAY 2014

52.232-18 Availability Of Funds APR 1984

52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-36 Payment by Third Party MAY 2014

52.232-37 Multiple Payment Arrangements MAY 1999

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.237-3 Continuity Of Services JAN 1991

52.242-13 Bankruptcy JUL 1995

52.243-1 Alt I Changes--Fixed Price (Aug 1987) - Alternate I APR 1984

52.244-6 Subcontracts for Commercial Items JAN 2019

52.246-25 Limitation Of Liability--Services FEB 1997

52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-4 Termination For Convenience Of The Government (Services)

(Short Form)

APR 1984

52.252-6 Authorized Deviations In Clauses APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.203-7003 Agency Office of the Inspector General DEC 2012

252.203-7004 Display of Hotline Posters OCT 2016

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7006 Billing Instructions OCT 2005

252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

OCT 2015

252.215-7013 Supplies and Services Provided by Nontraditional Defense

Contractors.

JAN 2018

252.216-7006 Ordering MAY 2011

252.225-7012 Preference For Certain Domestic Commodities DEC 2017

252.225-7048 Export-Controlled Items JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006

252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JUN 2013

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

(a) Definitions. As used in this provision--

Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for

Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Registered in the System for Award Management (SAM) means that--

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding

Accountability and Transparency Act of 2006 (see subpart 4.14) into SAM;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification

Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record ``Active''.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or

Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b)(1) An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation

``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in SAM.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state, and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

http://www.sam.gov/

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company headquarters name and address (reporting relationship within your entity).

(d) Processing time should be taken into consideration when registering. Offerors who are not registered in SAM should consider applying for registration immediately upon receipt of this solicitation. See https://www.sam.gov for information on registration.

(End of Provision)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 562111.

(2) The small business size standard is $38,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(n/a) Paragraph (d) applies.

(n/a) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

https://www.sam.gov/

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or

Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased

Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-

5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.] x (i) 52.204-17, Ownership or Control of Offeror.

x (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-

Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR

4.1201); except for the changes identified below. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2018)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF

1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

https://www.sam.gov/

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the

Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the

Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent

Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA

Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC

20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point

(DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or https://assist.dla.mil/online/start/ http://quicksearch.dla.mil/ http://assistdocs.com/ https://assist.dla.mil/wizard/index.cfm

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM).) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) Reserved.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

ADDENDA 52.212-1, INSTRUCTION TO OFFERORS – COMMERCIAL ITEMS

Paragraph (c) to be amended to read: (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 120 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS

INTENT TO AWARD WITHOUT DISCUSSIONS. Each offeror should contain the offeror’s best terms from a technical and price standpoint. Offerors should not assume that they would be contacted or afforded an opportunity to qualify, discuss, or revise their proposals. Offerors are cautioned that a proposal containing qualifications, conditions, or expressing unilateral interpretations of the RFP/contract requirements may be rejected and the offeror excluded from the potential competitive range.

Proposals will be evaluated on the basis of established criteria and award will be made to the Offeror whose proposal is the lowest price technically acceptable.

This action is subject to the service contract act – Wage Determination NO: 2015-5525, Revision NO: 7, Revision

Date: 08/07/2018 Washingon Counties: Callam, Grays Harbor, Jefferson, Kitsap, Mason or applicable County

Successful Offeror resides in.

SUBMISSION OF PRE-PROPOSAL INQUIRIES

A. Questions concerning any aspect of this solicitation, known as a Pre-Proposal Inquiry (PPI), shall be submitted no later than 14:30 PM Pacific Daylight Time (PDT), August 30, 2019, on the form provided as

Attachment 2. Submit your PPI via e-mail to sylva.kabuanseya@navy.mil. Use the PPI form provided as

Attachment 2.

B. Please limit your question to one question per PPI.

C. Government responses to written PPI will NOT be recognized as official unless and until the PPI and the

Government response is incorporated in the RFP by amendment.

D. Interested parties are specifically cautioned that verbal questions and verbal replies to questions during any part of the pre-proposal communication shall not have the effect of changing the RFP requirements or provisions.

PRE-PROPOSAL CONFERENCE, SITE VISIT, AND QUESTION AND ANSWER SESSION

A. No pre-proposal conference, site visit or question/answer session will be performed.

DIRECTIONS FOR SUBMISSION OF PROPOSALS

A. Proposals submitted in response to this solicitation shall be submitted as outlined in this section. No e-mail, facsimile, or other alternate method of submission will be accepted.

B. The price proposal and non-price (technical) proposal shall be submitted in separate bindings.

C. Proposals must be set forth full, accurate, and complete information as required by this request for proposal

(including attachments). The penalty for making false statements in…