N3220522R4143 Amendment 6.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is for the follow ing:

1) Remove red-line draw ings from the package for WI 0402. These are to not be utilized.

2) Incorporate RFC answ ers 010-012, 018, and 019.

3) Provide revised WIs 0204, 0294, and 0402. Changes are highlighted.

1. CONTRACT ID CODE PAGE OF PAGES

1 11

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 30-Sep-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N3220522R4143

X 9B. DATED (SEE ITEM 11)

24-Aug-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

30-Sep-2022

CODE

MILITARY SEALIFT COMMAND NORFOLK

471 EAST C. STREET

BLDG. SP-64

NAVAL STATION NORFOLK

NORFOLK VA 23511

N32205 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N3220522R4143

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been modified:

ACRONYM TABLE

ABIH American Board of Industrial Hygiene ABR Agreement for Boat Repair ABS American Bureau of Shipping ACO Administrative Contracting Officer AGR Additional Government Requirements AIHA American Industrial Hygiene Association ALT Alternate AMT Amount BLDG Building CCO Contract Change Order CD Compact Disc CDRL Contract Data Requirements List CD-ROM Compact Disc Read-Only Memory CFM Contractor Furnished Material CFP Contractor Furnished Property CFR Condition Found Report CHENG Chief Engineer CFR Code of Federal Regulations CIH Certified Industrial Hygienist CLIN Contract Line Item Number

CONUS

CPARS

Contiguous United States Contractor Performance Assessment Reporting System

DBIDS Defense Biometric Identification Systems DFARS Defense Federal Acquisition Regulation Supplement DOD Department of Defense DOD SAFE Department of Defense Secure Access File Exchange DON Department of the Navy EMAIL Electronic Mail ESRS Electronic Subcontract Report System FAPIIS Federal Awardee Performance and Integrity Information System FAR Federal Acquisition Regulation FBLR Fully-Burdened Labor Rate F/CC Fibers Per Cubic Centimeter FPCON Force Protection Condition FTR Federal Travel Regulations G&A General and Administrative GFI-TD Government Furnished Information – Technical Data GFM Government Furnished Material GFP Government Furnished Property GPE Governmentwide Point of Entry IAW In Accordance With ID Identification

ISO International Organization for Standardization JTR Joint Travel Regulations KO Contracting Officer KWh Kilowatt Hour LLTM Long Lead Time Material LPTA Lowest Price Technically Acceptable M&IE Meals and Incidental Expenses MSC Military Sealift Command MSCREP Military Sealift Command Representative MM Millimeter MSRA Master Ship Repair Agreement MTA Mid-Term Availability N/A Not Applicable NCACS Navy Commercial Access Control System NDA Non-Disclosure Agreement NO Number NSP Not Separately Priced ODC Other Direct Costs PAT Proficiency in Analytical Testing

PDF

PII

Portable Document Format Personally Identifiable Information

PM Program Manager PPE Principle Port Engineer PRIME Prime Contractor QA Quality Assurance QC Quality Control REV Revision RFC Request for Specification Clarification RFP Request for Proposal ROH/DD Regular Overhaul/Dry-Docking SECNAV Secretary of the Navy SF Standard Form SUB Subcontractor TPSN Time Phased Sequencing Network TWA Time-Weighted Average USC United States Code USCG United States Coast Guard USNS United States Naval Ship VR Voyage Repair WAWF Wide Area Workflow WI Work Item

SCOPE OF WORK

1. The contractor shall prepare for and accomplish the VR, overhaul, or alterations of the USNS GRASP (T-ARS

51) as specified herein and IAW the WI package as provided in Attachment J-1 – WI Package (Specifications).

Unless otherwise specified, all work shall be performed at the contractor’s shipyard.

2. In performing the WIs specified, the contractor shall be responsible for all of the following related work (in case of a discrepancy, the terms and conditions stated in the WIs take precedence over the following terms and conditions):

a. Providing the necessary management, procurement, production, testing, technical capability and resources, and quality assurance services.

b. Ensuring the timely procurement of CFM/CFP and the timely reporting, receipt, storage, installation, and accountability of GFM/GFP IAW FAR 52.245-1 and DFARS 252.211-7007, 252.245-7001, 252.245-7002, 252.245-7003, and 252.245-7004.

c. Using progress measurement systems to determine the physical progress of completed work for each of the elements in the scheduling plan, including material and manpower control, engineering, production, tests and trials IAW the CDRL and the contractor's own Technical Proposal, and the WI package. The progressing system shall permit a direct comparison of the physical progress of completed work to the planned performance measurement baseline for each of the elements in the scheduling plan.

d. Using management procedures and systems to identify behind-schedule conditions and unfavorable schedule variances based on the TPSN submitted with the contractor’s proposal. The applied procedures and systems shall provide timely identification of scheduling problem areas to permit prompt management action to correct unsatisfactory conditions.

e. Developing a performance milestone schedule/critical path chart to measure scheduled performance.

Deviations from the milestone schedule/critical path chart dates in WI 0013 must be submitted to and approved by the KO. A performance milestone schedule and critical path chart shall be developed and submitted IAW the WI Package. The performance milestone schedule shall include and clearly identify primary and parallel critical paths.

The resource loaded performance milestone schedule shall include, at a minimum, those milestones identified in WI 0013.

f. Using approved quality control procedures as required by this contract and the WI package to ensure procured material and performed production work conforms to the required quality standards.

g. Ensuring the ship's equipment and systems remain configured to existing baselines with regard to procured material, production work, and software.

h. Applying stringent configuration control procedures to ensure that configuration baselines are maintained for procured material and production work.

i. Providing for staging and storing of material (both Government-furnished and contractor-furnished) and LLTM for use in the availabilities from the date of award.

j. Managing all subcontractors’ performance during the availability. Ensure subcontractor work is to the same quality and standards as expected from the prime contractor. Develop and maintain a subcontractor management plan. The plan shall ensure that all communication and control of subcontractors is maintained by the prime contractor.

k. Employing good judgment and sound engineering practice and principles, particularly when WIs do not describe all details of accomplishing the work. The contractor shall be expected to have, either organically or through subcontractors, access to competent engineers who have a history of working solutions in a maritime environment.

3. Contract work shall be performed by an eligible contractor as defined below.

a. The contractor shall be capable of performing the full scope of the requirement stated herein within its own facilities, utilizing its own shop(s) and work force, or be capable of subcontracting for these elements beyond its managerial, technical, or physical capability or capacity. The contractor shall assume full responsibility for the integrated scheduling, cost, and quality of subcontractor performance.

b. The contractor shall be a company recognized as engaged in ship repair work and possess an organization capable of the full scope of planning, engineering, quality control, shipboard/offship production and component/system testing and trials. The contractor shall provide industry certifications such as: MSRA, ABR, or ISO Certification that would further emphasize the contractor's ability to perform the work. To be determined responsible, the contractor shall submit acceptable evidence to demonstrate its ability to accomplish the work. This will include a conclusive demonstration of having the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them (including, as appropriate, such elements as production control procedures, property control systems, quality assurance measures, and safety programs applicable to materials to be produced or services to be performed by the prospective contractor and/or subcontractors) at the time of award. The contractor’s proposal shall provide a documented and positive demonstration of established organizational elements as set forth below. These characteristics will be evaluated to determine a firm's eligibility for contract award:

1) Administration/Management Control. Established organization geared toward ship repair at all levels of size, value, and complexity, and toward technology innovation and process improvement. Clear lines of authority.

Delegation of responsibility. Mid-level managerial positions in place. Competent and experienced employees with ship repair experience. Capability to develop and integrate planning, estimating, and scheduling functions. Defined managerial responsibilities for production, quality assurance, material procurement/control, and subcontractor control.

2) Financial Control. Segregation of accounting costs. Adequate accounting system. Favorable cash flow-ratios. Availability of a line of credit or other source of financial income to support the work effort. Prompt payment of subcontractors and suppliers.

3) Production Control. A production organization. On board (or ability to obtain) trade mix/skills to perform ship repair work. Control of production efforts. Integration of other key functions with production. Use of scheduling techniques. Methods of progressing. Training available to trades employees.

4) Production Technical Support. Engineering and design support capabilities (in-house or subcontracted) with sufficient capability to diagnose and evaluate technical problems and issues and to make competent technical recommendations to MSC when necessary and appropriate. The offeror shall be fully cognizant of ABS rules and USCG regulations and how they apply and impact this specification package.

5) Material/Procurement Control. A material purchasing department with staff. Procedures for control of material (purchasing, monitoring, receipt, inspection, segregation, issuance, nonconformance, and disposal). An inventory system – ordering, tagging warehousing. CFM/GFM storage, control and protection. Existing environmentally-controlled warehouse space. Material handling equipment. Familiarity with the Navy logistics support system.

6) Subcontractor Control. Procedures for selecting, scheduling, managing, monitoring and controlling subcontractors.

7) Quality Control/Test and Trials. A quality control organization/department/staff. Quality assurance procedures/manual. Calibration and metrology system availability. Test memo writing capability. Nondestructive Testing capabilities. Welding procedures and welders’ qualifications. Ability to perform trend analysis. Quality control system shall be certified or equivalent to ISO 9001:2001 standards.

8) Safety/Security. Safety Organization/Manager or Engineer. Safety manual/procedures. Safety training.

First-aid capabilities or medical services. Fire protection/procedures. Physical yard security/security procedures.

9) Hazardous Material/Waste Control. Proper procedures and facilities to meet the legal requirements for removal, storage, and disposal of hazardous waste. Segregated storage. Documentation of licensed subcontractors responsible for control of hazardous waste removal, storage, and disposal. Appropriate state/federal agency-issued hazardous waste generator number. Disposal records which indicate type of material, date, and place of disposal.

10) Facilities. Although facility requirements may vary with the work authorized for a specific ship, the contractor must be a ship repair company that possesses or has available the following facilities:

o Pier, with services in place, accessible to the CLASS size ship for berthing o Structural Shop o Machine Shop o Pipe Shop o Electrical/Electronic Shop o Carpentry Shop o Rigging Equipment o Dry-dock – when required for docking of vessel in performance of the specification

11) Agreements. To be determined responsible, a prospective contractor must possess an MSRA, ABR or submit acceptable evidence in lieu of the aforementioned to effectively communicate and demonstrate its ability to obtain required resources.

c. The government reserves the right to perform a site survey(s) for verification of policies, procedures, capabilities and facilities prior to award.

4. Asbestos removal requirements.

a. During the performance of this contract the contractor and subcontractors may be required to perform work which involves the removal or disturbance of asbestos or asbestos-containing products. This requirement applies to each instance of asbestos removal or disturbance.

b. The contractor shall comply with the precautions required in 29 CFR 1910.1001, 29 CFR 1926.58 and 40 CFR Part 61 and all other applicable Federal, state, and local restrictions. The contractor shall forward a copy of all required notices, licenses and permits to the KO immediately upon issuance or receipt.

c. The latest change to the Federal, state, and local regulations in effect at the time of issuance of the contract shall govern. Compliance with these regulations is mandatory and is necessary to protect the employees of the contractor and Naval personnel from exposure to asbestos fibers in excess of the OSHA Action level airborne concentration (currently 0.1 f/cc of air).

d. During removal or disturbance, the contractor shall control airborne asbestos concentrations outside the removal boundary to less than 0.1 f/cc at all times.

e. After removal or disturbance is complete, the areas within the removal boundary shall not be released for re-occupancy until clearance air sampling demonstrates these spaces have concentrations of asbestos less than 0.1 f/cc.

f. In all respects, the performance of air sampling and analysis shall be performed IAW the OSHA Reference Method (Appendix A of 29 CFR 1910.1001), with the following additional specifications:

1) Aggressive clearance sampling shall be performed on 25 mm cassettes at 2.0 liters per minute for a minimum of four (4) hours.

2) In performing the clearance sampling, the pump shall be placed within the compartment where the removal or disturbance occurred. When this operation is conducted in a multilevel space, at least one pump shall be placed on each level.

3) Air sampling shall be performed by a person competent in sampling procedures and overseen by a CIH by the ABIH.

4) Laboratory analysis of samples shall be performed by a participant in the AIHA PAT Program rated proficient for asbestos and air.

g. Personal sampling shall be conducted using breathing zone air samples which are representative of the 8-hour TWA exposure of each individual. Samples shall be collected and analyzed using the OSHA Reference Method contained in either 29 CFR 1910.1001 (as amended) or 29 CFR 1926.58 (as amended).

h. The contractor agrees to indemnify MSC for any fines assessed by Federal, state, or local agencies, for the contractor's failure to properly follow applicable regulations.

i. The contractor shall insert this instruction in all subcontracts entered into under this contract.

5. Post-award substitution of any major subcontractor should not be effected unless the proposed substitution is submitted to the KO and official approval is obtained. The post-award substitution or insertion of a second-tier subcontractor will be treated in the same manner as the substitution of a major subcontractor and requires specific approval by the KO.

6. Substitution of key personnel.

a. The contractor agrees to assign to this contract those persons identified as key personnel who are necessary to fulfill the requirements of this contract and whose resumes were submitted with the proposal. No substitution of key personnel shall be made except IAW these instructions.

b. All proposed substitutions must be submitted, in writing, at least seven (7) days in advance of the proposed substitutions to the KO and must provide the information required by paragraph “c” below.

c. All requests for substitution must provide a detailed explanation of the circumstances necessitating the proposed substitution, a resume for the proposed substitute, and any other information as requested by the KO. All proposed substitutes must have qualifications equal to or higher than the qualifications of the person to be replaced.

The KO or his authorized representative will evaluate such requests and promptly notify the contractor of the approval or disapproval thereof.

7. It is anticipated the ship will arrive at the contractor’s yard on or about March 1, 2023. All work shall be completed in no more than 61 calendar days from the actual start date designated by the Government at the time of contract award.

8. The place of performance for this contract shall be the contractor’s facility. Due to operational and national security availability considerations, the location shall be Alaska, Hawaii, or West Coast.

Table 1: List of WIs:

USNS GRASP

( TARS 51 )

N3220522R4143

MTA- March 1, 2023

WORK ITEM INDEX REPORT

Item Number Title Category

SECTION 0000 GENERAL SERVICES AND REQUIREMENTS

0001 TARS SWI SCOPE GENERAL REQUIREMENTS AND

DEFINITIONS

NSP

0002 TARS SWI TECHNICAL AND MANUFACTURERS

REPRESENTATIVE

NSP

0003 TARS SWI APPROACH, BERTHING AND MOORING

REQUIREMENTS

NSP

0004 TARS SWI TESTING AND QUALITY ASSURANCE NSP

0005 TARS SWI ELECTRICAL SAFETY PROCEDURE

REQUIREMENTS

NSP

0006 TARS SWI HEAVY WEATHER PLAN NSP

0007 TARS SWI COLD WEATHER PLAN NSP

0010 TARS SWI FURNISH OFFICE FOR OVERHAUL

MANAGEMENT TEAM (OMT) REV 1

A

0011 TARS SWI GENERAL SERVICES FOR SHIP A

0012 TARS SWI INFORMATION TECHNOLOGY SERVICES A

0013 TARS SWI PROJECT PLANNING AND PRODUCTION

STATUS MONITORING REPORTS

A

0014 TARS SWI WEIGHT MOMENT REPORT A

0015 TARS SWI ILS GFM A

0016 TARS SWI FIRE PROTECTION AND SHIP SAFETY

PROGRAM

A

0017 TARS SWI HANDLING SHIPS STORES A

0018 TARS SWI DELIVERY AND REDELIVERY OF THE

VESSEL

A

0019 TARS SWI SHIPBOARD ACCESS AND SECURITY A

0020 TARS SWI GAS FREE CERTIFICATES A

0021 TARS SWI CLEAN AND GAS FREE TANKS, VOIDS,

COFFERDAMS, AND SPACES

A

0022 TARS SWI MACHINERY SPACE TURN-OVER DOCK

TRIALS AND SEA TRIALS

A

0023 TARS SWI HAZARDOUS WASTE DISPOSAL AT A

CONTRACTOR'S FACILITY

A

0024 TARS SWI PHYSICAL SECURITY AT PRIVATE

CONTRACTORS FACILITY

NSP

0025 TARS SWI PHYSICAL SECURITY AT PRIVATE

CONTRACTORS FACILITY

B

0030 TARS SWI CONTINUATION OF SERVICES B

0090 TARS SWI LEVEL 1 DAILY COVID-19 PREVENTION

AND CONTROL SERVICES

A

SECTION 0100 HULL AND STRUCTURAL

0101 AFT MAST PRESERVATION AND INSPECTION A

0102 PORTLIGHT REFURBISHMENT MESS DECKS A

0103 SHORE POWER ENCLOSURE STEEL REPAIRS A

0104 01-18-0 SCUTTLE AND HATCH RAMP REPAIRS A

0105 DECK HOUSE ABATEMENT AND PRESERVATION A

0106 01.5 TO 04 LEVEL DECK PRESERVATION A

0107 PILOTHOUSE STEEL DOUBLER RENEWAL A

0108 FOREPEAK TANK STEEL REPAIRS A

0186 TARS_CSI_CABLE PENETRATION INSPECTION (1

YR)

A

0191 TARS_CSI_SALVAGE HATCH - INSPECT AND

REFURBISH (2.5 YR) Rev 2

SECTION 0200 PROPULSION MACHINERY

0201 RED GEAR LO THERMOSTATIC VALVE

REPLACEMENT (TALT17-003)

A

0202 AUTOMATION AND PROPULSION CONTROL

SYSTEM REPAIR

A

0203 MAIN PROPULSION LINE SHAFT BEARING

REPLACEMENT

A

0204 REDUCTION GEAR AND CLUTCH INSPECTIONS Rev

A

0287 TARS_CSI_AUTOMATION AND PROPULSION

CONTROL INSPECTION AND TEST (1 YR)

A

0294 TARS-CSI-MAIN DIESEL ENGINE MAJOR OVERHAUL

(#2A1B) Rev 3

SECTION 0300 ELECTRICAL

0301 TANK LEVEL INDICATOR REPAIR AND

CALIBRATION

0353 TARS_CCSI_THERMOGRAPHIC SURVEY (1 YR) A

SECTION 0400 COMMUNICATION AND NAVIGATION

0402 T-ALT ECDIS AND RADAR RENEWAL Rev 2 A

0403 T-ALT SVDR RENEWAL A

0453 TARS_CCSI_ANNUAL GYRO SYSTEM A

0455 TARS_CCSI_ANNUAL RADIO COMMUNICATION

EQUIPMENT CERTIFICATION

A

0456 TARS_CCSI_MAGNETIC COMPASS SERVICE (2 YR) A

0459 TARS_CCSI_ECHO SOUNDER SERVICE (2.5 YR) A

0460 TARS_CCSI_ANNUAL INSPECTION OF MANUALLY

OPERATED ALARMS

A

0492 TARS_CSI_ ELECTRONIC TEST EQUIPMENT (GPETE)

CALIBRATION (1 YR)

SECTION 0500 AUXILIARY MACHINERY

0501 AFFF TANKS FILL PIPING RENEWALS A

0502 FORWARD HAWSER ROLLER REFURBISHMENT A

0503 FIREMAIN VALVE OVERHAUL A

0504 SHIPS WHISTLE MANUAL PULL CABLE REPAIR A

0505 ANCHOR WINDLASS SYSTEM SERVICING

OVERHAUL (New)

0554 TARS_CCSI_INSPECT, TEST AND CERTIFY NON-

CARGO LIFTING GEAR (1 YR)

A

0556 TARS_CCSI_INSPECT DECK CRANES (1 YR) A

0561 TARS_CCSI_GAUGE CALIBRATION (1 YR) A

0562 TARS_CCSI_SCBA ANNUAL INSPECTION A

0563 TARS_CCSI_SCBA COMPRESSOR AND FILLING

STATION INSPECTION AND MAINTENANCE (1 YR)

A

0565 TARS_CCSI_FIXED GAS FIREFIGHTING SYSTEM

INSPECTION AND TEST (1 YR) Rev 1

A

0567 TARS_CCSI_FIXED FOAM FIREFIGHTING SYSTEM

INSPECTION AND TEST (1 YR)

A

0569 TARS_CCSI_FIRE AND SMOKE DETECTION AND

ALARM SYSTEM (1 YR)

A

0570 TARS_CCSI_PORTABLE FIRE EXTINGUISHER

SERVICE (1 YR)

A

0571 TARS_CCSI_FIRE AND SMOKE DAMPER SERVICE (1

YR)

A

0572 TARS_CCSI_DEEP FAT FRYER AND RANGE HOOD

FIRE EXTINGUISHER SYSTEM (1 YR)

A

0573 TARS_CCSI_FIRE HOSES (1 YR) A

0574 TARS_CCSI_FIRE DOORS AND SHUTTERS (1 YR) A

0578 TARS_CSI HIGH PRESSURE AIR COMPRESSOR

SERVICE

A

0580 TARS_CSI_REFRIGERATION PLANTS SERVICING

AND REPAIRS (1 YR)

A

0587 TARS_CSI_OILY WATER SEPARATOR SYSTEM

SERVICING (1 YR)

A

0596 TARS_CSI_SALVAGE BOOM OVERHAUL AND

CERTIFICATION (5 YR) Rev 1

SECTION 0600 HABITABILITY OUTFITTING AND FURNISHINGS

0601 SHOWER ENCLOSURE AND DECK RENEWAL Rev 1 A

0602 PUBLIC HEAD DECKING RENEWAL A

0603 PRC DECK RENEWAL A

0604 SCULLERY DISHWASHER REFURBISHMENT A

0605 CREW LAUNDRY OVERHAUL A

0606 TRASH ROOM OVERHAUL A

0653 TARS_CCSI_ANNUAL RESCUE BOAT AND DAVIT

INSPECTION

A

0656 TARS_CCSI_ANNUAL LIFERAFT CERIFICATION A

0657 TARS_CCSI_ACCOMMODATION LADDER

INSPECTION (1 YR)

0662 TARS_CCSI_DEEP FAT FRYER INSPECTION (1 YR) A

SECTION 0800 HVAC

0801 01-49-1-Q FAN ROOM OVERHAUL A

0802 01-68-2-Q FAN ROOM OVERHAUL A

0803 1-26-5-Q FAN ROOM OVERHAUL A

0804 1-58-1-Q FAN ROOM OVERHAUL A

0805 1-58-4-Q FAN ROOM OVERHAUL A

0806 ELECTRIC HEATER GROOM AND INSPECT A

0881 TARS_CSI_AC CHILLER SERVICING (1 YR) A

SECTION 0900 DRYDOCKING

0958 TARS_CCSI_PROPELLER CLEAN AND POLISH - IN

WATER (1 YR)

(End of Summary of Changes)